Loading...
HomeMy WebLinkAbout267431 NORTHSTAR CONCRETE INC - CONTRACT - BID - 7509 CONCRETE MAINTENANCE PROJECT PHASE II (3)City of Fort Collins Purchasing SPECIFICATIONS AND Financial Services Purchasing Division 215 N. Mason St. 2" Floor PO Box 580 Fort Collins, CO 80522 970.221.6775 970.221.6707 fcgov. com/purchasing CONTRACT DOCUMENTS FOR CONCRETE MAINTENANCE PROJECT PHASE II 2015 Renewal BID NO. 7509 PURCHASING DIVISION 215 NORTH MASON STREET, 2ND FLOOR, FORT COLLINS amount equal to 100% of the Work completed. 95% of materials and equipment not incorporated in the Work (but delivered, suitably stored and accompanied by documentation satisfactory to OWNER as provided in paragraph 14.2 of the General Conditions) may be included in the application Section 00520 Page 3 for payment. 5.1.2. Upon Substantial Completion payment will be made in an amount sufficient, if necessary, to increase total payments to CONTRACTOR to 95% of the Contract Price, less such amounts as ENGINEER shall determine or OWNER may withhold in accordance with paragraph 14.7 of the General Conditions or as provided by law. 5.2. FINAL PAYMENT. Upon Final Completion and Acceptance of the Work in accordance with paragraph 14.13 of the General Conditions, OWNER shall pay the remainder of the Contract Price as recommended by ENGINEER as provided in said paragraph 14.13. ARTICLE 6. CONTRACTOR'S REPRESENTATION In order to induce OWNER to enter into this Agreement, CONTRACTOR makes the following representations: 6.1. CONTRACTOR has familiarized himself with the nature and extent of the Contract Documents, Work, site, locality, and with all local conditions and Laws and Regulations that in any manner may affect cost, progress, performance or furnishing of the Work. 6.2. CONTRACTOR has studied carefully all reports of explorations and tests of subsurface conditions and drawings of physical conditions which are identified in the Supplementary Conditions as provided in paragraph 4.2 of the General Conditions. 6.3. CONTRACTOR has obtained and carefully studied (or assumes responsibility for obtaining and carefully studying) all such examinations, investigations, explorations, tests, reports, and studies (in addition to or to supplement those referred to in paragraph 6.2 above) which pertain to the subsurface or physical condition at or contiguous to the site or otherwise may affect the cost, progress, performance or furnishing of the Work as CONTRACTOR considers necessary for the performance or furnishing of the Work at the Contract Price, within the Contract Times and in accordance with the other terms and conditions of the Contract Documents, including specifically the provisions of paragraph 4.2 of the General Conditions; and no additional examinations, investigations, explorations, tests, reports, studies or similar information or data are or will be required by CONTRACTOR for such purposes. 6.4. CONTRACTOR has reviewed and checked all information and data shown or indicated on the Contract Documents with respect to existing Underground Facilities at or contiguous to the site and assumes responsibility for the accurate location of said Underground Facilities. No additional examinations, investigations, explorations, tests, reports, studies or similar information or data in respect of said Underground Facilities are or will be required by CONTRACTOR in order to perform and furnish the SECTION 01310 CONSTRUCTION SCHEDULE 1.5 OWNER'S RESPONSIBILITY A. Owner's review is only for the purpose of checking conformity with the Contract Documents and assisting Contractor in coordinating the Work with the needs of the Project. It is not to be construed as relieving Contractor from any responsibility to determine the means, methods, techniques, sequences and procedures of construction as provided in the General Conditions. END OF SECTION 1.1 SURVEY REQUIREMENTS General Requirements - Page 7 of 18 SECTION 01330 SURVEY DATA A. The Owner shall provide the construction surveying for the street and landscaping improvements. City Survey Crews will perform the surveying required. B. The Contractor must submit a survey request form to the City Surveyor a minimum of 48 hours prior to requiring surveying. C. If the requested surveying cannot be accomplished in the time frame requested by the Contractor, the survey personnel shall notify the Contractor with the date on which the requested work will be completed. D. Should a sudden change in the Contractor's operations or schedule require the survey personnel to work overtime, the Contractor shall pay the additional overtime expense. E. The Contractor shall protect all survey monuments and construction stakes. If it is unavoidable to remove a survey monument or construction stakes, the Contractor is responsible for notifying the Surveyor and allowing enough time for the monuments or stakes to be relocated. The Contractor will be responsible for the cost of re -staking construction stakes and for the cost of re-establishing a destroyed monument. F. The Contractor shall notify the Engineer prior to concrete removal when property line markers are inscribed in the surface of the existing concrete, typically designated by "+" or "x" markings. The Contractor shall NOT reinstall all existing property line markers in the surface of the new concrete. The Contractor may NOT offset the existing mark for reinstallation but shall notify the City Survey Crews and request the offset location prior to removal of the concrete. If markers are removed without offsetting and reinstalling, the Contractor shall be responsible for all costs, including survey costs, associated with relocating and reinstalling the markers. G. The Contractor shall be responsible for transferring the information from the construction stakes to any necessary forms and for constructing all pipelines, drainage ways, pavements, inlets, walls, and other structures in accordance with the information on the stakes and grade sheets supplied by the Owner. END OF SECTION General Requirements — page 8 of 18 SECTION 01340 SHOP DRAWINGS 1.1 GENERAL A. Submit Shop Drawings, Samples, and other submittals as required by the individual specification. 1. Engineer will not accept Shop Drawings or other submittals from anyone but Contractor. B. Schedule: Reference Section 0 13 10, Construction Schedules. Submittals received by Engineer prior to the time set forth in the approved schedule will be reviewed at any time convenient to Engineer before the time required by the schedule. C. Any need for more than one re -submission, or any other delay in obtaining Engineer's review of submittals, will not entitle Contractor to extension of the Contract Time unless delay of the Work is directly caused by failure of Engineer to return any scheduled submittal within 10 days after receipt in his office of all information required for review of the submittals or for any other reason which prevents Engineer's timely review. Failure of Contractor to coordinate submittals that must be reviewed together will not entitle Contractor to an extension of Contract Time or an increase in Contract Price. D. Resubmit for review a correct submittal if errors are discovered during manufacture or fabrication. E. Contractor shall not use materials or equipment for which Shop Drawings or samples are required until such submittals, stamped by Contractor and properly marked by Engineer, are at the site and available to workmen. F. Contractor shall not use Shop Drawings which do not bear Engineer's mark "NO EXCEPTION TAKEN" in the performance of the Work. Review status designations listed on Engineer's submittal review stamp are defined as follows: 1. NO EXCEPTION TAKEN: Signifies material or equipment represented by the submittal conforms with the design concept, complies with the information given in the Contract Documents and is acceptable for incorporation in the Work. Contractor is to proceed with fabrication or procurement of the items and with related work. Copies of the submittal are to be transmitted for final distribution. 2. REVISE AS NOTED: Signifies material or equipment represented by the submittal conforms with the design concept, complies with the information given in the Contract Documents and is acceptable for incorporation in the Work in accordance with Engineer's notations. Contractor is to proceed with the Work in accordance with Engineer's notations and is to submit a revised submittal responsive to notations marked on the returned submittal or written in the letter of transmittal. 3. REJECTED: Signifies material or equipment represented by the submittal does not conform to the design concept or comply with the information given in the Contract Documents and is not acceptable for use in the Work. Contractor is to submit submittals responsive to the Contract Documents. 4. FOR REFERENCE ONLY: Signifies submittals which are for supplementary information only; pamphlets, general information sheets; catalog cuts, standard sheets, bulletins and similar data, all of which are useful to Owner in design, operation, or maintenance, but which by their nature do not constitute a basis for determining that items represented thereby conform with the design concept or comply with the information given in the Contract Documents. Engineer reviews such submittals for general information but not for substance. 1.2 SHOP DRAWINGS A. Include the following information as required to define each item proposed to be furnished. 1. Detailed installation drawings showing foundation details, and clearances required for construction. 2. Relation to adjacent or critical features of the Work or materials. General Requirements — page 9 of 18 SECTION 01340 SHOP DRAWINGS 3. Field dimensions, clearly identified as such. 4. Applicable standards, such as ASTM or Federal Specification numbers. 5. Drawings, catalogs or parts thereof, manufacturer's specifications and data, instructions, performance characteristics and capacities, and other information specified or necessary: a. For Engineer to determine that the materials and equipment conform with the design concept and comply with the intent of the Contract Documents. b. For the proper erection, installation, and maintenance of the materials and equipment which Engineer will review for general information but not for substance. c. For Engineer to determine what supports, anchorages, structural details, connections and services are required for materials and equipment, and the effect on contiguous or related structures, materials and equipment. 6. Complete dimensions, clearances required, design criteria, materials of construction and the like to enable Engineer to review the information effectively. B. Manufacturer's standard drawings, schematics and diagrams: 1. Delete information not applicable to the Work. 2. Supplement standard information to provide information specifically applicable to the Work. C. Format. 1. Present in a clear and thorough manner. 2. Minimum sheet size: 8 ''/2" x 11". 3. Clearly mark each copy to identify pertinent products and models. 4. Individually annotate standard drawings which are furnished, cross out items that do not apply, describe exactly which parts of the drawing apply to the equipment being furnished. 5. Individually annotate catalog sheets to identify applicable items. 6. Reproduction or copies of portions of Contract Documents: a. Not acceptable as complete fabrication or erection drawings. b. Acceptable when used as a drawing upon which to indicate information on erection or to identify detail drawings. 7. Clearly identify the following: a. Date of submission. b. Project title and number. c. Names of Contractor, Supplier and Manufacturer. d. Specification section number, specification article number for which items apply, intended use of item in the work, and equipment designation. e. Identify details by reference to sheet, detail, and schedule or room numbers shown in the Contract Documents. f. Deviations from Contract Documents. g. Revisions on re -submittals. h. Contractor's stamp, initialed or signed, certifying to review of submittal, verification of products, field measurements and field construction criteria, and coordination of the information within the submittal with requirements of the Work and the Contract Documents. 1.3 SUBMISSION REQUIREMENTS A. Make submittals promptly in accordance with approved schedule, and in such sequence as to cause no delay in the Work or in the work of any other contractor. B. Minimum number required: 1. Shop Drawings. a. Three (3) copies minimum, two (2) copies which will be retained by Engineer. General Requirements —page 10 of 18 SECTION 01340 SHOP DRAWINGS 1.4 RE -SUBMISSION REQUIREMENTS A. Make corrections or changes required by Engineer and resubmit until accepted. B. In writing call Engineer's attention to deviations that the submittal may have from the Contract Documents. C. In writing call specific attention to revisions other than those called for by Engineer on previous submissions. D. Shop Drawings. 1. Include additional drawings that may be required to show essential details of any changes proposed by Contractor along with required wiring and piping layouts. END OF SECTION General Requirements — page I l of 18 SECTION 01410 TESTING 1.1 GENERAL A. Provide such equipment and facilities as the Engineer may require for conducting field tests and for collecting and forwarding samples. Do not use any materials or equipment represented by samples until tests, if required, have been made and the materials or equipment are found to be acceptable. Any product which becomes unfit for use after approval shall not be incorporated into the work. B. All materials or equipment proposed to be used may be tested at any time during their preparation or use. Furnish the required samples without charge and give sufficient notice of the placing of orders to permit the testing. Products may be sampled either prior to shipment or after being received at the site of the work. C. Tests shall be made by an accredited testing laboratory selected by the Owner. Except as otherwise provided, sampling and testing of all materials and the laboratory methods and testing equipment shall be in accordance with the latest standards and tentative methods of the American Society for Testing Materials (ASTM). D. Where additional or specified information concerning testing methods, sample sizes, etc., is required, such information is included under the applicable sections of the Specifications. Any modification of or elaboration on these test procedures which may be included for specific materials under their respective sections in the Specifications shall take precedence over these procedures. 1.2 OWNER'S RESPONSIBILITIES A. Owner shall be responsible for and shall pay all costs in connection with testing for the following: 1. Soil tests, except those called for under Submittals thereof. 2. Tests not called for by the Specifications of materials delivered to the site but deemed necessary by Owner. 3. Concrete test, except those called for under Submittals thereof. 1.3 CONTRACTOR'S RESPONSIBILITIES A. In addition to those inspections and tests called for in the General Conditions, Contractor shall also be responsible for and shall pay all costs in connection with testing required for the following: 1. All performance and field testing specifically called for by the specifications. 2. All retesting for Work or materials found defective or unsatisfactory, including tests covered under 1.2 above. 3. All minimum call out charges or stand by time charges from the tester due to the Contractor's failure to pave, pour, or fill on schedule for any reason except by action of the Engineer. B. Contractor shall notify the Engineer 48 hours prior to performing an operation that would require testing. 1.4 CONTRACTOR'S QUALITY CONTROL SYSTEM A. General: The Contractor shall establish a quality control system to perform sufficient inspection and tests of all items of Work, including that of his subcontractors, to ensure conformance to the functional performance of this project. This control shall be established for all construction except where the Contract Documents provide for specific compliance tests by testing laboratories or engineers employed by the Owner. The Contractor's control system shall specifically include all testing required by the various sections of these Specifications. B. Superintendence: The Contractor shall employ a full time Superintendent to monitor and coordinate all facets of the Work. The Superintendent shall have adequate experience to perform the duties of Superintendent, shall be assigned solely to this project, and shall remain on site during construction activities. General Requirements —page 12 of 18 SECTION 01410 TESTING C. Contractor's quality control system is the means by which he assures himself that his construction complies with the requirements of the Contract Documents. Controls shall be adequate to cover all construction operations and should be keyed to the proposed construction schedule. D. Records: Maintain correct records on an appropriate form for all inspections and tests performed, instructions received from the Engineer and actions taken as a result of those instructions. These records shall include evidence that the required inspections or tests have been performed (including type and number of inspections or test, nature of defects, causes for rejection, etc.) proposed or directed remedial action and corrective action taken. Document inspections and tests as required by each section of the Specifications, and provide copies to Engineer weekly. END OF SECTION General Requirements — page 13 of 18 SECTION 01510 TEMPORARY UTILITIES 1.1 UTILITIES A. Furnish all utilities necessary for construction. B. Make arrangements with Owner as to the amount of water required and time when water will be needed. 1. Meters may be obtained through the Water Utility Meter Shop at 221-6759 2. Unnecessary waste of water will not be tolerated. C. Furnish necessary water trucks, pipes, hoses, nozzles, and tools and perform all necessary labor. 1.2 SANITARY FACILITIES A. Furnish temporary sanitary facilities at each site for the needs of construction workers and others performing work or furnishing services on the Project. B. Properly maintain sanitary facilities of reasonable capacity throughout construction periods. C. Enforce the use of such sanitary facilities by all personnel at the site. D. Obscure facilities from public view to the greatest practical extent. END OF SECTION General Requirements — page 14 of 18 SECTION 01560 TEMPORARY CONTROLS 1.1 NOISE CONTROL A. The Contractor shall take reasonable measures to avoid unnecessary noise when construction activities are being performed in populated areas. Refer to Revision of Section 108 for additional requirements. B. Construction machinery and vehicles shall be equipped with practical sound muffling devices, and operated in a manner to cause the least noise consistent with efficient performance of the Work. C. Cease operation of all machinery and vehicles between the hours of 6:00 p.m. and 7:00 a.m. 1.2 DUST CONTROL A. Dusty materials in piles or in transit shall be covered to prevent blowing material. B. The Contractor shall be respectful to pedestrians and bicyclists when sweeping road surfaces. The Contractor shall cease operation until the citizen(s) has cleared the area. C. Earth and road surfaces subject to dusting due to construction activities and detouring of traffic shall be kept moist with water or by application of a chemical dust suppressant. 1. Chemical dust suppressant shall not be injurious to existing or future vegetation. 1.3 POLLUTION CONTROL A. Prevent the pollution of drains and water courses by sanitary wastes, concrete, sediment, debris and other substances resulting from construction activities. 1. Retain all spent oils, hydraulic fluids, and other petroleum fluids in containers for proper disposal off the site. 2. Prevent sediment, debris, or other substances from entering sanitary sewers, storm drains and culverts. 1.4 EROSION CONTROL A. Take such measures as are necessary to prevent erosion of soil that might result from construction activities. Measures in general will include: a. Control of runoff. b. Trapping of sediment. c. Minimizing area and duration of soil exposure. d. Approved temporary materials such as hay bales, sand bags, plastic sheets, riprap, or culverts to prevent the erosion of banks and beds of watercourses or drainage swales where runoff will be increased due to construction activities. B. Preserve natural vegetation to greatest extent possible. C. Locate temporary storage and route construction traffic so as to preserve vegetation and minimize erosion. D. Comply with the City of Fort Collins' Storm Drainage Erosion Control Manual. 1.5 TRAFFIC CONTROL A. Maintain traffic control in accordance with the latest revisions of the "Manual of Uniform Traffic Control Devices" (MUTCD), the City of Fort Collins "Work Area Traffic Control Handbook," and the "Larimer County Urban Area Street Standards." In the event of a conflict between the MUTCD criteria and the City's criteria, the City's criteria shall govern. See Revision of Sections 104 and 630. General Requirements — page 15 of 18 SECTION 01560 TEMPORARY CONTROLS 1.6 PARKED VEHICLES A. See Revision of Section 104 for issues related to parked vehicles. 