Loading...
HomeMy WebLinkAbout515527 TITAN MACHINERY INC - PURCHASE ORDER - 9145612 (2)City of F6rt Collins Date: 04/13/2015 Vendor: 515527 TITAN MACHINERY INC 7250 GREENRIDGE RD WINDSOR CO 80550-8000 PURCHASE ORDER PO Number Page 9145612 1 of 12 This number must appear on all invoices, packing sli s and labels. Ship To: ENGINEERING DEPT-MASON CITY OF FORT COLLINS ENGINEERING DEPT-MASON 281 N. COLLEGE AVE FORT COLLINS CO 80524 Delivery Date: 09/26/2014 Buyer: DOUG CLAPP Note: ref. bid # 8003 Line Description Quantity UOM Unit Price Extended Ordered Price Snow Removal Equipment 1 LOT LS 89,681.00 Snowblower for MAX bid dated 9/19/14 -Snowblower - $80,999.00 model # M-8000 MD as per bid specifications -freight - no cost options - -replaceable weld -in fan liners - $882.00 -telescoping spout - $2,575.00 -castor wheels (1 set) - $2,935.00 -work lights (1 set) - $450.00 -upgraded 2-way remote control with digital display - $1,750.00 -shear pin bolts - quantity - 10pcs = $9.00each - total = $90.00 -subtotal - $8,682.00 = $ 89,681.00 Dept: Transfort/ Streets Deliver Equipment and documents to: Fleet Services Shop 906 W. Vine Fort Collins, CO 80521 City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by Gerry S. Paul City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax:970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 invoices @fcgov.com PURCHASE ORDER PO Number Page F6rt Clty Of 9145612 10of12 Collins This number must appear on all invoices, packing slips and labels. Line Description Quantity UOM Unit Price Extended Ordered Price 53230)(2)(D), and 49 CFR 661.7. Date Signature Company Name Title 11.CARGO PREFERENCE REQUIREMENTS Cargo Preference - Use of United States -Flag Vessels - The contractor agrees: a. to use privately owned United States -Flag commercial vessels to ship at least 50 percent of the gross tonnage (computed separately for dry bulk carriers, dry cargo liners, and tankers) involved, whenever shipping any equipment, material, or commodities pursuant to the underlying contract to the extent such vessels are available at fair and reasonable rates for United States -Flag commercial vessels; b. to furnish within 20 working days following the date of loading for shipments originating within the United States or within 30 working days following the date of leading for shipments originating outside the United States, a legible copy of a rated, "on -board" commercial ocean bill -of - lading in English for each shipment of cargo described in the preceding paragraph to the Division of National Cargo, Office of Market Development, Maritime Administration, Washington, DC 20590 and to the FTA recipient (through the contractor in the case of a subcontractor's bill -of -lading.) c. to include these requirements in all subcontracts issued pursuant to this contract when the subcontract may involve the transport of equipment, material, or commodities by ocean vessel. 12.ENERGY CONSERVATION REQUIREMENTS Energy Conservation - The contractor agrees to comply with mandatory standards and policies relating to energy efficiency which are contained in the state energy conservation plan issued in compliance with the Energy Policy and Conservation Act. 13.RECYCLED PRODUCTS Recovered Materials - The contractor agrees to comply with all the requirements of Section 6002 of the Resource Conservation and Recovery Act (RCRA), as amended (42 U.S.C. 6962), including but not limited to the regulatory provisions of 40 CFR Part 247, and Executive Order 12873, as they apply to the procurement of the items designated in Subpart B of 40 CFR Part 247. 14.ADA Access Accessibility. Facilities to be used in public transportation service must comply with 42 U.S.C. Sections 12101 et seq. and DOT regulations, " Transportation Services for Individuals with Disabilities (ADA)," 49 CFR Part 37; and Joint ATBCB/DOT regulations, " Americans with Disabilities (ADA) Accessibility Specifications for Transportation Vehicles," 36 CFR Part 1192 and 49 CFR Part 38. Notably, DOT incorporated by reference the ATBCB' s " Americans with Disabilities Act Accessibility Guidelines" (ADAAG), revised July 2004, which include accessibility guidelines for buildings and facilities, and are incorporated into Appendix A to 49 CFR Part 37. DOT also added specific provisions to Appendix A modifying the ADAAG, with the result that buildings and facilities must comply with both the ADAAG and amendments thereto in Appendix A to 49 CFR Part 37. 15.CITY OF FORT COLLINS BID PROTEST PROCEDURES The City of Fort Collins has a protest procedure, covering any phase of solicitation or award, including but not limited to specification or award. The protest procedures are available from the Purchasing Department, City of Fort Collins, 215 N. Mason, Street, 2nd Floor, P. O. Box 580, Fort Collins, CO. 80522. You may also request a copy of the procedures by emailing: Purchasing@fcgov.com <mailto:Purchasing@fcgov.com> or calling 970- 221-6775. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by Gerry S. Paul City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone: 970-221-6775 Fax:970-221-6707 Email: purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 invoices @fcgov.com ,�t� Collins of PURCHASE ORDER PO Number Page 9145612 11 of 12 This number must appear on all invoices, packing slips and labels. Line Description Quantity UOM Unit Price Extended Ordered Price 2 additional cost for larger ACS coupler City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by Gerry S. Paul City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax:970-221-6707 Email:purchasing@fcgov.com 1 LOT EA 1,850.00 Total $91,531.00 Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 invoices @fcgov.com Purchase Order Ternis and Conditions Page, 12 of 12 I. COMMERCIAL DETAILS. Tax exemptions. By statute the City of Fort Collins is exempt from state and local taxes. Our Exemption Number is 98-04502. Federal Excise Tax Exemption Certificate of Registry 84-6000587 is registered with the Collector of Internal Revenue, Denver, Colorado (Ref. Colorado Revised Statutes 1973, Chapter 39-26, 114 (a). Goods Rejected. GOODS REJECTED due to failure to meet specifications, either when shipped or due to defects of damage in transit, may be returned to you for credit and are not to be replaced except upon receipt of written instructions from the City of Fort Collins. Inspection. GOODS are subject to the City of Fort Collins inspection on arrival. Final Acceptance. Receipt of the merchandise, services or equipment in response to this order can result in authorized payment on the part of the City of Fort Collins. However, it is to be understood that FINAL ACCEPTANCE is dependent upon completion of all applicable required inspection procedures. Freight Terms. Shipments must be F.O.B., City of Fort Collins, 700 Wood St., Fort