The URL can be used to link to this page

Home My WebLink About507242 CUSTOM SOLAR LLC - CONTRACT - RFP - 8330 PHOTO VOLTAIC SOLAR FOR NEW DOWNTOWN PARKINGSERVICES AGREEMENT WORK ORDER TYPE THIS AGREEMENT made and entered into the day and year set forth below, by and between THE CITY OF FORT COLLINS, COLORADO, a Municipal Corporation, hereinafter referred to as the "City" and CUSTOM SOLAR LLC hereinafter referred to as "Service Provider". WITNESSETH: In consideration of the mutual covenants and obligations herein expressed, it is agreed by and between the parties hereto as follows: 1. Services to be Performed. a. This Agreement shall constitute the basic agreement between the parties for services for 8330 Photo Voltaic Solar for Downtown Parking Garage. The conditions set forth herein shall apply to all services performed by the Service Provider on behalf of the City and particularly described in Work Orders agreed upon in writing by the parties from time to time. Such Work Orders, a sample of which is attached hereto as Exhibit "A", consisting of one (1) page and incorporated herein by this reference, shall include a description of the services to be performed, the location and time for performance, the amount of payment, any materials to be supplied by the City and any other special circumstances relating to the performance of services. A general scope of services is attached hereto as Exhibit “B”, consisting of thirty-two (32) pages, and incorporated herein by this reference. The only services authorized under this Agreement are those which are performed after receipt of such Work Order, except in emergency circumstances where oral work requests may be issued. Oral requests for emergency actions will be confirmed by issuance of a written Work Order within two (2) working days. Irrespective of references in Exhibit A to certain named third parties, Service Provider shall be solely responsible for performance of all duties hereunder. b. The City may, at any time during the term of a particular Work Order and without invalidating the Agreement, make changes within the general scope of the particular services assigned and the Service Provider agrees to perform such changed services. 2. Changes in the Work. The City reserves the right to independently bid any services rather than issuing work to the Service Provider pursuant to this Agreement. Nothing within this Agreement shall obligate the City to have any particular service performed by the Service Provider. 3. Time of Commencement and Completion of Services. The services to be performed pursuant to this Agreement shall be initiated as specified by each written Work Order or oral emergency service request. Oral emergency service requests will be acted upon without waiting for a written Work Order. Time is of the essence. Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 1 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D 4. Contract Period. This Agreement shall commence upon execution by all parties and shall continue in full force and effect until August 31, 2017, unless sooner terminated as herein provided. In addition, at the option of the City, the Agreement may be extended for additional one year periods not to exceed four (4) additional one year periods. Renewals and pricing changes shall be negotiated by and agreed to by both parties. Written notice of renewal shall be provided to the Service Provider and mailed no later than thirty (30) days prior to contract end. 5. Delay. If either party is prevented in whole or in part from performing its obligations by unforeseeable causes beyond its reasonable control and without is fault or negligence, then the party so prevented shall be excused from whatever performance is prevented by such cause. To the extent that the performance is actually prevented, the Service Provider must provide written notice to the City of such condition within fifteen (15) days from the onset of such condition. 6. Early Termination by City/Notices. Notwithstanding the time periods contained herein, the City may terminate this Agreement at any time without cause by providing written notice of termination to the Service Provider. Such notice shall be mailed at least fifteen (15) days prior to the termination date contained in said notice unless otherwise agreed in writing by the parties. All notices provided under this Agreement shall be effective when mailed, postage prepaid and sent to the following address: Service Provider: City: Copy to: Custom Solar LLC Attn: Willie Mein 2840 Wilderness Place, Suite F Boulder, CO 80301 City of Fort Collins Attn: Brian Hergott PO Box 580 Fort Collins, CO 80522 City of Fort Collins Attn: Purchasing Dept. PO Box 580 Fort Collins, CO 80522 In the event of early termination by the City, the Service Provider shall be paid for services rendered to the termination date, subject only to the satisfactory performance of the Service Provider's obligations under this Agreement. Such payment shall be the Service Provider's sole right and remedy for such termination. 7. Contract Sum. This is an open-end indefinite quantity Agreement with no fixed price. The actual amount of work to be performed will be stated on the individual Work Orders. The City makes no guarantee as to the number of Work Orders that may be issued or the actual amount of services which will in fact be requested. 8. Payments. a. The City agrees to pay and the Service Provider agrees to accept as full payment for all work done and all materials furnished and for all costs and expenses incurred in performance of the work the sums set forth for the hourly labor rate and material costs, with markups, stated within the Bid Schedule Proposal Form, attached hereto as Exhibit "B", consisting of thirty-two (32) pages, and incorporated herein by this reference. Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 2 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D Payment shall be made by the City only upon acceptance of the work by the City and upon the Service Provider furnishing satisfactory evidence of payment of all wages, taxes, supplies and materials, and other costs incurred in connection with the performance of such work. 9. City Representative. The City's representative will be shown on the specific Work Order and shall make, within the scope of his or her authority, all necessary and proper decisions with reference to the work requested. All requests concerning this Agreement shall be directed to the City Representative. 10. Independent Contractor. It is agreed that in the performance of any services hereunder, the Service Provider is an independent contractor responsible to the City only as to the results to be obtained in the particular work assignment and to the extent that the work shall be done in accordance with the terms, plans and specifications furnished by the City. 11. Subcontractors. Service Provider may not subcontract any of the Work set forth in the Exhibit A, Statement of Work without the prior written consent of the city, which shall not be unreasonably withheld. If any of the Work is subcontracted hereunder (with the consent of the City), then the following provisions shall apply: (a) the subcontractor must be a reputable, qualified firm with an established record of successful performance in its respective trade performing identical or substantially similar work, (b) the subcontractor will be required to comply with all applicable terms of this Agreement, (c) the subcontract will not create any contractual relationship between any such subcontractor and the City, nor will it obligate the City to pay or see to the payment of any subcontractor, and (d) the work of the subcontractor will be subject to inspection by the City to the same extent as the work of the Service Provider. 12. Personal Services. It is understood that the City enters into the Agreement based on the special abilities of the Service Provider and that this Agreement shall be considered as an agreement for personal services. Accordingly, the Service Provider shall neither assign any responsibilities nor delegate any duties arising under the Agreement without the prior written consent of the city. 13. Acceptance Not Waiver. The City's approval or acceptance of, or payment for any of the services shall not be construed to operate as a waiver of any rights under the Agreement or of any cause of action arising out of the performance of this Agreement. 14. Warranty. a. Service Provider warrants that all work performed hereunder shall be performed with the highest degree of competence and care in accordance with accepted standards for work of a similar nature. b. Unless otherwise provided in the Agreement, all materials and equipment incorporated into any work shall be new and, where not specified, of the most suitable grade of their respective kinds for their intended use, and all workmanship shall be acceptable to Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 3 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D City. c. Service Provider warrants all equipment, materials, labor and other work, provided under this Agreement, except City-furnished materials, in accordance with the warranties stated in Exhibit B, General Scope of Services. Upon receipt of written notice from City of any such defect or nonconformances, the affected item or part thereof shall be redesigned, repaired or replaced by Service Provider in a manner and at a time acceptable to City. 15. Default. Each and every term and condition hereof shall be deemed to be a material element of this Agreement. In the event either party should fail or refuse to perform according to the terms of this Agreement, such party may be declared in default thereof. 16. Remedies. In the event a party has been declared in default, such defaulting party shall be allowed a period of ten (10) days within which to cure said default. In the event the default remains uncorrected, the party declaring default may elect to (a) terminate the Agreement and seek damages; (b) treat the Agreement as continuing and require specific performance; or (c) avail himself of any other remedy at law or equity. If the non- defaulting party commences legal or equitable actions against the defaulting party, the defaulting party shall be liable to the non-defaulting party for the non-defaulting party's reasonable attorney fees and costs incurred because of the default. 17. Binding Effect. This writing, together with the exhibits hereto, constitutes the entire Agreement between the parties and shall be binding upon said parties, their officers, employees, agents and assigns and shall inure to the benefit of the respective survivors, heirs, personal representative, successors and assigns of said parties. 18. Indemnity/Insurance. a. The Service Provider agrees to indemnify and save harmless the City, its officers, agents and employees against and from any and all actions, suits, claims, demands or liability of any character whatsoever, brought or asserted for injuries to or death of any person or persons, or damages to property arising out of, result from or occurring in connection with the performance of any service hereunder. b. The Service Provider shall take all necessary precautions in performing the work hereunder to prevent injury to persons and property. c. Without limiting any of the Service Provider's obligations hereunder, the Service Provider shall provide and maintain insurance coverage naming the City as an additional insured under this Agreement of the type and with the limits specified within Exhibit "C", consisting of one (1) page, attached hereto and incorporated herein by this reference. The Service Provider before commencing services hereunder shall deliver to the City's Director of Purchasing and Risk Management, P. O. Box 580, Fort Collins, Colorado 80522 one copy of a certificate evidencing the insurance coverage required from an insurance company acceptable to the city. Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 4 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D 19. Entire Agreement. This Agreement, along with all Exhibits and other documents incorporated herein, shall constitute the entire Agreement of the parties. Covenants or representations not contained in this Agreement shall not be binding on the parties. 20. Law/Severability. This Agreement shall be governed in all respect by the laws of the State of Colorado. In the event any provision of this Agreement shall be held invalid or unenforceable by any court of competent jurisdiction such holding shall not invalidate or render unenforceable any other provision of this Agreement. 21. Prohibition Against Employing Illegal Aliens. Pursuant to Section 8-17.5-101, C.R.S., et. seq., Service Provider represents and agrees that: a. As of the date of this Agreement: 1) Service Provider does not knowingly employ or contract with an illegal alien who will perform work under this Agreement; and 2) Service Provider will participate in either the e-Verify program created in Public Law 208, 104th Congress, as amended, and expanded in Public Law 156, 108th Congress, as amended, administered by the United States Department of Homeland Security (the “e-Verify Program”) or the Department Program (the “Department Program”), an employment verification program established pursuant to Section 8-17.5-102(5)(c) C.R.S. in order to confirm the employment eligibility of all newly hired employees to perform work under this Agreement. b. Service Provider shall not knowingly employ or contract with an illegal alien to perform work under this Agreement or knowingly enter into a contract with a subcontractor that knowingly employs or contracts with an illegal alien to perform work under this Agreement. c. Service Provider is prohibited from using the e-Verify Program or Department Program procedures to undertake pre-employment screening of job applicants while this Agreement is being performed. d. If Service Provider obtains actual knowledge that a subcontractor performing work under this Agreement knowingly employs or contracts with an illegal alien, Service Provider shall: 1) Notify such subcontractor and the City within three days that Service Provider has actual knowledge that the subcontractor is employing or contracting with an illegal alien; and 2) Terminate the subcontract with the subcontractor if within three days of receiving the notice required pursuant to this section the subcontractor does not cease employing or contracting with the illegal alien; except that Service Provider shall not terminate the contract with the subcontractor if during such three days the subcontractor provides information to establish that the subcontractor has not knowingly employed or contracted with an illegal alien. e. Service Provider shall comply with any reasonable request by the Colorado Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 5 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D Department of Labor and Employment (the “Department”) made in the course of an investigation that the Department undertakes or is undertaking pursuant to the authority established in Subsection 8-17.5-102 (5), C.R.S. f. If Service Provider violates any provision of this Agreement pertaining to the duties imposed by Subsection 8-17.5-102, C.R.S. the City may terminate this Agreement. If this Agreement is so terminated, Service Provider shall be liable for actual and consequential damages to the City arising out of Service Provider’s violation of Subsection 8-17.5-102, C.R.S. g. The City will notify the Office of the Secretary of State if Service Provider violates this provision of this Agreement and the City terminates the Agreement for such breach. 22. Special Provisions. Special provisions or conditions relating to the services to be performed pursuant to this Agreement are set forth in Exhibit D - Confidentiality, consisting of one (1) page, attached hereto and incorporated herein by this reference. Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 6 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D THE CITY OF FORT COLLINS, COLORADO By: Gerry Paul Purchasing Director DATE: ATTEST: City Clerk APPROVED AS TO FORM: Senior Assistant City Attorney CUSTOM SOLAR LLC By: Printed: Title: CORPORATE PRESIDENT OR VICE PRESIDENT Date: Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 7 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D Manager Willie Mein 8/23/2016 8/25/2016 EXHIBIT A WORK ORDER FORM PURSUANT TO AN AGREEMENT BETWEEN THE CITY OF FORT COLLINS AND CUSTOM SOLAR LLC AGREEMENT DATED: Work Order Number: Purchase Order Number: Project Title: 8330 Photo Voltaic Solar for Downtown Parking Garage Commencement Date: Completion Date: Maximum Fee: (time and reimbursable direct costs): Project Description: Scope of Services: Service Provider agrees to perform the services identified above and on the attached forms in accordance with the terms and conditions contained herein and in the Services Agreement between the parties. In the event of a conflict between or ambiguity in the terms of the Services Agreement and this Work Order (including the attached forms) the Services Agreement shall control. The attached forms consisting of ___ (_) pages are hereby accepted and incorporated herein, by this reference, and Notice to Proceed is hereby given. SERVICE PROVIDER By:_______________________________ Date:_____________________________ CITY OF FORT COLLINS By:_________________________________ Project Manager Date: ______________________________ By: _______________________________ Gerry Paul Purchasing Director (over $60,000.00) Date: ____________________________ Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 8 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D 8330: Photovoltaic Solar for New Downtown Parking Garage Approach to Scope of Work and Project Phasing The project will be conducted in 2 phases through the issuance of Work Orders, whereas phase 1 is design consultation for the parking garage and phase 2 is engineering and construction of the photovoltaic system. The Scope of Work for Phase 1 is provided below and the price is $13,000. Consultant shall invoice for Phase 1 upon the City’s acceptance of parking garage design. Phase I – Includes meeting with the project design team to determine best carport support system by providing analysis of the carport in the permit drawings and changes necessary to make it work with the panel design to provide optimum energy production. Assist with reviewing the cost of garage contractor support system or Solar contractor support system. Provide PV panel options, glare analysis and electrical input on inverter and utility interconnection locations and infrastructure rough-ins necessary for PV system. The Scope of Work for Phase 2 is provided herein and the preliminary price is $105,300, which is the difference of the original proposal price of $118,300 minus $13,000 for Phase 1: design consultation. The Scope of Work and price of Phase 2 is subject to change based on the results of Phase 1, and the finalized Scope of Work for Phase 2 will be provided in a subsequent Work Order. Additional optional cost estimates are provided in the Scope of Work for both Phases 1 and 2 and can be added via change order or the issuance of additional Work Orders. The Phase 2 Scope of Work provided herein will serve as the basis for cost negotiations for the final design resulting from Phase 1. EXHIBIT B GENERAL SCOPE OF SERVICES Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 9 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D 7 Technical Approach and Product/Technology Description The system detailed below will comply with all of the current RFP and contract specifications. System Design Custom Solar has designed the system utilizing all American made components utilizing the currently engineered carport structure with options to modify the design. The system has been designed as a turnkey installation including permits, utility interconnections, material procurement and installation. Custom Solar will work the City of Fort Collins to determine the best design to fit the parking garage. Custom Solar will work with the City of Fort Collins team to set up the proper networking to establish good data monitoring communications and will train City staff at the end of the project. Staff training will include hazard identification, system shut down procedures, identification of performance issues and monitoring portal access. An O&M manual will be left onsite for City staff use as well as for the maintenance team. The proposed system as designed will connect to the carport structure as shown in the provided plan set from the RFP solicitation. The PV system will require 90' of the planned 150' structure shown in the drawings. The size of the structure can be reduced to match the array size. Custom Solar requests that the contractor building/erecting the structure add welded metal tabs to the top of the 4x4 beams to allow for the connection of the solar panels to the structure. Providing tabs on the structure will allow Custom Solar to install the PV system to the carport structure without harming the protective galvanized/painted coating on the structure and allow for easier integration. Alternatively Custom Solar requests that the 4x4 HSS beams be replaced with Z-purlins, C-Purlins or Angle to facilitate drilling holes through the beams to bolt panels directly to the structure. Custom Solar can provide structural engineering for the PV systems connection to the carport structure. Custom Solar's planned layout is below. PHASE 2 Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 10 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D 8 The system has been designed to 54.72kW-dc to meet the requested size of 50kW. The system has been designed using (192) American made Solarworld 285W solar panels. The panels will be paired with (4) Fronius Transformerless Inverters for an AC system rating of 57kW with a favorable 0.96 DC/AC ratio. The inverters have been proposed to be installed on the roof of the building so as to comply with the NEC rapid shutdown requirements and simplify maintenance requirements. We can work with the City if alternative locations are preferred. As designed the PV system will fit between the four light posts planned for the top story of the garage without mechanical interference. The NW light poles do not cause any shading issues for the solar array but the SW light poles will cause a shadow on the PV system in the mornings primarily during the winter. It is a suggestion to relocate the SW light pole further south by ~15' to remove all shading from the PV system. Additional lighting may be required below the PV system. Custom Solar has reviewed the electrical drawings provided in the solicitation and approve of the location shown for the electrical interconnection. Locating the 200A breaker on the utility side of the main breaker allows for the interconnection of up to 57.6kW-AC and can be upgraded in the future to a larger switch to facilitate an expansion of the system. Relocating the switch/breaker to the load side of the main is feasible but will limit the PV AC capacity to 46kW with no room for future expansion. The rough electrical layout has been provided below in the form of a basic one-line diagram. Custom Solar plans to interconnect the system to the 200A breaker as shown. Custom Solar acknowledges that the conduit runs to the electrical room from the roof will be provided by others and requests a minimum 2.5" raceway. Custom Solar plans on pulling wire from the roof to the electrical room and installing all of the necessary disconnects and meters required at ground level per NEC code and Utility requirements. Technology Overview The products used for this project have proven themselves to be very reliable. The project uses standard monocrystalline panels which have a proven track record and have been install for decades. While the technology is nothing new, the products have greatly improved in both performance and quality. Additionally due to the minimal shading concerns seen Custom Solar has chosen to install 4 centralized inverters to reduce the risk of failures seen with DC optimizers and Micro inverter products seen within the last decade. The centralized inverters operate at up to 1000V both decreasing voltage drop along the strings and increasing the efficiency and performance of the inverters. Additionally the inverters used can be mounted in interior locations or exterior next to the PV arrays to me rapid shutdown requirements if necessary. Our current plan is to install the inverter underneath the solar canopies but we can work with the City to determine the final locations. Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 11 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D 9 PV Modules The PV modules used in this project are manufactured by Solar World an American Tier 1 manufacture. The model of the panels is a SW 285 W Mono which is guaranteed to have a power output of 0 to +5W over the labeled power rating upon delivery. The PV modules are manufactured with monocrystalline cells and do not use toxic Cadmium. The panels have been designed for wind and snow loads up to 170 psf. Spec sheets are attached in the "Supplementary Equipment Documentation". Custom Solar has been installing Solarworld panels since 2008 with great success. The PV modules performance will be verified during the construction of the system by testing string voltages and comparing the system output to the expected output. Each string will be tested for insulation resistance, short circuit current, open circuit voltage and ground continuity. Inverters The inverters used in this system are the Fronius 3-Phase Transformerless String Inverters. The max efficiency of the inverter is 98%. The data sheets can be found in the "Supplementary Equipment Documentation". Custom Solar has been using the Fronius products since 2008 and has experienced high reliability with the product. 7KH)URQLXVLQYHUWHUVDUH6PDUW*ULGUHDG\ZLWKPDQ\GLIIHUHQWYDULDEOHVDEOHWREHDGMXVWHG6RPHEXWQRW DOORIWKHDYDLODEOHFRQWUROVLQFOXGH,QYHUWHUVKXWGRZQ3RZHUOLPLWLQJ5HDFWLYH3RZHU3RZHU)DFWRU IUHTXHQF\FRQWUROHWF0DQXIDFWXUHGRFXPHQWDWLRQKDVEHHQLQFOXGHGLQWKHDSSHQGL[GHWDLOLQJWKH DGGLWLRQDOIHDWXUHV Carport Mounting Systems Custom Solar plans to utilize Unirac Solar Mount Rail to connect the PV System to the carport structure. The rail is capable of supporting the 4' spans in between supports and has built in grounding features allowing for a much cleaner installation. The racking system is American made. The system is capable of meeting the local 30psf snow load and 126mph 3-sec gust. The systems design weight will fall below 5 psf for design purposes. Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 12 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D 10 System Performance and Monitoring Performance Estimation The systems first year total energy production estimate is shown in the table below. The system is expected to produce 68,392kWh in the first year of serves given past weather data for the area. The annual system degradation is expected to be no more than 3% in the first year and 0.5% for every year following. The production estimates have been generated using NREL's PVwatts calculator with site specific and equipment specific data. Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 13 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D 11 Performance Verification & Monitoring The monitoring system provided for this system is manufactured by Egauge Systems. The monitoring system has been used on several commercial sites including on City of Fort Collins facilities. The monitoring system will provide information on the performance and health of the system by recording panel temperature and solar irradiance to develop a model of expected production. The monitoring system will report instantaneous power production information accessible via a web based portal with access given to the installer, owner and any third party users. The basic monitoring will record both energy and power of the inverters onsite and compare it to the modeled energy output. The system will send alerts to the maintenance staff when the system is underperforming or when the system is down so that issues can be immediately resolved. Custom Solar plans to connect the monitoring system via an Ethernet connection to the Cities internet network to establish the most reliable internet connection available. There are no ongoing fees associated with the Egauge when installed using an internet connection. The system performances will be measured and compared to the expected performance by comparing the actual performance to the expected performance as calculated in the following formula: System Adjustment Factors: 1. PV Array DC Capacity (kW) = P 2. Temperature Adjustment = (1-(Tpanel°C-25°C) x (Tcoeff)) = T 3. Irradiance Adjustment = (IRR / 1000W/m^2) = I 4. Inverter Efficiency = E 5. Mismatch and DC and AC wire Losses (~4%) = .96 = M 6. Soiling (0% at time of install) = 1.0 = S Inverter Expected Power = P x T x I x E x M x S The end user interface is an easy to use web-based portal that displays both current and past performance. There are several friendly public views available on the Egauge portal as well as a more comprehensive view used for maintaining the system and analyzing the performance of the system. The portal keeps track of individual inverter performance, alarms, status alongside weather data. An example of the Egauge web based portal with performance modeling can be seen here: http://proto2.egaug.es/5750C/ Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 14 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D 12 Example views of Egauge Monitoring System shown below: Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 15 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D 13 System Maintenance and Support Custom Solar has a team of 3 people dedicated to technical/customer support. This staff responds to both commercial and residential customer support issues. Our staff reviews all installed systems monthly to ensure all systems are operational. Additionally systems are setup to alert staff in the event of system issues. System availability on all system monitored has been historically above 98%. Issues related to Custom Solar's standard workman warranty are covered by Custom Solar including assistance in claiming manufacture warranties. Custom Solar will handle all O&M if the system is pursued under the terms of a PPA for the full term of the PPA. Under the terms of a PPA it is in Custom Solar’s best interest to respond to and repair all system alerts/issues promptly to insure the system is operating at full capacity and generating a return on the investment. Custom Solar responds to all down systems within 24 hours of an issue being reported by a monitoring system or customer. Phone response hours are limited to 8 am to 5 pm Monday through Friday with emails monitored through the weekends. Depending on the severity of the issue Custom Solar can deploy staff on the weekends to resolve and issue. Warranty and Service Information Under a Power Purchase Agreement Custom Solar will operate and maintain the system for the full PPA term. If the customer chooses to purchase the system or buy out the remaining PPA, Custom Solar warrants the workmanship of the installation for 10 years from the original install date and provides assistance in obtaining manufacture warranties for the life of the system. Solar World (Panels) Warranty • 10 Year Workmanship Warranty • 25 Year Linear Production Warranty • Degradation: First year actual output power will be no less than 97% of labeled power output. From year 2 to year 25, the actual annual power decline will be no more than 0.7 %. By the end of year 25, the actual power output will be no less than 80.2 % of the labeled power output. Fronius (Inverter) Warranty • 10 Year Warranty Standard • Custom Solar has included the 20 year warranty extension in the PPA cost. Unirac - Solar Mount (Racking) Warranty • 10 Year Warranty Data sheets and warranties included for all equipment in the Appendix. Recommendations x Tilting the System - Custom Solar highly recommends tilting the system a minimum of 5° to prevent soiling by allowing natural cleaning by water runoff. Additionally tilting the system will greatly improve production of the system. For this system a 10° tilt will increase the production by 4,440kWh/yr or about 6.5%. Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 16 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D 14 Purchase Cost The system as designed is a 54.72kW-dc system designed utilizing all American made products. The system will be installed on the carport structure (built by others) and interconnected to the buildings electrical service. The pricing below is representative of the system described in the preceding pages. The Turn Key Purchase Price is : $118,300 • Pricing Includes Performance Bonding • Pricing Excludes City, County or State Taxes (These should not apply) • Pricing does not take into account 30% Federal Income Tax Credit or local rebates • Pricing does not take into account any prevailing wages • Expected Total kWh Output in the 1st year is 68,392kWh Power Purchase Agreement The PPA pricing below is representative of the system described for the Turn Key Price above. PPA Rate (1 st Year) = $0.145/kWh (Assumes project is eligible for $10,000 utility rebate) Annual Escalator = 2.9% Year 7 buyout option = $143,912 The buyout value at year seven (or any year thereafter) is determined by the Net Present Value of anticipated future income from system generation at a 3% discount. End of Term Options – Includes option for host to extend PPA Agreement or have system removed by Provider. A. Extension Includes two options to extend PPA term by five years. B. Removal Upon the end of the Term the Agreement (except in the case where the Term ends as a result of the purchase by the Purchaser of the Generating Facility by reason of exercise of the Purchase Option granted herein), Provider will sever, disconnect, and remove the Generating Facility and all other Provider property from the Site. Provider may abandon in place conductors between the roof and the electrical room, and any other components installed within finished walls of the Building. All removal, repair and restoration will be at Provider’s sole expense. Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 17 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D 15 Options The options listed below can be added or subtracted from the turn key purchase price and are outside of the PPA pricing model. A. Inverter Warranty Extension o Inverter warranties can be upgraded to 20 years - Add $4,600 B. Tier 1 Panel (Non-American Made) - o Substitute Solarworld 285W panels for Renesola 260W panels o System Size decreases from 54.72kW to 49.92kW and production decrease by 6,740kWh/yr o Subtract $19,100 from Turn Key Price. o This price assumes no other adders are chosen so bonding will no longer be required as the contract price will fall below $100,000. If adders are chosen in addition to this option subtract $16,100. C. Carport Structure 1. Carport Structure Custom Solar can procure, install and engineer the carport canopy. Canopy structure would only include the area shown in the site plan covered by PV panels. The structure will come with painted main supports and galvanized purlins designed to integrate with the PV panels for a cleaner installation (See images below). Main structural supports will be located at 20' intervals instead of every 10' as detailed for the current structure. Clearance height set at 9'. Pricing includes working with Parking Garage Engineers to determine the proper integration with the facilities structure. Pricing is good for 45 days on the carport structure. Any pricing increase over 10% due to the cost of steel increasing will be added to the final bid after 45 days. Pricing includes welding the main support beams for the structure to an integrated metal plate installed on the Pilaster and provided by others. Pricing does not include foundation/pilaster installation or engineering. Add $49,000 2. Tilt structure 10° to the SW to increase production - Add $1,400 3. Install Metal decking beneath structure to provided water mitigation (Not Water Proofing) and to hide wiring. - Add $8,100 Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 18 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D solarworld.com SW 285 MONO Designed to withstand heavy accumulations of snow and ice Every component is tested to meet 3 times IEC requirements Sunmodule Plus: Positive performance tolerance 25-year linear performance warranty and 10-year product warranty Glass with anti-reflective coating -0/+5 Wp Anti-Reflective Coating TUV Power controlled: Lowest measuring tolerance in industry World-class quality Fully-automated production lines and seamless monitoring of the process and mate- rial ensure the quality that the company sets as its benchmark for its sites worldwide. SolarWorld Plus-Sorting Plus-Sorting guarantees highest system efficiency. SolarWorld only delivers modules that have greater than or equal to the nameplate rated power. 