1.7 HAUL ROUTES The Engineer reserves the right to set haul routes in order to protect pavements, both new and old, from heavy loads. These pavements may include, but are not limited to, recently constructed pavements, recently overlaid pavements, and/or pavements whose condition would be significantly damaged by heavy loads. END OF SECTION General Requirements — page 16 of 18 Work at the Contract Price, within the Contract Times and in accordance with the other terms and conditions of the Contract Documents, including specifically the provision of paragraph 4.3. of the General Conditions. 6.5. CONTRACTOR has correlated the results of all such observations, examinations, investigations, tests, reports and data with the terms and conditions of the Contract Documents. 6.6. CONTRACTOR has given ENGINEER written notice of all conflicts, errors or discrepancies that he has discovered in the Contract Documents and the written resolution thereof by ENGINEER is acceptable to CONTRACTOR. ARTICLE 7. CONTRACT DOCUMENTS 7.1 The Contract Documents which comprise the entire Agreement between OWNER and CONTRACTOR concerning the Work consist of the General Conditions, Supplementary Conditions, those items included in the definition of "Contract Documents" in Article 1.10 of the General Conditions, and such other items as are referenced in this Article 7, all of which are incorporated herein by this reference. 7.2 Forms for use by CONTRACTOR in performing the Work and related actions in carrying out the terms of this Agreement are deemed Contract Documents and incorporated herein by this reference, and include, but are not limited to, the following: 7.2.1 Certificate of Substantial Completion 7.2.2 Certificate of Final Acceptance 7.2.3 Lien Waiver Releases 7.2.4 Consent of Surety 7.2.5 Application for Exemption Certificate 7.2.6 Application for Payment 7.3 Drawings, consisting of a cover sheet and sheets numbered as follows: n/a The Contract Drawings shall be stamped "Final for Construction" and dated. Any revisions made shall be clearly identified and dated. 7.4. Addenda Numbers N/A to N/A, inclusive. 7.5. The Contract Documents also include all written amendments and other documents amending, modifying, or supplementing the Contract Documents pursuant to paragraphs 3.5 and 3.6 of the General Conditions. 7.6. There are no Contract Documents other than those listed or incorporated by reference in this Article 7. The Contract Documents may only be amended, modified or supplemented as provided in paragraphs 3.5 and 3.6 of the General Conditions. ARTICLE 8. MISCELLANEOUS 8.1. Terms used in this Agreement which are defined in Article I of the General Conditions shall have the meanings indicated in the General Conditions. SECTION 01700 CONTRACT CLOSEOUT 1.1 CLEANING AND RESTORATION A. Return the premises and adjacent properties to conditions existing or better than existing at the time the work was begun. This will include providing labor, equipment and materials for cleaning, repairing, and replacing facilities damaged or soiled during construction. The Engineer will be the judge of the degree of restoration required. 1.2 PROJECT RECORD DOCUMENTS A. Maintain on the job site, and make available to the Engineer upon request, one current marked -up set of the drawings which accurately indicate all approved variations in the completed work that differ from the design information shown on the drawings. Further, these drawings should reflect all underground obstacles encountered. B. These record drawings along with any survey records, photographs, and written descriptions of work as may be required by the Engineer shall be submitted prior to project acceptance. END OF SECTION General Requirements — page 17 of 18 SECTION 01800 METHOD OF MEASUREMENT AND BASIS OF PAYMENT 1.1 DEFECTIVE WORK A. Owner shall not pay for defective work and repair or additional work required to bring the project to a point of acceptance. 1.2 BID PRICE A. The Total Bid Price covers all Work required by the Contract Documents. All work not specifically set forth as a pay item in the Bid Form shall be considered a subsidiary obligation of Contractor and all costs in connection therewith shall be included in the prices bid for the various items of Work. B. Prices shall include all costs in connection with the proper and successful completion of the Work, including furnishing all materials, equipment and tools, and performing all labor and supervision to fully complete the Work. C. Unit prices shall govern over extensions of sums. D. Unit prices shall not be subject to re -negotiation. 1.3 ESTIMATED QUANTITIES A. All quantities stipulated in the Bid Form at unit prices are approximate and are to be used only as a basis for estimating the probable cost of the Work and for the purpose of comparing the bids submitted to the Work. The basis of payment shall be the actual amount of materials furnished and Work done. B. Contractor agrees that he will make no claim for damages, anticipated profits, or otherwise on account of any difference between the amount of Work actually performed and materials actually furnished and the estimated amount therefor. END OF SECTION General Requirements — page 18 of 18 SECTION 02000 PROJECT SPECIFICATIONS The Colorado Department of Transportation "Standard Specifications for Road and Bridge Construction", latest revision, and the Larimer County "Urban Area Street Standards" (hereafter referred to as the "Standard Specifications"), latest revision, are made a part of this Contract by this reference, except as revised herein, and are hereby adopted as the minimum Standard Specifications of Compliance for this project. In those instances where the Standard Specifications conflict with any of the provisions of the preceding Sections, the preceding Sections shall govern. INDEX OF REVISIONS SECTION 104 Traffic and Parking Control 105 Control of Work 107 Safety and Protection and Restoration of Property and Landscape 108 Prosecution and Progress 201 Clearing and Grubbing 202 Removal of Structures and Obstructions 203 Excavation and Embankment 208 Erosion Control and Inlet Protection 212 Seeding, Fertilizer, and Sodding 304 Aggregate Base Course 403 Hot Mix Asphalt — Patching 601 Finishing Hardened Concrete Surfaces 604 Inlets and Culverts 608 & 609 Sidewalks, Curb and Gutter, Drive Approaches, Aprons, Crosspans, Pedestrian Access Ramps, Flatwork, and Concrete Pavement 623 Irrigation System 627 Pavement Markings 630 Construction Zone Traffic Control REVISION OF SECTION 104 TRAFFIC AND PARKING CONTROL Section 104 of the Standard Specifications is hereby revised as follows: MAINTAINING TRAFFIC Subsection 104.04 shall be amended to include the following. It shall be the Contractor's responsibility to clear parking from the streets when such parking will interfere with the work. Prior to work that requires the street(s) to be closed to parking and/or traffic, the street(s) shall be posted for "NO PARKING". "NO PARKING" signs shall be placed at a minimum of 100 foot intervals. The placement of these signs shall take place at least 24 hours prior to the commencement of work and shall clearly show the type of work, and the day, date, and times that the message on the sign is in effect. (For example, if a street is to be repaired on Wednesday, July 2, the street shall be posted no later than Tuesday, July 1, by 7:00 a.m. with a sign that reads similar to "NO PARKING, WEDNESDAY, JULY 2, 7:00 A.M. TO 6:00 P.M., Concrete Repairs (see sample "NO PARKING" sign on page 4). "NO PARKING" signs shall remain in place until the street is opened to traffic and all clean-up operations completed. No Parking signs may be placed, maintained and removed by a representative of the Contractor, the Traffic Control Supervisor, or Flagger. All information on the "NO PARKING" signs, with the exception of the type of work, date, and time shall be in block letters permanently affixed to the sign. Any information added to a sign, such as dates, shall be clearly legible and written in block style letters. The "NO PARKING" signs shall be in effect for one or two days only. In the event the Contractor deems it necessary to remove a vehicle that has not adhered to the "NO PARKING" notification, the Contractor shall first make every reasonable effort to locate and contact the owner of the vehicle. Should the Contractor be unable to locate the owner of the vehicle, the Contractor shall notify the Engineer to arrange for towing. If the "NO PARKING' sign has been in place for a minimum of 24 hours, the City will make every reasonable effort to remove the offending vehicle within four (4) hours of notification from the Contractor. The Contractor shall not be entitled to additional compensation for delays associated with the towing of illegally parked vehicles. The Contractor shall have an approved Traffic Control Plan on site at all times. Traffic control signage on the construction site shall be set up in accordance with the approved traffic control plan and in accordance with the specifications. Work performed by the Contractor without an approved traffic control plan or when "NO PARKING" signs have not been placed as required by the specifications shall not be paid. The Contractor shall also be subject to a pay deduction of up to $1,000.00 per occurrence per day for traffic control not in compliance with referenced specifications or requirements contained herein. Issues subject to deductions may include but are not limited to: Traffic Control Supervisor not on the project site at all times (unless pre -approved by the Engineer) An approved traffic control plan not on site Traffic control device set up by flagging personnel unless assisting the Traffic Control Supervisor Traffic control signage not set up in accordance with the approved traffic control plans Inadequate flagging personnel and/or flagging equipment The Engineer shall issue a written warning to the Contractor, Subcontractor, and/or Traffic Control Supervisor documenting the type of violation. The Engineer shall determine the deduction amount based on the Engineers' opinion of the infraction severity and the number of previous infractions. Upon issuance of the third violation, the Engineer may request the Subcontractor, Traffic Control Supervisor and/or flagging personnel be removed from the project. Removal from the project in which the violations were issued shall be in effect for the remainder of the year. The contractor shall find replacement Traffic Control Subcontractor, TCS, and/or flagging personnel within two weeks of the third notice without an adjustment to contract price or working days or the Contract may be terminated and rebid. Project Specifications - Page 2 of 48 REVISION OF SECTION 104 TRAFFIC AND PARKING CONTROL At or near the end of each work day, a representative of the Contractor, the Traffic Control Supervisor, and the Engineer shall meet to discuss the progress of the work, the placement of upcoming traffic control devices including "NO PARKING" signs. The quantity of traffic control devices used that day and for the next day shall be agreed upon by the Contractor and the Engineer. Any necessary adjustments shall be made. The Contractor and Engineer shall also review and determine the proposed means of handling parking and traffic control for the upcoming work. It is the responsibility of the Contractor to minimize any inconvenience to the public as a result of their work The Contractor shall maintain access at all times to all businesses within the project. The installation schedule shall be communicated to all businesses and residents affected by the work at least 48 hours prior to starting work. Any changes to the traffic control, as directed by the Engineer, including additional signs, barricades, and/or flaggers needed shall be immediately implemented. Traffic control shall be paid under Revision of Section 630, "Construction Zone Traffic Control' found herein. Project Specifications - Page 3 of 48 REVISION OF SECTION 104 TRAFFIC AND PARKING CONTROL I$] PARKING Wed JUlY 2 7:00 AM - 6:00 PM CONCRETE REPAIRS END OF SECTION Project Specifications - Page 4 of 48 REVISION OF SECTION 105 CONTROL OF WORK Section 105 of the Standard Specifications is hereby revised as follows: AUTHORITY OF THE ENGINEER Subsection 105.01 shall be amended to include the following: No phase of construction shall start until the Traffic Control Plan has been approved. Failure to have an approved Traffic Control Plan shall constitute cause for the Owner to stop work. During periods of Traffic Control non-compliance, the Contractor may be assessed $1,000.00 per day, may forfeit payment of work and materials installed, and may lose contract working days as determined by the Owner. The Contractor shall not be entitled to compensation for delays associated with non -compliant periods. PLANS, SHOP DRAWINGS, WORKING DRAWINGS, OTHER SUBMITTALS, AND CONSTRUCTION DRAWINGS Subsection 105.02 shall be amended to include the following: The Contractor shall furnish the required submittals in TABLE 105-1 one week before the commencement of work. Three (3) copies shall be furnished to the Engineer, two (2) copies will be returned to the Contractor upon approval. Submittals shall not be measured and paid for separately but shall be included in the work. TABLE 105-1 SUMMARY OF CONTRACTOR SUBMITTALS Section No. Description Approval Needed Reoccurring 107.02 Topsoil Soil Analysis or Soil Sample Submittal Yes Yes 108.03 Schedule of Work Yes Yes 203.05 Borrow Material Gradation Yes Yes 208.02 Erosion Control Devices Yes No 208.06 Spill Kit: List of items included within kit Yes No 212.02 1 Sod/Seed Yes No 304.02 Aggre ate Base Course/Recycled Concrete Soil Analysis Yes No 601.01 Exposed Sand Finish Yes No 608.00 Concrete Mix Designs Yes No 608.00 Curing Compound Yes No 608.00 Finishing Aide Yes No 608.00 MSDS Sheets for Curmg Compound and Finishing Aide Yes No 630.00 Traffic Control Plans Yes Yes 630.11 TCS Qualifications reoccurs when TCS and fla ers change) Yes No 630.11 Resident Notification Letter Yes I Yes COOPERATION BY CONTRACTOR Subsection 105.10 shall be amended to include the following: The City of Fort Collins is committed to comply with the United States Environmental Protection Agency (EPA) and the Streets Department Environmental Management System (EMS) requirements that vehicles on City projects shall comply with the "Anti Idling Policy" to reduce environmental impacts related to construction. Contractors and Subcontractors shall comply with turning off vehicles and equipment instead of idling for long periods (more than thirty (30) seconds after stopping at destination and/or not more than five (5) minutes aggregated within sixty (60) minutes). Exceptions for powering auxiliary equipment and for safety or health emergencies are allowed COOPERATION WITH UTILITIES Project Specifications - Page 5 of 48 REVISION OF SECTION 105 CONTROL OF WORK Subsection 105.11 shall be amended to include the following: Concrete construction and reconstruction operations at intersections may involve the destruction and replacement of traffic signal loop detectors and/or new detectors may be installed at intersections where they do not currently exist. The existing traffic signal loop detectors shall be removed by the Contractor at no additional cost. New and replacement loop detectors shall be installed by the City Traffic Division. The Contractor shall cooperate with the schedule of this work to insure the timely installation of loop/camera detectors. The Contractor shall coordinate with the City Traffic Division to insure that their work is completed before concrete placement operations begin. COOPERATION BETWEEN CONTRACTORS Subsection 105.12 shall be amended to include the following: City Utilities, Streets, Parks, Traffic, and utility Contractors may perform work related to the project within or near the limits of this project. The Contractor shall conduct the work without interfering or hindering the progress or completion of the work being performed by other Contractors. The Contractor shall coordinate extensively with these entities to minimize traffic control and scheduling conflicts and ensure timely completion of all the work. The contractor shall allow supporting utility work within their traffic control areas and provide flagging, if necessary, in support of their work and safety requirements. INSPECTION AND TESTING OF WORK Subsection 105.16 shall be amended to include the following: The Contractor shall keep the Engineer informed of his future construction operations to facilitate scheduling of required inspection, measuring for pay quantities, and sampling. The Contractor shall notify the Engineer a minimum of 24 hours in advance of starting any construction operation that will require inspection, measuring for pay quantities, or sampling. Failure of the Contractor to provide such notice will relieve the Owner and the Engineer from any responsibility for additional costs or delays caused by such failure. Inspection of the work or materials shall not relieve the Contractor of any obligations to fulfill his contract or complete warranty elements as prescribed. Work and materials not meeting specifications shall be corrected and unsuitable work or materials may be rejected, notwithstanding that such work or materials have been previously inspected by the Engineer or that payment therefore has been included in the progress estimate. MAINTENANCE DURING CONSTRUCTION Subsection 105.19 shall be amended to include the following: The roadway area, including curb, gutter, and sidewalk, adjacent to and through the construction area shall be cleaned of debris generated by the Contractor at the earliest opportunity, but in no case shall the area not be cleaned after the completion of the day's work. Large debris (greater than one inch) and regardless of the source, shall be picked up and disposed of offsite at the contractors expense. Smaller particulate debris shall be blown from the sidewalks, driveways, curb, and gutter into the street where it can be picked up by a sweeper without transmitting debris back on sidewalk areas. It shall be the Contractor's responsibility to provide the necessary manpower and equipment to satisfactorily clean the roadway area at no extra cost. The Contractor shall utilize a combination of pick-up brooms, side brooms, and/or other equipment as needed to clean the streets. The requirement to sweep the street shall be suspended during the leaf fall period between September 12`s and November 12ie unless directed by the Engineer for areas with minimal leaf fall. All sweeping and clean up equipment shall be approved by the Engineer prior to the commencement of work. The Contractor shall maintain the streets during the construction process as prescribed above. If a street requires additional sweeping by City forces, the Owner shall deduct from compensation due the Contractor sufficient funds to cover the Owner's cost to provide the sweeping service. Project Specifications - Page 6 of 48 REVISION OF SECTION 105 CONTROL OF WORK All cost of maintaining the work during construction and before the project is accepted, shall not be measured and paid for separately but shall be included in the work. END OF SECTION Project Specifications - Page 7 of 48 REVISION OF SECTION 107 SAFETY AND PROTECTION AND RESTORATION OF PROPERTY AND LANDSCAPING Section 107 of the Standard Specifications is hereby revised as follows: Subsection 107.06 shall be amended to include the following: Personnel on Street Maintenance Program (SMP) projects shall use protective equipment prescribed by Local, State, and Federal safety regulations to attempt to control or eliminate hazards or exposure to illness or injury. The Contractor and Subcontractors are responsible for providing and insuring the use of the required Personal Protective Equipment (PPE). Only Personal Protective Equipment complying with the Occupational Safety and Health Administration (OSHA) or American National Standards Institute (ANSI) regulations shall be used. The Contractor shall be responsible for the compliance of their employees and the Subcontractor's employees. The Contractor's safety representative shall make regular field inspections to audit and document compliance. An employee of the Contractor or Subcontractor who refuses to use the prescribed protective equipment designed for their protection, or willfully damages such equipment, constitutes cause for the Engineer to request removal of the employee from the site. The Contractor's personnel shall be required to wear safety vests, hard hats, and steel toe boots while on the construction site(s). Subsection 107.12 shall be amended to include the following: The fact that any underground facility (sprinkler systems, utility services, etc.) is not shown on the plans, details, or construction documents shall not relieve the Contractor of his responsibilities as provided for in the Contract. It shall be the Contractor's responsibility, pursuant thereto, to ascertain the location of such underground improvements which may be subject to such damage by reason of his operations. Any pruning of vegetation shall require the written permission of the property owner and/or the Engineer. If the landscape removal area adjacent to the concrete repair is six (6) inches or less in width, the Contractor shall repair any subsurface utilities including irrigation systems, clean the area of all construction debris (i.e. concrete, road base, etc.) to a minimum depth of four (4) inches, prepare all edges to be clean and vertical, and place and compact imported topsoil. The topsoil shall be compacted (until firm, but not over compacted) utilizing a hand operated roller or other method approved by the Engineer. At the Engineers discretion, any areas to be restored where the disturbed area is greater than six (6) inches in width and greater than 12 inches in length adjacent to the concrete repair, the Engineer may require the Contractor to clean and prepare the area along the entire length of the repair location as stated above to a minimum one foot (12 inches) wide, place sod on the prepared surface, water the new sod once thoroughly, and notify the property owner in writing of the nature of the work that has taken place. The Contractor shall also notify the property owner of the fact that the sod will be watered only once by the Contractor and provide the property owner the recommended watering schedule suggested by the sod supplier. The Contractor shall make every effort to minimize the need for sod placement. If the existing asphalt along the concrete toe is in good condition and salvageable during concrete removal, as determined by the Engineer, the Contractor shall preserve the existing asphalt. Minimizing the landscape removal areas behind the sidewalk, curb and gutter shall continue to be the primary goal. The pay item for "Asphalt Pavement Preservation" is intended to compensate the Contractor for additional removal time, backfill, sprinkler repair, and sodding that shall be required while preserving the existing asphalt and minimizing the removal area behind the repair. "Asphalt Pavement Preservation" shall provide compensation for this type of repair and shall be measured and paid in addition to the concrete pay item for the type of repair (i.e., Driveover Curb, Gutter and 6" Sidewalk — Remove & Replace). Revision of Section 608 and 609 defines the measurement and payment for these removals. The placement of backfill and top soil for concrete repair locations shall be completed within two (2) working days of the placement of the concrete. Excavated soils from the repair locations may be stockpiled on site and used as backfill for areas behind the new concrete installation and below the top four (4) inches of the surface. Imported Topsoil shall consist of loose friable river bottom or farmland loam, reasonably free of manmade Project Specifications - Page 8 of 48 8.2. No assignment by a party hereto of any rights under or interests in the Contract Documents will be binding on another party hereto without the written consent of the party sought to be bound; and specifically but not without limitations, moneys that may become due and moneys that are due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to the contrary in any written consent to an assignment no assignment will release or discharge that assignor from any duty or responsibility under the Contract Document. 