Collins, CO 80522, unless otherwise specified on this order. If permission is given to prepay freight and charge separately, the original freight bill must accompany invoice. Additional charges for packing will not he accepted. Shipment Distance. Where manufacturers have distributing points in various parts of the country, shipment is expected from the nearest distribution point to destination, and excess freight will be deducted from Invoice when shipments are made from greater distance. Permits. Seller shall procure at sellers sole cost all necessary permits, certificates and licenses required by all applicable laws, regulations, ordinances and rules of the state, municipality, territory or political subdivision where the work is performed, or required by any other duly constituted public authority having jurisdiction over the work of vendor. Seller further agrees to hold the City of Fort Collins harmless from and against all liability and loss incurred by them by reason of an asserted or established violation of any such laws, regulations, ordinances, rules and requirements. Authorization. All parties to this contract agree that the representatives are, in fact, bona fide and possess full and complete authority to bind said parties. LIMITATION OF TERMS. This Purchase Order expressly limits acceptance to the terms and conditions stated herein set forth and any supplementary or additional terms and conditions annexed hereto or incorporated herein by reference. Any additional or different terms and conditions proposed by seller are objected to and hereby rejected. 2. DELIVERY. PLEASE ADVISE PURCHASING AGENT immediately if you cannot make complete shipment to arrive on your promised delivery date as noted. Time is of the essence. Delivery and performance must be effected within the time stated on the purchase order and the documents attached hereto. No acts of the Purchasers including, without limitation, acceptance of partial late deliveries, shall operate as a waiver of this provision. In the event of any delay, the Purchaser shall have, in addition to other legal and equitable remedies, the option of placing this order elsewhere and holding the Seller liable for damages. However, the Seller shall not be liable for damages as a result of delays due to causes not reasonably foreseeable which are beyond its reasonable control and without its fault of negligence, such acts of God, acts of civil or military authorities, governmental priorities, fires, strikes, flood, epidemics, wars or riots provided that notice of the conditions causing such delay is given to the Purchaser within five (5) days of the time when the Seller first received knowledge thereof In the event of any such delay, the date of delivery shall be extended for the period equal to the time actually lost by reason of the delay. 3. WARRANTY. The Seller warrants that all goods, articles, materials and work covered by this order will conform with applicable drawings, specifications, samples and/or other descriptions given, will be fit for the purposes intended, and performed with the highest degree of care and competence in accordance with accepted standards for work of a similar nature. The Seller agrees to hold the purchaser harmless from any loss, damage or expense which the Purchaser may suffer or incur on account of the Sellers breach of warranty. The Seller shall replace, repair or make good, without cost to the purchaser, any defects or faults arising within one (1) year or within such longer period of time as may be prescribed by law or by the terms of any applicable warranty provided by the Seller after the date of acceptance of the goods furnished hereunder (acceptance not to be unreasonably delayed), resulting from imperfect or defective work done or materials furnished by the Seller. Acceptance or use of goods by the Purchaser shall not constitute a waiver of any claim under this warranty. Except as otherwise provided in this purchase order, the Sellers liability hereunder shall extend to all damages proximately caused by the breach of any of the foregoing warranties or guarantees, but such liability shall in no event include loss of profits or loss of use. NO IMPLIED WARRANTY OR MERCHANTABILITY OR OF FITNESS FOR PURPOSE SHALL APPLY. 4. CHANGES IN LEGAL TERMS. The Purchaser may make changes to legal terms by written change order. 5. CHANGES IN COMMERCIAL TERMS. The Purchaser may make any changes to the terms, other than legal terms, including additions to or deletions from the quantities originally ordered in the specifications or drawings, by verbal or written change order. If any such change affects the amount due or the time of performance hereunder, an equitable adjustment shall be made. 6. TERMINATIONS. The Purchaser may at any time by written change order, terminate this agreement as to any or all portions of the goods then not shipped, subject to any equitable adjustment between the parties as to any work or materials then in progress provided that the Purchaser shall not be liable for any claims for anticipated profits on the uncompleted portion of the goods and/or work, for incidental or consequential damages, and that no such adjustment be made in favor of the Seller with respect to any goods which are the Sellers standard stock. No such termination shall relieve the Purchaser or the Seller of any of their obligations as to any goods delivered hereunder. 7. CLAIMS FOR ADJUSTMENT. Any claim for adjustment must be asserted within thirty (30) days from the date the change or termination is ordered. 8. COMPLIANCE WITH LAW. The Seller warrants that all goods sold hereunder shall have been produced, sold, delivered and furnished in strict compliance with all applicable laws and regulations to which the goods are subject. The Seller shall execute and deliver such documents as may be required to effect or evidence compliance. All laws and regulations required to be incorporated in agreements of this character are hereby incorporated herein by this reference. The Seller agrees to indemnify and hold the Purchaser harmless from all costs and damages suffered by the Purchaser as a result of the Sellers failure to comply with such law. 9. ASSIGNMENT. Neither party shall assign, transfer, or convey this order, or any monies due or to become due hereunder without the prior written consent of the other party. 10. TITLE. The Seller warrants full, clear and unrestricted title to the Purchaser for all equipment, materials, and items furnished in performance of this agreement, free and clear of any and all liens, restrictions, reservations, security interest encumbrances and claims of others. 