25-year linear performance guarantee and extension of product warranty to 10 years SolarWorld guarantees a maximum performance digression of 0.7% p.a. in the course of 25 years, a significant added value compared to the two-phase warranties com- mon in the industry. In addition, SolarWorld is offering a product warranty, which has been extended to 10 years.* *in accordance with the applicable SolarWorld Limited Warranty at purchase. www.solarworld.com/warranty geprüte Sicherheit Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 19 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D SW 285 MONO SW-01-6007US 12-2014 THERMAL CHARACTERISTICS NOCT 46 °C TC Isc 0.04 %/°C TC Voc -0.30 %/°C TC Pmpp -0.41 %/°C Operating temperature -40°C to 85°C PERFORMANCE AT 800 W/m², NOCT, AM 1.5 Maximum power Pmax 213.1 Wp Open circuit voltage Voc 36.4 V Maximum power point voltage Vmpp 28.7 V Short circuit current Isc 7.96 A Maximum power point current Impp 7.43 A Minor reduction in efficiency under partial load conditions at 25°C: at 200 W/m², 100% (+/-2%) of the STC efficiency (1000 W/m²) is achieved. COMPONENT MATERIALS Cells per module 60 Cell type Mono crystalline Cell dimensions 6.17 in x 6.17 in (156.75 x 156.75 mm) Front Tempered glass (EN 12150) Frame Clear anodized aluminum Weight 39.5 lbs (17.9 kg) ADDITIONAL DATA Power sorting1 -0 Wp / +5 Wp J-Box IP65 Module leads PV wire per UL4703 with H4 connectors Module type (UL 1703) 1 Glass Low iron tempered with ARC SYSTEM INTEGRATION PARAMETERS Maximum system voltage SC II / NEC 1000 V Maximum reverse current 25 A Number of bypass diodes 3 Design Loads* Two rail system 113 psf downward 64 psf upward Design Loads* Three rail system 170 psf downward 71 psf upward Design Loads* Edge mounting 30 psf downward 30 psf upward * Please refer to the Sunmodule installation instructions for the details associated with these load cases. PERFORMANCE UNDER STANDARD TEST CONDITIONS (STC)* 1) Measuring tolerance (Pmax ) traceable to TUV Rheinland: +/- 2% (TUV Power Controlled). Maximum power Pmax 285 Wp Open circuit voltage Voc 39.7 V Maximum power point voltage Vmpp 31.3 V Short circuit current Isc 9.84 A Maximum power point current Impp 9.20 A Module efficiency m 17.0 % *STC: 1000 W/m², 25°C, AM 1.5 All units provided are imperial. SI units provided in parentheses. SolarWorld AG reserves the right to make specification changes without notice. Module current [A] Module voltage [V] 1000 W/m² 800 W/m² 600 W/m² 25-YEAR LIMITED WARRANTY Valid from 03.25.2015 Plus By purchasing the solar modules (hereafter referred to as: products) from SolarWorld Americas Inc. (“SolarWorld”), you have chosen a level of quality, which meets the highest requirements. SolarWorld assumes that use in accordance with regulations will reliably maintain the function of the products to produce electricity (hereinafter referred to as: functional capability) as well as reliably maintaining the performance of the products. As a sign of our conﬁdence in this quality, SolarWorld is happy to grant you as the end-user of the products (i. e., the person who put the products into operation correctly for the ﬁrst time or the person who has legitimately purchased the products from such an end-customer without any modiﬁcations) the rights which are presented below: A - Limited product warranty: 1. SolarWorld provides you with a warranty for the functional capability of the products until ten years has elapsed since the purchase of the product and that the product: ȯ M``gn5)}3}nfg¡f)JgM`%)}))5)ȄJMJ`MfMJ)M`M¡n3J)n`}fn%`)ȃ A condition for this is correct installation and use in accordance with regulations, as described in the installation instructions enclosed with the product. ȯ M``gn)Z)ng¡`n%Mg>n}%Mn`n}Mngn3J)>`ȃ ȯ MJM`)g%ngg)n}z`>M``})fMg3)g%nz)}Mng`ȄM3J)¡})Mg``)%z}n3)- sionally and are not permanently positioned in water (puddle). However, damage to the cable, which is caused by abrasion on a rough lower surface owing to insufficient ﬁxing or owing to unprotected running of the cable over sharp edges, is excluded. Any damage caused by animals (e. g., rodent bites, birds, insects) is also exempted. ȯ MJM`fMgMf3}f)M``gn3}))«)zJ)gMM3}n¡M3MMMg``)%n}})`¡ȃƳJ)z- pearance of the product as well as any scratches, stains, mechanical wear, rust, mould, optical deterioration, discoloration and other changes, which occurred after delivery by SolarWorld, do not represent defects, insofar as the change in appearance does not lead to a deterioration in the functional capability of the product. A claim in the event of glass breakage arises only to the extent that there was no external inﬂuence. ɶȃŶ3J)z}n%) JMMng)n3J)n)f)gMng)%%)3)%}Mg>JMz)}Mn%g%JMJg)5) on the functional capability of the product, SolarWorld will repair the defective products, supply replacement products or provide the customer with an appropriate residual value of the products as compensation at its discretion. B - Limited performance guarantee: ɴȃ ƭn`}Ǆn}`%>}g))JJ)`nzn3J)z}n%M``fngn`)ɽɻɰn3)5)- tive output during the ﬁrst year after purchase of the product and as of the second year after pur- J)n3J)z}n%ȄJ))5)M)nzM``%)`Mg)gg``¡¡gnfn})Jgɳȃɻɰ3n}z)}Mn% n3ɶɸ¡)}ȄnJ¡J))g%n3J)ɶɹJ¡)}3)}z}J)g`nzn3`)ɼɳȃɶɰn3 )5)M)nzM``)JM))%ȃŶgJ)))gn3g)>M)%)MMngn3`z}n%z)}3n}fg) from the so-called threshold values, SolarWorld will either supply you with replacement products, which make it possible to maintain actual performance, carry out repairs, which make it possible to achieve actual performance or provide you with ﬁnancial compensation for the lower performance of the product. During the ﬁrst 15 years of the guarantee period SolarWorld will exclusively either supply replacement products, which make it possible to maintain the actual performance or carry out repairs, which make such an actual performance possible. After 15 years of the guarantee period SolarWorld is free to also grant ﬁnancial compensation for the lower performance of the products. 2. When replacement products are supplied, there is no entitlement for the use of new products or Jn)JMJ})>nn%g)ȃƕgJ)ng}}¡Ȅƭn`}Ǆn}`%MJn}M«)%n`nzz`¡)%g%ȵ or repaired products as replacements. C - Further conditions of entitlement: ɴȃ ƳJ)z)}Mn%n3J)z)}3n}fg)>}g))g%)}őȺM})}M)%nz)}Mn%n3ɶɹ¡)}3}nfJ) purchase of the product and will not be extended even in the event of a repair or exchange of a product. ɶȃƳJ))5)M)nzg%J)`nzn3J)z}n%})n)%))}fMg)%3n}J))}M9Mng n3g¡>}g)))Mg>g%}%)ng%MMngȄ%)}M)%g%)}ŶŜŒɺɳɽɳɸȃƳJ)%)MM) f)})f)gn3z)}3n}fg)M}}M)%n¡})n>gM«)%f)}Mg>MgM)n}J}n>J SolarWorld’s own measurements (the assessment of measurement tolerances is undertaken in n}%g)MJŜƏɹɳɷɼɳȺȃƳJ)>}g))%n)gnn)}}gzn}nn})}gJ)z}n%n} for a new delivery of repaired or replacement products. It also does not cover the costs of the instal- lation or reinstallation of products, as well as other expenditure by the end-customer or seller. ɷȃƕg)}JMzn3``z}n%JMJJ)))g})z`)%z)nƭn`}Ǆn}`%ȃ / Perfect Welding / Solar Energy / Perfect Charging / AFCI & NEC 2014 Compliant TECHNICAL DATA FRONIUS SYMO (10.0-3 208-240, 12.0-3 208-240, 10.0-3 480, 12.5-3 480, 15.0-3 208) INPUT DATA SYMO 10.0-3 208-240 SYMO 12.0-3 208-240 SYMO 10.0-3 480 SYMO 12.5-3 480 SYMO 15.0-3 208 Recommended PV power (kWp) 8.0 - 13.0 9.5 - 15.5 8.0 - 13.0 10.0 - 16.0 12.0 - 19.5 Max. usable input current (MPPT1/MPPT 2) 25.0 A / 16.5 A 50.0 A Max. usable input current total (MPPT 1 + MPPT 2) 41.5 A 50.0 A Max. array short circuit current (1.5 * Imax) MPPT 1/MPPT 2) 37.5 A / 24.8 A 75.0 A Integrated DC string fuse holders NA 6- and 6+ MPP-voltage range 300 - 500 V 300 - 800 V 350 - 800 V 325 - 850 V Operating voltage range 200 - 600 V 200 - 1000 V 325 – 1000 V Max. input voltage 600 V 1000 V Nominal input voltage 208 V 350 V 350 V NA NA 325 V 240 V 370 V 370 V NA NA NA 480 V NA NA 675 V 685 V NA Admissable conductor size DC AWG 14 - AWG 6 copper direct, AWG 6 aluminum direct, AWG 4 - AWG 2 copper or aluminum with input combiner Number of MPPT 21 OUTPUT DATA SYMO 10.0-3 208-240 SYMO 12.0-3 208-240 SYMO 10.0-3 480 SYMO 12.5-3 480 SYMO 15.0-3 208 Max. output power 208 V 9995 VA 11995 VA NA NA 15000 VA 240 V 9995 VA 11995 VA NA NA NA 480 V NA NA 9995 VA 12495 VA NA Max. continuous output current 208 V 27.7 A 33.3 A NA NA 41.6 A 240 V 24.0 A 28.9 A NA NA NA 480 V NA NA 12.0 A 15.0 A NA Recommended OCPD/AC breaker size 208 V 35 A 45 A NA NA 60 A 240 V 30 A 40 A NA NA NA 480 V NA NA 15 A 20 A NA Max. Eʋciency 97.0 % 97.0 % 98.1 % 98.1 % 97.3% CEC Eʋciency 208 V 96.5 % 96.5 % NA NA 96.5% 240 V 96.5 % 96.5 % NA NA NA 480 V NA NA 96.5 % 97.0 % NA Admissable conductor size AC AWG 14 - AWG 6 Grid connection 208 / 240 V 208 / 240 V 480 V Delta +N** 208 V Frequency 60 Hz Total harmonic distortion < 1.5 % < 1.75 % < 1.75 % < 1.5 % < 3.5% Power factor 0 - 1 ind./cap. FRONIUS SYMO / Powering commercial projects that last. The Fronius Symo. / Featuring ten models ranging from 10 kW to 24 kW, the transformerless Fronius Symo is the ideal compact three- phase inverter for all commercial applications. The high system voltage and wide input range ensure maximum flexi- bility in system design. With low roof loading, NEMA 4X and 1000 V DC rating, the Fronius Symo can be mounted in many different ways, including flat on a roof or on a pole. The modern design is equipped with the SnapINverter mounting system, allowing for lightweight, secure and convenient installation. Several industry-leading features are available with the Fronius Symo including Wi-Fi®* and SunSpec Modbus interfaces for seamless monitoring and data- logging, field proven Arc Fault Circuit Interruption (AFCI), NEC 2014 compliant, and Fronius’ superb online and mo- bile monitoring platform Fronius Solar.web. N W S E / Flexible Design / Integrated Data Communication / Smart Grid Ready / SnapINverter TECHNICAL DATA (10.0-3 208/240, 12.0-3 208/240, 10.0-3 480, 12.5-3 480, 15.0-3 208) TECHNICAL DATA (15.0-3 480, 17.5-3 480, 20.0-3 480, 22.7-3 480, 24.0-3 480) INPUT DATA SYMO 15.0-3 480 SYMO 17.5-3 480 SYMO 20.0-3 480 SYMO 22.7-3 480 SYMO 24.0-3 480 Recommended PV power (kWp) 12.0 – 19.5 14.0 - 23.0 16.0 - 26.0 18.0 - 29.5 19.0 - 31.0 Max. usable input current (MPPT1/MPPT 2) 33.0 A / 25.0 A Max. usable input current total (MPPT 1 + MPPT 2) 51 A Max. array short circuit current (1.5 * Imax) MPPT 1/MPPT 2) 49.5 A / 37.5 A Integrated DC string fuse holders NA NA 6- and 6+ MPP-voltage range 350 - 800 V 400 - 800 V 450 - 800 V 500 - 800 V 500 - 800 V Operating voltage range 200 - 1000 V Max. input voltage 1000 V Nominal input voltage 208 V NA NA NA NA NA 240 V NA NA NA NA NA 480 V 685 V 695 V 710 V 720 V 720 V Admissable conductor size DC AWG 14 - AWG 6 copper direct, AWG 6 aluminum direct, AWG 4 - AWG 2 copper or aluminum with input combiner Number of MPPT 2 GENERAL DATA STANDARD WITH ALL FRONIUS SYMO MODELS Dimensions (width x height x depth) 20.1 x 28.5 x 8.9 inches Degree of protection NEMA 4X Night time consumption < 1 W Inverter topology Transformerless Cooling Variable speed fan Installation Indoor and outdoor installation Ambient operating temperature range -40°F - + 140 °F (-40 - +60 °C) Permitted humidity 0 - 100 % (non-condensing) DC connection terminals 6x DC+ and 6x DC- screw terminals for copper (solid / stranded / ʉne stranded) or aluminum (solid / stranded) AC connection terminals Screw terminals 14-6 AWG Certiʉcates and compliance with standards (Except Symo 15.0 208 V) UL 1741-2010, UL1998 (for functions: AFCI and isolation monitoring), IEEE 1547-2003, IEEE 1547.1-2008, ANSI/IEEE C62.41, FCC Part 15 A & B, NEC Article 690, C22. 