8.3. OWNER and CONTRACTOR each binds itself, its partners, successors, assigns and legal representatives to the other party hereto, its partners, successors, assigns and legal representatives in respect to all covenants, Agreement and obligations contained in the Contract Document. REVISION OF SECTION 107 SAFETY AND PROTECTION AND RESTORATION OF PROPERTY AND LANDSCAPING materials subsoil, refuse, stumps, roots, rocks, brush, weeds, noxious weed seeds, heavy clay, hard clods, trash, toxic substances, or other material which would be detrimental to the proper development of vegetative growth. Imported topsoil shall have 100% passing the 1/4" screen and shall contain a combination of sand, clay, and friable loam. The Contractor shall submit a soil analysis or sample for approval by the Engineer. The topsoil shall be in a relatively dry state but shall contain sufficient moisture to allow compaction and shall be placed during dry weather. The topsoil shall be fine graded to eliminate rough and low areas and ensure positive drainage. The existing levels, profiles, and contours shall be maintained. If the area to be repaired is only damaged on the surface, the Contractor shall remove the damaged areas of sod to a depth that will allow new sod to be placed, place new sod, water once and notify the property owner in writing of the nature of the work that has taken place. The Contractor shall also notify the property owner of the fact that the sod will be watered only once by the Contractor and provide the property owner the recommended watering schedule suggested by the sod supplier. The minimum overall width of the area to be sodded shall be one (1.0') foot. For concrete repair locations, the placement of sod shall be completed by the end of the first working day of the week following the placement of the concrete. Sprinkler systems - Sprinkler systems designated for relocation shall be capped off at the limits of construction and protected from damage by the Contractor. Sprinkler heads shall be salvaged and stockpiled on each property for use when reconstructing the sprinkler systems. Sprinkler systems damaged outside of the construction limits as a result of construction operations shall be replaced at the Contractor's expense within three (3) working days from the date of damage. All landscaping that is damaged due to construction operations shall be replaced by the Contractor at his expense unless a written waiver is obtained from the property owner and submitted to the Engineer. Re -sodded lawns shall be watered once by the Contractor. All costs for protecting and restoring landscaping and lawns shall be considered a subsidiary obligation of the Contractor in connection with the various items of the Work and no measurement or payment shall be made separately for the protection and restoration of landscaping and lawns. All restoration of landscaping and lawns damaged by construction operations, other than concrete repair, shall take place within three (3) working days from the date of damage. In areas where the Engineer directs new work or the reconstruction area requires grade adjustment, the placement of topsoil, sod, and sprinkler relocation will be provided by the City under separate contract. All labor, materials, tools, equipment, incidentals, and work involved in protecting or repairing underground facilities shall be considered incidental to the Work and shall not be measured and paid for separately. END OF SECTION Project Specifications - Page 9 of 48 REVISION OF SECTION 108 PROSECUTION AND PROGRESS Section 108 of the Standard Specifications is hereby revised as follows: SCHEDULE Subsection 108.03 shall be amended to include the following: A schedule of work must be submitted prior to starting work and shall include the number of working days per area to complete all work items covered by the contract but shall not exceed the number of contract working days. Location of vicinity maps are referenced in Section 03500, Project Maps. The schedule should take any priorities into consideration and include projected start and end dates for each area. Area and street quantities are described in Section 02500, Quantity Estimates. Prior to award, mutually acceptable milestones shall be determined by the Contractor and the City based on the schedule of working days discussed above. LIMITATION OF OPERATIONS Subsection 108.05 shall be amended to include the following: The work shall be completed within the following calendar months: DETERMINATION AND EXTENSION OF CONTRACT TIME Subsection 108.08 shall be amended to include the following: Working hours on residential and collector streets shall be 7.00 a.m. to 6:00 p.m., Monday through Friday, or as approved by the Engineer. Working hours on arterial streets shall be restricted to 8:30 a.m. to 3:30 p.m., or as approved by the Engineer. Working hours within CDOT right-of-way (S.H. 287 College Ave. and Hwy 17 Mulberry St.) shall be restricted to 9:00 am. to 3:00 p m. The above time restrictions shall apply to the days' preparatory work, equipment maintenance, and clean up unless approved by the Engineer. Contract working days shall be completed in one hundred forty (190) consecutive working days and during the months of March through November. The Contractor shall mobilize to begin work within ten (10) working days of the Notice to Proceed and shall continue installations through completion of the contract. FAILURE TO COMPLETE WORK ON TIME Subsection 108.09 shall be amended to include the following: Failure to meet the agreed upon milestones, mobilize within the days specified, or fully complete the project in one hundred ninety (190) consecutive working days, shall result in liquidated damages assessed against the Contractor. Project Specifications - Page 10 of 48 REVISION OF SECTION 108 PROSECUTION AND PROGRESS At the City's option, liquidated damages in the amount of $1,000.00 per day may be retained from any monies due the Contractor, or the City may retain an alternate Contractor(s) to complete the work, or portion thereof, and retain any costs incurred above and beyond the bid prices of the Contract from any monies due the Contractor in lieu of liquidated damages. Production rates and progress toward the scheduled work shall be monitored on a monthly basis. Should it be determined that milestones in the agreed to schedule are not being accomplished a written warning will be issued from the Pavement Engineer. If the backlog in the needed work is not addressed within the next pay period, the City may pursue remedial measures detailed above. END OF SECTION Project Specifications - Page 11 of 48 REVISION OF SECTION 201 CLEARING AND GRUBBING Section 201 of the Standard Specifications is hereby revised as follows: CONSTRUCTION REQUIREMENTS Subsection 201.02 shall be amended to include the following: When tree roots are encountered during construction operations, the Contractor shall notify the Engineer prior to root removal. The Engineer and the City Forester's representative shall then make a determination regarding removal. When it is apparent that the tree roots have heaved the concrete section, the Contractor shall remove the section(s) of concrete as early as possible to allow time for inspection and to schedule root grinding operations, under separate contract. Root grinding will be scheduled as soon as possible to minimize delays in construction. Delays to concrete installation due to root grinding shall not be considered for additional traffic control payment or additional days added to the total contract working days but shall be anticipated in the Contractor's schedule. Where it is anticipated that tree roots may be encountered, great care shall be taken by the Contractor to prevent any damage to the roots with tools or equipment. Damage to roots during concrete removal shall be trimmed and cut with a sharpened, sanitized saw, cut orthogonally to its longitudinal axis as closely as practical, to leave the freshly cut root surface in a clean and smooth condition. Axes or other blunt objects shall not be used to cut tree roots. BASIS OF PAYMENT Subsection 201.04 shall be amended to include the following: All costs for removing tree roots shall be considered a subsidiary obligation of the Contractor in connection with the various items of the Work and no measurement or payment shall be made separately for the removal and trimming of tree roots. END OF SECTION Project Specifications - Page 12 of 48 REVISION OF SECTION 202 REMOVAL OF STRUCTURES AND OBSTRUCTIONS Section 202 of the Standard Specifications is hereby revised as follows: DESCRIPTION Subsection 202.01 shall be amended to include the following: This work consists of sawing and cutting to facilitate controlled breaking and removal of concrete, asphalt, and flagstone to a neat line. CONSTRUCTION REQUIREMENTS Subsection 202.02 shall be amended to include the following: Sawing of concrete and asphalt shall be done to a true line having a vertical face, unless otherwise specified. The depth of the saw cut in concrete and asphalt shall be of sufficient depth to ensure a vertical, smooth face, free from breakage, or as directed by the Engineer. Cuts in asphalt or concrete pavement shall be made such that each edge shall be parallel or at right angles to the direction of traffic. Dust created by sawing shall be mitigated by wet sawing or other means approved by the Engineer. Residue from sawing shall be removed by the Contractor at the earliest opportunity. Residue will not be allowed to run through the gutter flow line for more than fifty (50) feet. The Contractor shall prevent tracking of residue onto the roadway or walkway and shall prevent discharge into the storm drainage system. The Contractor shall use a storm water protection device or other means of controlling run off of residue as approved by the Engineer. See Section 208 "Erosion Control and Inlet Protection' contained herein. METHOD OF MEASUREMENT Subsection 202.11 shall be amended to include the following: Sawing shall be measured by the lineal foot. This item shall only be measured and paid where the Engineer directs sawing not already being paid under another item. Sawing related to the items described in Revision of Section 604 - Inlets and Culverts, and Section 608 & 609 Sidewalks, Curb & Gutter, Drive Approaches, Aprons, Crosspans, Pedestrian Access Ramps, Flatwork, and Concrete Pavement, shall be considered a subsidiary obligation of the Contractor, and shall not be measured and paid for separately. Erosion control measures used during sawing are considered incidental to sawing operations and shall not be measured and paid for separately. BASIS OF PAYMENT Subsection 202.12 shall be amended to include the following: Payment shall be made under: Pay Item Unit 202.01 Sawcutting 4 to 6" Lineal Foot The above prices and payments shall include full compensation for famishing all labor, materials, tools, equipment, and incidentals and for doing all work involved in Sawcutting as specified in these specifications, as shown on the plans, and as directed by the Engineer. END OF SECTION Project Specifications - Page 13 of 48 REVISION OF SECTION 203 EXCAVATION AND EMBANKMENT Section 203 of the Standard Specifications is hereby revised as follows: DESCRIPTION Subsection 203.01 shall be amended to include the following: This work shall consist of removing and disposing of the existing pavement, base or other material, preparing the subgrade for the subsequent course, and placing borrow in accordance with the specifications and in reasonably close conformity with the lines, grades, and typical cross sections shown on the plans or as designated by the Engineer. All excavation will be classified, "General Excavation", as hereafter described. The Contractor shall dispose of all excavated material. CONSTRUCTION REQUIREMENTS Subsection 203.05 shall be amended to include the following: General Excavation shall consist of the excavation of all materials of whatever character required for the work not being removed under some other item. The Contractor shall be responsible for the protection of the subgrade/base course until subsequent courses have been placed. The excavation will be accomplished in the following manner: General Excavation: The areas to be removed will be marked on the surface with paint by the Engineer. A straight vertical cut shall be made through the pavement, if necessary, to provide a square or rectangular opening, such that each edge will be parallel or at right angles to the direction of traffic. Wheel cutting, ripping, and tearing of asphalt using construction equipment such as a grader (blade) shall not be allowed. If, in the opinion of the Engineer, the subgrade material is unsuitable, it shall be removed to the limits and depths designated. Where excavation to the finished grade section (including General Excavation and Patching) results in a subgrade of unsuitable soil, the Contractor shall remove the unsuitable materials and backfill to the finished grade section with approved material as directed by the Engineer. After the material has been removed to the depth specified by the Engineer, the Contractor shall prepare the subgrade by compacting with a sheepsfoot roller, rubber tired roller, and/or other compaction equipment as approved by the Engineer. The subgrade preparation shall not be measured and paid for separately, but shall be included in the contract unit price for General Excavation. Borrow Borrow shall be placed as directed by the Engineer. The minimum amount of borrow shall be one load (approximately ten (10) ton). The cost for compaction shall be included in the contract unit price for Borrow. Borrow material shall meet the grading requirement for Class 1 (Pit Run) or Class 5 (Road Base) Aggregate Base Course. Class 1 Aggregate Base Course need not be crushed and can be of the pit run variety provided it falls within the gradation requirements as shown in the Standard Specifications. The material required for the specific location shall be directed by the Engineer. Load slips shall be consecutively numbered for each day and submitted to the Engineer daily Project Specifications - Page 14 of 48 REVISION OF SECTION 203 EXCAVATION AND EMBANKMENT METHOD OF MEASUREMENT Subsection 203.13 shall be amended to include the following: The Contractor and the Engineer shall field measure and agree upon the excavated quantity before any further work continues. Should the Contractor fail to request the Engineer to measure any work and performs other work that would prevent the Engineer from measuring pay quantities, the Contractor shall not be compensated for materials not measured by the Engineer. Borrow shall be paid by the ton at the proper moisture. Haul and water necessary to bring mixture to optimum moisture content will not be measured or paid for separately, but shall be included in the contract unit price for Borrow. Aggregate Base Course that is placed as a result of excavation of unsuitable subgrade shall be paid for at the unit price for Borrow. The accepted quantities of Excavation will be paid for at the contract unit price per cubic yard, complete -in - place. Subgrade preparation, moisture conditioning, compaction, haul, and disposal will not be measured and paid for separately. BASIS OF PAYMENT Subsection 203.14 and 207.05 shall be amended to include the following: Payment shall be made under: Pay Item Unit 203.01 General Excavation Cubic Yard 203.02 Borrow Ton The above prices and payments shall include full compensation for furnishing all labor, materials, tools, equipment, and incidentals, and for doing all the work involved in Excavation and Borrow including haul, stockpiling, placing material, watering or drying soil, compaction, proof rolling, finish grading, complete -in -place, and disposal of unusable materials as shown on the plans, as specified in these specifications, and as directed by the Engineer. END OF SECTION Project Specifications - Page 15 of 48 REVISION OF SECTION 208 EROSION CONTROL AND INLET PROTECTION Section 208 of the Standard Specifications is hereby revised as follows: DESCRIPTION Subsection 208.01 shall be amended to include the following: This work shall consist of providing, installing, maintaining, removing, and relocating when required, erosion control devices during the installation of the Work and at a minimum at all inlets to prevent or minimize erosion, sedimentation, pollution of any state waters, and infiltration of construction materials into the inlets. Work shall be in accordance with the latest editions of The City of Fort Collins Urban Drainage and Flood Control District Urban Drainage Criteria Manual, the City of Fort Collins Environmental Standard Operating Procedures, (Section 04000 contained herein), and the Colorado Department of Transportation Standard Specifications for Road and Bridge Construction. Any loss of time or materials related to erosion and erosion control shall be the sole responsibility of the Contractor. Any damage to surrounding properties or facilities, either on site or off site, related to erosion caused by construction or due to a spill event, shall be the sole responsibility of the Contractor. MATERIALS Subsection 208.02 shall be amended to include the following: The Contractor shall submit the type of material to be used for erosion control measures prior to beginning the work. See Details Section 03000 contained herein. Contractor shall submit the type of material to be used for erosion control measures prior to beginning the work. 1. Inlet protection shall include sufficient length to protect around the perimeter of the inlet opening. 2. Erosion control devices around inlets near a load site shall be required. 