11. NONWAIVER. Failure of the Purchaser to insist upon strict performance of the terms and conditions hereof, failure or delay to exercise any rights or remedies provided herein or by law, failure to promptly notify the Seller in the event of a breach, the acceptance of or payment for goods hereunder or approval of the design, shall not release the Seller of any of the warranties or obligations of this purchase order and shall not be deemed a waiver of any right of the purchaser to insist upon strict performance hereof or any of its rights or remedies as to any such goods, regardless of when shipped, received or accepted, as to any prior or subsequent default hereunder, nor shall any purported oral modification or rescission of this purchase order by the Purchaser operate as a waiver of any of the terms hereof. 12. ASSIGNMENT OF ANTITRUST CLAIMS. Seller and the Purchaser recognize that in actual economic practice, overcharges resulting from antitrust violations are in fact home by the Purchaser. Theretofore, for good cause and as consideration for executing this purchase order, the Seller hereby assigns to the Purchaser any and all claims it may now have or hereafter acquired under federal or state antitrust laws for such overcharges relating to the particular goods or services purchased or acquired by the Purchaser pursuant to this purchase order. 13. PURCHASERS PERFORMANCE OF SELLERS OBLIGATIONS. If the Purchaser directs the Seller to correct nonconforming or defective goods by a date to be agreed upon by the Purchaser and the Seller, and the Seller thereafter indicates its inability or unwillingness to comply, the Purchaser may cause the work to be performed by the most expeditious means available to it, and the Seller shall pay all costs associated with such work. The Seller shall release the Purchaser and its contractors of any tier from all liability and claims of any nature resulting from the performance of such work. This release shall apply even in the event of fault of negligence of the party released and shall extend to the directors, officers and employees of such party. The Seller's contractual obligations, including warranty, shall not be deemed to be reduced, in any way, because such work is performed or caused to be performed by the Purchaser. 14. PATENTS. Whenever the Seller is required to use any design, device, material or process covered by letter, patent, trademark or copyright, the Seller shall indemnify and save harmless the Purchaser from any and all claims for infringement by reason of the use of such patented design, device, material or process in connection with the contract, and shall indemnify the Purchaser for any cost, expense or damage which it may be obliged to pay by reason of such infringement at any time during the prosecution or after the completion of the work. In case said equipment, or any part thereof or the intended use of the goods, is in such suit held to constitute infringement and the use of said equipment or part is enjoined, the Seller shall, at its own expense and at its option, either procure for the Purchaser the right to continue using said equipment or parts, replace the same with substantially equal but noninfringing equipment, or modify it so it becomes noninfiinging. 15. INSOLVENCY. If the Seller shall become insolvent or bankrupt, make an assignment for the benefit of creditors, appoint a receiver or trustee for any of the Sellers property or business, this order may forthwith be canceled by the Purchaser without liability. 16. GOVERNING LAW. The definitions of terms used or the interpretation of the agreement and the rights of all parties hereunder shall be construed under and governed by the laws of the State of Colorado, USA. The following Additional Conditions apply only in cases where the Seller is to perform work hereunder, including the services of Sellers Representative(s), on the premises of others. 17. SELLERS RESPONSIBILITY. The Seller shall carry on said work at Seller's own risk until the same is fully completed and accepted, and shall, in case of any accident, destruction or injury to the work and/or materials before Seller's final completion and acceptance, complete the work at Seller's own expense and to the satisfaction of the Purchaser. When materials and equipment are furnished by others for installation or erection by the Seller, the Seller shall receive, unload, store and handle same at the site and become responsible therefor as though such materials and/or equipment were being furnished by the Seiler under the order. 18. INSURANCE. The Seller shall, at his own expense, provide for the payment of workers compensation, including occupational disease benefits, to its employees employed on or in connection with the work covered by this purchase order, and/or to their dependents in accordance with the laws of the state in which the work is to be done. The Seller shall also carry comprehensive general liability including, but not limited to, contractual and automobile public liability insurance with bodily injury and death limits of at least $300,000 for any one person, $500,000 for any one accident and property damage limit per accident of $400,000. The Seller shall likewise require his contractors, if any, to provide for such compensation and insurance. Before any of the Sellers or his contractors employees shall do any work upon the premises of others, the Seller shall furnish the Purchaser with a certificate that such compensation and insurance have been provided. Such certificates shall specify the date when such compensation and insurance have been provided. Such certificates shall specify the date when such compensation and insurance expires. The Seller agrees that such compensation and insurance shall be maintained until after the entire work is completed and accepted 19. PROTECTION AGAINST ACCIDENTS AND DAMAGES. The Seller hereby assumes the entire responsibility and liability for any and all damage, loss or injury of any kind or nature whatsoever to persons or property caused by or resulting from the execution of the work provided for in this purchase order or in connection herewith. The Seller will indemnify and hold harmless the Purchaser and any or all of the Purchasers officers, agents and employees from and against any and all claims, losses, damages, charges or expenses, whether direct or indirect, and whether to persons or property to which the Purchaser may be put or subject by reason of any act, action, neglect, omission or default on the part of the Seller, any of his contractors, or any of the Sellers or contractors officers, agents or employees. In case any suit or other proceedings shall be brought against the Purchaser, or its officers, agents or employees at any time on account or by reason of any act, action, neglect, omission or default of the Seller of any of his contractors or any of its or their officers, agents or employees as aforesaid, the Seller hereby agrees to assume the defense thereof and to