2 No. 107.1-01 ( September 2001), UL1699B Issue 2 -2013, CSA TIL M-07 Issue 1 -2013 Certiʉcates and compliance with standards (Symo 15.0 208 V) UL 1741-2015, UL1998 (for functions: AFCI, RCMU and isolation monitoring), IEEE 1547-2003, IEEE 1547.1-2003, ANSI/IEEE C62.41, FCC Part 15 A & B, NEC 2014 Article 690, C22. 2 No. 107.1-01 (September 2001) , UL1699B Issue 2 -2013, CSA TIL M-07 Issue 1 -2013 GENERAL DATA SYMO 10.0-3 208-240 SYMO 12.0-3 208-240 SYMO 10.0-3 480 SYMO 12.5-3 480 SYMO 15.0-3 208 Weight 91.9 lbs. 76.7 lbs. 78.3 lbs. PROTECTIVE DEVICES STANDARD WITH ALL FRONIUS SYMO MODELS AFCI & 2014 NEC Compliant Yes DC disconnect Yes DC reverse polarity protection Yes Ground Fault Protection with Isolation Monitor Interrupter Yes INTERFACES AVAILABLE WITH ALL FRONIUS SYMO MODELS USB (A socket) Datalogging and inverter update possible via USB 2x RS422 (RJ45 socket) Fronius Solar Net, interface protocol AVAILABLE WITH THE FRONIUS DATAMANAGER 2.0 CARD ( ONLY ONE CARD REQUIRED FOR UP TO 100 INVERTERS ) Wi-Fi/Ethernet/Serial/ Datalogger and webserver Wireless standard 802.11 b/g/n / Fronius Solar.web, SunSpec Modbus TCP, JSON / SunSpec Modbus RTU 6 inputs and 4 digital I/Os Load management; signaling, multipurpose I/O **+N for sensing purposes - no current carrying conductor. Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 23 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D OUTPUT DATA SYMO 15.0-3 480 SYMO 17.5-3 480 SYMO 20.0-3 480 SYMO 22.7-3 480 SYMO 24.0-3 480 Max. output power 208 V NA NA NA NA NA 240 V NA NA NA NA NA 480 V 14995 VA 17495 VA 19995 VA 22727 VA 23995 VA Max. continuous output current 208 V NA NA NA NA NA 240 V NA NA NA NA NA 480 V 18.0 A 21.0 A 24.0 A 27.3 A 28.9 A Recommended OCPD/AC breaker size 208 V NA NA NA NA NA 240 V NA NA NA NA NA 480 V 25 A 30 A 30 A 35 A 40 A Max. Eʋciency 98.0 % 98.0 % CEC Eʋciency 208 V NA NA NA NA NA 240 V NA NA NA NA NA 480 V 97.0 % 97.5 % 97.5 % 97.5 % 97.5 % Admissable conductor size AC AWG 14 - AWG 6 Grid connection 480 V Delta +N** Frequency 60 Hz Total harmonic distortion < 1.5 % < 1.25 % < 1.0 % <1.25 % < 1.0 % Power factor 0 - 1 ind./cap. TECHNICAL DATA (15.0-3 480, 17.5-3 480, 20.0-3 480, 22.7-3 480, 24.0-3 480) **+N for sensing purposes - no current carrying conductor. GENERAL DATA STANDARD WITH ALL FRONIUS SYMO MODELS Dimensions (width x height x depth) 20.1 x 28.5 x 8.9 inches Degree of protection NEMA 4X Night time consumption < 1 W Inverter topology Transformerless Cooling Variable speed fan Installation Indoor and outdoor installation Ambient operating temperature range -40°F - + 140 °F (-40 - +60 °C) Permitted humidity 0 - 100 % (non-condensing) DC connection terminals 6x DC+ and 6x DC- screw terminals for copper (solid / stranded / ʉne stranded) or aluminum (solid / stranded) AC connection terminals Screw terminals 14-6 AWG Certiʉcates and compliance with standards UL 1741-2010, UL1998 (for functions: AFCI and isolation monitoring), IEEE 1547-2003, IEEE 1547.1-2008, ANSI/IEEE C62.41, FCC Part 15 A & B, NEC Article 690, C22. 2 No. 107.1-01 ( September 2001), UL1699B Issue 2 -2013, CSA TIL M-07 Issue 1 -2013 GENERAL DATA SYMO 15.0-3 480 SYMO 17.5-3 480 SYMO 20.0-3 480 SYMO 22.7-3 480 SYMO 24.0-3 480 Weight 95.7 lbs. PROTECTIVE DEVICES STANDARD WITH ALL FRONIUS SYMO MODELS AFCI & 2014 NEC Compliant Yes DC disconnect Yes DC reverse polarity protection Yes Ground Fault Protection with Isolation Monitor Interrupter Yes INTERFACES AVAILABLE WITH ALL FRONIUS SYMO MODELS USB (A socket) Datalogging and inverter update possible via USB 2x RS422 (RJ45 socket) Fronius Solar Net, interface protocol AVAILABLE WITH THE FRONIUS DATAMANAGER 2.0 CARD ( ONLY ONE CARD REQUIRED FOR UP TO 100 INVERTERS ) Wi-Fi/Ethernet/Serial/ Datalogger and webserver Wireless standard 802.11 b/g/n / Fronius Solar.web, SunSpec Modbus TCP, JSON / SunSpec Modbus RTU 6 inputs and 4 digital I/Os Load management; signaling, multipurpose I/O TECHNICAL DATA (15.0-3 480, 17.5-3 480, 20.0-3 480, 22.7-3 480, 24.0-3 480) Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 24 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D / Perfect Welding / Solar Energy / Perfect Charging v05 May 2015 EN Further information about all Fronius products and our global sales partners and representatives can be found at www.fronius.com WE HAVE THREE DIVISIONS AND ONE PASSION: SHIFTING THE LIMITS OF POSSIBILITY. / Whether welding technology, photovoltaics or battery charging technology ɽ our goal is clearly defined: to be the innovation leader. With around 3,300 employees worldwide, we shift the limits of what’s possible - our record of over 900 granted patents is testimony to this. While others progress step by step, we innovate in leaps and bounds. Just as we’ve always done. The responsible use of our resources forms the basis of our corporate policy. Fronius USA LLC 6797 Fronius Drive Portage, IN 46368 USA pv-support-usa@fronius.com www.fronius-usa.com REV. 1.15.16 FRONIUS SYMO 24.0-3 480 TEMPERATURE DERATING CURVE FRONIUS SYMO 24.0-3 480 CEC EFFICIENCY CURVE OUTPUT POWER [W] 80 90 100 110 120 0 5,000 20,000 25,000 10,000 15,000 AMBIENT TEMPERATURE [°F] ■ 500 VDC ■ 720 VDC ■ 800 VDC EFFICIENCY [%] 70 75 90 95 100 0 0.1 0.2 0.3 0.5 0.75 1 ■ 500 VDC ■ 725 VDC ■ 800 VDC 80 85 STANDARDISED OUTPUT POWER PAC/PAC,R Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 25 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D / Battery Charging Systems / Welding Technology / Solar Electronics E L E C T R I C G R I D C O M M U N I C A T I O N / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / Battery Charging Systems / Welding Technology / Solar Electronics v02 2012 EN Text and images correspond to the current state of technology at the time of printing. Subject to modifications. All information is without guarantee in spite of careful editing - liability excluded. Copyright © 2011 Fronius™. All rights reserved. WE HAVE THREE DIVISIONS AND ONE PASSION: SHIFTING THE LIMITS. / Whether Battery Charging Systems, Welding Technology or Solar Electronics - our goal is clearly defined: to be the technology and quality leader. With around 3,000 employees worldwide, we shift the limits of what’s possible - our more than 850 active patents are testimony to this. While others progress step by step, we innovate in leaps and bounds. Further information about all Fronius products and our global sales partners and representatives can be found at www.fronius.com EN v01 May 2013 as13 Fronius International GmbH Froniusplatz 1 4600 Wels Austria pv@fronius.com www.fronius.com Fronius UK Limited Maidstone Road, Kingston Milton Keynes, MK10 0BD United Kingdom pv-sales-uk@fronius.com www.fronius.co.uk Fronius Australia Pty Ltd. 90-92 Lambeck Drive Tullamarine VIC 3043 Australia pv-sales-australia@fronius.com www.fronius.com.au Q U/UN P 0.9 1.0 1.1 1.2 Q(U) Ž3 8 Grid voltage in optimum range. No intervention needed. Grid voltage approaching limit values. Targeted reactive power control stabilises the voltage [Q(U)]. Reactive power is not enough to keep the voltage within the limit value. In-phase effective power control prevents a shutdown [P(U)]. Overvoltage range (mandatory shutdown) Q Reactive power Ž3 &KDQJHLQHIIHFWLYHSRZHU U Voltage UN Nominal voltage Voltage-dependent reactive power control Voltage-dependent effective power control STABLE GRID DUE TO TARGETED ASYMMETRICAL FEED / Should the voltage be too high in just one phase, Fronius inverters can reduce the power in this phase while feeding more energy into the grid in the other two phases. This targeted asymmetrical feed means there is no loss of energy and the grid voltage is improved. ADVANCED GRID FEATURES FOR A STABLE GRID / The Advanced Grid Features (AGF) incorporate a range of functions that support reliable grid operation. They prevent grid faults and unexpected failures leading to yield losses. In line with new guidelines for energy fed into the grid, these features can be activated at any time. OPTIMISING REACTIVE AND EFFECTIVE POWER FOR MAXIMUM YIELDS / PV systems may only feed energy into the grid if the grid voltage is within specified limits. Generating peaks can cause 6(B7R:B(1B86B FRONIUS LIMITED WARRANTY TERMS AND CONDITIONS YDOLGIURP 7KHVH OLPLWHG ZDUUDQW\ WHUPV DQG FRQGLWLRQV DSSO\ WR RULJLQDO LQVWDOODWLRQRI)URQLXVLQYHUWHUVLQWKH8QLWHG6WDWHVRI$PHULFD 7KHZDUUDQW\KROGHULVWKHRZQHURIWKHLQVWDOOHG)URQLXVSURGXFW Content of the warranty: Fronius Warranty Plus/Warranty Extension Plus 7KH )URQLXV :DUUDQW\ 3OXV:DUUDQW\ ([WHQVLRQ 3OXV FRYHUV PDWHULDOVVHUYLFLQJDQGWUDQVSRUWXQGHUWKHWHUPVDQGFRQGLWLRQV LQGLFDWHGEHORZ Fronius Warranty/Warranty Extension 7KH)URQLXV:DUUDQW\:DUUDQW\([WHQVLRQFRYHUVPDWHULDOVXQGHU WKHWHUPVDQGFRQGLWLRQVLQGLFDWHGEHORZ Duration of warranty: ,QHDFKFDVHWKHZDUUDQW\SHULRGEHJLQVWKHGD\WKDWWKHSURGXFWV OHDYHWKH)URQLXVIDFWRU\ Fronius string inverters (wall-mounted devices) )URQLXV VWULQJ LQYHUWHUV DUH VXSSOLHG ZLWK D \HDU )URQLXV :DUUDQW\3OXV Fronius central inverters (free-standing devices) )URQLXVFHQWUDOLQYHUWHUVDUHVXSSOLHGZLWKD\HDU)URQLXV :DUUDQW\3OXV Fronius Rapid Shut-down Box (RSB) )URQLXV5DSLG6KXWGRZQER[HVDUHVXSSOLHGZLWKD\HDU)URQLXV :DUUDQW\3OXV Warranty claim: ,IDIDXOWVKRXOGRFFXUGXULQJWKH)URQLXVZDUUDQW\SHULRGDQGWKH IDXOW LV FRYHUHG E\ WKH OLPLWHG ZDUUDQW\ WHUPV DQG FRQGLWLRQV )URQLXVUHVHUYHVWKHULJKWWR PDNHWKHFRUUHVSRQGLQJVSDUHSDUWVDYDLODEOH PDNHDQHTXLYDOHQWUHSODFHPHQWGHYLFHDYDLODEOH UHSDLUWKLVIDXOWDWLWVSUHPLVHVRURQWKHFXVWRPHU VSUHPLVHV RUKDYHWKHVHVHUYLFHVFDUULHGRXWE\DVXLWDEO\WUDLQHGLQVWDOOHU Materials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cope and validity of the warranty )URQLXVZDUUDQWLHVDSSO\RQO\ WR)URQLXVSURGXFWVWKDWKDYHEHHQ LGHQWLILHGXQDPELJXRXVO\E\WKHLUVHULDOQXPEHUDQGFHUWLILHGIRUWKH FRXQWU\RILQVWDOODWLRQ2WKHUFRPSRQHQWVRIWKHSKRWRYROWDLFV\VWHP DV ZHOO DV V\VWHP DGGRQV V\VWHP PRQLWRULQJ DQG GDWD FRPPXQLFDWLRQ FRPSRQHQWVDQ\DFFHVVRULHVDQGSUHSURGXFWLRQ GHYLFHVDUHH[FOXGHGIURPWKHZDUUDQW\ Exclusions from the Fronius warranties )DLOXUHWRREVHUYHWKHRSHUDWLQJLQVWUXFWLRQVLQVWDOODWLRQ LQVWUXFWLRQVRUPDLQWHQDQFHSURFHGXUHV ,PSURSHUFRPPLVVLRQLQJWUDQVSRUWRSHUDWLRQ ,QDGHTXDWHYHQWLODWLRQRIWKHGHYLFH $Q\ZRUNSHUIRUPHGRQWKHGHYLFHE\SHUVRQVZKRKDYHQRW EHHQDXWKRULVHGE\)URQLXV )DLOXUHWRREVHUYHVDIHW\UXOHVDQGLQVWDOODWLRQVWDQGDUGV )RUFHPDMHXUH VWRUPOLJKWQLQJRYHUYROWDJHILUHHWF 2 9 16" 1411 BROADWAY BLVD NE ALBUQUERQUE, NM 87102 USA WWW.UNIRAC.COM PRODUCT LINE: DRAWING TYPE: DESCRIPTION: REVISION DATE: SOLARMOUNT PART DETAIL RAIL APRIL 2016 LEGAL NOTICE PRODUCT PROTECTED BY ONE OR MORE US PATENTS. SHEET SM-P01 1 4" BOLT LOCATION 3 8" BOLT LOCATION DRAWING NOT TO SCALE ALL DIMENSIONS ARE NOMINAL 3 4" Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 30 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D 1411 BROADWAY BLVD NE ALBUQUERQUE, NM 87102 USA WWW.UNIRAC.COM PRODUCT LINE: DRAWING TYPE: DESCRIPTION: REVISION DATE: SOLARMOUNT PART & ASSEMBLY BONDING TOP CLAMPS APRIL 2016 LEGAL NOTICE PRODUCT PROTECTED BY ONE OR MORE US PATENTS SHEET SM-A07 DRAWING NOT TO SCALE ALL DIMENSIONS ARE NOMINAL BONDING SM MID CLAMP BONDING SM END CLAMP MID CLAMP END CLAMP 1 4" 15 16" 17 8" Ø1 4" Ø1 4" 1 3 16" 11 2" 1 8" VARIES - REFER TO SHEET SM-P04 Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 31 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D SMSOLAR MOUNT MANUFACTURER’S LIMITED PRODUCT WARRANTY PUB15MAR02 http://www.unirac.com/residential/unirac-warranty WARRANTY Unirac, Inc., (“Unirac”) warrants to the buyer (“Buyer”) at the original installation site (“Site”) that any of the