3. Erosion control devices on the downstream side of an aggregate stockpile or truck washout area shall be required as directed by the Engineer. Recycled Rubberized Inlet Protection shall meet the following requirements: 1. Infill material: Shredded recycled rubber 2. Weight: approximately 10 lbs. per linear foot 3. Diameter: Approximately 9 inches 4. Geotextile fabric: Made of a durable fabric with atypical weight of 6-10 ozlyd. CDOT Gravel Bag Inlet Filter shall meet the following requirements or approved Equal: 1. Infill material: CDOT #67 washed rock or approve equal 2. Weight: approximately 20 lbs per linear foot 3. Diameter: Approximately 5 inches 4. Geotextile fabric: CDOT Class 1 Erosion Control Fabric, typical weight of 6-8 oz/yd. CONSTRUCTION REQUIREMENTS Subsection 208.03 shall be amended to include the following: All erosion control measures shall be installed prior to starting the Work. Straw wattles shall not be allowed. Devices shall be approved by the Engineer. Protection devices shall be installed on the downstream side at load sites, stockpiles, base piles, and truck wash out areas, or as directed by the Engineer, and shall not be measured and paid for separately. Project Specifications - Page 16 of 48 REVISION OF SECTION 208 EROSION CONTROL AND INLET PROTECTION It shall be the Contractor's responsibility to ensure that all sidewalks, driveways, curbs, gutters, and roads within and adjacent to the project are cleaned of construction debris that may enter the inlets during the course of the work and at the end of each day. Inlet protection shall include sufficient length to protect around the perimeter of the inlet opening. Drop and Combo Inlet filters All storm drainage system inlets shall be filtered using a CDOT Class 1 Erosion anchored with CDOT Control Fabric Gravel Bag Inlet Filter lining the perimeter of the grate, before water is discharged into streams or onto adjacent properties. These methods are applicable to existing and proposed drainage systems. Curb -opening Inlets Type R curb -opening Inlets shall be filtered with a CDOT Gravel Bag Filter or as Approved by the Engineer. Maintenance The Contractor shall continuously maintain erosion and sediment control devices to properly function during the course of construction. See Detail SC-5 contained herein for the connection of multiple Gravel Bags (rock socks). All inlet protection devices shall be inspected and repairs made after each runoff event. Sediments shall be removed when one half the design depth has been filled. Sediments shall also be removed immediately from the traveled way of roads and disposed of properly. MATERIALS HANDLING AND SPILL PREVENTION Subsection 208.06 shall be amended to include the following: Appropriate Spill Kits shall be on site with each piece of equipment at all times during installation of the Work and during equipment maintenance and fueling (see Section 04000 ESOP). The Contractor shall submit a description of the items contained in each Spill Kit for approval by the Engineer. METHOD OF MEASUREMENT Subsection 208.11 shall be amended to include the following: "Stormwater Protection — CDOT Gravel Bag Filter" and "Stormwater Protection - Recycled Rubber Filled Wattle" shall be measured and paid by the lineal foot for each inlet location when devices are installed and accepted, whether the protection device is new or has been relocated, and as directed by the Engineer. Inlet protection shall include sufficient length to protect around the perimeter of the grate. Excessive lengths shall not be paid. "Stormwater Protection — Gravel Bag Inlet Filters" shall be measured and paid per each installed and accepted, and as directed by the Engineer Excavation required for removal of accumulated sediment from traps, basins, and other clean out excavation of accumulated sediment, and the proper disposal of sediment, shall be considered incidental to the work and not be measured and paid separately. Street sweeping of sediment shall not be measured and paid for separately. All construction material that enters an inlet due to the Work shall be removed from the inlet interior and removed from the site to an approved disposal location. This work shall not be measured and paid for separately. Project Specifications - Page 17 of 48 REVISION OF SECTION 208 EROSION CONTROL AND INLET PROTECTION Spill Kits required on site and with equipment and vehicles shall not be measured and paid for separately. Erosion control measures used during sawcutting are considered incidental to all sawing operations and shall not be paid for separately. BASIS OF PAYMENT Subsection 208.12 shall be amended to include the following: Payment shall be made under: Pay Item Unit 208.01 Stormwater Protection — CDOT Gravel Bag (rock sock) Lineal Foot 208.02 Stormwater Protection - Recycled Rubber Filled Wattle Lineal Foot 208.03 Stormwater Protection — CDOT Gravel Bag Inlet Filter Each The above prices and payments shall include full compensation for furnishing all labor, materials, tools, equipment, and incidentals and for doing all work involved in installing, maintaining, removing, and relocating when required, erosion control measures, as shown on the plans, as specified in these specifications, and as directed by the Engineer. END OF SECTION Project Specifications - Page 18 of 48 OWNER: CITY OF FO(f COLLINS f� By: v DA ATTE ERR , CITY MANAGER By: GERRY PALX DIRECTOR OF PURCHASING AND RISK MANAGEMENT Date: *4.� r Attest: City Clerk Address for giving notices: P. O. Box 580 Fort Collins. CO 80522 A roved as to F�rm \y Assi I ant City Attorney CONTRACTOR: NORTHSTAR CONCRETE INC. Title: ` (44-c�, l V W4L,,1 Date Z- 70 6 S (CORPORATE SEAL) Attest: A r s for giving notices: L- XZAJ.I � boS3 --7 License No.: REVISION OF SECTION 212 SEEDING, FERTILIZER AND SODDING Section 212 of the Standard Specifications is hereby revised as follows: DESCRIPTION Subsection 212.01 shall be amended to include the following: This work shall consist of soil preparation and furnishing and placing topsoil and blue grass sod in accordance with these specifications, accepted horticulture practice, and in reasonably close conformity with the existing topography of the location. This work shall not include locations of concrete repair in which grade changes and additional work is directed by the Engineer. See Section 107 "Safety and Protection and Restoration of Property" found herein. MATERIALS Subsection 212.02 shall be amended to include the following: Topsoil Topsoil shall conform to the requirements of Sections 107 found herein and CDOT 207. Sod Bluegrass sod shall be nursery grown, 99% Kentucky Blue Grass and 99% weed free. Other sod type may be used only if approved in writing by the Engineer. The 1% allowable weeds shall not include any undesirable perennial or annual grasses or plants. Soil thickness of sod cuts shall not be less than 3/4 inch nor more than one inch. Sod shall be cut in uniform strips with minimum dimensions of 12 inches in width and 48 inches in length. The Contractor shall submit a sample of the sod he proposes to furnish and the sample shall serve as a standard. Any sod furnished, whether in place or not, that is not up to the standard of the sample may be rejected. Sod that has been cut for more than 24 hours shall not be used. Each load of sod shall be accompanied by a certificate from the grower stating the type of sod, and the date and time of cutting. CONSTRUCTION REQUIREMENTS Subsection 212.05 shall be amended to include the following: Sodding: Soil Preparation: The area shall be cleaned with a minimum depth of four (4) inches (where topsoil does not exist) and a minimum width of one (1) foot, all irregularities in the ground surface shall be removed, and all edges clean and vertical. Sticks, stones, debris, and other similar material more than '/2 inch in diameter shall be removed. Any objectionable depressions or other variances from a smooth grade shall be corrected. Topsoil Placement: Topsoil shall be placed and compacted with a minimum depth of four (4) inches. The amount of compaction required shall be as directed by the Engineer. Sod Placement: The minimum width for sod shall be one (1) foot. The area to be sodded shall be smooth. The sod shall be laid by staggering joints with all edges touching. On any slopes, the sod shall run approximately parallel to the slope contours. The Contractor shall water the sod once and notify the property owner in writing of the nature of the work that has taken place, that the sod has been only watered once, and provide the recommended watering schedule for new sod placement as recommended by the sod supplier. Sod placement/replacement required due to Contractor negligence shall follow the requirements of this section but shall not be measured and paid for under the terms of this contract. Project Specifications - Page 19 of 48 REVISION OF SECTION 212 SEEDING, FERTILIZER AND SODDING BASIS OF PAYMENT Subsection 212.08 shall be amended to include the following: No measurement or payment shall be made for re -sodding or seeding lawns damaged by the Contractor adjacent to new concrete when the grade of the existing lawn reasonably matches the grade of the new concrete. Re - sodding and seeding in this instance shall be considered incidental to the work being performed. Seeding and Sod shall only be paid when requested by the Engineer for specific situations, shall be paid by the square foot at the contract unit price, and shall include full compensation for items noted below. In areas where the Engineer directs new work or the reconstruction area requires grade adjustment the placement of topsoil, sod, and sprinkler relocation will be provided by the City under separate contract. Payment shall be made under: Pav Item Unit 207.01 Imported Topsoil Cubic Yard 212.01 Sod Square Foot 212.02 Landscape/Irrigation Labor Hour The above prices and payments shall include full compensation for furnishing all labor, materials, tools, equipment, and incidentals and for doing all work involved in the placement of seeding and sodding, including haul, stockpiling, placing material, repairing sprinklers, watering or drying soil, compaction, finish grading, complete -in -place, and as shown on the plans, as specified in these specifications, and as directed by the Engineer. END OF SECTION Project Specifications - Page 20 of 48 REVISION OF SECTION 304 AGGREGATE BASE COURSE Section 304 of the Standard Specifications is hereby revised as follows: DESCRIPTION Subsection 304.01 shall be amended to include the following: This work shall consist of furnishing and placing one or more courses of aggregate base or recycled concrete on a prepared subgrade. MATERIALS Subsection 304.02 shall be amended to include the following: Aggregate Base Course shall meet the grading requirements for Class 5. Recycled concrete may be substituted for Aggregate Base Course as authorized by the Engineer. Recycled asphalt shall not be used as subgrade beneath concrete sidewalk, curb, and gutter. CONSTRUCTION REQUIREMENTS Subsection 304.04 shall be amended to include the following: The contractor shall be responsible for the protection of the subgrade/base course until subsequent courses have been placed. Load slips shall be consecutively numbered for each day and submitted daily to the Engineer. Borrow or Aggregate Base Course that is placed as a result of excavation of unsuitable subgrade shall be paid for at the unit price for Borrow under Revision of Section 203, Excavation and Embankment. METHOD OF MEASUREMENT Subsection 304.07 shall be amended to include the following: The accepted quantities for Aggregate Base Course shall be measured and paid for at the contract unit price per ton at the proper moisture. Haul and water necessary to bring mixture to optimum moisture content including compaction efforts shall not be measured and paid for separately, but shall be included in the contract unit price for Aggregate Base Course. Aggregate Base Course shall be paid at 90% of the daily total amount as determined by the daily load slips submitted to and as accepted by the Engineer at the end of each day. The intended use of Aggregate Base Course is to bring the subgrade of the concrete repair area to finished grade. The remaining 10% of the daily quantity anticipates Aggregate Base Course being used as form board reinforcement, storm water protection, or for other incidental items. If excessive waste above 10% becomes apparent, the quantity shall be adjusted and deducted from the total daily quantity as determined by the Engineer. Aggregate Base Course contaminated from failure to protect open excavations shall not be paid. Borrow or Aggregate Base Course that is placed as a result of excavation of unsuitable subgrade shall be paid for at the unit price for Borrow under Revision of Section 203, Excavation and Embankment. BASIS OF PAYMENT Project Specifications - Page 21 of 48 REVISION OF SECTION 304 AGGREGATE BASE COURSE Subsection 304.08 shall be amended to include the following: Payment shall be made under: Pay Item Unit 304.01 Aggregate Base Course Ton The above prices and payments shall include full compensation for furnishing all labor, materials, tools, equipment, and incidentals, and for doing all work involved in the placement of Aggregate Base Course including haul and water, stockpiling, placing material, watering or drying soil, compaction, proof rolling, finish grading, complete -in -place, and disposal of unusable materials as shown on the plans, as specified in these specifications, and as directed by the Engineer. END OF SECTION Project Specifications - Page 22 of 48 REVISION OF SECTION 403 HOT MIX ASPHALT - PATCHING Section 403 of the Standard Specifications is hereby revised as follows: DESCRIPTION Subsection 403.01 shall be amended to include the following: This work shall consist of the placement of hot mix asphalt as a temporary repair to provide vehicle or pedestrian access, until such time as the permanent repair can be made. CONSTRUCTION REQUIREMENTS Subsection 403.03 shall be amended to include the following: In all concrete repair locations, the Contractor shall remove no more than six (6) inches in width of asphalt pavement. The pavement areas shall be temporarily patched with Hot Mix Asphalt grading `S', `SX', or as approved by the Engineer. Temporary asphalt patching shall be placed at the typical depth of two (2) inches. The depth of patching may be increased to a maximum depth of six (6) inches as directed by the Engineer. Prior to installation of two (2) inches of temporary asphalt patching the Contractor shall use a bond breaking material (Le., curing compound, form oil, etc), as approved by the Engineer. The bond breaking material shall be applied to the face of the new concrete adjacent to the temporarypatch installation. Temporary asphalt depths greater than two (2) inches shall have a paper bond breaking material or other bond breaking method approved by the Engineer to mitigate damage to the new concrete during permanent patching. METHOD OF MEASUREMENT Subsection 403.04 shall be amended to include the following: The accepted quantities for Temporary Patching will be measured and paid for at the contract unit price per ton. Pavement cutting, excavation, subgrade preparation, haul, disposal, bond breaking material, installation, and bituminous material will not be measured or paid for separately, but shall be included in the contract unit price for Temporary Patching. Load slips shall be consecutively numbered for each day and shall include the batch time, asphalt grading, and weight of asphalt. BASIS OF PAYMENT Subsection 403.05 shall be amended to include the following: Payment shall be made under: Pay Item Unit 403.01 Temporary Patching Ton The above prices and payments shall include full compensation for furnishing all labor, materials, tools, equipment, and incidentals and for doing all the work involved in Temporary Patching, including pavement cutting, excavation, haul, disposal, surface preparation, and bituminous materials, complete -in -place, as shown on these plans, as specified in these specifications, and as directed by the Engineer. END OF SECTION Project Specifications - Page 23 of 48 REVISION OF SECTION 601 FINISHING HARDENED CONCRETE SURFACES Section 601 of the Standard Specification is hereby revised as follows DESCRIPTION Subsection 601.14 shall be amended to include the following: This work shall consist of preparing, rolling, spraying retarder, and exposing the sanded concrete surface sand including all materials, labor, tools and incidentals to obtain an exposed sand finish. The unit cost shall include the additional work and materials only for exposing the sand finish and shall be paid in addition to the unit cost for the item installed (i.e., Flatwork 4", Flatwork 6", etc.). MATERIALS Concrete shall meet the requirements specified in Revision of Section 608 and 609 contained herein. Material deviations from Revision of Section 608 and 609 shall be submitted and approved by the Engineer. CHI 027 Surface Treatment or approved equivalent shall be applied to the concrete surface to create the texture. The Engineer shall specify the depth of penetration of the retarder. Slabs may be sealed in accordance with the manufacture's recommendations. CONSTRUCTION REQUIREMENTS The Contractor shall have a minimum of five (5) years' experience exposing the sand finish for cast -in -place concrete. The Contractor shall submit a list of prior installation locations for review and evaluation for quality and installation expertise to the Engineer. The Contractor shall submit samples showing finish, color, and sealer including a color chart, product data, and equipment data. The slab thickness, jointing, reinforcement (if any), and expansion joint locations shall be approved by the Engineer. The Contractor shall place one (1) on -site test section determined by the Engineer to determine surface consistency. All concrete work shall be performed by a skilled Craftsman with a minimum of two (2) years' experience in exposing the sand finish. A minimum of one qualified Craftsman is required at each finishing operation requiring exposed sand finish. The subgrade shall be prepared and forms installed as specified herein. After concrete placement, the Contractor shall screed the concrete to the finished grade. Exposed sand finish surfaces shall be prepared using a double drum roller tamp prior to floating. The roller shall provide uniformity during rolling including the surface areas in the comers of the slab. Deviations from this process must be approved 48 hours prior to scheduled placement of fresh concrete. The retarder shall be applied per the manufacturer's recommendations using an approved sprayer to achieve a uniform and consistent application rate. Area(s) adjacent to the new installation shall be protected from damage as required by the Engineer. At the appropriate time, the concrete paste shall be washed from the surface with a power washer or other means as approved by the Engineer. The overall texture shall be free from texture deficiencies such as deep or shallow surface inconsistencies. Care shall be taken to contain the cement paste when washed from the concrete surface. Wattles or containment pits shall be required to ensure that no residue runs through the gutter or enters inlets. The method of containment shall be approved by the Engineer. The paste residue shall be removed from the site and properly disposed. After the initial curing period the surface of the slab shall be sealed. Project Specifications - Page 24 of 48 REVISION OF SECTION 601 FINISHING HARDENED CONCRETE SURFACES METHOD OF MEASURMENT Subsection 601.09 shall be amended to include the following: Concrete placement shall be in accordance with Revision of Section 608 and 609. Concrete materials, placement, forming, subgrade preparation, including equipment, tools, and labor to install concrete shall not be included under "Exposed Sand Finish — Up Charge" and shall be paid at the contract unit price for the corresponding type of installation (i.e., Flatwork 411, Flatwork 611, etc.) "Exposed Sand Finish — Up Charge" shall be measured and paid by the square foot at the contract unit price for the accepted quantities and shall include labor, materials, and equipment for retarder application, tamp rolling, exposing the sand finish, storm water protection, and cleanup. BASIS OF PAYMENT Subsection 601.20 shall be amended to include the following: Payment will be made under: Pay Item Unit 601.01 Exposed Sand Finish — Up Charge Square Foot The above prices and payments shall include full compensation for furnishing all labor, materials, tools, equipment, and incidentals and for doing all additional work involved in "Exposed Sand Finish — Up Charge" as specified in these specifications, as shown on the plans, and as directed by the Engineer. END OF SECTION Project Specifications - Page 25 of 48 REVISION OF SECTION 604 INLETS AND CULVERTS Section 604 of the Standard Specifications is hereby revised as follows: DESCRIPTION Subsection 604.01 shall be amended to include the following: This work shall consist of the installation of, or removal and replacement of inlets, inlet decks, and sidewalk culverts in accordance with these specifications, and in reasonably close conformity with the lines and grades shown on the plans or established by the Engineer. CONSTRUCTION REQUIREMENTS Subsection 604.01 to 604.05 shall be amended to include the following: Type R Inlets shall be installed per CDOT M&S Standards, latest revision, standard plan number MS-604-12. All reinforcing steel encountered during removal shall be replaced with new steel of the grade and size as shown on the details found herein and shall not be measured and paid for separately. Expansion joint material shall be installed every 500' in long runs and between the new structure and existing concrete slabs, where called for, and around fire hydrants, poles, inlets, sidewalk culverts, mid -block