defend the same at the Sellers own expense, to pay any and all costs, charges, attorneys fees and other expenses, any and all judgments that may be incurred by or obtained against the Purchaser or any of its or their officers, agents or employees in such suits or other proceedings, and in case judgment or other lien be placed upon or obtained against the property of the Purchaser, or said parties in or as a result of such suits or other proceedings, the Seller will at once cause the same to be dissolved and discharged by giving bond or otherwise. The Seller and his contractors shall take all safety precautions, famish and install all guards necessary for the prevention of accidents, comply with all laws and regulations with regard to safety including, but without limitation, the Occupational Safety and Health Act of 1970 and all rules and regulations issued pursuant thereto. Revised 03/2010 PURCHASE ORDER PO Number I Page City Of 9145612 J2 of 12 Fort Collins This number must appear on all invoices, packing slips and labels. Line Description Quantity UOM Unit Price Extended Ordered Price Contact: Greg or Eric ph# 970-221-6613 '*Please call 24 hours prior to delivery " shop hours 7:30am to 3:30pm 1.NO GOVERNMENT OBLIGATION TO THIRD PARTIES No Obligation by the Federal Government. (1) The Purchaser and Contractor acknowledge and agree that, notwithstanding any concurrence by the Federal Government in or approval of the solicitation or award of the underlying contract, absent the express written consent by the Federal Government, the Federal Government is not a party to this contract and shall not be subject to any obligations or liabilities to the Purchaser, Contractor, or any other party (whether or not a party to that contract) pertaining to any matter resulting from the underlying contract. (2) The Contractor agrees to include the above clause in each subcontract financed in whole or in part with Federal assistance provided by FTA. It is further agreed that the clause shall not be modified, except to identify the subcontractor who will be subject to its provisions. 2.PROGRAM FRAUD AND FALSE OR FRAUDULENT STATEMENTS AND RELATED ACTS Program Fraud and False or Fraudulent Statements or Related Acts. (1) The Contractor acknowledges that the provisions of the Program Fraud Civil Remedies Act of 1986, as amended, 31 U.S.C. § 3801 et seq. and U.S. DOT regulations, "Program Fraud Civil Remedies," 49 C.F.R. Part 31, apply to its actions pertaining to this Project. Upon execution of the underlying contract, the Contractor certifies or affirms the truthfulness and accuracy of any statement it has made, it makes, it may make, or causes to be made, pertaining to the underlying contract or the FTA assisted project for which this contract work is being performed. In addition to other penalties that may be applicable, the Contractor further acknowledges that if it makes, or causes to be made, a false, fictitious, or fraudulent claim, statement, submission, or certification, the Federal Government reserves the right to impose the penalties of the Program Fraud Civil Remedies Act of 1986 on the Contractor to the extent the Federal Government deems appropriate. (2) The Contractor also acknowledges that if it makes, or causes to be made, a false, fictitious, or fraudulent claim, statement, submission, or certification to the Federal Government under a contract connected with a project that is financed in whole or in part with Federal assistance originally awarded by FTA under the authority of 49 U.S.C. § 5307, the Government reserves the right to impose the penalties of 18 U.S.C. § 1001 and 49 U.S.C. § 5307(n)(1) on the Contractor, to the extent the Federal Government deems appropriate. (3) The Contractor agrees to include the above two clauses in each subcontract financed in whole or in part with Federal assistance provided by FTA. It is further agreed that the clauses shall not be modified, except to identify the subcontractor who will be subject to the provisions. 3.ACCESS TO RECORDS AND REPORTS Access to Records - The following access to records requirements apply to this Contract: A. Where the Purchaser is not a State but a local government and is the FTA Recipient or a subgrantee of the FTA Recipient in accordance with 49 C.F.R. 18.36(i), the Contractor agrees to provide the Purchaser, the FTA Administrator, the Comptroller General of the United States or any of their authorized representatives access to any books, documents, papers and records of the Contractor which are directly pertinent to this contract for the purposes of making audits, examinations, excerpts and transcriptions. Contractor also agrees, pursuant to 49 C.F.R. 633.17 to provide the FTA Administrator or his authorized representatives including any PMO Contractor City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by Gerry S. Paul City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax:970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 invoices @fcgov.com of F6rt '� PURCHASE ORDER PO Number Page 9145612 3 of 12 This number must appear on all invoices, packing slips and labels. Line Description Quantity UOM Unit Price Extended Ordered Price access to Contractor's records and construction sites pertaining to a major capital project, defined at 49 U.S.C. 5302(a)1, which is receiving federal financial assistance through the programs described at 49 U.S.C. 5307, 5309 or 5311. B. The Contractor agrees to permit any of the foregoing parties to reproduce by any means whatsoever or to copy excerpts and transcriptions as reasonably needed. C. The Contractor agrees to maintain all books, records, accounts and reports required under this contract for a period of not less than three years after the date of termination or expiration of this contract, except in the event of litigation or settlement of claims arising from the performance of this contract, in which case Contractor agrees to maintain same until the Purchaser, the FTA Administrator, the Comptroller General, or any of their duly authorized representatives, have disposed of all such litigation, appeals, claims or exceptions related thereto. Reference 49 CFR 18.39(i)(11). D. FTA does not require the inclusion of these requirements in subcontracts. Requirements for Access to Records and Reports by Types of Contract Contract CharacteristicsOperational Service ContractTurnkeyConstructionArchitectural Engineering<shading ="10%">Acquisition of Rolling StockProfessional Services I State Grantees a. Contracts below SAT ($100,000) b. Contracts above $100,000/Capital Projects None None unless1 non-competitive award Those imposed on state pass thru to Contractor None Yes, if non- competitive award or if funded thru2 5307/5309/5311 None None unless non-competitive award None None unless non-competitive award None None unless non-competitive award II Non State Grantees a. Contracts below SAT ($100,000) b. Contracts above $100,000/Capital Projects Yes3 Yes3 Those imposed on non -state Grantee pass thru to Contractor Yes Yes Yes Yes Yes Yes Yes Yes Sources of Authority: 1 49 USC 5325 (a) 2 49 CFR 633.17 3 18 CFR 18.36 (i) 4.FEDERAL CHANGES Federal Changes - Contractor shall at all times comply with all applicable FTA regulations, policies, procedures and directives, including without limitation those listed directly or by reference in the Master Agreement between Purchaser and FTA, as they may be amended or promulgated from time to time during the term of this contract. Contractor's failure to so comply shall constitute a material breach of this contract. 