SolarMount components designed and manufactured by Unirac ඹ and installed at the Site (“Product”) shall be free from defects in material and workmanship which substantially impair their ability to perform their intended function, as referenced in the Unirac Product Information, for a period of ten (10) years – except that any factory-applied anodized finish is warranted to be free from substantial manufacturing- related visible peeling or cracking or chalking under normal atmospheric conditions for a period of five (5) years (“Finish Warranty”) – from the earlier of 1) the date the installation of the Product at the Site is substantially complete, or 2) 120 days after the purchase of the Product by the original Buyer of the Product (“Warranty Period”). WARRANTY TRANSFERENCE Buyer may transfer this Warranty to subsequent Site owners, or if original Buyer is a contractor, to the Site owner, so long as the transferee agrees to the terms of this Limited Warranty as if it were the Buyer. Proof of purchase is required for any warranty claim. FINISH WARRANTY LIMITATIONS The Finish Warranty does not apply to any issues caused by foreign residue deposited on the finish, or an installation in atmospheric conditions more corrosive than normal conditions. The Finish Warranty is VOID if the practices specified by AAMA 609 & 610-02 – “Cleaning and Maintenance for Architecturally Finished Aluminum” (www.aamanet.org) are not followed. WARRANTY LIMITATIONS This Limited Warranty covers only the Product, and not PV modules, electrical components and or wiring used in conjunction with the Product or any other materials not provided by Unirac. Goods which may be sold by Unirac, but which are not designed or manufactured by Unirac are not warranted by Unirac, are sold only with the warranties, if any, of the original manufacturers thereof. This Limited Warranty does not cover damage to the Product that occurs during its shipment, storage, installation or use, or from force majeure acts including fire, flood, earthquake, storm, hurricane or other natural disaster, war, terrorist activities, acts of foreign enemies and criminal acts. This Limited Warranty does not cover damages or problems caused by the connection to or use of alternative materials not purchased from Unirac Price List. This Limited Warranty shall be void if A) installation of the Product is not performed in accordance with the Unirac Product Information, B) if the Product has been modified, repaired, or reworked in a manner not previously authorized by Unirac in writing, or C) the Product is installed in an environment for which it was not designed, each as determined by Unirac in its sole discretion. WARRANTY CLAIMS If, within the Warranty Period, the Product shall be proven at Unirac’s sole discretion to be nonconforming, then Unirac shall repair or provide a replacement for the nonconforming Product, or any nonconforming part thereof, at Unirac’s option. Any such repair or replacement does not cause the beginning of new warranty terms, nor shall the Warranty Period of this Limited Warranty be Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 33 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 34 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D SILICON IRRADIANCE SENSOR Measurement of Solar Irradiance General Information Since 1994 we have been developing and producing different types of silicon irradiance sensors. Until now several 10000 sensors were sold worldwide. Our silicon sensor is an affordable solution for measurement of solar irradiance. The powder-coated aluminium case in conjunction with the solar cell laminated between glass and Tedlar foil builds a very reliable and rugged sensor. Mode of Operation A silicon solar cell can be used as an irradiance sensor, because the short-circuit current is proportional to irradiance. Our sensors are build out of a monocrystalline solar cell connected to a shunt. Due to the low resistance of the shunt the cell operates next to short-circuit. The temperature coefficient of the short-circuit current creates a small error. There fore all of our silicon sensors with the extension „TC“ have an active temperature compensation, which reduces this error by factor 20. The compensation is realized by using a specific temperature sensor lamina- ted to the rear side of the solar cell. The electronic circuit integrated for this com - pensation has a very low power consump- tion. The current consumption of the Si- 01TC out of the internal Lithium battery is only about 15 μA. Our silicon sensors are manufactured in different types with an internal or exter- nal power supply, with different output sig- nals and with an optional sensor output for the cell temperature. All sensors are calibrated in simulated sunlight against a reference cell of the same type. The reference cell is periodically reca- librated by Fraunhofer ISE, Freiburg. Mechanical Construction The solar cell is embedded in Ethylen- Vinyl-Ace tat (EVA) between glass and Tedlar. The laminated cell is integrated into a case of powder-coated aluminium. Therefore the sensor construction is com- parable to that of a standard PV module. The electrical connection is realized by a 3 m cable or a water proof (IP67) connector. Optional Temperature Measurement Additionally to the irradiance measure- ment our silicon sensors with the extension “-T” are able to measure the temperature of the solar cell. Therefore a temperature sen- sor is mounted to the rear side of the cell to detect the correct cell temperature. INGENIEURBÜRO Mencke & Tegtmeyer GmbH Meßgeräte für die Solartechnik INGENIEURBÜRO Mencke & Tegtmeyer GmbH Ingenieurbüro Mencke & Tegtmeyer GmbH · Hameln · © November 2012 SI-SENSOR General information • Solar cell: Monocrystalline Silicon (50 mm x 33 mm) • Temperature coefficient of solar cell for Si-02-types: approx. 0.0005 1/K • Current shunt: 0,1 Ω (TC = 20 ppm / K) with 1 V and 20 mA output 0,12 Ω (TC = 20 ppm / K) with10 V output • Operating temperature: – 20 °C to 70 °C • Electrical connection done via shielded cable, length 3 m • Case, protection mode: Powder-coated aluminum, IP 65 • Dimension, weight: 154mm x 86mm x 40mm, appr. 340 g ACCURACY Irradiance • Error with temperature compensation compared to pyranometer within the operating range of -20 °C to 70 °C and vertically beam of irradiance: ± 5 % • Non-linearity of the electronic circuit: ± 0,3% from reading for 50 to 1300 W/m2 Temperature • Accuracy at 25 °C: ± 1,5 °C • Non-linearity: ± 0,5 °C • Error (over operating temperature range of -20…-70°C): ± 2,0 °C Customs Numbers for all silicon irradiance sensors 85 41 40 90 EXTEND OF SUPPLY Options • Silicon sensor with shielded cable, 0,14 mm2, UV- and temperature resistant • Ready-made cable of the requested length • Version with waterproof connector (Si-01TCbatt always with connector) SILICON IRRADIANCE SENSOR Technical Data Sensor Types: Typ Si-01TC-batt Si-01TC Si-01TC-T Si-02 Si-02-Pt100 Si-02-Pt1000 Si-420TC Si-420TC-T Si-13TC Si-13TC-T Irradiance Cell Temperature Power Supply Temperature Output Output Compensation Signal Signal Internal Yes 0 to 1 V per ./. Li-Battery 0 to 1000 W/m2 5 to 28 VDC Yes 0 to 1 V per ./. 0 to 1000 W/m2 5 to 28 VDC Yes 0 to 1 V per 1,235 V + T[°C]*10mV/°C 0 to 1000 W/m2 ./. No appr. 60 mV per ./. 1000 W/m2 ./. No appr. 60 mV per Pt100, class A 1000 W/m2 Pt1000, class A 12 to 28 VDC Yes 4 to 20 mA per ./. 0 to 1200 W/m2 12 to 28 VDC Yes 4 to 20 mA per (13,88+0,08/°C*T[°C])mA 0 to 1200 W/m2 12 to 28 VDC Yes 0 to 10 V per 0 to 1300 W/m2 12 to 28 VDC Yes 0 to 10 V 2,268V+86,9mV/°C*T SILICON IRRADIANCE SENSOR Electrical connection and Pin numbers ELECTRICAL CONNECTION Colors of cable Irradiance: Orange Power Supply (Plus): Red Power Supply / Signal (Minus): Black Temperature: Brown; only versions with „-T“ Shield: Black (bigger diameter) ELECTRICAL CONNECTION OPTIONAL VERSION WITH CONNECTOR The electrical connection of the Si sensor is realized with the inbuilt connector and the suitable plug. Technical Data of the plug • Cable dimensions (best / max): 0,14 mm2 / 0,25 mm2 (AWG26 / AWG24) • Diameter for cable: 3,5 … 5 mm • Protection mode: IP67 in conjunction with the suitable connector The connection of the different Silicon irradiance sensors are listed in the follo- wing table. The pin numbers are printed at the inside of the plug. Please take care of the mounting of the plugs as shown at the end of the next page. Only if these moun- ting steps are done the plug reaches IP67 when connected. Typ Si-01TC-batt Si-01TC Si-01TC-T Si-02 Si-02-Pt100 Si-02-Pt1000 Si-420TC Si-420TC-T Si-13TC Si-13TC-T Pin Numbers of the plug Pin 1 Pin 2 Pin 3 Pin 4 Plus Signal Minus Signal not available not available Irradiance Irradiance Plus Signal Minus Signal* Plus Signal not available Irradiance Irradiance Power Supply Plus Signal Plus Signal Plus Signal Minus Signal* Temperature Irradiance Power Supply Irradiance Plus Signal Minus Signal not available not available Irradiance Irradiance Plus Signal Minus Signal Pt100 Pt100 Irradiance Irradiance Pt1000 Pt1000 Plus Signal Minus Signal* Plus Signal not available Irradiance Irradiance Power Supply Plus Signal Plus Signal Plus Signal Minus Signal* Temperature Irradiance Power Supply Irradiance Plus Signal Minus Signal* Plus Signal Irradiance Irradiance Power Supply Plus Signal Plus Signal Plus Signal Minus Signal* Temperature Irradiance Power Supply Irradiance * Minus signals of all sensors are identical to supply ground Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 37 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D SILICON IRRADIANCE SENSOR Handling and Installation SPECIALS • The Si-01TC-batt can be used for direct reading of irradiance via a digital voltme- ter because of its internal Lithium battery and the calibration factor of 1 V per 1000 W/m2. • Attention: Because of the internal Lithium battery of the Si-01TC-batt please use only voltmeters with a high input resistance (more than 1 MΩ). • Attention: The maximum load at the output signals with the Si-420TC(-T) is 400 Ω. • Attention: Horizontally mounting leads to increased reflexion on the glass surface and therefore to higher measurement errors. MECHANICAL INSTALLATION The Si sensor has two tounges with each two M6 and one M8 drills. The installa- tion at a suitable construction must use at least one suitable screw with washers at each mounting bracket. During installation the pressure compensation element near the electrical connec- tion must not be damaged. If the cap of the element has loosened, it can be snapped on again. HANDLING CASE The Si sensor can be cleaned using a smooth cotton cloth, water and a mild clea- ning fluid. An opening of the sensor case by the user or installation staff is not necessary. If the case is opened, we can not guarantee the seal of the case anymore. SI-02-PT100-4L WITH PRECISION SHUNT Additional to the sensor specifications mentioned above, we offer the Si-02-Pt100-4L with a precision shunt for short circuit measurement. The differing technical specifications are Shunt Type: Burster Type 1178 Resistor Value: 0.1 Ohm Precision: ±0.1 % Temperature Coefficient: 10 ppm Long therm stability: 0.02 % Cable 4 m LiYCY 6 x AWG26, weather and uv-proof Temperature Sensor Pt100 class A with 4-wire-connection MOUNTING OF PLUG Ingenieurbüro Mencke & Tegtmeyer GmbH · Hameln · © November 2012 Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 38 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D Virtus Module ReneSola.com 250W, 255W, 260W Guarantee linear power output material & workmanship 100% 95% 90% 85% 80% 0% 25 80.0% Added Value Performance Figures in % YEAR 01 97.0% 5 10 15 20 Mechanical Load Capability of up to 5400 Pa ĂƐǇ/ŶƐƚĂůůĂƟŽŶĂŶĚ,ĂŶĚůŝŶŐĨŽƌsĂƌŝŽƵƐƉƉůŝĐĂƟŽŶƐ Me Conforms with IEC 61215:2005, IEC 61730: 2004, UL 1703 PV Standards /^KϵϬϬϭ͕K,^^ϭϴϬϬϭ͕/^KϭϰϬϬϭĞƌƟĮĞĚ ƉƉůŝĐĂƟŽŶůĂƐƐ, Safety Class II, &ŝƌĞZĂƟŶŐ ,ŝŐŚDŽĚƵůĞŽŶǀĞƌƐŝŽŶĸĐŝĞŶĐŝĞƐ /^K Safety Fire ƉƉ C UL US LISTED CUS Intertek CM TUV NORD CERT GmbH I E C 6 1 2 1 5 / 6 1 7 3 0 - 1 / 6 1 7 3 Cell Type Glass Frame Junction Box