ramps, radius points at intersections, and other fixed objects (i.e., slabs or curbs). Expansion joint material shall be full depth, installed vertically, and in accordance with the CDOT M&S Standards for Concrete Pavement Joints, MS-412-1. The joint shall be edged with a suitable edging tool and sealed in accordance with CDOT Section 412.18, sealing joints. METHOD OF MEASUREMENT Subsection 604.01 to 604.05 shall be amended to include the following: Items defined with "Remove & Replace" or "Reconstruct", for each inlet type, shall be measured and paid per each under the corresponding type of inlet, shall include two, three and one half foot (3.5) transitions measured from inside face of box on each side, and shall include salvaged hardware material (i.e., bonnet, frame, grate, etc.). "Material Only" items for the corresponding structures shall not be paid in addition to items designated "Remove & Replace" unless the materials cannot be salvaged and the Contractor has been directed to use new materials by the Engineer. Care shall be taken during removals to salvage hardware material to the maximum extent feasible (i.e., frames, grates, adjustable bonnets, angle iron faces, steel rods, etc.). Salvable material shall be reinstalled in the structure or remain the property of the City of Fort Collins and shall be stockpiled by the Contractor at specified locations within the project limits. The Contractor shall safeguard salvable materials and shall be responsible for the expense of repairing or replacing damaged or missing material until it is re -incorporated into the work or is loaded onto City equipment by the Contractor. When concrete is to be removed and replaced around an existing grate without disturbing the deck or basin, this shall not constitute "Reconstruct Inlet Deck". These locations shall be measured and paid for separately under the items described in Revision of Sections 608 and 609. Subsection 604.06 and 604.08 shall be amended to include the following: Items defined with "Remove & Replace" or "Reconstruct", for each inlet type, shall be measured and paid per each under the corresponding type of inlet, shall include salvaged hardware material (i.e., bonnet, frame, grate, etc.). "Material Only" items for the corresponding structures shall not be paid in addition to items designated "Remove & Replace" unless the materials cannot be salvaged and the Contractor has been directed to use new materials by the Engineer. Items defined with "Reconstruct", for each inlet type shall be measured and paid per each under the Project Specifications - Page 26 of 48 REVISION OF SECTION 604 INLETS AND CULVERTS corresponding type of inlet, shall include salvaged hardware material (i.e., bonnet, frame, grate, etc.) Care shall be taken during removals to salvage hardware material to the maximum extent feasible (i.e., frames, grates, adjustable bonnets, angle iron faces, steel rods, etc.). Salvable material shall be reinstalled in the structure or remain the property of the City of Fort Collins and shall be stockpiled by the Contractor at specified locations within the project limits. The Contractor shall safeguard salvable materials and shall be responsible for the expense of repairing or replacing damaged or missing material until it is re -incorporated into the work or is loaded onto City equipment by the Contractor Subsection 604.11 and 640.16 shall be amended to include the following: Items defined with "Remove & Replace", for each inlet type and concrete sidewalk culvert, shall be measured and paid per each under the corresponding type of inlet, shall include two, three and one half foot (3.5) transitions measured from inside face of box on each side, and shall include salvaged hardware material (i.e., bonnet, frame, grate, etc.). "Material Only" items for the corresponding structures shall not be paid in addition to items designated "Remove & Replace': Items defined with "Reconstruct", for each inlet type shall be measured and paid per each under the corresponding type of inlet, shall include two three and one half foot (3.5) transitions measured from inside of face of box on each side, and shall include salvaged hardware material (i.e., bonnet, frame, grate, etc.) Care shall be taken during removals to salvage hardware material to the maximum extent feasible (i.e., frames, grates, adjustable bonnets, angle iron faces, steel rods, etc.). Salvable material shall be reinstalled in the structure or remain the property of the City of Fort Collins and shall be stockpiled by the Contractor at specified locations within the project limits. The Contractor shall safeguard salvable materials and shall be responsible for the expense of repairing or replacing damaged or missing material until it is re -incorporated into the work or is loaded onto City equipment by the Contractor. When only the throat (gutter area only, excluding the hood/deck) of the inlet is marked for repair, the installation shall be measured and paid by the square foot under Revision of Section 608 and 609, "Crosspan 8" — Remove & Replace". "Material Only" items shall be paid per each only when existing material for the structure cannot be salvaged, does not meet current specifications, cannot be provided by the City, or as requested by the Engineer. "Material Only" shall be paid in addition to the "Reconstruct Inlet Deck" or "Metal Sidewalk Culvert - Salvaged Material" items for the corresponding structure as directed by the Engineer. "Material Only" shall not be paid when damage to the existing hardware material was due to construction operations or carelessness during removal and shall be replaced by the Contractor at the Contractors expense. The Contractor shall notify the Engineer immediately when issues prevent salvage of the existing material. "Metal Sidewalk Culvert - Salvaged Material" shall be measured and paid per each and shall include reinstallation of salvaged hardware material (i.e., frame, grate, etc.). The Contractor shall provide new brass or galvanized screws for the plate reinstallation. "Metal Sidewalk Culvert — Salvaged Material" shall be constructed per the standard details contained herein for Attached Vertical and Drive -Over Curb and Gutter (details D-10, D-11) with the following modifications: Concrete for the floor beneath the metal plate shall be three (3) feet wide centered beneath the plate. The subgrade beneath the concrete floor shall be compacted, firm, and non -yielding and have a transition slope length of one (1) foot beyond the floor on each side (see details D -10 and D-11, sections B-B) and shall be sloped to match the bottom of the grade for the adjacent or proposed concrete sidewalk. Expansion material shall be installed full depth and set vertically at the top of the subgrade slope on each side of the chase. The typical structure length, measured parallel with the sidewalk, shall be five (5) feet with fifteen (15) inches on each side from the edge of the plate to the expansion material. `Metal Sidewalk Culvert' shall not include adjacent sidewalk beyond the five (5) feet structure dimension." Project Specifications - Page 27 of 48 REVISION OF SECTION 604 INLETS AND CULVERTS The installation of the plate shall typically be aligned flush with the back of the existing sidewalk and shall be offset from the vertical plane of the flow line by a minimum of three (3) inches. Dimension variances of existing plates and offset from the flowline shall be field fit to match existing conditions and shall be modified as directed by the Engineer. In no case shall the plate extend flush with the vertical plane of the flow line or be less than four (4) feet when measured perpendicular to the sidewalk. Hollywood style curb and gutter, an exception to standard installations, shall be installed as directed by the Engineer and measured and paid as agreed between Contractor and Engineer utilizing existing pricing to the maximum extent possible. "Metal Sidewalk Culvert — Material Only" shall be measured and paid per each based on 11.25 square feet (standard plate size) and shall be paid only when existing material cannot be salvaged, does not meet criteria, cannot be provided by the City, or as requested by the Engineer. "Material Only" shall be paid in addition to the "Metal Sidewalk Culvert - Salvaged Plate". The standard dimensions shall be two feet six inches (2.5' measured parallel with sidewalk) by four feet six inches (4.5' measured perpendicular to sidewalk), or 11.25 square feet. Actual dimensions may vary and shall be verified. "Metal Sidewalk Culvert - Additional 5/8" Plate" shall be measured and paid by the square foot, shall include the 5/8" thick plate and frame as designated in the drawings contained herein, and shall be the basis to increase or decrease payment when variances from the typical structure sizes are required. The cost per square foot shall be used to add or deduct from payment under "Additional Square Foot Plate". Payment shall be made in addition to "Metal Sidewalk Culvert — Material Only". "Concrete Sidewalk Culvert" shall be constructed per the standard detail contained herein (D-12) with the following modifications: The #5 bars shown in Detail D-12, section C-C, shall be extended to the end of the transitions on both sides of the culvert and shall have three (3) inches of clearance from the expansion material installed at each end of the culvert. Expansion material shall be full depth and set vertically on each side of the culvert. When only the throat (gutter area only, excluding the hood/deck)) of an Inlet, Sidewalk Chase, or Concrete Sidewalk Culvert" is marked for repair, the installation shall be measured and paid by the square foot under Revision of Section 608 and 609, "Crosspan 8" — Remove & Replace". The thickness of the expansion material shall be one half (1/2) inch or three quarter (3/4) inch as directed by the Engineer. Expansion shall be measured and paid as "Expansion" by the lineal foot under Revision of Section 608 and 609, "Expansion". Sawcutting for items contained in this section shall be incidental to the work and shall not be measured and paid for separately. Erosion control measures used during Sawcutting are considered incidental to all sawcutting operations and shall not be measured and paid for separately. BASIS OF PAYMENT Subsection 604.07 shall be amended to include the following: Payment shall be made under: Pay Item Unit 604.01 Type R Inlet — Remove & Replace (5' Opening, 5' Max depth, CDOT) Each 604.03 Type R Inlet — Reconstruct Inlet Deck (5' Opening, CDOT) Each Project Specifications - Page 28 of 48 SECTION 00530 NOTICE TO PROCEED Description of Work: 7509 Concrete Maintenance Project Phase II — 2015 Renewal To: Northstar Concrete Inc. This notice is to advise you: That the contract covering the above described Work has been fully executed by the CONTRACTOR and the OWNER. That the required CONTRACTOR's Performance Bond and Payment Bond have been received by the OWNER. The: the OWNER has approved the said Contract Documents. Therefore, as the CONTRACTOR for the above described Work, you are hereby authorized and directed to proceed within () calendar days from receipt of this notice as required by the Agreement. Dated this day of 20_ The dates for Substantial Completion and Final Acceptance shall be 20_and , 20_, respectively. City of Fort Collins OWNER : Title: ACKNOWLEDGMENT OF NOTICE Receipt of the above Notice to Proceed is hereby acknowledged this _day of 20 CONTRACTOR: Northstar Concrete Inc. Title: REVISION OF SECTION 604 INLETS AND CULVERTS 604.05 Type R Inlet — Material Only (CDOT) Each 604.06A Area Inlet - Remove & Replace (5' Max depth) Detail D-9A Each 604.08A Area Inlet - Reconstruct Inlet Deck (4' Opening) Detail D-9A Each 604.10A Area Inlet - Material Only, Detail D-9A Each 604.11 Catch Basin - Remove & Replace (5'max depth, D-1313) Each 604.13 Catch Basin - Reconstruct Inlet Deck (D-13B) Each 604.15 Catch Basin - Material Only (D-13B) Each 604.16 Modified Type 13 Curb Inlet - Remove & Replace (5' Max Depth, D-13A) Each 604.18 Modified Type 13 Curb Inlet - Reconstruct Inlet Deck (D-13A) Each 604.20 Modified Type 13 Curb Inlet - Material Only (D-I3A) Each 604.21 Concrete Sidewalk Culvert - Remove & Replace (D-12, D-13) Each 604.22 Metal Sidewalk Culvert - Salvaged Material (D-10, D-11) Each 604.23 Metal Sidewalk Culvert - Material Only (D-10, D-I 1) Each 604.24 Metal Sidewalk Culvert - Additional 5/8" Plate (D-10, D-I 1) Square Foot The above prices and payments shall include full compensation for furnishing all labor, materials, tools, equipment, and incidentals and for doing all work involved in Inlets and Culverts, including demolition, disposal, reinforcement, and materials, complete -in -place, as specified in these specifications, as shown on the plans, and as directed by the Engineer. END OF SECTION Project Specifications - Page 29 of 48 REVISION OF SECTION 608 AND 609 SIDEWALKS, CURB AND GUTTER, DRIVE APPROACHES, APRONS, CROSSPANS, PEDESTRIAN ACCESS RAMPS, FLATWORK, AND CONCRETE PAVEMENT Sections 608 and 609 of the Standard Specifications are to be deleted and replaced with the latest revision of the Larimer County Urban Area Street Standards, except as noted herein: DESCRIPTION This work consists of the construction of concrete sidewalks, curb and gutter, drive approaches, aprons, crosspans, pedestrian access ramps, and concrete pavement in accordance with these specifications and in conformity with the lines and grades shown on the plans or established by the Engineer. MATERIALS The mix designs for all types of concrete to be utilized shall be determined by the Contractor, submitted to the Engineer two weeks prior to beginning work, and approved a minimum of one week prior to the beginning of construction. Cement used shall conform to the Standard Specification for Portland Cement, ASTM C 150-85, AASHTO M85, Type I, Type 1/II, or Type III. The air content shall be four (4) percent to seven (7) percent "High Early" concrete shall be used for all concrete repair locations. "High Early" concrete shall have a specified compressive strength of 4000 psi and a minimum 48 hour compressive strength of 3000 psi. The concrete shall have a maximum water/cement ratio of 0.45. The type of concrete placed at a particular location may be modified by the Engineer but shall not have less than the minimum required compressive strength specified herein and shall be approved by the Engineer. See Section 10.5.2 `Rigid Pavement Design' and Section 22.5.6 `Portland Cement Concrete Pavement', in the "Larimer County Urban Area Street Standards for Street Construction". Water Reducing Agents shall conform to ASTM C 494-82. Accelerating Agents shall conform to ASTM C 494-82. Calcium Chloride shall not be utilized as an accelerating agent. The Contractor shall famish a load slip containing the information required by AASHTO M157, Section 13, Subsection 13.1 and 13.2, with each batch of concrete. In addition, the type of concrete (mix code) shall be shown on each load slip and a copy of the batch weights shall accompany each concrete ticket. Concrete delivered without a load slip containing complete information as specified will be subject to rejection. Curing materials shall be white pigmented liquid linseed oil based or paraffin based curing compound, and shall conform to ASTM Specification C 309-81 Type II, Class B. The application rate for curing compound shall be 150 sq. ft./gal. The curing compound shall be applied immediately upon completion of the finishing in a uniform pattern resulting in complete coverage of the area. Curing compound shall also be sprayed on the concrete surfaces after removal of the forms (back of curb and toe face of gutter). CONSTRUCTION REQUIREMENTS "Remove and Haul Fillet" shall be defined as concrete or asphalt installed in the flow line of the gutter and shall be paid per each. Care shall be taken during removal of fillets to protect the existing concrete sidewalk and gutter from damage. Any damage to the existing concrete shall be repaired or replaced at the Contractors expense. Monolithic hybrids of curb, gutter, sidewalk and highback vertical curb and gutter will be replaced using the same configuration as it was originally installed, unless a flaw in its engineering should become apparent. In these cases the design may be modified by the Engineer. The finished exposed surface and edging of the concrete shall have a broomed finish. Smooth surfaces around the perimeter of the adjoining concrete shall not be matched unless directed by the Engineer. Project Specifications - Page 30 of 48 REVISION OF SECTIONS 608 AND 609 SIDEWALKS, CURB AND GUTTER, DRIVE APPROACHES, APRONS, CROSSPANS, PEDESTRIAN ACCESS RAMPS, FLATWORK, AND CONCRETE PAVEMENT All newly installed concrete shall be date stamped by the Contractor. If the installation is larger than one concrete section, only one stamp per area of installation shall be required. The stamp shall include the Contractor's name and year of installation. The concrete shall be stamped at the appropriate curing time so the Contractor's name and year of installation are clearly legible. Typically, the stamp shall be installed at the back edge of the sidewalk, on the right hand side when viewing the installation from the street, or as directed by the Engineer. The maximum spacing for transverse joints in crosspans, concrete pavement, and sidewalk shall be ten (10) feet or as directed by the Engineer. All concrete control joints shall be tooled to one quarter (1/4) of the concrete thickness or as directed by the Engineer. All construction joints for crosspans and/or aprons adjacent to new or existing concrete shall be constructed in accordance with the detail for "Concrete Construction Joints" contained herein. This item will not be measured or paid for separately under the terms of this contract. Forms shall be installed at the full depth of the concrete placement. The Contractor shall be responsible for the protection of the subgrade and/or base course until the concrete is placed. The Contractor shall protect the concrete against moisture loss, rapid temperature change, rain, flowing water, mechanical injury, pedestrian and vehicular traffic, and Contractor's equipment for a minimum of 36 hours after the placement of curing compound for 48 hour high early concrete. Asphalt patching against fresh concrete shall not be permitted during the time frames for protection of the concrete. The Contractor shall not sprinkle water on the surface of the newly placed concrete to assist with finishing. The use of a finishing aide may be approved on a limited case by case basis only when the material to be used has been submitted to the Engineer for approval prior to use in the field. Concrete blankets shall be used when the ambient temperature is expected to fall to 32°F or below within 36 hours after placement and shall remain in place for a minimum period of 36 hours for 48 hour high early concrete. This item will not be measured or paid for separately under the terms of the contract. The debris immediately adjacent to a concrete repair location shall be completely cleaned up on the work day following the placement of the concrete. If required, the concrete shall be protected as stated above. Any damage caused during the cleanup process shall be the Contractor's responsibility. In locations where concrete pavement is replaced, the new pavement shall have a minimum thickness of eight (8) inches. Existing pavement shall be saw cut to obtain a straight and neat edge for paving and shall be deep enough to cut through the entire pavement thickness. The subgrade plane shall not vary more than one half (1/2) inch in ten (10) feet. All concrete pavement joints shall be sealed with an asphalt filler compound, or approved equal, in accordance with the detail for "Concrete Pavement Joints" contained herein or as directed by the Engineer. The cost for joint sealing shall be included in the contract unit price for "Concrete Pavement 8"- Remove & Replace." The top of the new pavement shall be even with the existing concrete pavement and the newly installed concrete shall be consolidated with a mechanical vibrator. All construction joints shall be doweled except for expansion joints, joints along existing curb and gutter, and contraction joints, in accordance with the detail for "Concrete Pavement Joints" contained herein. In addition, dowels shall be 16" smooth epoxy coated #5 bars. The dowels shall be eighteen (18) inches in length. The drilled holes shall be eight (8) inches deep and spaced at twelve (12) inches on center. The holes may be drilled so the rebar fits snuggly or installed using a concrete adhesive. Dowel bars for adjacent panels shall be coated entirely with a bond breaking material approved by the Engineer. When a batch of concrete delivered to the site does not conform to the minimum specified air content, an air entraining admixture shall not be allowed to be added on site. Project Specifications - Page 31 of 48 REVISION OF SECTIONS 608 AND 609 SIDEWALKS, CURB AND GUTTER, DRIVE APPROACHES, APRONS, CROSSPANS, PEDESTRIAN ACCESS RAMPS, FLATWORK, AND CONCRETE PAVEMENT Restoration of landscape shall be in accordance with Revision of Section 107, "Safety and Protection and Restoration of Property and Landscape" found herein. The time frame for restoration shall be within two (2) working days from the time the