5.TERMINATION A.Termination for Convenience (General Provision) The (Recipient) may terminate this contract, in whole or in part, at any time by written notice to the Contractor when it is in the Government's best interest. The Contractor shall be paid its costs, including contract close-out costs, and profit on work performed up to the time of termination. The Contractor shall promptly submit its termination claim to (Recipient) to be paid the Contractor. If the Contractor has any property in its possession belonging to the (Recipient), the Contractor will account for the same, and dispose of it in the manner the (Recipient) directs. B.Termination for Default [Breach or Cause] (General Provision) If the Contractor does not deliver supplies in accordance with the contract delivery schedule, or, if the contract is for services, the Contractor fails to perform in the manner called for in the contract, or if the Contractor fails to comply with any other provisions of the contract, the (Recipient) may terminate this contract for default. Termination shall be effected by serving a notice of termination on the contractor setting forth the manner in which the Contractor is in default. The contractor will only be paid the contract price for supplies delivered and accepted, or services performed in accordance with the manner of performance set forth in the contract. If it is later determined by the (Recipient) that the Contractor had an excusable reason for not performing, such City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by Gerry S. Paul City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax:970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 invoices @fcgov.com PURCHASE ORDER PO Number I Page F6rt City Of 9145612 4 of 12Collins This number must appear on all invoices, packing slips and labels. Line Description Quantity UOM Unit Price Extended Ordered Price as a strike, fire, or flood, events which are not the fault of or are beyond the control of the Contractor, the (Recipient), after setting up a new delivery of performance schedule, may allow the Contractor to continue work, or treat the termination as a termination for convenience. C.Opportunity to Cure (General Provision) The (Recipient) in its sole discretion may, in the case of a termination for breach or default, allow the Contractor [an appropriately short period of time] in which to cure the defect. In such case, the notice of termination will state the time period in which cure is permitted and other appropriate conditions If Contractor fails to remedy to (Recipient)'s satisfaction the breach or default of any of the terms, covenants, or conditions of this Contract within [ten (10) days] after receipt by Contractor of written notice from (Recipient) setting forth the nature of said breach or default, (Recipient) shall have the right to terminate the Contract without any further obligation to Contractor. Any such termination for default shall not in any way operate to preclude (Recipient) from also pursuing all available remedies against Contractor and its sureties for said breach or default. D.Waiver of Remedies for any Breach In the event that (Recipient) elects to waive its remedies for any breach by Contractor of any covenant, term or condition of this Contract, such waiver by (Recipient) shall not limit (Recipient)'s remedies for any succeeding breach of that or of any other term, covenant, or condition of this Contract. E.Termination for Convenience (Professional or Transit Service Contracts) The (Recipient), by written notice, may terminate this contract, in whole or in part, when it is in the Government's interest. If this contract is terminated, the Recipient shall be liable only for payment under the payment provisions of this contract for services rendered before the effective date of termination. F.Termination for Default (Supplies and Service) If the Contractor fails to deliver supplies or to perform the services within the time specified in this contract or any extension or if the Contractor fails to comply with any other provisions of this contract, the (Recipient) may terminate this contract for default. The (Recipient) shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. The Contractor will only be paid the contract price for supplies delivered and accepted, or services performed in accordance with the manner or performance set forth in this contract. If, after termination for failure to fulfill contract obligations, it is determined that the Contractor was not in default, the rights and obligations of the parties shall be the same as if the termination had been issued for the convenience of the Recipient. G.Termination for Default (Transportation Services) If the Contractor fails to pick up the commodities or to perform the services, including delivery services, within the time specified in this contract or any extension or if the Contractor fails to comply with any other provisions of this contract, the (Recipient) may terminate this contract for default. The (Recipient) shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of default. The Contractor will only be paid the contract price for services performed in accordance with the manner of performance set forth in this contract. If this contract is terminated while the Contractor has possession of Recipient goods, the Contractor shall, upon direction of the (Recipient), protect and preserve the goods until surrendered to the Recipient or its agent. The Contractor and (Recipient) shall agree on payment for the preservation and protection of goods. Failure to agree on an amount will be resolved under the Dispute clause. If, after termination for failure to fulfill contract obligations, it is determined that the Contractor was not in default, the rights and obligations of the parties shall be the same as if the termination had been issued for the convenience of the (Recipient). Invoice Address: City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by Gerry S. Paul City of Fort Collins Accounting Department City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax: 