Dimension Output Cable Weight Installation Hole Location 6 inches Virtus, 60 (6x10) pcs in series ,ŝŐŚdƌĂŶƐŵŝƐƐŝŽŶ͕>ŽǁůƌŽŶ͕dĞŵƉĞƌĞĚ'ůĂƐƐ ŶŽĚŝǌĞĚůƵŵŝŶƵŵůůŽǇ IP65/IP67 rated, with bypass diodes *64.6 x 39.1 x 1.6 inches ϭϮt'͕ϯϵ͘ϰŝŶĐŚĞƐ 41.9 Ibs ^ĞĞƌĂǁŝŶŐďŽǀĞ Container Pallets per Container Pieces per Container ϮϬ͛'W 12 300 ϰϬ͛,Y Ϯϴ 770 ϰϬ͛'W Ϯϴ 700 ReneSola.com Operating Temperature Maximum System Voltage Maximum Series Fuse Rating -40 o F ~нϭϴϱ o F 1000VDC (EU) / 600VDC (US) ϮϬ;hͿͬϮϬ;h^Ϳ Temperature Coefficient of Voc Temperature Coefficient of Isc Temperature Coefficient of Pmax Nominal Operating Cell Temperature (NOCT) Rev No: JC/TDS/2013.02 *Contact Renesola for tolerance specification CAUTION: All rights reserved. Design and specification are subject to change without prior notice. WĂĐŬŝŶŐ/ŶĨŽƌŵĂƟŽŶ DĂǆŝŵƵŵZĂƟŶŐƐ ůĞĐƚƌŝĐĂůŚĂƌĂĐƚĞƌŝƐƟĐƐ^d Maximum Power (Pmax) Power Tolerance Module Efficiency Maximum Power Current (lmp) Maximum Power Voltage (Vmp) Short Circuit Current (lsc) Open Circuit Voltage (Voc) Values at Standard Test Conditions STC (Air Mass AM1.5, Irradiance 1000W/m2 , Cell Temperature 25o CĎ ůĞĐƚƌŝĐĂůŚĂƌĂĐƚĞƌŝƐƟĐƐEKd Maximum Power (Pmax) Maximum Power Current (lmp) Maximum Power Voltage (Vmp) EXHIBIT C INSURANCE REQUIREMENTS 1. The Service Provider will provide, from insurance companies acceptable to the City, the insurance coverage designated hereinafter and pay all costs. Before commencing work under this bid, the Service Provider shall furnish the City with certificates of insurance showing the type, amount, class of operations covered, effective dates and date of expiration of policies, and containing substantially the following statement: “The insurance evidenced by this Certificate will not reduce coverage or limits and will not be cancelled, except after thirty (30) days written notice has been received by the City of Fort Collins.” In case of the breach of any provision of the Insurance Requirements, the City, at its option, may take out and maintain, at the expense of the Service Provider, such insurance as the City may deem proper and may deduct the cost of such insurance from any monies which may be due or become due the Service Provider under this Agreement. The City, its officers, agents and employees shall be named as additional insureds on the Service Provider 's general liability and automobile liability insurance policies for any claims arising out of work performed under this Agreement. 2. Insurance coverages shall be as follows: A. Workers' Compensation & Employer's Liability. The Service Provider shall maintain during the life of this Agreement for all of the Service Provider's employees engaged in work performed under this Agreement: 1. Workers' Compensation insurance with statutory limits as required by Colorado law. 2. Employer's Liability insurance with limits of $100,000 per accident, $500,000 disease aggregate, and $100,000 disease each employee. B. Commercial General & Vehicle Liability. The Service Provider shall maintain during the life of this Agreement such commercial general liability and automobile liability insurance as will provide coverage for damage claims of personal injury, including accidental death, as well as for claims for property damage, which may arise directly or indirectly from the performance of work under this Agreement. Coverage for property damage shall be on a "broad form" basis. The amount of insurance for each coverage, Commercial General and Vehicle, shall not be less than $1,000,000 combined single limits for bodily injury and property damage. In the event any work is performed by a subcontractor, the Service Provider shall be responsible for any liability directly or indirectly arising out of the work performed under this Agreement by a subcontractor, which liability is not covered by the subcontractor's insurance. Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 41 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D No new insurance required EXHIBIT D CONFIDENTIALITY IN CONNECTION WITH SERVICES provided to the City of Fort Collins (the “City”) pursuant to this Agreement (the “Agreement”), the Service Provider hereby acknowledges that it has been informed that the City has established policies and procedures with regard to the handling of confidential information and other sensitive materials. In consideration of access to certain information, data and material (hereinafter individually and collectively, regardless of nature, referred to as “information”) that are the property of and/or relate to the City or its employees, customers or suppliers, which access is related to the performance of services that the Service Provider has agreed to perform, the Service Provider hereby acknowledges and agrees as follows: That information that has or will come into its possession or knowledge in connection with the performance of services for the City may be confidential and/or proprietary. The Service Provider agrees to treat as confidential (a) all information that is owned by the City, or that relates to the business of the City, or that is used by the City in carrying on business, and (b) all information that is proprietary to a third party (including but not limited to customers and suppliers of the City). The Service Provider shall not disclose any such information to any person not having a legitimate need-to-know for purposes authorized by the City. Further, the Service Provider shall not use such information to obtain any economic or other benefit for itself, or any third party, except as specifically authorized by the City. The foregoing to the contrary notwithstanding, the Service Provider understands that it shall have no obligation under this Agreement with respect to information and material that (a) becomes generally known to the public by publication or some means other than a breach of duty of this Agreement, or (b) is required by law, regulation or court order to be disclosed, provided that the request for such disclosure is proper and the disclosure does not exceed that which is required. In the event of any disclosure under (b) above, the Service Provider shall furnish a copy of this Agreement to anyone to whom it is required to make such disclosure and shall promptly advise the City in writing of each such disclosure. In the event that the Service Provider ceases to perform services for the City, or the City so requests for any reason, the Service Provider shall promptly return to the City any and all information described hereinabove, including all copies, notes and/or summaries (handwritten or mechanically produced) thereof, in its possession or control or as to which it otherwise has access. The Service Provider understands and agrees that the City’s remedies at law for a breach of the Service Provider’s obligations under this Confidentiality Agreement may be inadequate and that the City shall, in the event of any such breach, be entitled to seek equitable relief (including without limitation preliminary and permanent injunctive relief and specific performance) in addition to all other remedies provided hereunder or available at law. Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 42 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D The ACORD name and logo are registered marks of ACORD CERTIFICATE HOLDER © 1988-2014 ACORD CORPORATION. All rights reserved. ACORD 25 (2014/01) AUTHORIZED REPRESENTATIVE CANCELLATION CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) JECT LOC POLICY PRO- GEN'L AGGREGATE LIMIT APPLIES PER: CLAIMS-MADE OCCUR COMMERCIAL GENERAL LIABILITY PREMISES (Ea occurrence) $ DAMAGE TO RENTED EACH OCCURRENCE $ MED EXP (Any one person) $ PERSONAL & ADV INJURY $ GENERAL AGGREGATE $ PRODUCTS - COMP/OP AGG $ DED RETENTION $ CLAIMS-MADE OCCUR $ AGGREGATE $ UMBRELLA LIAB EACH OCCURRENCE $ EXCESS LIAB DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) INSR LTR TYPE OF INSURANCE POLICY NUMBER POLICY EFF (MM/DD/YYYY) POLICY EXP (MM/DD/YYYY) LIMITS PER STATUTE OTH- ER E.L. EACH ACCIDENT E.L. DISEASE - EA EMPLOYEE E.L. DISEASE - POLICY LIMIT $ $ $ ANY PROPRIETOR/PARTNER/EXECUTIVE If yes, describe under DESCRIPTION OF OPERATIONS below (Mandatory in NH) OFFICER/MEMBER EXCLUDED? WORKERS COMPENSATION AND EMPLOYERS' LIABILITY Y / N AUTOMOBILE LIABILITY ANY AUTO ALL OWNED SCHEDULED HIRED AUTOS NON-OWNED AUTOS AUTOS AUTOS COMBINED SINGLE LIMIT BODILY INJURY (Per person) BODILY INJURY (Per accident) PROPERTY DAMAGE $ $ $ $ THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSD ADDL WVD SUBR N / A $ $ (Ea accident) (Per accident) OTHER: THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: INSURED PHONE (A/C, No, Ext): PRODUCER ADDRESS: E-MAIL FAX (A/C, No): CONTACT NAME: NAIC # INSURER A : INSURER B : INSURER C : INSURER D : INSURER E : INSURER F : INSURER(S) AFFORDING COVERAGE SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. 7/25/2016 Commercial Risk Solutions 6600 E Hampden Ave Ste 200 Denver CO 80224 Custom Solar LLC 2840 Wilderness Place, Ste F Boulder CO 80301 Westfield Insurance Pinnacol Assurance 24112 41190 Demetra Ramey 303-996-7859 303-757-7719 DRamey@crsdenver.com CUSTS-2 2000022015 A Y CWP0126513 11/10/2015 11/10/2016 1,000,000 500,000 5,000 1,000,000 2,000,000 2,000,000 X X X A Y X X X CWP0126513 11/10/2015 11/10/2016 1,000,000 A X X X 0 CWP0126513 11/10/2015 11/10/2016 1,000,000 1,000,000 B Y 4160305 12/1/2015 12/1/2016 X 1,000,000 1,000,000 1,000,000 Certificate Holder is included as additional insured for ongoing operations on the General Liability and included as additional insured on the Auto Liability with respect to operations of the named insured for the certificate holder as required by written contract. All policy terms, conditions and exclusions apply. City of Fort Collins Purchasing Department PO Box 580 Fort Collins CO 80522 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D Short Circuit Current (lsc) Open Circuit Voltage (Voc) Values at Normal Operating Cell Temperature, Irradiance of 800 W/m2 , spectrum AM 1.5, ambient temperature 20o C, wind speed 1 m/s :ϮϲϬDͲϮϰͬďǀ 260 W 0 ~ +5W 16.0% ϴ͘ϱϲ 30.4 V ϵ͘Ϭϵ 37.6 V :ϮϲϬDͲϮϰͬďǀ :ϮϱϬDͲϮϰͬďǀ 250 W 0 ~ +5W 15.4% ϴ͘Ϯϵ 30.2 V ϴ͘ϴϰ 37.3 V :ϮϱϬDͲϮϰͬďǀ ϭϴϲt ϲ͘ϱϵ Ϯϴ͘Ϯs ϳ͘ϭϯ 35.0 V :ϮϱϱDͲϮϰͬďǀ 255 W 0 ~ +5W 15.7% ϴ͘ϰϯ 30.3 V ϴ͘ϵϴ 37.4 V :ϮϱϱDͲϮϰͬďǀ ϭϴϵt ϲ͘ϲϵ Ϯϴ͘Ϯs ϳ͘ϮϬ 35.0 V 193 W ϲ͘ϳϳ Ϯϴ͘ϱs ϳ͘Ϯϳ 35.2 V DĞĐŚĂŶŝĐĂůŚĂƌĂĐƚĞƌŝƐƟĐƐ ŚĂƌĂĐƚĞƌŝƐƟĐƐ Irradiance 200W/m2 400W/m2 600W/m2 ϴϬϬtͬŵ2 1000W/m2 ĸĐŝĞŶĐǇ 15.7% 16.0% 16.1% 16.1% 16.0% Virtus Module 250W, 255W, 260W /ͲsƵƌǀĞƐ 0 5 10 15 20 25 30 35 40 0 2 4 6 8 10 200W/m2 400W/m2 600W/m2 800W/m2 1000W/m2 Current (A) Voltage (V) ƌĂǁŝŶŐKŶůǇĨŽƌZĞĨĞƌĞŶĐĞ -0.29%/ o C 0.04%/ o C -0.39%/ o C 45 o C 2 o +_ C Dimensions sĂƌŝĞĚ/ƌƌĂĚŝĂƟŽŶĸĐŝĞŶĐŝĞƐ 39.1 inches 1.6 inches 37.3 inches 64.6 inches 39.4 inches 33.9 inches 53.5 inches ϮͲϬ͘ϭϲ഼ ϰͲϬ͘ϯ഼yϬ͘ϯ഼ ϴͲϬ͘ϯϱ഼yϬ͘ϱϱ഼ ϭϲͲϬ͘ϯϭ഼yϬ͘ϭϰ഼ Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 40 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D 0 - 2 PV ASSOCIATION CYCLE Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 39 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D 0 to 1300 W/m2 Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 36 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D Schwarzer Weg 43A D-31789 Hameln Germany Tel:+49(0)5151/403699-0 Fax: +49(0)5151/403699-19 email: info@ib-mut.de http://www.ib-mut.de Banking account: Stadtsparkasse Hameln (BLZ 25450001) Account 52233 VAT No. DE258133277 Customs No. DE6018572 Finanzamt Hameln 22/200/62745 Amtsgericht Hannover HRB 202636 Management: Dipl.-Ing. Detlef Mencke Dipl.