concrete was placed for backfrll with topsoil and by no later than the end of the first working day of the following week for sod replacement. Concrete washout/truck washout areas shall be contained in such a manner that no visual evidence of cement or aggregate spoils remain on the site. In addition, direct washout to curb and gutter flow lines or inlet structures is prohibited. Washout may be accomplished by use of an identified off -site location or a designated spoillbase pile (see Section 208 Erosion Control and Inlet Protection), and shall include the placement of a Stormwater Protection Device on the downstream side of the washout area. Methods shall be submitted and approved by the Engineer. Flagstone sidewalk, brick pavers and trolley roadbed bricks shall be salvaged to the maximum extent feasible. All flagstones, pavers, and bricks shall become the property of the City of Fort Collins. Flagstones shall be hauled by the Contractor and delivered to the City's site located at 1500 Hoffman Mill Road. Loading, unloading, and hauling shall not be measured and paid for separately but shall be included in "Remove Concrete". In areas where the Engineer directs the re -setting of flagstone, the existing flagstone shall be salvaged and reset on a compacted base. The elevation of the flagstone shall match as closely as possible the surface treatment of the surrounding area. METHOD OF MEASUREMENT Sawcutting related to the items in this section shall be considered a subsidiary obligation of the Contractor, and shall not be measured or paid for separately. Erosion control measures used during sawcutting shall be considered incidental and shall not be measured or paid for separately. "Remove Concrete" shall include removal and disposal or salvage of existing asphalt, concrete, or flagstone. This item shall be paid where the Engineer directs removal only, and removal is not already being paid under another item. "Apron 8" shall be paid by the square foot and, when installed on a radius, shall include the area from the back of the curb to the apron legs and from point of curvature to point of curvature. The area of an Apron shall be calculated as follows (see diagram below): Project Specifications - Page 32 of 48 REVISION OF SECTIONS 608 AND 609 SIDEWALKS, CURB AND GUTTER, DRIVE APPROACHES, APRONS, CROSSPANS, PEDESTRIAN ACCESS RAMPS, FLATWORK, AND CONCRETE PAVEMENT 10 A ((A*C) - (Tr (A-B) (C-D)/4)) C Is "Barrier Curb 12" shall be paid by the lineal foot and shall be modified from drawing 703 as follows Two #4 deformed bars shall be doweled horizontally into the adjacent curb. #4 bars shall run continuously and be installed at four (4) inches on center, measured from the top of the curb. Curb reveal shall typically be six (6) inches measured from top of curb or as directed by the Engineer. "Pedestrian Access Ramp" shall be measured by the square foot and shall include the area between the back of the curb and both points of curvature, if on the radius, or the top of transition if mid -block. "Pedestrian Access Ramp Highback Curb" shall be measured by the square foot. The length shall be measured from the back of the curb to the top of the transition at the back of the ramp, and the width shall be measured at the midpoint. All Pedestrian Access Ramps shall be placed in accordance with the details contained herein. Ramp items shall include all labor, materials (except truncated domes), equipment and incidentals, saw -cutting, removal, haul, and disposal, and for doing all work involved in removal and replacement of pedestrian access ramps. "Truncated Dome Panels" shall be paid by the square foot, placed in all pedestrian access ramps, and shall be paid in addition to "Pedestrian Access Ramp" or "Pedestrian Access Ramp Highback Curb". This item shall include all labor, materials, and surface preparation to supply and place the panels at pedestrian access ramps. Truncated dome panels shall be cast iron, and shall meet all American with Disabilities Act (ADA) requirements. The type of truncated dome panels to be used shall be submitted to the Engineer for approval prior to installation. Dome panels shall be placed at the same time as the initial ramp placement. There shall be no voids beneath the bottom of the dome panels and the concrete. "Colored Concrete San Diego Buff — Upcharge" shall include the additional cost for the color additive only and shall be measured and paid by the square foot in addition to the corresponding item installed (i.e., Flatwork 6", Splashblock 4"). "Alley Approach 8" shall be measured by the square foot from the lip of the gutter (if the gutter has been removed) to the back of the sidewalk and the width shall be measured at the midpoint. "Expansion" shall be measured and paid by the lineal foot. The thickness shall be one half (1/2) inch or three quarter (3/4) inch minimum, depending on the installation location, and be installed every 500' in long runs and Project Specifications - Page 33 of 48 REVISION OF SECTIONS 608 AND 609 SIDEWALKS, CURB AND GUTTER, DRIVE APPROACHES, APRONS, CROSSPANS, PEDESTRIAN ACCESS RAMPS, FLATWORK, AND CONCRETE PAVEMENT between new structure slabs, existing concrete slabs, and around fire hydrants, poles, inlets, sidewalk under - drains, mid -block ramps, radius points at intersections, and other fixed objects (i.e. ends of sidewalk slabs and curbs), as directed by the Engineer. Expansion joint material shall be full depth, set vertically, and installed in accordance with the CDOT M&S Standards for Concrete Pavement Joints. The joint shall be edged with a suitable edging tool. "Exposed Aggregate — Up Charge" shall include only the additional cost for exposing the aggregate including labor, water, other incidentals, and clean up related to exposing the surface aggregate and shall be measured and paid by the square foot in addition to the corresponding item installed. (i.e., Flatwork 6", Splashblock 4"). "Reset Flagstone" shall be measured and paid by the square foot of re -set area in addition to "Remove Concrete". Material for leveling, moisture conditioning, and labor for installation and compaction shall not be paid separately. "Haul & Dispose Concrete with Wire/Rebar" shall be paid for separately by the ton only when the Hoffman Mill site does not accept concrete containing wire and/or rebar. Weight slips shall be required for each load transported to any locations other than Hoffman Mill. "Exposed Sand Finish — Up Charge" shall be measured and paid by the square foot for the accepted quantities and shall include retarder material and application, tamp rolling, and exposing the sand finish, including retarding, sealer, equipment, labor, storm water protection, and cleanup. "Asphalt Pavement Preservation" shall be measured and paid by the lineal foot along concrete gutter, drainage pans and aprons that were replaced with the project. The Engineer shall assess the asphalt condition and determine the required removal. This item shall only be paid when the concrete removal can be accomplished without damage requiring permanent patching to the existing asphalt along the concrete toe base on the Engineers judgment. This item is provided as incentive to preserve the existing asphalt and provide compensation for additional costs that may be associated with the removal and restoration of the landscaping. Pay items followed by "Remove & Replace" shall include all labor, materials, tools, equipment, and incidentals, and all work involved in the removal and installation, complete -in -place, including sawcutting, hauling, disposal, etc. BASIS OF PAYMENT Subsection 608.06 shall be amended to include the following: Payment shall be made under: Pay Item Unit 608.01 Remove Concrete Square Foot 608.02 Remove and Haul Fillet Each 608.03 Apron 8" - Remove & Replace Square Foot 608.04 Crosspan 8" - Remove & Replace Square Foot 608.05 Driveover Curb, Gutter, and 6" Sidewalk - Remove & Replace Lineal Foot 608.06 Driveover Curb, Gutter, No Sidewalk - Remove & Replace Lineal Foot 608.07 Vertical Curb, Gutter, and 6" Sidewalk - Remove & Replace Lineal Foot 608.08 Vertical Curb, Gutter, No Sidewalk - Remove & Replace Lineal Foot Project Specifications - Page 34 of 48 REVISION OF SECTIONS 608 AND 609 SIDEWALKS, CURB AND GUTTER, DRIVE APPROACHES, APRONS, CROSSPANS, PEDESTRIAN ACCESS RAMPS, FLATWORK, AND CONCRETE PAVEMENT 608.09 Vertical Outfall Curb, Gutter - Remove & Replace Lineal Foot 608.10 Barrier Curb 12" — Remove & Replace Lineal Foot 608.11 Hollywood Curb, Gutter, and 6" Sidewalk - Remove & Replace Lineal Foot 608.12 Hollywood Curb, Gutter, No Sidewalk - Remove & Replace Lineal Foot 608.13 Highback Curb, Gutter, No Sidewalk - Remove & Replace Lineal Foot 608.14 Pedestrian Access Ramp - Remove & Replace Square Foot 608.15 Pedestrian Access Ramp Highback Curb — Remove & Replace Square Foot 608.16 Truncated Dome Panel Square Foot 608.17 Flatwork 4" - Remove & Replace Square Foot 608.18 Flatwork 6" - Remove & Replace Square Foot 608.19 Replace Flatwork— 1" Additional Depth Square Foot 608.20 Colored Concrete 4" San Diego Buff — Up Charge Square Foot 608.21 4' Valley Pan 6" — Remove & Replace Square Foot 608.22 Concrete Pavement 8" - Remove & Replace Square Foot 608.23 Alley Approach 8" - Remove & Replace Square Foot 608.24 Expansion Lineal Foot 608.25 Splashblock 4" — Remove & Replace Square Foot 608.26 Exposed Aggregate 4" — Up Charge Square Foot 608.27 Reset Flagstone Square Foot 608.28 Haul & Dispose Concrete with Wire/Rebar Ton 608.29 Asphalt Pavement Preservation Lineal Foot The above prices and payments shall include full compensation for tarnishing all labor, materials, tools, equipment, and incidentals, and for doing all work involved in Sidewalks, Curb and Gutter, Drive Approaches, Aprons, Crosspans, Pedestrian Access Ramps, Flatwork, and Concrete Pavement including sawcutting, removal, haul and disposal, finish grading, materials, complete -in -place, as shown on the plans, as specified in these specifications, and as directed by the Engineer. END OF SECTION Project Specifications - Page 35 of 48 REVISION OF SECTION 623 IRRIGATION SYSTEM Section 623 of the Standard Specifications is herby revised as follows: DESCRIPTION Subsection 623.01 shall be amended to include the following: This work shall consist of furnishing and installing irrigation sleeves beneath the new concrete. MATERIALS Subsection 623.02 shall be revised as follows: The irrigation sleeve shall be three (3) inch diameter PVC pipe, schedule 40. REQUIREMENTS Subsection 623.14 shall be amended to include the following: The irrigation sleeve shall be installed to a minimum depth of four (4) inches below finished subgrade. Backfill over pipe shall be compacted prior to concrete placement. A survey stake shall be installed at the ends of each sleeve, marked "Irrigation Sleeve", and painted blue. The stake shall be installed at a height that will not create a pedestrian or maintenance hazard as approved by the Engineer. METHOD OF MEASUREMENT Subsection 623.32 shall be amended to include the following: "Irrigation Sleeve" shall be paid for by the lineal foot complete -in -place. BASIS OF PAYMENT Subsection 623.33 shall be amended to include the following: Payment shall be made under: Pay item Unit 623.01 Irrigation Sleeve — Three (3") inch PVC Lineal Foot The above prices and payments shall include full compensation for furnishing all labor, materials, tools, equipment, and incidentals, and for doing all the work involved in installing the three (3") inch irrigation sleeve, including excavation, installation, compaction of backfill, haul and disposal, as shown on the plans, as specified in these specifications, and as directed by the Engineer. END OF SECTION Project Specifications - Page 36 of 48 REVISION OF SECTION 627 PAVEMENT MARKINGS Section 627 of the Standard Specifications is herby revised as follows: DESCRIPTION This work shall consist of furnishing, installing, and removing temporary pavement marking in accordance with the latest revisions of the Fort Collins Traffic Operations Manual, City of Fort Collins Work Area Traffic Control Handbook, Larimer County Urban Area Street Standards (LCUASS), Colorado Department of Transportation Road and Bridge Construction , and the Manual on Uniform Traffic Control Devices for Streets and Highways (MUTCD), and in conformity to the lines, dimensions, patterns, locations, and details shown on the plans or established by the Engineer. CONSTRUCTION REQUIREMENTS Subsection 627.03 shall be amended to include the following: Permanent pavement markings shall be installed by the City of Fort Collins. Temporary pavement markings/delineation of lanes may include temporary tape, tabs, or vertical panels as required by the Engineer and shall be installed by the Contractor. PAVEMENT MARKINGS/DELINEATION OF LANES Sub -section 627.10 shall be amended to include the following: City crews shall install permanent pavement striping. Typically, City crews may also install temporary striping as directed by the Engineer. When City crews cannot install temporary striping, the Engineer may request that the Contractor install temporary striping or maintain traffic control devices until such time that the City crew can install striping. Temporary pavement markings/delineation of lanes shall be suitable for use on asphalt or Portland cement pavements, shall be installed on roadways that will be opened to traffic prior to permanent stripping by the City, and shall conform as follows: 1. The surface to which the tape is applied shall be clean, dry, and free of dirt, oils, and grease. The tape/tab/vertical panels shall be pressed down immediately after application until it adheres properly and conforms to the surface. 2. All roads shall have temporary pavement markings before they are opened to traffic unless City Crews have been scheduled to install permanent pavement markings prior to opening the road to traffic. 3 Markings applied to the final road surface shall not leave scars that conflict with permanent markings. 4. Temporary markings shall be installed in such a way that the markings adequately follow the desired alignment. 5. Temporary pavement marking tape/delineation/vertical panels shall be required for all lane lines a. Lane lines shall be "tapped" intermittently with a 2' long by 4" wide reflective temporary strip at fifty (50') foot intervals. b. Stop bars shall be "tapped" to a minimum width of 12". Stop bars shall NOT be required at signalized intersections. Contractor may be required to provide additional signage (i.e. Stop Sign Ahead, Stop Here On Red, etc.); `Stop Here On Red" signs shall be required at signalized intersections. c. It is the Contractor's responsibility to notify the Engineer prior to completion of work to allow scheduling of the permanent pavement markings to be installed by City crews. Project Specifications - Page 37 of 48 REVISION OF SECTION 627 PAVEMENT MARKINGS 6. Removable pavement markings shall be installed in accordance with the manufacture's recommendations and maintained by the Contractor until permanent pavement markings are installed by City crews. 7. Temporary edge lines are not typically required unless there is no existing gutter or required by the Engineer. 8. All tape shall be removed by the Contractor after permanent markings have been completed by the City. 9. It is the Contractor's responsibility to maintain the temporary markings, at the Contractor's expense, until the permanent pavement marking is installed by City crews. BASIS OF PAYMENT Subsection 627.13 shall be amended to include the following: All costs for installing temporary stripping shall not be measured and paid for separately including traffic control devices and related traffic control incidentals. If flagging during permanent striping is required after the Contractor has completed all daily work, it shall be paid under Revision of Section 630, "Flagging", as directed by the Engineer. END OF SECTION Project Specifications - Page 38 of 48 SECTION 00600 BONDS AND CERTIFICATES 00610 Performance Bond 00615 Payment Bond 00630 Certificate of Insurance 00635 Certificate of Substantial Completion 00640 Certificate of Final Acceptance 00650 Lien Waiver Release (CONTRACTOR) 00660 Consent of Surety 00670 Application for Exemption Certificate REVISION OF SECTION 630 CONSTRUCTION ZONE TRAFFIC CONTROL Section 630 of the Standard Specifications is hereby revised as follows: DESCRIPTION Subsection 630.01 shall be amended to include the following: This work shall consist of famishing, installing, moving, maintaining, and removing temporary construction traffic control devices, including but not limited to signs, advance warning arrow panels, variable message boards, barricades, channelizing devices, and delineators as required by the latest revisions of the City of Fort Collins "Work Area Traffic Control Handbook," the "Manual on Uniform Traffic Control Devices for Streets and Highways" (MUTCD), the Larimer County Urban Area Street Standards (LCUASS), and the Colorado Department of Transportation Road and Bridge Standard Specifications (CDOT). In the event of a conflict between the MUTCD criteria and the City's criteria, the City of Fort Collins criteria shall govern. MATERIALS Subsection 630.02 shall be amended to include the following: All traffic control devices shall meet or exceed the required minimum standards set forth in the City of Fort Collins Work Area Traffic Control Handbook and the MUTCD. Traffic control devices shall be clean and in good operating condition when delivered and shall be maintained on a daily basis. All traffic control devices shall be clearly marked and free of crossed out information or any other form of defacement that detracts from the purpose for which they are intended (i.e. crossed out information, information written in long -hand, etc.) Sign blanks with sign faces on both sides must have the back sign face covered when in use to avoid confusion to motorists and bicyclists traveling in the opposite direction and residents potentially affected by information the sign may present. CONSTRUCTION REQUIREMENTS Subsection 630.10 shall be amended to include the following: CONTRACTOR RESPONSIBILITY The Contractor shall be responsible for ensuring safe passage through the work zone for vehicles, pedestrians, and bicycles. The City of Fort Collins shall not be responsible for any loss or damage to equipment due to theft or vandalism or -for any damages to public or private property caused by the Contractor's construction activities. Private or public property which is damaged by the Contractors' installation, equipment, or employees will be the sole responsibility of the Contractor. The Contractor may be required to use Variable Message Boards to advise road users about upcoming work on Arterial and Collector streets as required by Traffic Operations through the approved traffic control plan. When required, the Engineer will issue direction for the number of boards, general locations for placement, and message verbiage. The typical quantity of Variable Message Boards shall be: Six (6) on Arterial streets, four (4) on Collector streets, none on Residential streets, but may be modified as directed by the Engineer. Variable Message Boards shall be placed a minimum of 5 working days prior to the project start date. If full closures on Arterial and Collector streets are authorized, Variable Message Boards shall remain in place until completion of the project. Lane closures on Arterial and Collector streets shall require message boards to remain in place for two days after starting work. Fully automated Variable Message Boards shall be installed and operate continuously during the afore mentioned durations on Arterial and Collector streets. Two-way traffic shall be maintained at all times unless approved by the Engineer. Lane width shall be Project specifications - Page 39 of 48 REVISION OF SECTION 630 CONSTRUCTION ZONE TRAFFIC CONTROL maintained at a minimum of ten (10) feet between traffic control devices. The Contractor will provide 24 hour minimum notice to the City of Fort Collins Traffic Department when project operations will be near a signalized intersection. TRAFFIC CONTROL PLAN - GENERAL Hand drawn plans shall NOT be accepted. Notification of residents and businesses shall be the responsibility of the Contractor, Contractor Representative, Traffic Control Supervisor or the Traffic Control Supervisor Representative and shall consist of distributing letters indicating the nature of the work to be completed, any special instructions to the residents (i.e. limits on lawn watering during concrete placement, etc.), dates and times of the work, and parking and access restrictions that will apply. Sample notifications shall be submitted to the Engineer for review prior to starting the project. Notification letters or door hangers shall include a local phone number which residents with questions may use to contact the Contractor and a link to the City of Fort Collins Street Department web site where citizens may find additional information and project updates at "www.fceov.com/streets". Only approved notifications shall be distributed a minimum of 48 hours prior to the commencement of each phase of the Work. Traffic Control Plans shall be submitted for approval prior to commencement of all work. Traffic control conditions vary significantly in the field and the Contractor is