970-221-6707 Email: purchasing@fcgov.com PO Box 580 Fort Collins, CO 80522-0580 invoices @fcgov.com ,�rt� Collins of PURCHASE ORDER PO Number Page 9145612 5 of 12 This number must appear on all invoices, packing slips and labels. Line Description Quantity UOM Unit Price Extended Ordered Price H.Termination for Default (Construction) If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract or any extension or fails to complete the work within this time, or if the Contractor fails to comply with any other provisions of this contract, the (Recipient) may terminate this contract for default. The (Recipient) shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. In this event, the Recipient may take over the work and compete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the Recipient resulting from the Contractor's refusal or failure to complete the work within specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the Recipient in completing the work. The Contractor's right to proceed shall not be terminated nor the Contractor charged with damages under this clause if- 1. the delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include: acts of God, acts of the Recipient, acts of another Contractor in the performance of a contract with the Recipient, epidemics, quarantine restrictions, strikes, freight embargoes; and 2. the contractor, within [10] days from the beginning of any delay, notifies the (Recipient) in writing of the causes of delay. If in the judgment of the (Recipient), the delay is excusable, the time for completing the work shall be extended. The judgment of the (Recipient) shall be final and conclusive on the parties, but subject to appeal under the Disputes clauses. If, after termination of the Contractor's right to proceed, it is determined that the Contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if the termination had been issued for the convenience of the Recipient. I.Termination for Convenience or Default (Architect and Engineering) The (Recipient) may terminate this contract in whole or in part, for the Recipient's convenience or because of the failure of the Contractor to fulfill the contract obligations. The (Recipient) shall terminate by delivering to the Contractor a Notice of Termination specifying the nature, extent, and effective date of the termination. Upon receipt of the notice, the Contractor shall (1) immediately discontinue all services affected (unless the notice directs otherwise), and (2) deliver to the Contracting Officer all data, drawings, specifications, reports, estimates, summaries, and other information and materials accumulated in performing this contract, whether completed or in process. If the termination is for the convenience of the Recipient, the Contracting Officer shall make an equitable adjustment in the contract price but shall allow no anticipated profit on unperformed services. If the termination is for failure of the Contractor to fulfill the contract obligations, the Recipient may complete the work by contact or otherwise and the Contractor shall be liable for any additional cost incurred by the Recipient. If, after termination for failure to fulfill contract obligations, it is determined that the Contractor was not in default, the rights and obligations of the parties shall be the same as if the termination had been issued for the convenience of the Recipient. J.Termination for Convenience of Default (Cost -Type Contracts) The (Recipient) may terminate this contract, or any portion of it, by serving a notice or termination on the Contractor. The notice shall state whether the termination is for convenience of the (Recipient) or for the default of the Contractor. If the termination is for default, the notice shall state the manner in which the contractor has failed to perform the requirements of the contract. The Contractor shall account for any property in its possession paid for from funds received from the (Recipient), or property supplied to the Contractor by the (Recipient). If the termination is for default, the City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by Gerry S. Paul City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone: 970-221-6775 Fax:970-221-6707 Email.purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 invoices @fcgov.com „.F�co�rt� Collins of PURCHASE ORDER PO Number Page 9145612 6 of 12 This number must appear on all invoices, packing slips and labels. Line Description Quantity UOM Unit Price Extended Ordered Price (Recipient) may fix the fee, if the contract provides for a fee, to be paid the contractor in proportion to the value, if any, of work performed up to the time of termination. The Contractor shall promptly submit its termination claim to the (Recipient) and the parties shall negotiate the termination settlement to be paid the Contractor. If the termination is for the convenience of the (Recipient), the Contractor shall be paid its contract close-out costs, and a fee, if the contract provided for payment of a fee, in proportion to the work performed up to the time of termination. If, after serving a notice of termination for default, the (Recipient) determines that the Contractor has an excusable reason for not performing, such as strike, fire, flood, events which are not the fault of and are beyond the control of the contractor, the (Recipient), after setting up a new work schedule, may allow the Contractor to continue work, or treat the termination as a termination for convenience. 6.CIVIL RIGHTS REQUIREMENTS Civil Rights - The following requirements apply to the underlying contract: (1) Nondiscrimination - In accordance with Title VI of the Civil Rights Act, as amended, 42 U.S.C. § 2000d, section 303 of the Age Discrimination Act of 1975, as amended, 42 U.S.C. § 6102, section 202 of the Americans with Disabilities Act of 1990, 42 U.S.C. § 12132, and Federal transit law at 49 U.S.C. § 5332, the Contractor agrees that it will not discriminate against any employee or applicant for employment because of race, color, creed, national origin, sex, age, or disability. In addition, the Contractor agrees to comply with applicable Federal implementing regulations and other implementing requirements FTA may issue. (2) Equal Employment Opportunity - The following equal employment opportunity requirements apply to the underlying contract: (a) Race, Color, Creed, National Origin, Sex - In accordance with Title VII of the Civil Rights Act, as amended, 42 U.S.C. § 2000e, and Federal transit laws at 49 U.S.C. § 5332, the Contractor agrees to comply with all applicable equal employment opportunity requirements of U.S. Department of Labor (U.S. DOL) regulations, "Office of Federal Contract Compliance Programs, Equal Employment Opportunity, Department of Labor,” 41 C.F.R. Parts 60 et seq., (which implement