-Ing. Dirk Tegtmeyer Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 35 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D extended. Unirac’s aggregate liability for all warranty claims shall not exceed the original Purchase Price of the nonconforming Product. Buyer shall bear all costs of shipment or transportation related to the repair or replacement of the nonconforming product. Such repair or replacement shall be Buyer’s sole remedy and shall fulfill all of Unirac’s obligations with respect to the Product and all warranty claims. EXCEPT FOR THE LIMITED WARRANTY EXPRESSED ABOVE, UNIRAC MAKES NO REPRESENTATION OR WARRANTY OF ANY KIND WHATSOEVER AND HEREBY DISCLAIMS ALL OTHER WARRANTIES, EXPRESS OR IMPLIED, INCLUDING THE IMPLIED WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, COURSE OF DEALING AND USAGE OF TRADE. UNIRAC SHALL NOT BE LIABLE FOR LOSS OF USE, REVENUE OR PROFIT, OR FOR DIRECT, INDIRECT, SPECIAL, PUNITIVE, LIQUIDATED, INCIDENTAL OR CONSEQUENTIAL DAMAGES, OR FOR ANY OTHER LOSS OR COST OF A SIMILAR TYPE, OR FOR CLAIMS BY BUYER FOR DAMAGES OF BUYER’S CUSTOMERS, CLAIMS OF THIRD PARTIES OR INJURY TO PERSONS OR PROPERTY ARISING OUT OF ANY DEFECT OR NONCONFORMITY IN THE PRODUCT COVERED BY THIS WARRANTY, EVEN IF CAUSED BY THE NEGLIGENCE OF UNIRAC. ALL SUCH DAMAGES AND EXPENSES ARE HEREBY EXCLUDED. ඹ Excluding Plastic Wire Management Clips EFFECTIVE DATE: FEBRUARY 28, 2014 Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 32 of 42 DocuSign Envelope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ther legal information SELLER DISCLAIMS ALL IMPLIED WARRANTIES AND SIMILAR OBLIGATIONS (OTHER THAN THAT THE GOODS WILL BE NEW AND GOOD TITLE) INCLUDING BUT NOT LIMITED TO THOSE OF FITNESS FOR A PARTICULAR PURPOSE, AND MERCHANTABILITY, WHETHER OTHERWISE ARISING BY LAW, CUSTOM, USAGE, TRADE PRACTICE, COURSE OF DEALING, OR COURSE OF PERFORMANCE. 7KHUH DUH QR ZDUUDQWLHV ZKLFK H[WHQG EH\RQG WKRVH H[SUHVV ZDUUDQWLHV FRQWDLQHGLQWKH$JUHHPHQW%X\HUDIILUPVWKDWLWKDVQRWUHOLHGXSRQ 6HOOHU¶V VNLOO QRU MXGJPHQW WR VHOHFW RU IXUQLVK WKH *RRGV IRU DQ\ SDUWLFXODU SXUSRVH EH\RQG WKH VSHFLILF H[SUHVV ZDUUDQWLHV LQ WKH $JUHHPHQW6HOOHUGRHVQRWZDUUDQWWKH*RRGVZLOOFRPSO\ZLWKWKH UHTXLUHPHQWVRIDQ\VDIHW\RUHQYLURQPHQWDOFRGHRUUHJXODWLRQRI DQ\ IHGHUDO VWDWH PXQLFLSDOLW\ RU RWKHU MXULVGLFWLRQ EH\RQG WKH VSHFLILF H[SUHVV ZDUUDQWLHV LQ WKH $JUHHPHQW 6HOOHU GRHV QRW ZDUUDQWWKDWWKH*RRGVZLOORSHUDWHZLWKDQ\DFFHVVRULHVRUZLWKLQ DQ\V\VWHPQRWVROGXQGHUWKH$JUHHPHQWDQG6HOOHU¶VZDUUDQW\LV OLPLWHGWRWKHRSHUDWLRQRIWKH*RRGVLQDVWDQGDORQHPRGH6RPH FRXQWULHVVWDWHVRUSURYLQFHVGRQRWDOORZWKHH[FOXVLRQRUOLPLWDWLRQ RILPSOLHGZDUUDQWLHVRUWKHOLPLWDWLRQRILQFLGHQWDORUFRQVHTXHQWLDO GDPDJHV IRU FHUWDLQ SURGXFWV VXSSOLHG WR FRQVXPHUV RU WKH OLPLWDWLRQ RI OLDELOLW\ IRU SHUVRQDO LQMXU\ VR VXFK OLPLWDWLRQV DQG H[FOXVLRQVPD\EHOLPLWHGLQWKHLUDSSOLFDWLRQWRDQHQGXVHUDQG RWKHUV:KHQWKHLPSOLHGZDUUDQWLHVDUHQRWDOORZHGWREHH[FOXGHG LQWKHLUHQWLUHW\WKH\ZLOOEHOLPLWHGWRWKHGXUDWLRQRIWKHDSSOLFDEOH ZULWWHQZDUUDQW\7KHZDUUDQW\JLYHVVSHFLILFOHJDOULJKWVZKLFKPD\ YDU\GHSHQGLQJRQORFDOODZ 2WKHU OHJDO ZDUUDQW\ RU OLDELOLW\ FODLPV DJDLQVW )URQLXV UHPDLQ XQDIIHFWHGE\WKLVZDUUDQW\ ,QWKHHYHQWRIVXFKFODLPVSOHDVHFRQWDFWWKHYHQGRURI\RXUGHYLFH 2XU *HQHUDO 'HOLYHU\ DQG 3D\PHQW &RQGLWLRQV XQGHU /HJDO LQIRUPDWLRQRQRXUZHEVLWH ZZZIURQLXVFRP DOVRDSSO\ 3UHYLRXVO\ YDOLG ZDUUDQW\ FRQGLWLRQV DUH UHSODFHG E\ WKHVH FRQGLWLRQV )URQLXV UHVHUYHV WKH ULJKW WR PDNH FKDQJHV WR WKH ZDUUDQW\SURFHVVDWDQ\WLPH &XUUHQW DQG GHWDLOHG LQIRUPDWLRQ DERXW ZDUUDQW\ WHUPV DQG FRQGLWLRQV FDQ EH IRXQG RQ RXU ZHEVLWH DW ZZZIURQLXVFRPVRODUZDUUDQW\ Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 29 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D LQWKHHYHQWRIDZDUUDQW\FODLPGXULQJWKHZDUUDQW\ SHULRGSURYLGHGWKHRWKHUWHUPVRIWKHVHZDUUDQW\FRQGLWLRQVDUH PHW Servicing 7KHVHUYLFHVZDUUDQW\PHDQVWKDW)URQLXVZLOOEHDUWKHODERXUFRVWV DVVRFLDWHGZLWKWKHPDWHULDOVLQWKHHYHQWRIDZDUUDQW\FODLPGXULQJ WKH ZDUUDQW\ SHULRG SURYLGHG WKH RWKHU WHUPV RI WKHVH ZDUUDQW\ FRQGLWLRQV DUH PHW DQG SURYLGHG WKHVH VHUYLFHV DUH SURYLGHG E\ )URQLXVLWVHOIRUDQLQVWDOOHU Transport 7KH WUDQVSRUW ZDUUDQW\PHDQVWKDW)URQLXV ZLOO EHDU WKH FRVWV RI GRPHVWLF WUDQVSRUW LQ WKH HYHQW RI D ZDUUDQW\ FODLP GXULQJ WKH ZDUUDQW\ SHULRG SURYLGHG WKH RWKHU WHUPV RI WKHVH ZDUUDQW\ FRQGLWLRQV DUH PHW DQG SURYLGHG WKHVH FRVWV DUH LQFXUUHG LQ WKH FRXUVHRIWKHWUDQVSRUWSURFHVVDJUHHGEHWZHHQWKHLQVWDOOHUDQG )URQLXV 7KH LQVWDOOHU LV UHVSRQVLEOH WR WKH ZDUUDQW\ KROGHU IRU DGKHULQJWRWKHWUDQVSRUWSURFHVV General provisions 'HYLFHV RU FRPSRQHQWV DUH WR EH UHWXUQHG LQ WKH RULJLQDO RU HTXLYDOHQW SDFNDJLQJ )URQLXV UHWDLQV RZQHUVKLS RI UHSODFHPHQW GHYLFHVDQGFRPSRQHQWVLQVLGHRURXWVLGHRIWKHZDUUDQW\ZDUUDQW\ H[FOXVLRQ XQWLO WKH IDXOW\ SDUWVGHYLFHV KDYH EHHQ UHFHLYHG ,QDOO FDVHVRZQHUVKLSRIWKHIDXOW\GHYLFHSDUWVLVWUDQVIHUUHGWR)URQLXV ZKHQWKHUHSODFHPHQWGHYLFHLVUHFHLYHG,IWKHIDXOW\GHYLFHSDUWV LVDUHQRWUHWXUQHGWR)URQLXVZLWKLQGD\VWKH\ZLOOEHFKDUJHGWR WKHLQVWDOOHUDWWKHFXUUHQWUHSODFHPHQWSULFHV Fronius Warranty Extension/Warranty Extension Plus $Q H[WHQGHG ZDUUDQW\ FDQ EH SXUFKDVHG XS WR PRQWKV DIWHU GLVSDWFKE\)URQLXV)URQLXVPD\UHMHFWRUGHUVUHFHLYHGODWHU7KH H[WHQGHGZDUUDQWLHVRQO\DSSO\WR)URQLXVLQYHUWHUVXQDPELJXRXVO\ LGHQWLILHG E\ WKHLU VHULDO QXPEHU ,W LV SRVVLEOH WR H[WHQG WKH ZDUUDQW\ WR RU \HDUV IURP GLVSDWFKE\)URQLXV Considerations when making a warranty claim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ervices Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 28 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D the voltage to approach the upper limit values. To prevent an undesired shutdown in these situations, Fronius inverters can influence both effective power and reactive power in a target- ed manner. Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 27 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / / STORAGE PRODUCTION PRODUCTION PROSUMER STORAGE SMART GRID READY / As the number of decentralised energy generators rises, so too does the need for an intelligent power grid. In the Smart Grid of the future, generators will communicate with both consumers and the grid to ensure a stable mains supply. Grid operators in the future will also be imposing new requirements on local generators such as photovoltaic systems - requirements that Fronius inverters already meet today. FUTURE-PROOF AND COMMUNICATIVE / With Fronius, you are choosing an inverter packed with a range of intelligent features that is accepted by all energy providers. Over a system service life of at least 20 years, future requirements can be met through quick and easy software updates or plug-in cards. / Smart Grids need communication. Data from the inverter, such as power and voltage, can help the power supply companies to assess the condition of the grid. A communication link with decentralised generators also allows the activation and configuration of grid- supporting functions to prevent losses or power failures. / This symbol stands for a plethora of intelligent features. Fronius inverters are communicative, future-proof and provide stable grid operation. / Fully equipped for the grid of tomorrow with Fronius inverters. Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 26 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D Mounting System / PC Board Replacement Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 22 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D ɸȃƳJ))}fn3J)}M>J>}g)%n¡nMgJMŒ)}M9)Mgz}>}zJŃȺg%őȺ}MJJ) original purchase of the products, insofar as they were purchased by the original end-customer 3)}ɴɴȃɳɴȃɶɳɴɸȃƭn`}Ǆn}`%})MgJ)}M>Jn%Zn`g}¡z)M`)}M)Mgn}%g)MJ this document at any time. However, any product purchases, which have already been concluded, })fMgg5))%¡JMȤMg`%Mg>J)n`g}¡z)M`)}M)Mgn}%g)MJJM%n- ment. You can ﬁnd out about the current status of this document at any time under www.solarworld-usa.com. D - Assertion of claims: ƳJ))}Mngn3J))}M)z)M9)%g%)}ŃȺg%őȺ})|M})¡nȹMȺnMg3n}fJ)Jn}M«)%)``)}ȵ dealer of the product of the alleged defect in writing, or (ii) to send this written notiﬁcation directly nJ)%%})f)gMng)%MgŧȺȄM3J))``)}ȵ%)`)}JnJn`%)Mg3n}f)%gn`ng>)}) Mȹ)ȃ>ȃȄ owing to business closure or insolvency). Any notiﬁcation of defects is to be added to the original sales }))Mz)M%)g)n3J)z}J)g%J)Mf)n3J)z}J)n3J)ƭn`}Ǆn}`%z}n%ȃƳJ) )}MngJn`%])z`)MJMgM ))]n3J)n}})g)n3J)%)3)ȃƳJ)ngg)Mg>3n}3n} J)})n>gMMngn3J)n}})g)n3%)3)M]gn`)%>)f)gn3f)}M`g%ȵn}z}n)Mg>)}}n} for claims from the product guarantee (letter A). For claims from the performance guarantee (letter őȺJ)ngg)Mg>3n}M]gn`)%>)f)gn3J)`n)}z)}3n}fg)n3J)z}n%ȃƳJ)})}gn3 products is permitted only after the written consent of SolarWorld has been obtained. E - Use in accordance with this Limited Warranty. ɴȃ ƳJ))}M)%)}M)%n)g))g})%ng`¡M3J)z}n%Mz}nz)}`¡)f`)%Ȅ)%g% operated. Services provided by SolarWorld must therefore be withdrawn if the defects to the product are not exclusively based on the products themselves; e. g., in the following cases: a. Delays on your part or on the part of the ﬁtter in observing the assembly, operational and fMg)gg)Mg}Mngn}Mg3n}fMngȄM3JM`)%n%)3)g%ȵn}`nn3J)z}n%ȗ performance. b. Exchange, repair or modiﬁcation of the products, if this was not undertaken correctly and professionally. c. Incorrect use of the products. %ȃǃg%`MfȄ%)}MngJ}n>J) )}g`Mg=)g)g%ȵn}z)}ngȵgMf`ȃ )ȃŶgn}})n}>)n}Mgzz}nz}M)}gzn})3n})Mg``MngȄM3JM`)%n%)3)g%ȵn} loss of the products’ performance. f. Damage to the customer system or incompatibility of the customer’s system equipment with the z}n%ȄM3JM`)%n%)3)g%ȵn}`nn3J)z}n%ȗz)}3n}fg)ȃ g. Use of products on mobile units such as vehicles or ships. h. Inﬂuences such as dirt or contamination on the faceplate; contamination or damage by e. g., smoke, extraordinary salt contamination, or other chemicals. Mȃ Ŧn})fZ)})J=nn%Mg>Ȅ9})Ȅ) z`nMngȄ3``Mg>}n]Ȅ%M})n}Mg%M})`M>JgMg>}M])Ȅ or other extreme weather conditions such as hail, hurricanes, whirlwinds, sandstorms or other circumstances outside the control of SolarWorld. ɶȃƳJ))gM`)f)g})3)}})%ng%)}ŃȺg%őȺM``gn)>}g)%M3g%nngJ)fg3- })}ȗ`)`n})}M`gf)}ngJ)ơǃfn%`)J)))gJg>)%Ȅ%)`))%Ȅz))`)%n5n}f%) g})n>gM«`)ȃ F - Exclusive remedy: ƳJ)})f)%M))3n}JMgJMƈMfM)%Ǆ}}g¡})J)) `M)})f)%M)M``)n¡n z}n%z}J)}ȃƭn`}Ǆn}`%J``gn)`M`)3n}%f>)ȄMgZ}¡n}`n}MMg>nn3n}})`)% nz}n%) )z)3n}JMgJMƈMfM)%Ǆ}}g¡ȃŶgz}M`}Ȅg%)}gnM}fg)J`` SolarWorld be liable for incidental, consequential, special or other indirect damages in any way con- nected with a product. SolarWorld’s aggregate liability, if any, shall be limited to a product’s purchase price or any service furnished in connection with a product, as the case may be. G - Your contacts: Ƴn}))M))}M)g%)}JMƈMfM)%Ǆ}}g¡Ȅz`))ngJ)Jn}M«)%)``)}ȵ%)`)}n3¡n} z}n%n}ƭn`}Ǆn}`%J)3n``nMg>%%}))ȅŒnf)}ƭ)}M)Ȅƭn`}Ǆn}`%Ńf)}MŶgȃȄɶɹɷɳɳ NW Evergreen Road, Hillsboro, OR, 97124, USA. Email: customerservice@solarworld-usa.com. Phone: ȹɼɹɹȺɸɺɻȢɺɹɶɻȃŦ ȅȹɹɳɷȺɼɸɸȢɷɸɳɷȃ H - Choice of law: ƳJMƈMfM)%Ǆ}}g¡ȄMg`%Mg>MJn`MfMMngJ)}M>Jg%})zngMM`MM)>}g)%J)})g%)}Ȅ shall be governed and construed in accordance with the laws of the State of Oregon, without regard to the conﬂicts of law provisions thereof. I - Validity: ƳJ)3n``nMg>`)ngMg``J)}})gz}n%nJMJJMƈMfM)%Ǆ}}g¡Mn)zz`M)%ȃ ơ}n%ȄJMJ%ngnzz)}MgJM`MȄ})`ngnZ)nJMƈMfM)%Ǆ}}g¡ȃ Sunmodule/Sunmodule Plus/black/laminate SW 245 poly ƭǄɶɹɳzn`¡ SW 255 poly ƭǄɶɺɳzn`¡ SW 265 poly ƭǄɶɻɳzn`¡ ƭǄɶɺɳfngn SW 265 mono ƭǄɶɻɳfngn SW 275 mono ƭǄɶɼɳfngn SW 285 mono ƭǄɶɽɳfngn SW 295 mono ƭǄɷɳɳfngn ƭǄɷɴɳǉƈfngn ƭǄɷɴɹǉƈfngn ƭǄɷɶɳǉƈfngn ƭǄɷɶɹǉƈfngn ƭǄɷɷɳǉƈfngn ƭǄɷɷɹǉƈfngn ƭǄɷɸɳǉƈfngn ƭǄɷɸɹǉƈfngn ƭǄɷɹɳǉƈfngn ƭǄɷɹɹǉƈfngn J - Exclusion of liability: ƳJMƈMfM)%Ǆ}}g¡M) z})`¡Mg)g%)%n) `%)``nJ)}) z})n}Mfz`M)%}}gM)ȄMg`%- ing without limitation the warranties of merchantability and ﬁtness for a particular purpose, to the z)}Mn%)3n}JJ)})MgȃƳJMƈMfM)%Ǆ}}g¡>M)¡nz)M9`)>`}M>JȄg%¡nf¡`nJ) other rights which vary from state-to-state. Some states do not allow limitations on implied warran- ties or the exclusion or limitation of damages, so some of the above limitations may not apply to you. K - Severability: Ŷ3g¡z}nMMngn3JMƈMfM)%Ǆ}}g¡MJ)`%g)g3n})`)n}M``)>`¡n}n}nJ)}n%¡n3 nfz))gZ}M%MMngȄJz}nMMngJ``)fn%M9)%nJ)fMgMff) )g})|M})%JJ J)})n3JMƈMfM)%Ǆ}}g¡M``ngMg)Mg3``3n})g%)5)ȃ ųM``n}nȄɴɴȃɳɴȃɶɳɴɸ Mukesh Dulani President SolarWorld Americas Inc. Ardes Johnson Vice President, Sales and Marketing SolarWorld Americas Inc. ƭǄȢɳɶȢɹɳɶɽƸƭɳɸȢɶɳɴɹ Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 21 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D 400 W/m² 200 W/m² 100 W/m² ISC VOC 37.44 (951) 39.37 (1000) Services Agreement - Work Order Type 8330 Photovoltaic Solar for Downtown Parking Garage Page 20 of 42 DocuSign Envelope ID: 70907281-6CA2-4138-8C76-309C36F9F82D