responsible for submitting traffic control plans for each work location. Minimum traffic control requirements for Arterial, Collector, and Residential streets are contained herein. Plans shall be specific to the project area showing street names, existing signing and striping conditions at intersections and the location for proposed devices. Devices temporarily not in use shall be removed from the area. Moving shall include devices removed from the project and later returned to use. Devices may be temporarily placed and/or stored in the City right-of-way in such a manner that minimizes the hazards to pedestrians, bicyclists, and vehicles, as approved by the Engineer. Traffic control devices shall be removed from the site immediately upon completion of the work for any street(s). In the event there is a safety issue, the Engineer may issue a "Stop Work Order" until the issue(s) is corrected. The Contractor shall not be entitled to any additional compensation for delays associated with the "Stop Work Order". Approved traffic control plans shall be available on site at all times for review and inspection. See Revision of Section 104. TRAFFIC CONTROL PLAN - PROJECT Traffic control plans shall be submitted for all work locations prior to commencement of any work. Plans shall be submitted along with the City of Fort Collins Traffic Approval Forms. Traffic control plans shall be prepared by a Traffic Control Supervisor certified by the American Traffic Safety Services Association (ATSSA) or a Worksite Traffic Control Supervisor certified by the Colorado Contractor's Association (CCA). Hand drawn plans shall NOT be accepted Typical Traffic Control Plans for work within the right-of-way shall be submitted for approval to the Engineer as follows: Typical submittals for scheduled residential work shall be submitted by 8:00 am. two (2) working days prior to commencement of the work. Typical submittals for residential work scheduled on Monday and Tuesday shall be submitted the previous Thursday by 8:00 a.m. Submittals for full closures on residential streets shall be submitted five (S) working days prior to the commencement of work. Project Specifications - Page 40 of 48 REVISION OF SECTION 630 CONSTRUCTION ZONE TRAFFIC CONTROL Submittals for full closures on Arterial and Collector streets shall be submitted ten (10) working days prior to the commencement of work All plans shall be delivered to the Engineer, 625 Ninth Street, Fort Collins. Facsimiles of plans shall not be accepted. No phase of the construction shall start until the Traffic Control Plan has been approved. Failure to have an approved Traffic Control Plan shall constitute cause for the City to stop work. See Revision of Sections 104 and 105. A Traffic Control Plan shall be submitted for each Arterial and each Collector street scheduled for work. Each residential area shall have one typical Traffic Control Plan submitted for the area. When changes to the Area Traffic Control Plan(s) are required, a re -submittal for the area shall be provided for approval. For required closures in a residential (i.e., closure for a crosspan repair) a separate submittal from the Area Traffic Control Plan shall be provided. The Traffic Control Plan shall include, as a minimum, the following: 1. A traffic control Approval Form submittal with each traffic control plan. The Approval Form shall be legibly written and filled out completely. 2. A detailed diagram which shows the location of all sign placements-, including advance construction signs (if not previously approved) and speed limit signs; method, length and time duration for lane closures, and location of flag persons. 3. A tabulation of all traffic control devices shown on the detailed diagram including, but not limited to: construction signs; vertical panels; vertical panels with lights; Type I, Type I1, and Type III barricades; cones; drum channelizing devices; advance warning flashing or sequencing arrow panels. Certain traffic control devices may be used for more than one operation or phase. However, all devices required for any particular phase must be detailed and tabulated for each phase. 4. Number of flaggers to be used and flagger locations. Flagger locations shall be located where approaching motorists, bicyclists, and pedestrians have sufficient distance to safely stop at the specified point. 5. Parking and access restrictions to be in effect. 6. Detailed pedestrian and bicycle movement. 7. All applicable notes (i.e., sign spacing, taper length and posted speed limit, pedestrian routes, etc.) Approval of the proposed method of handling traffic does not relieve the Contractor of liability specifically assigned under this contract. Project Specifications - Page 41 of 48 REVISION OF SECTION 630 CONSTRUCTION ZONE TRAFFIC CONTROL FIGURE 630-1 TYPICAL ARTERIAL TRAFFIC CONTROL PLAN OWNER TRAFFIC CONTROL CONTRACTOR COMPANY CANTACT NAME DATE PHONE* TCS CERT# SHEET# 2 - ROAD WORK AHEAD 2 - LEFT LANE CLOSED AHEAD 2-TRANSITION(L) 40 - 29' TRAFFIC CONES TYPICAL LEFT LANE t NOT DRAWN TO SCALE ARTERIAL STREETS - Shall include Flagging personnel required for the road classification, control of cross traffic, and as required for the Contractor's daily work activities in addition to the minimum signage required by the specifications. Flagging shall be paid separately under "Flagging". Approved Variable Message Boards shall be required for Arterial streets, shall be shown on the drawing, and shall be paid for separately under "Variable Message Board". Advance Warning Arrow Boards may be requested by the Engineer and shall be paid for separately under "Advance Warning Arrow Board". Project Specifications - Page 42 of 48 REVISION OF SECTION 630 CONSTRUCTION ZONE TRAFFIC CONTROL FIGURE 630-2 TYPICAL COLLECTOR TRAFFIC CONTROL PLAN OWNER NOT DRAWN TO SCALE DEVICE TABULATION 2- ROAD WORK AHEAD 2 - ONE LANE ROAD AHEAD 2-FLAGGER AHEAD 20 - 28" TRAFFIC CONES COLLECTOR STREETS -Shall include Flagging personnel required for the road classification, control of cross traffic, and as required for the Contractor's daily work activities in addition to the minimum signage required by the specifications. Flagging shall be paid separately under "Flagging". Approved Variable Message Boards may be required for collector streets and shall be shown on the plans and paid for separately under "Variable Message Board". Advance Warning Arrow Boards may be requested by the Engineer and shall be paid for separately under "Advance Warning Arrow Board". Project Specifications -Page 43 of 48 REVISION OF SECTION 630 CONSTRUCTION ZONE TRAFFIC CONTROL FIGURE 630-3 TYPICAL RESIDENTIAL TRAFFIC CONTROL PLAN OWNER TRAFFIC CONTROL CONTRACTOR RESIDENTIAL STREETS -Shall include Flagging personnel required for the road classification, control of cross traffic, and as required for the Contractor's daily work activities in addition to the minimum signage required by the specifications. Flagging shall be paid separately under "Flagging". Variable Message Boards are typically not required for residential streets. TRAFFIC CONTROL MANAGEMENT Subsection 630.11 shall be amended to include the following: The Contractor shall designate an individual, other than the Superintendent, to be the Traffic Control Supervisor. Traffic Control Management shall be performed by a Traffic Control Supervisor (TICS). The TCS(s) shall possess a current American Traffic Safety Services Association (ATSSA) certification as a Worksite Traffic Control Supervisor or a current Colorado Contractor's Association (CCA) certification as a Traffic Control Supervisor. Proof of certification for all personnel assigned to the project(s) shall be provided to the City Traffic Department and the Traffic Control Supervisor shall have approved traffic control plans for the work site and current copies of the City of Fort Collins' "Work Area Traffic Control Handbook", and Part VI of the MUTCD, pertaining to Project Specifications -Page 44 of 48 REVISION OF SECTION 630 CONSTRUCTION ZONE TRAFFIC CONTROL traffic control for street and highway construction, available on site at all times The TCS shall have a minimum of one year experience as a certified TCS. Qualifications shall be submitted to the Engineer for approval a minimum of five (5) working days prior to commencement of the work. The TCS shall be required to be on site at all times during construction. It is the intent of the specifications that the TCS be the same throughout the year. The TCS shall be equipped with a cellular phone Traffic Control Management shall be maintained on a 24 hour per day basis. The Contractor shall make arrangements so that the Traffic Control Supervisor or their approved representative will be available on every working day, "on call" at all times, and available upon request of the Engineer during non -working hours. A 24 hour telephone number shall be provided to the Engineer. Outside of construction hours, the response time from the Engineers' contact shall be 30 minutes or less and correction of the issue(s) shall be one (1) hour or less. If, in the opinion of the Engineer, any traffic control individual does not perform their duties at or to the minimum industry standard, the Contractor will be required to replace that individual. TCS duties shall include, but are not limited to: 1. Supervise and direct project flaggers. 2. Prepare, revise, and submit Traffic Control Plans as required. 3. Coordinate all traffic control related operations, including those of the Subcontractor and supplier. 4. Coordinate project activities with appropriate police and fire control agencies, Transfort, school districts and other affected agencies and parties prior to construction. 5. Notify residents and businesses at least 48 hours prior to construction. a. Notifications may be accomplished by a representative of the TCS such as a flagger and shall be hand typed and hand delivered to all businesses and residents. 6. Inspect traffic control devices on a calendar day basis for the duration of the project to ensure devices are functioning properly and are clean and legible. 7. Oversee all requirements covered by the plans and specifications which contribute to the convenience, safety, and orderly movement of traffic. 8. Breaking flaggers for short periods of no more than fifteen (15) minutes over a sixty (60) minute period. 9. Set up and removal of traffic control device. 10. Maintain a project traffic control diary which shall become part of the City's project records. This diary/log shall be submitted to the Engineer daily and shall include the following information as a minimum a. Date. b. The time of traffic control inspections. c. Project description and location. d. Traffic Control Supervisor's name. e. Types and quantities of traffic control devices used per approved MHT. f. List of flaggers used, including start time, stop time and number of flagging hour breaks. g. Traffic control problems (traffic accidents; damaged, missing or dirty devices, etc.) and corrective action taken. METHOD OF MEASUREMENT Subsection 630.15 shall be amended to include the following: "Traffic Control" shall be paid based on the cost of the total actual work performed during the pay period using the traffic control cost percentage in 630.01. The total cost of the work for the pay period shall be multiplied by the established percentage and shall be added to the pay application. This percentage of total work performed shall include all traffic control equipment, Traffic Control Supervisor (TCS), and all other incidentals to the work excluding Variable Message Boards (VMB), Flaggers, and Advanced Warning Arrow Boards; these items will be paid for separately. Project Specifications - Page 45 of 48 REVISION OF SECTION 630 CONSTRUCTION ZONE TRAFFIC CONTROL Items such as traffic control submittals, sand bags, sign stands, fencing, lighting, electricity, fuel, and caution tape shall not be measured and paid for separately and shall be considered a subsidiary obligation in conjunction with traffic control items. Business signs, Neighborhood Traffic Only signs and Detour Placard street names are not considered Specialty Signs and shall not be measured or paid for separately but shall be included in the percentage cost for the month. "Variable Message Board" shall be measured and paid per each per day in addition to the monthly percentage. "Flagging" shall be measured and paid per hour in addition to the monthly percentage and shall be provided based on the Contractors daily work activities, number/location of intersections, or as directed by the Engineer, and shall include all related equipment and incidentals (i.e., Stop/Slow paddles, communication devices if required, personal protective equipment). Hours of non -flagging work in excess of those authorized shall not be measured and paid for separately but shall be at the Contractor's expense including personnel break times, and stand by time. Flaggers shall be provided with hand signs such as Stop/Slow paddles and electronic communication devices when required and follow the current MUTCD standards. Flagger equipment and devices shall not be measured and paid for separately. "Advance Warning Arrow Board" shall be paid per each per day in addition to the monthly percentage. All costs associated with Traffic Control Plan review shall not be measured or paid for separately, but shall be considered incidental to the Work including re -submittal fees. The City may deduct from compensation due the Contractor $10.00 per day for each traffic control device not removed from the site immediately upon completion of the work or as directed by the Engineer. The Contractor may provide larger construction traffic signs than those typically used in accordance with the City of Fort Collins Work Area Traffic Control Handbook and the MUTCD as approved by the Engineer, however, no payment shall be made for the additional panel size. The City of Fort Collins "Standard Master Street Plan Map" depicting the street classifications (Arterial, Collector, and Residential) can be found at the following link: httn://citydocs fc2ov.com/?dt=Master+Street+Plan+Man&dn=GIS+MAPS&vid=192&cmd=showdt Line Items 630.60 to 630.67 shall be utilized when the total cost of the areas work (less the traffic control) is within the range of cost specified by the correlating line item. For example, the project engineer adds a project area for the contractor to complete and that area is on an arterial roadway. Upon completion, the areas total repair costs add up to a total of $4500. In this case, line item 630.61 would be applied to the pay application. Project Specifications - Page 46 of 48 REVISION OF SECTION 630 CONSTRUCTION ZONE TRAFFIC CONTROL BASIS OF PAYMENT Subsection 630.16 shall be amended to include the following: Payment shall be made under: Pay Item Unit 630.20 Traffic Control Percentage 630.30 Variable Message Board Per Each/Per Day 630.40 Flagging Hour 630.50 Advance Warning Arrow Board Per Each/Per Day 630.60 ART -Small Area Up -Charge $0 to $1000 Lump sum/area 630.61 ART - Small Area Up -Charge $1001 to $5000 Lump sum/area 630.62 ART - Small Area up -Charge $5001 to $10000 Lump sum/area 630.63 ART - Small Area Up -Charge $10001415000 Lump sum/area 630.64 RES/COL -Small Area Up -Charge $0 to $1000 Lump sum/area 630.65 RES/COL - Small Area Up -Charge $1001 to $5000 Lump sum/area 630.66 RES/COL - Small Area up -Charge $5001 to $10000 Lump sum/area 630.67 RES/COL - Small Area Up -Charge $10001415000 Lump sum/area The above prices and payments shall include full compensation for furnishing all labor, materials, tools, equipment, and incidentals, and for doing all the work involved in setup/removal/modification, notifications and delivery for Construction Zone Traffic Control as directed by the Engineer. Project Specifications - Page 47 of 48 REVISION OF SECTION 630 CONSTRUCTION ZONE TRAFFIC CONTROL SPECIAL CONDITIONS FOR WORK ON ARTERIALS AND COLLECTORS NOTE: CROSS STREET TRAFFIC SHALL BE MAINTAINED AT ALL TIMES UNLESS AUTHORIZED BY THE ENGINEER IN WRITING. NOTE: FULL CLOSURES ON ARTERIAL AND COLLECTOR STREETS SHALL BE ALLOWED UNDER EXTREME CIRCUMSTANCES AND ONLY UPON APPROVAL OF THE ENGINEER. PLANS SHALL BE APPROVED A MINIMUM OF TWO (2) WEEKS PRIOR TO THE COMMENCEMENT OF WORK AND/OR THE TIME REQUIRED TO ADEQUATELY NOTIFY THE PUBLIC THROUGH THE MEDIA. NOTE: CONSTRUCTION OR REPAIR WORK WILL NOT BE PERMITTED AT OR IN THE VICINITY OF A SIGNALIZED INTERSECTION OR ANY ARTERIAL AND COLLECTOR STREETS THAT HAVE MAJOR TRAFFIC VOLUMES BETWEEN THE HOURS OF 7:00 A.M. TO 8:30 A.M OR 3:30 P.M TO 6:30 P.M. (EXCEPT IN THE CASE OF AN EMERGENCY). EXCEPTIONS MAY BE MADE FOR CONSTRUCTION OR REPAIR WORK ON ARTERIAL AND COLLECTOR STREETS BETWEEN THE HOURS OF 7:00 A.M. TO 6: P.M., MONDAY THROUGH FRIDAY EXCLUDING HOLIDAYS, WHEN ALL EQUIPMENT, LABOR, TRAFFIC CONTROL DEVICES, AND CONSTRUCTION ARE NOT IN THE VICINITY OF AN INTERSECTION. THE ENGINEER SHALL AUTHORIZE SUCH WORK AND SPECIFY THE REQUIRED DISTANCE FROM THE INTERSECTION. NOTE: TIME RESTRICTIONS ON S.H. 287 AND HWY 17 (COLLEGE AVENUE AND MULBERRY STREET EAST OF LEMAY) SHALL TYPICALLY BE RESTRICTED FROM 9:00 A.M TO 3:00 P.M. NOTE: CONSTRUCTION HOURS, EXCEPT FOR EMERGENCIES SHALL BE LIMITED TO 7:00 A.M. TO 6:00 P.M., MONDAY THROUGH FRIDAY EXCLUDING HOLIDAYS, UNLESS OTHERWISE AUTHORIZED IN WRITING BY THE ENGINEER. SPECIAL CONDITIONS FOR WORK ON RESIDENTIAL STREETS NOTE: FULL CLOSURES ON ALL RESIDENTIAL STREETS SHALL BE ALLOWED AS SHOWN ON THE TRAFFIC CONTROL PLANS. Project Specifications - Page 48 of 48 SECTION 00610 PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS: that Northstar Concrete Inc. 1220 S Garfield Ave., Loveland, CO 80537 (an Individual), (a Partnership), a Corporation hereinafter referred to as the 'Principal' and (Firm) North American Specialty Insurance Company (Address) 475 N Martingale Road, Suite 850, Schaumburg, IL 60173 hereinafter referred to as "the Surety", are held and firmly bound unto City of Fort Collins. 300 Laporte Ave, Fort Collins, Colorado 80522 a (Municipal Corporation) hereinafter referred to as the "OWNER", in the penal sum of One Million Seven Hundred Eleven Thousand Two Hundred Fifty -Seven Dollars and Twenty Cents ($1,711.257.20) in lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, successors and assigns, jointly and severally, firmly by these presents. THE CONDITIONS OF THIS OBLIGATION are such that whereas the Principal entered into a certain Agreement with the OWNER, dated the 9th day of February, 2015, a copy of which is hereto attached and made a part hereof for the performance of The City of Fort Collins Project, 7509 Concrete Maintenance Project Phase 11 — 2015 Renewal. NOW, THEREFORE, if the Principal shall well, truly and faithfully perform its duties, all the undertakings, covenants, terms, conditions and agreements of said Agreement during the original term thereof, and any extensions thereof which may be granted by the OWNER, with or without Notice to the Surety and during the life of the guaranty period, and if the Principal shall satisfy all claims and demands incurred under such Agreement, and shall fully indemnify and save harmless the OWNER from all cost and damages which it may suffer by reason of failure to do so, and shall reimburse and repay the OWNER all outlay and expense which the OWNER may incur in making good any default then this obligation shall be void; otherwise to remain in full force and effect. PROVIDED, FURTHER, that the said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Agreement or to the Work to be performed thereunder or the Specifications accompanying the same shall in any way affect its obligation on this bond; and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Agreement or to the Work or to the Specifications. PROVIDED, FURTHER, that no final settlement between the OWNER and the CONTRACTOR shall abridge the right of any beneficiary hereunder, whose claim may be unsatisfied. PROVIDED, FURTHER, that the Surety Company must be authorized to transact business in the State of Colorado and be acceptable to the OWNER. SECTION 03000 DETAILS Curb and Gutter 701 Curb and Gutter/Sidewalk 702 Curb, Gutter and Sidewalk Details D-6 Median (Island Curbs) 703 Standard Driveway Approach (I & II) 706.1-3 Standard Driveway Approach (III & IV) 707.1-2 Street Intersection Crosspan 708 Metal Sidewalk Culvert for Vert. Curb & Gutter and Sidewalk D-10 Metal Culvert for Drive -Over Curb, Gutter, and Sidewalk D-11 Curb Inlet Type R M-604-12 (1,2) Concrete Sidewalk Culvert D-12,13 Area Inlet D-9a Modified Type 13 Inlet 13-A Catch Basin 13-B Alley Intersections 803 Standard Manhole Cover 1201 Standard Sidewalk 1601 Sidewalk Detail 1602 Access Ramp Details 1603 Detached Walk/Intersection Detail 1604 Detached Walk/Intersection Detail 1605 Pedestrian Ramp Detail 1606 Residential Local Street Access Ramps 1606 a Truncated Dome Warning for Access Ramps 1607 Median Islands and Pedestrian Refuge Area 1608 Sidewalk Widening Details 2501 Concrete Pavement Joints M-412-1 2'-6' C3 1 1/2'R. N 26R. Gutter edge may be tapered or battered. (Typical for all Curb & & Gutter Types) i°• CO VERTICAL 21.75' .R b.5' 13.63' 2 + 9 d. " ROLL—OVER (LOVELAND) CURB AND GUTTER NO: 1 DRAWING LARIMER COUNTY CONSTRUCTION URBAN AREA 03/01/02 701 STREET STANDARDS DRAWINGS DATE. yZ�1 >ao V >- o z F-3 y tMi \ a z � w o r C7 a o � � z c� 31° 14" N. 17" T FL t I i••. u. U �3 ILL k M ro r m 1' min. (F,C.) 2' min, (L) Slope to curb 1/4"/Ft. 4:1 max, ,� d ... ; •' , .. <. •. CU 48:1 min. s See Drawing 1601 CO For Thickness O N DRIVE -OVER CURB, GUTTER AND DETACHED SIDEWALK \I � 2 min. 1 /4"/Ft. - CURB & GUTTER IN A CUT OR FILL I Excavatlon 5'(L) 1' 1I \ 'd ° ° •- \ Fill \ \ I DRIVE -OVER CURB, GUTTER AND ATTACHED SIDEWALK . N LIMITS OfC&G " i 14 IN. 17 IN. 3 FT. 9 IN. (1.17 FT.) I \ (1.42 FT.) (3.75 FT.) Z z M M pvl n � 1 1/2 IN. FLOW LINE 41N. C D 8 IN. rc (15IFN'T.)15IFT.)