Executive Order No. 11246, "Equal Employment Opportunity," as amended by Executive Order No. 11375, "Amending Executive Order 11246 Relating to Equal Employment Opportunity," 42 U.S.C. § 2000e note), and with any applicable Federal statutes, executive orders, regulations, and Federal policies that may in the future affect construction activities undertaken in the course of the Project. The Contractor agrees to take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, creed, national origin, sex, or age. Such action shall include, but not be limited to, the following: employment, upgrading, demotion or transfer, recruitment or recruitment advertising, layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. In addition, the Contractor agrees to comply with any implementing requirements FTA may issue. (b) Age - In accordance with section 4 of the Age Discrimination in Employment Act of 1967, as amended, 29 U.S.C. § § 623 and Federal transit law at 49 U.S.C. § 5332, the Contractor agrees to refrain from discrimination against present and prospective employees for reason of age. In addition, the Contractor agrees to comply with any implementing requirements FTA may issue. (c) Disabilities - In accordance with section 102 of the Americans with Disabilities Act, as amended, 42 U.S.C. § 12112, the Contractor agrees that it will comply with the requirements of U.S. Equal Employment Opportunity Commission, "Regulations to Implement the Equal Employment Provisions of the Americans with Disabilities Act," 29 C.F.R. Part 1630, pertaining to employment of persons with disabilities. In addition, the Contractor agrees to comply with anv implementing requirements FTA may issue. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by Gerry S. Paul City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax:970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 invoices @fcgov.com F6nC'ollinsc�t PURCHASE ORDER PO Number Page 9145612 7 of 12 This number must appear on all invoices, packing slips and labels. Line Description Quantity UOM Unit Price Extended Ordered Price (3) The Contractor also agrees to include these requirements in each subcontract financed in whole or in part with Federal assistance provided by FTA, modified only if necessary to identify the affected parties. 7.DISADVANTAGED BUSINESS ENTERPRISE (DBE) a. This contract is subject to the requirements of Title 49, Code of Federal Regulations, Part 26, Participation by Disadvantaged Business Enterprises in Department of Transportation Financial Assistance Programs. The national goal for participation of Disadvantaged Business Enterprises (DBE) is 10%. The agency' s overall goal for DBE participation is _ %. A separate contract goal [of _ % DBE participation has] [has not] been established for this procurement. b. The contractor shall not discriminate on the basis of race, color, national origin, or sex in the performance of this contract. The contractor shall carry out applicable requirements of 49 CFR Part 26 in the award and administration of this DOT -assisted contract. Failure by the contractor to carry out these requirements is a material breach of this contract, which may result in the termination of this contract or such other remedy as City of Fort Collins deems appropriate. Each subcontract the contractor signs with a subcontractor must include the assurance in this paragraph (see 49 CFR 26.13(b)). c. {If a separate contract goal has been established, use the following) Bidders/offerors are required to document sufficient DBE participation to meet these goals or, alternatively, document adequate good faith efforts to do so, as provided for in 49 CFR 26.53. Award of this contract is conditioned on submission of the following [concurrent with and accompanying sealed bid] [concurrent with and accompanying an initial proposal] [prior to award]: 1. The names and addresses of DBE firms that will participate in this contract; 2. A description of the work each DBE will perform; 3. The dollar amount of the participation of each DBE firm participating; 4. Written documentation of the bidder/offeror' s commitment to use a DBE subcontractor whose participation it submits to meet the contract goal; 5. Written confirmation from the DBE that it is participating in the contract as provided in the prime contractor' s commitment; and 6. If the contract goal is not met, evidence of good faith efforts to do so. [Bidders][Offerors] must present the information required above [as a matter of responsiveness] [with initial proposals] [prior to contract award] (see 49 CFR 26.53(3)). {If no separate contract goal has been established, use the following) The successful bidder/offeror will be required to report its DBE participation obtained through race -neutral means throughout the period of performance. d. The contractor is required to pay its subcontractors performing work related to this contract for satisfactory performance of that work no later than 30 days after the contractor' s receipt of payment for that work from the City of Fort Collins. In addition, [the contractor may not hold retainage from its subcontractors.] [is required to return any retainage payments to those subcontractors within 30 days after the subcontractor's work related to this contract is satisfactorily completed.] [is required to return any retainage payments to those subcontractors within 30 days after incremental acceptance of the subcontractor' s work by the City of Fort Collins and contractor' s receipt of the partial retainage payment related to the subcontractor' s work.] e. The contractor must promptly notify City of Fort Collins whenever a DBE subcontractor performing work related to this contract is terminated or fails to complete its work, and must make good faith efforts to engage another DBE subcontractor to perform at least the same amount of work. The contractor may not terminate any DBE subcontractor and perform that work through its own forces or those of an affiliate without prior written consent of Citv of Fort Collins. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by Gerry S. Paul City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax:970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 invoices @fcgov.com City Of PURCHASE ORDER PO Number Page 9145612 s of 12 Fort Collins�slips This number must appear on all invoices, packing and labels. Line Description Quantity UOM Unit Price Extended Ordered Price &INCORPORATION OF FEDERAL TRANSIT ADMINISTRATION (FTA) TERMS Incorporation of Federal Transit Administration (FTA) Terms - The preceding provisions include, in part, certain Standard Terms and Conditions required by DOT, whether or not expressly set forth in the preceding contract provisions. All contractual provisions required by DOT, as set forth in FTA Circular 4220.1 E, are hereby incorporated by reference. Anything to the contrary herein notwithstanding, all FTA mandated terms shall be deemed to control in the event of a conflict with other provisions contained in this Agreement. The Contractor shall not perform any act, fail to perform any act, or refuse to comply with any (name of grantee) requests which would cause (name of grantee) to be in violation of the FTA terms and conditions. 9.GOVERNMENT-WIDE DEBARMENT AND SUSPENSION (NONPROCUREMENT) Background and Applicability In conjunction with the Office of Management and Budget and other affected Federal agencies, DOT published an update to 49 CFR Part 29 on November 26, 2003. This government -wide regulation implements Executive Order 12549, Debarment and Suspension, Executive Order 12689, Debarment and Suspension, and 31 U.S.C. 6101 note (Section 2455, Public Law 103-355, 108 Stat. 3327). The provisions of Part 29 apply to all grantee contracts and subcontracts at any level expected to equal or exceed $25,000 as well as any contract or subcontract (at any level) for Federally required auditing services. 49 CFR 29.220(b). This represents a change from prior practice in that the dollar threshold for application of these rules has been lowered from $100,000 to $25,000. These are contracts and subcontracts referred to in the regulation as " covered transactions." Grantees, contractors, and subcontractors (at any level) that enter into covered transactions are required to verify that the entity (as well as its principals and affiliates) they propose to contract or subcontract with is not excluded or disqualified. They do this by (a) Checking the Excluded Parties List System, (b) Collecting a certification from that person, or (c) Adding a clause or condition to the contract or subcontract. This represents a change from prior practice in that certification is still acceptable but is no longer required. 49 CFR 29.300. Grantees, contractors, and subcontractors who enter into covered transactions also must require the entities they contract with to comply with 49 CFR 29, subpart C and include this requirement in their own subsequent covered transactions (i.e., the requirement flows down to subcontracts at all levels). Clause Language The following clause language is suggested, not mandatory. It incorporates the optional method of verifying that contractors are not excluded or disqualified by certification. Suspension and Debarment This contract is a covered transaction for purposes of 49 CFR Part 29. As such, the contractor is required to verify that none of the contractor, its principals, as defined at 49 CFR 29.995, or affiliates, as defined at 49 CFR 29.905, are excluded or disqualified as defined at 49 CFR 29.940 and 29.945. The contractor is required to comply with 49 CFR 29, Subpart C and must include the requirement to comply with 49 CFR 29, Subpart C in any lower tier covered transaction it enters into. By signing and submitting its bid or proposal, the bidder or proposer certifies as follows: The certification in this clause is a material representation of fact relied upon by {insert agency name}. If it is later determined that the bidder or proposer knowingly rendered an erroneous certification, in addition to remedies available to {insert agency name), the Federal Government may pursue available remedies, including but not limited to suspension and/or debarment. The bidder or proposer agrees to comply with the requirements of 49 CFR 29, Subpart C while this offer is valid and throughout the period of any contract that may arise from this offer. The bidder or proposer further agrees to include a provision requiring such compliance in its lower tier City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by Gerry S. Paul City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax:970-221-6707 Email: purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 invoices @fcgov.com City of F6rt Collins PURCHASE ORDER PO Number Page 9145612 9.f12 This number must appear on all invoices, packing slips and labels. Line Description Quantity UOM Unit Price Extended Ordered Price covered transactions. 10.BUY AMERICA The contractor agrees to comply with 49 U.S.C. 53230) and 49 C.F.R. Part 661, which provide that Federal funds may not be obligated unless steel, iron, and manufactured products used in FTA-funded projects are produced in the United States, unless a waiver has been granted by FTA or the product is subject to a general waiver. General waivers are listed in 49 C.F.R. 661.7, and include final assembly in the United States for 15 passenger vans and 15 passenger wagons produced by Chrysler Corporation, and microcomputer equipment and software. Separate requirements for rolling stock are set out at 49 U.S.C. 53230)(2)(C) and 49 C.F.R. 661.11. Rolling stock must be assembled in the United States and have a 60 percent domestic content. A bidder or offeror must submit to the FTA recipient the appropriate Buy America certification (below) with all bids or offers on FTA-funded contracts, except those subject to a general waiver. Bids or offers that are not accompanied by a completed Buy America certification must be rejected as nonresponsive. This requirement does not apply to lower tier subcontractors. Certification requirement for procurement of steel, iron, or manufactured products Certificate of Compliance with 49 U.S.C. 53230)(1) The bidder or offeror hereby certifies that it will meet the requirements of 49 U.S.C. 53230)(1) and the applicable regulations in 49 C.F.R. Part 661.5. Date Signature Company Name Title Certificate of Non -Compliance with 49 U.S.C. 53236)(1) The bidder or offeror hereby certifies that it cannot comply with the requirements of 49 U.S.C. 53230)(1) and 49 C.F.R. 661.5, but it may qualify for an exception pursuant to 49 U.S.C. 53230)(2)(A), 53230)(2)(B), or 53230)(2)(D), and 49 C.F.R. 661.7. Date Signature Company Name Title Certification requirement for procurement of buses, other rolling stock and associated equipment Certificate of Compliance with 49 U.S.C. 53230)(2)(C). The bidder or offeror hereby certifies that it will comply with the requirements of 49 U.S.C. 53230)(2)(C) and the regulations at 49 C.F.R. Part 661.11. Date Signature Company Name Title Certificate of Non -Compliance with 49 U.S.C. 53230)(2)(C) The bidder or offeror hereby certifies that it cannot comply with the requirements of 49 U.S.C. 53230)(2)(C) and 49 C.F.R. 661.11, but may qualify for an exception pursuant to 49 U.S.C. 53230)(2)(A), 5323 i)(2)(B), or Invoice Address: City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by Gerry S. Paul City of Fort Collins City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Accounting Department Phone:970-221-6775 Fax: 970-221-6707 Email: purchasing@fcgov.com PO Box 580 Fort Collins, CO 80522-0580 invoices @fcgov.com