�—�. \J DRIVE —OVER CURB, GUTTER AND SIDEWALK 2 FT 6 IN. 6 IN— WHERE WALK ADJOINS A CURB, IT SHALL BE CONSTRUCTED 1/4 INCH ABOVE THE CURB. 4 1/2 IN. SLOPE SIDEWALK TO CURB — 1 1/2 IN. 1/4 IN. TO 1/2 IN. PER FT. 2 I, 1 1/2 IN. R ' ' D 4TIN. D 2 IN. R p f ;e e ° D 6 IN. z I � 4 FT. MIN. 8IN.I D D 12 IN. a VERTICAL 6 IN. CURB, GUTTER AND SIDEWALK EDGED SURFACE 1/8 IN. R. 3/4IN. MIN. 4.43 FT' 1.18 FT. .58 FT 2.67 FT. . • p: n .09 FT. ►.a.,.t•� .. ;. 11 FT. A .30 FT �' � � ' d � d e p. � 4 IN. D . DUMMY JOINT FOR WALKS e e s IN Al D COMBINATION CURB, GUTTER AND SIDEWALK "HOLLYWOOD" (OBSOLETE — FOR REPLACEMENT ONLY) CURB, GUTTER AND SIDEWALK DETAILS CITY OF FORT COLLINS fiQA STORMWATER APPROVED: DETAIL UTILITIES CONSTRUCTION DETAILS DATE: 11/13/00 D _ 6 DRAWN BY: NBJ CR7 of roK cdBD. 9 1-1/2' 4-1/2' 1 1/2'R. 1-1 /2' TO 2- R_ 7-A v N * . �•' •°. OUT FALL CURB & GUTTER (FORT COLLINS ONLY) 6- 1/8' TO 1/4'R. 1 112' 1/2'R. * Et. id ,�+. . 1 1/4 d' 1 /8' TO 1/4-R_ nA 'zt 1 /4' 1 12' — 1 1--I \— ASPHALT OR —/ F �c 6' w/concrete pavement CONCRETE PAVEMENT 8' w/asphalt BARRIER CURB (KEY WAY OR EPDXY) MOUNTABLE CURB (KEY WAY OR EPDXY) (SECTION B) (SECTION M) 6' 6' 6- 1 1 /4' J d Q -0 W (p .A'' •� .d' ♦. LL 10 (D .... ' r d O . .• ROADWAY `.'• .«, :•. PAVEMENT p . 8' BARRIER CURB 6' MOUNTABLE CURB (COOT TYPE 2 SECTION B M-609-1 CURB W/6- REVEAL) Notes: a.) Bottom of curb shall be poured to a depth no less than on the compacted subgrade of the pavement. b.) Raised center medians shall be 8' barrier curb or 8' epoxy curb only. MEDIAN (ISLAND CURBS) LARIMER COUNTY CONSTRUCTION REVISION NO: 2 DRAWING URBAN AREA DRAWINGS STREET STANDARDS DATE: 04/01/07 703 1 rno X = Curb Transition Length W p}ght of W ay Y = Parkway Width Varies ° ched W = Driveway Width, See � Deta ° Standard Drawing Series 707 � •'• 1 W V T =Concrete Thickness - 6' Residential, d ° \� 8" Commercial petache \ X, Refer to Chapter 25 for minimum removal dimensions. PERSPECTIVE W =Width Ramp if necessary IA Ramp if necessary ROW . ° '. • •' • v.:ilr. 4. .•• .' a : ',1:12 (max.) . o n �1:12 (max.);` . • ; ..I r—� . ( nv� �`. • etached 1... • , i.. u Sidewalk • .. Varies " ( �'' Varies" •. �' ' •'d ' • .'_ Ra •.� • mp Length • Ramp Length — — — — — — — W y l y W W W yl W W I a)I W y � W W a W W W I r Back of curb Lip See note 3 I A See Note 3 See Note 2 EX= (min.) Driveway Width x=Z (min.) See Note 2 Varies NOTE: " Ramp length not to exceed 15'-0", slope must be uniform. 1. Concrete driveway must be c provided to the property line. 2. 0' Curb Height, a Y2 min - 2' max See Section A -A o 3. Standard Curb and Gutter a Walk Y 1 Section, See Standard :50 max. •' Drawing 701 1 � ( ) 1:12 (max.) 1 /4' per ft. 7 " per ft. Expansion Joint if drive I` SECTION A -A T N continues as concrete N.T.S. NOT TO SCALE STANDARD DRIVEWAY APPROACH DETACHED WALK (Type I) LARIMER COUNTY CONSTRUCTION REVISION NO: 4 DRAWING URBAN AREA DRAWINGS STREET STANDARDS DATE: O6/26/14 706.1 W A�acned \ X = Curb Transition Length, Varies" W = Driveway Width (See Drawing Series 707) T = Concrete Thickness - 6" Residential, 8" Commercial. Refer to Chapter 25 for minimum removal dimensions. PERSPECTIVE W = Width A Retaining Curb (Optional), See Drawing 1603 (TYP) ROW J/ W .Y J• N a .1 d. IL :.• ,:{:: • . •.....•� •';• S '.: ; ..:':.I I � x �'r , ..' ::. ''f:: ../. / '1:�2 (max.) E 1 12 (max.)/. Attached Sidewalk '.� • I 40. ` OL Back of curb See Note 3 I A See Note 2 VariiesDriveway Width Varies Varies ' Ramp length not to exceed 15'-0', slope must be uniform. Expansion Joint if driveway continues as concrete NOTE 1. Concrete driveway shall be provided to the property line. 2. 0" Curb Height, See Section A -A 3. Full Curb and Gutter, See Standard Drawing 701. J y Y2' min - 2" max m � 0 0 o` 1:12 (ryna, cYi 1 ^ Per ft.')m 1:50 (max.) 1 /4" per e`ft t.. i Jna SECTION A -A N.T.S. — See Note 3 See Note 2 2" NOT TO SCALE STANDARD DRIVEWAY APPROACH ATTACHED `'TALK (TYPE II) LARIMER COUNTY CONSTRUCTION REVISION NO: 4 DRAWING URBAN AREA DRAWINGS STREET STANDARDS DATE: 06/26/14 706.2 W d H � tj C=7 tz Cn tv tv x a z za � coo C/) t4 W xRj C •3 `5' 9 C2] [n z x 0 0 � ►yC ro ~d W � r N CJ G� n 1. I i A SIDEWALK L4P— — — — -1-- See Note 6 MATCH FLOWLINE CURB & GUTTER --i z H 3 4 o T / CONTRACTION JOINT (TYP) 1 i 5' 6' WING —I Varies P i � DPP See Note 5 DRIVEWAY WIDTH NOTE: ADDITIONAL ROW OR AN EASEMENT PER DRAWING 707 MAY BENEEDED,1 SIDEWALK TO BE INSIDE ROW. 1.0' SIDEWALK 1 4• MIN. I � & WING Flowline ` See Note 5 5 --1 SIDEWALK BACK OF CURB See Note 6 DRIVEWAY WITH SIDEWALK ATTACHED TO CURB 5 61 DRIVEWAY ER DRAWINGWIDTH D 07 6 � 5 � v n RAMP -VARIES 14' MIN. r per n., t5014- 5o MAX. rot y:tz rvux. T SECTION A -A NOTES. 1. See LCUASS Drawing Series 707 for driveway width. 2. Concrete class per LCUASS Section 22 3. Rough broom finish full width of ramp and wings. Trowel and use light hair broom finish for sidewalk area 4. T = 6• for residential and 8• for commercial 5. 0• curb height, See Section A -A 6. Standard curb and gutter section, See Standard Drawing 701 Detached Sidewalk W � Parkway. Flare Driveway I If Concrete Driveway Expansion Joint — _ q �t 1"per ft. ,A I 1:12 (max) / i See Note 6 — -- —— — — — — — — �� 3 rol � y See Note 4 v See Note 3 _ I — — °D — `A TYPE Ill DETACHED WALK 1:50 Slope 1:12 (max.) 1 /4" per ft. er ft. rL F SECTIONS A -A N.T.S, NOTES: z 1. 6 wide pan for residential streets. H 2. All intersections to have access ramps. 3. Standard Curb and Gutter Section, See Standard Drawing 701 C 4. 0' Curb Height, See Section A -A 5. All of these pedestrian improvements shall be in ROW or a pedestrian or public access easement. 6. Detectable Warning to extend the full width of the ramp and be 2'-0" in the direction of travel. Material to be approved by local engineer 7. T = 6" for residential and 8" for commercial. 8. Distance from back of curb to the beginning of Detectable Warning cannot be greater than 5'-0" Detached Sidewalk IV 41 �L 14/ DRIVEWAY WIDTHS CLASSIRCATION APPROACH MINIMUM MAXIMUM TYPE WIDTH WIDTH RESIDENTIAL: Single Family I or II 12' 24' Multi Family 9 I, 11, III, or IV 24' 36' - ' Commercial I, 11, III, or IV 24' 31T Industrial I, II, III, or IV 24' 36' • High volume driveways (Type III or IV) allowed for 350 or greater trip ends/day. * 30' maximum for 3 car garages. * *No single opening shall exceed 36'. Wider driveways shall be divided w/a median not less than 6' wide. to H t= O C7 tyz •C O C7 rA Cn O `Lf ..3 Q z x a t� x 3 S c � � Q z o z tn:j �? t= vs t'rJ to tw �z 0 If Concrete Driveway I Expansion Joint Flare 14e 14, 41 y 14 V .: y Sidewalk 1/4"pelrrftpe 1:12(max.) 1" per ft. rL F SECTIONS A -A N.T.S. � A om rn 3 CD 7 N)� TYPE IV ATTACHED WALK NOTES: 1. 6' wide pan for residential streets. 2. All intersections to have access ramps. Z 3. Standard Curb and Gutter Section, See Standard Drawing 701. y 4. 0' Curb Height, See Section A -A 5. All of these pedestrian improvements must be in ROW or a pedestrian or public access easement. O 6. Pedestrian landing area, minimum required 4 ft length x 4 ft width, n max slope in any direction is 1:50 or k per foot. 7. Detectable Warning to extend the full width of the landing area and be 2.0' in the direction of travel beginning 6' from flowline. Material to be approved by the local engineer. 8. T = Concrete thickness, 6" for Residential and 8' for Commercial See Note 5 A See Note 6 See Note 4 @F� See Note 3 a Ramp if walk continues on Private Property. Pedestian landing area, See note 6 Retaining Curb (Optional), See Standard Drawing 1603 Sidewalk DRIVEWAY WIDTHS CLASSIFICATION APPROACH MINIMUM MAXIMUM TYPE WIDTH WIDTH RESIDENTIAL: Single Family* I or II 12 24' ` Multi Family • I, Il, III, or IV 24' 36' ` ' Commercial I, II, III, or IV 24' 36' ` Industrial I, II, III, or IV 24' 36' • High volume driveways (Type III or IV) allowed for 350 or greater trip ends/day. * 30' maximum for 3 car garages. * *No single opening shall exceed 36'. Wider driveways shall be divided w/a median not less than 6' wide. IN WITNESS WHEREOF, this instrument is executed in three (3) counterparts, each one of which shall be deemed an original, this 13th day of February , 2015. IN PRESENCE OF: (Title) (Corporate Seal) iN "'RESENCE OF: IN PRESENCE OF: Witness (Surety Seal) Principal Other Partners 0 By: Concrete, Inc. Surety North American Specialty Insurance Company By: �u_ _ t_ '� + - �l2 Diane F. Clementson, Attorney -in -Fact 475 N Martingale Road, Suite 850 Schaumburg IL 60173 (Address) NOTE: Date of Bond must not be prior to date of Agreement. If CONTRACTOR is Partnership, all partners should execute Bond. ROADWAY WIDTH CONTROL JOINTS CONTROL JOINT REQUIRED FOR PANS OVER 40' A it LENGTH WALK 8' TRANSITION FROM C & G SECTION TO PAN SECTION, TYPICAL BOTH SIDES. 6' MINIMUM (LOCAL) 8' MINIMUM (COLLECTOR) 10' MINIMUM (ARTERIAL) Fd 8" MIN. FOR RESIDENTIAL. USE CONCRETE PAVEMENT DESIGN + 1/2" FOR COLLECTOR & ARTERIALS. SECTION A -A NOTE: ALL INTERSECTIONS TO HAVE ACCESS RAMPS —+— ---5- — CONTROL JOINTS (TYP.) TOOL JOINT_ AT 10' O.C. A� TOOL JOINT DOWELL IF (for monolithic pour) COLD JOINT (See Standard Drawing 714) PLAN VIEW PARALLEL STREET CLASSIFICATION W CROSS PAN WIDTH LOVELAND DEPTH OF INVERT FT. COLLINS DEPTH OF INVERT d (MIN.) d (MAX.) d Arterial 10' 1 1 /4" 2 1 /2" 1 1/2- Collector 8' 1 " 2" 1 1 /8" Local 6' x 3/4" 1 1 /2" 7/8" ** 8' MIN. WIDTH WHERE CROSSING A COLLECTOR ROADWAY. SEE DETAIL "A; 10 FT. 0 IN. MIN. SECTION A 7FT. 2 FT •Ir-- --�1• I� II •III x x x I,I x x II II• PLACE FIRST SCREW II x x EDGE II OF x x x PLATTEN7 l IX xxx 5/8 IN. X 2 FT. 6 IN. X 4 FT. 6 IN. RAISED PATTEREN NON—SKID GALV. STEEL PLATE (AASHTO M-111) A' PLAN VIEW SLOPE PLATE TO MATCH 4 FT. 6 IN. SIDEWALK 1/2 IN.- I FLUAUNE (AS SHOWN ON PLANS)I� fi IN. SECTION A -A 3 IN., 2 FT. 0 IN. �y �t3 IN. 4 51 8 IN.----t/LIN � � 4 IN. t' - c • 8_IN. MIN. i 1/2 IN. a n 2:1 SLOPE 3 FT. 0 IN. I 2:1 SLOPE 5 FT. 6 IN. SECTION B-B 5/8 IN. 3/8 IN. BRASS SCREW-18 IN. O.C. PLATE I�.,-- W/ PLATETERSUNK HEAD RUSH 3x2x3/8 IN. �.---�1L41N. GALVANIZED ANGLE NO. 3 REBAR Y `� ANCHOR-18 IN. O.C. DETAIL 'A' REV. DATE 12/11/13 METAL SIDEWALK CULVERT FOR VERT. CURB & GUTTER AND SIDEWALK CITY OF APPROVED: '` ` }, �c FORT COLUNS STORMWATER _ DETAIL //~� [I, N7 , DATE: 12/12/00 D — O FORT 221-6, co. CONSTRUCTION DETAILS (o'�o) 221-e7oo DRAWN BY: NBJ 10 RAISED PAT2TEREN NON—SKID GALV. AIN. MIN. FT. 0 IN. SECTION NOTE: FLOW INTO STEEL PLATE (AASHTO M-111) FT. STREET 2 FT JJ •II x x II X 11" XXII II JJ ,1 I,xxx 11• 9110EFRDGEW X ONT EI{ $. OF LATE SEE DETAIL "A" 'I X x x x x 1{ A PLAN VIEW SIDEWALK ATE TO MATCH 14 IN. E 14 IN. 4 FT. 0 IN. 2 FT. 0 IN. PLANS 1/2 IN. / FLOWLINE (AS SHOWN ONif 1— 6 IN, ° F ` 6 IN. SECTION A -A 3 IN. 2 FT. 0 IN. 3 tN. 2 7 8 IN. 1/4 IN. — 4 IN. a ^ B IN. 5 3/4 IN 2:1 SLOPE 3 FT. 0 IN. 2:1 SLOPE- 4 FT. 11 IN.. 1� SECTION B- B 5/8 IN. 3/8 IN. BRASS SCREW-18 IN. O.C. GALVANIZED W/ COUNTERSUNK LAB RSUNK HEAD FLUSH PLATE GENERAL NOTES; GALVABIN. e1t4 �•. GALVANIZED 1. WHEN THEANGLE CURB IS SEPERATED FROM THE SIDEWALK - THE STEEL PLATE SHALL BE PLACED ON THE SIDEWALK AND THE CONCRETE CHANNEL(WITH 6 IN, NO. 3 REBAR " THICK WALL ON EACH SIDE) CONTINUED INTO THE ANCHOR-18 IN. D.C. CURB AND GUTTER. DETAIL "A" REV. DATE 12/11/13 METAL CULVERT FOR DRIVE -OVER CURB, GUTTER AND SIDEWALK Q�t MY OF FORT COLUNS STORMWATER APPROVED: DETAIL DATE: 12/18/00 IES ft Fonr doll+. co. CONSTRUCTION DETAILS D -11 DRAWN BY: NBJ (970) 221-0700 � MINION No CO p ■RRAON I'ARO°It TRUN;1 1 3'TION � — INLET PAY LENGTH CUTTER B PLAN VIEW 8' 1" A L • 1°'-0° . Fat LENGTH CJ 10 FT. OU MORE, PROVIDE y09 IWMENNCE ACCESS AT BOTH ENDS WIN 409 N ADORIM& MANHOLE AM Aa COVER. - 1..... A CUT REANFORCDfAT BM /CCOROINMT. 601 i.: STATION POOR AT WWOIN1 e OF INLET ALONG FLAWLINE S NOW ENDS OF B F BEAN 01 I9 IN.ET J° QR'IND FACE OF cm a�� 30" Y'�EIEET SH I OF NaIYA BMRIER Aa COTTER HERE. DIRECTIaICURB FIRM SEE CHANNEL LAYOUT ON SWEET 2. ION TO GUTTER uRHR I��.•�--°�� aces BIR • Ili• Law CUT OFF OR BEND BARS TO CLEM "HOLE i•—L•°'-0" L•10--0" �L•19.0" 3" -�II TTH ' 1EC 1 4" 2• 40a 601 40J 402 /OB a0a ( B� 1 YANaLE 1+ —{--- • IT, a" INLET STEPS an 403 '." 403 403 403 I -. 2" MR. Ri FOR AL Y.I •.� 7• N23w 503 401 a 2• COAL. J• PLR. 401 `a oCO1 401 fi0I e01 401 `" as I 2:1 9/�D.c sYi D.C. _ u^ ac. a� J• CLR. ^'( �' 2:1 P/r PIPE SPACER 406 L• a NH 1 N4' X4' l 12" O.0 L•10-1 I9-H4' o °. at. fYP B" O.C. o eee 11a Il/f LOrX NUT IV 11M. TY-CLA - 3. 0.R. - b] �aDJ ee o ae °• —r C WAL RYP.) - /03 40 sOJ 403 40 407 -�B• NBw 9. O.C. A/i' OIA. s 24" IT- - • .. .' ' - GAV. STEEL ROD A 2 M. A DRAINANETERGE EEISHAUL U. O. n TC b7 P AL < s BE P ACE PLAT SUB SHOLL 11. O.0 401 W O.C. 7-0. O.C. _ �IJ" CUR,, O.C.06 MD'� 10" EHHOHENT BE PLTION R NIHINUE ll• D.C. 6. O.6" O.C. - . ll 0 4D/D. (FYP.) �• - ° ELEVATION OR A LOW ROND ONOWY II` 6" O.C. 8" D&. 6" D.C..a• O.C. i/1 TEIRE BASE. TINCHEHE HOLE _ - °'-a" 11'-B• 16'-0• J'4.3 r%' PLATE SHALL BE PLUUYED WITH {0T3 SECTION A -A REGULAR INLET ACCEPTANCE�EOFF�THE W D �I C �1 D�1 CURB FACE ASSEMBLY RLEr G 41 L•lo'-M I*504 •PLACE ENTIRE M°ETeLY BEFORE PDxnw CONCRETE. 2" AL NDua 8OI 101 Bog CO 2 S01 / 402 a" S02 a1J 03 CONSNIT -0" 3n CLR. YIN. 0oJ2 SLWE/0J 413 — — — — � — bJ AN412 W'O.C. — --�H S'l0] 412 I TI a13 J y a0.C, fi p.C.3"QRCos CDC.JpI au SECTION B� vMINLE �J _ _ _ _ _ _ _ _6 END VIEW 2^ cLR. NOTE: wwaE RIK AM COVER,STATION POINT NCO OUTFLOW POPE SHALL BE LOCATED SECTION A -A INLET 3-.D AT THE SAVE END OF THE INLET. 12" 408 WITH DROP BOX AV H>5 FT. 11 D.e SECTIONS C-C & D-D (DOTTED BARS ME OH SECTION 0-0) Computer File Information Sheet Revisions Colorado Department of Transportation STANDARD PLAN NO. Creation Dote: 07/04/12 Initbh: DO Dote: Comments 4201 East Arkansas Menus Last Modification Date: 07/04/12 Initial,: LTA M) DenvPhoner, Colorado ]9J-90 30222 CURB INLET TYPE R M-604-12 Full Path:www.colaradodat.info/Oualneas/deal nsuppart FON:(303) 757-9820 Drawing File Name: 5040120302.d n CR-X) CM Ver.: IAmostallan V° Stak: Nat to SCOW Unk. English QMProject Development Branch DD/LTA Issued By: Project Osvelopment Branch July 4, 2012 Sheet No. 1 of 2 MET BARRIGENERAL NOTES• CLANG F�i6CE W 3, �� SEE SHEET 2. WHEN A HYPE R LIOL IE USED WITH GUTTER CURB Ala OUi1ER J Fi.7RNSITION IaINRIBLE ,HAUL k 606TRUCTEO. aRe FILE TRANSITION SHAL BE PAID Fat M CM AND CUTTER NO ABLE CURB AHD GUTTER TRANSITION CURB ♦- FOR A 1'-0" PAN SLOPE 2" PER FT. SLOPE 22 TO GUTTER 1'/•• R 409R as •SLOPE •I•/FT �o®mi®�i®�0�ai©fil�lia f�O®010ii10Y0iil0fi0ia I I I �0�010�10�®�10�0 mo001t)))lilf�WlliTii�lii l�'911ii�ia� 0l0®01o�la�o�la�a� �0�010�10�0�10�0� ®oaloll��l 1����1a®ate 0©�lt5�01©�10�®�10�0 IC'111�IfYi701aIC�ll©I�'A11��IIEI•�o� L. CO Fl l� l� � l l� � i t)i!• � O if ffi 7' I I O � o O B�''� ����l�ol�lo_�Ieilr�Ie�lo W VARIABLE REFER TO TALE TWO. I v 1 y Is INCLUDE t4, UB IN. BARS (SEE CHANNEL LAYOUT). REGULAR INLETS DROP BOX INLETS TABLE ONE -BAR LIST FOR CURB INLETS. TYPE IR" LENGTH ND. REO'D. NO. RED-D. L - 5 FT. L -10 FT. L - 15 FT. 401 402 410 REGU.IR MOP BOA CDNC. CU. YOS STEEL LDS. UONC, CU. YDS. STEEL LDS. CMG. W. Y05. STEEL L85. ,0.T 407 ,03 407 VAIN MH 10 7 12 28S 5.3 497 7.4 706 3'-6" 3'-2" Y-2" 10 7 3.4 305 5.7 526 7.9 747 4'4" 3'•8" 24- 12 9 3.7 326 6.D 559 8.4 7M 4'-8" 4L2" 3'-r 12 9 19 334 6.4 671 8.8 903 4'-6• Y-r 14 II 4.1 354 6.7 602 9.3 644 SIC 5'-r 4'-r M' IB 13 1 6 4.4 375 6.0 .4 NO 6'-0" S'-0" 4'-B• 3'-Ir I6 13 16 6 4.6 392 6.2 615 7.6 860 6'-0" 6'-2• 5'-2" 4' 5' is IS IB 8 4.6 402 5.4 637 7.8 NO T-0" 6'-B• Y-B^ 4'-Il" 20 17 19 10 S0 423 6.6 654 8.0 897 T-6" T-2• 6-2• 5'-5• 20 17 20 A 53 430 6.9 884 83 907 6'-0" 7'-8• e'-B" "r 22 19 22 a 5.5 411 7.1 684 8.5 M7 e'-6" 8'-2" 7-2" It" 21 21 23 L4 5.1 471 7.3 702 8.7 944 9'b• 6'-6• T6" 6'-II" 24 21 21 1{ .0 479 7.6 711 9.0 BS4 9'-2" 8'-Y 7'-!• 26 23 26 16 62 490 7.6 7 9.2 974 T-11• 28 25 27 111 6.4 5" 8.0 ]{9 9.4 092 10'4" 9'-2" 8'-0^ 28 25 26 IB 6.7 527 B.] 7!B BJ AO 11'V' 10'd" 9'-0" 6'-11" JO 27 20 1.9 547 0.5 779 9.9 1022 NOTES: FOR L•5 FT., L•10 FT., NA L•15 FT. REGWR BUM TOTAL QUANTITIES NEEDED ARE OUTSIDE M HEAVY BLACK LINE. DROP BOX INLETS: TOTAL DUMMIES NEEDED ARE INSIDE AXE HEAVY BLACK LINE. STEEL HEIGHTS GO NOT INCLUDE STRUCTURAL STEEL CHANNEL. TABLE TWO - BARS AND QUANTITIES VARIABLE WITH 11H11 SEE LATE It U, L J N A PLAN VIEW ]0" 2%' I �i - 241/," r_J4" ELEVATION VIEW WEIGHTS. COVER = 125 LBS. ♦WAG= IN LBS. MANHOLE RING (TYP.) TOTAL = 260 IN. GENERAL NOTES 1. CONCRETE SHILL BE CLASS O. INLET WAY BE CAST -IN LACE M PRECAST. 2. CONCRETE WALLS SHILL BE FORMED ON BOTH SIDES AND SHILL BE 8 IN. THICK. 3. INLET STEPS SHALL BE IN CONFORMANCE WITH AAMTO W 109. 1. CURB FACE ASSEMBLY SHALL BE GALVANIZED AFTER WELDING. 5. EXPOSED CONCRETE CIPMERS SHALL BE CHAMFERED {'R M. CURB AND GUTTER CORNERS SHALL BE FINISHED TO MATCH THE EXISTING CARD AND CUTTER BEYOND THE TRANSITION GUTTER. S. RE1T4FOiCING BARS SNAIL HE DEFORMED AND SHALL NAVE A 2 IN MINIMUM CLEARANCE. ALL REILFORCJ% BARS SHALL BE EPDXY COATED. 7. DIMENSIONS AND WEIGHTS OF TYPICAL MA6aE RING AND COVER OF NOMINAL. 8. MATERIAL FOR MA6ALE RINGS AND COVERS SHALL BE GRAY OR DUCTILE CAST 190M IN ACCORDANCE WITH SUBSECTION 712,06, 9. SINCE PIPE ENTRIES INTO THE INLET ARE VARIABLE, THE DIMENSIONS SHOWN ARE TYPICAL. ACTUAL DIMENSIONS AND OUATITES FOR CONCRETE AND REINFORCEMENT SNAIL BE AS REOIIIEO IN THE WORK. QUANTITIES INCLUDE VOLUMES OCCUPIED BY PIPES 10. STRUCTLBAL STEEL SHALL BE GALVANIZED AA SHALL OL IN ACCORDANCE WITH SUBSECTION 712.06. 11. ALL MANHOLE COVERS SHALL BE CAST WITH A'NO DUMPING DRAINS TO STREW MESSAGE AND A FISH SYMBOL. THE SURFACE OF THE MUMBLE COVER SHALL HAVE A NON -SLIP PATTERN. 2 #{ GALS IN., FOR 5 FT. INLET ONE 11/2 IN. HO.E 29" i9' 2v 24" 29' { t4 BARS6"12 a" 6" FM 10 FLILET35" 30"-t�]0" 35" TREE 1y. IN. HOLES 1a-1a' SECTION AT HOLE nYP.I Ir 22• 92• 22• 24" 22^ 22" 22" Ir B f4 BAPS 4• A" m Ir 4" 4• FOR 15 FT.INLFT w".J.-DO" �L 3m M- FIVE I%t IN. HOLES 15'-10" CHANNEL LAYOUT DETAILS SEE CURB FACE ASSEMBLY ON SHEET I. TYPE 11 TYPE NI TYPE IV TYPE V TYPE VI TYPE VII TYPE Vla TYPE X 29" f 20•IpI 10.5 20• ,p6 I J4" LENGTH '{ `' B• ��� 111 B � vAWE 410 L BM BENDING DIAGRAMS �(DIMENSIIXdS ARE OUT-TO-0UT OF BAR) Colorado Deportment of Transportation STANDARD PLAN NO. 4201 07 Pnone (303) Arkansas Avem .d. 3 222 d CURB INLET TYPE R M-604-12 E a,: (303) 757-9820 Project Development Branch DDATA fud .d By: Prnj.ct O&V.Iwm nt Branch UWy 4, 2D12 Sheet No. 2 of 2 A- 7 3 F7. 1— 6 IN. 1 I FT, C 9 IN. 6 IN. THICK SIDEWALK (TYPJ 4 FT. 1 FT. 6 IN I B (TYPJ If L6 ITN. / t it TN. 2 FT. #4 APS A L 12 N ❑L A-� WALK 1 FT. NORMAL BACK 5 #5 BARS AT C 9 IN. O.C. I �2 #5 BARS AT 6 IN. O.C. B BACK OF CURB --SEE DETAIL 'A' WApprD cup s BE 8.5 FLUSH WITH CURE FACE BAR R IN. 2 1 1 IN. LONG / 8 i /4 IN.-1 IN. LCG 2 N, •1 d: 2 IN. 4:1 I ,� . 6 IN.. ..' 6 IN. 2:1 $ 5 BAR p 1 1 /2 IN. PPE SPACER AND 1 1/4 N. LOCK NUT 8 IN. ^- •'' ., T 1 1/41N. DIA. X 241N. GALV. • 3 IN. STEEL ROD — THREADED ' 3 1/2 IN. AT TOP. 6 IN. 4 IN. 3 IN. X 3 IN. X 3/8 IN. PLATE J 6 IN. T NORM_A�/ FLOW LINE BE 8.5 WITH 1 1/2 IN. DIA. HOLE IN CENTER — EXTEND CHANNEL TO OUTSIDE EDGE OF WALL. --� B IN. DETAIL "A" 0 IN. SEE DETAIL ^B• 1}4 BARS 6 IN. il5 BARS 8 1/2 IN. 1R SLOPE 6 IN. BARS /W BARS IN. O.C. 80THWAYS SECTION A -A DEPRESSED GUTTER WARPED GUTTER —TOP OF CURB 2 IN LTERED FLOW LINE SECTION B-B (REINFORCEMENT NOT SHOWN) 11 FT 0 IN 6 I"' DETAIL "B" 1 FT. 4 BARS 5 BARS GENERAL N�TESI I. SIDEWALK SHALL BE 6 IN. THICK FOR 3 FT. ON 6 IN. EITHER SIDE OF CULVERT. ADD 1 N 4 BARS ADD`1 M a BARS 2. TOP SLAB OF CULVERT SHALL BE SLOPE TO 14 I/2 IN MATCH SIDEWALK. SEE D-6. 3. EXPOSED STEEL SHALL BE GALVANIZED IN ACCORDANCE WITH AASHTO M-111. 4. KEY JOINTS WHERE WALLS CONNECT TO TOP SLAB AND BASE. qq BARS-12 IN. O.C. �OTHWAYS 5. REINFORCEMENT IN WALLS AND BASE SHALL BE 3 IN. FROM THE SIDE EXPOSED TO EARTH. SECTION C—C REINFORCEMENT IN TOP SLAB SHALL BE 1 1/2 IN CLEAR, CONCRETE SIDEWALK CULVERT FOR VERT. CURB, GUTTER AND SIDEWALK APPROVED: DETAIL CITY OF FORT COLLINS STORM WATER UTILITIES CONSTRUCTION DETAILS DATE: 12/19/00 D -12 CPY or Fort colt DRAWN BY: NBJ 3 FT A� EXTEND WALK 1 FT. NORM BEYOND NORMAL BACK OF WALK. - 6 IN. / 6A4 BARS AT 11 IN. O.C. C 9yy IN. 6 IN. THICK L SIDEWALK CTYP.) 4 FT. 6 IN. I FT. B 11 IN. 17 IN L 14 IN p4 L BC 8.5 FLUSH — WITH CURB FACE I3 IN. X 3 IN. X 3/8 IN. PLATE A - I 1/2 IN. R 5 M5 BARS AT 9 IN. O.C. C 8C 8.5 WITH 1 1/2 IN. DIA. HOLE J IN CENTER - EXTEND CHANNEL TO OUTSIDE E[ 2 #5 BARS AT 6 IN. D.C. B OF CURB R��JBACK EE DETAIL 'A' 4 14 7 ° ° _ 4 — # S BAR a 6 IN. // 2 AN151 1/4 INE OCK NUT T 1 1/4 IN. DIA. X 24 IN. GALV. 1 IN STEEL ROD —THREADED 3 1/2 IN. AT TOP. - 3•IN.. 6 IN. �u DETAIL "A-' —'-i DETAIL #4 BARS 6 IN. 6 IN. #5 BARS 1% 4BARS 8 1/2 IN. SLOPE - —L 6 IN. / t /#4 BARS-12 IN. O.0 \���// BOTHWAYS SECTION A —A WARPED GUTTER DEPRESSED GUTTER WARPED GUTTER TOP OF CURB NORMAL 3 1 4 IN. •• LTERED FLOW LINE LINE SECTION B-B (REINFORCEMENT NOT SHOWN) ' - IJL 1 MIL p 1 FT. GENERAL NOTES, 4 p 4 BARS 5 BARS 1. SIDEWALK SHALL BE 6 IN. THICK FOR 3 FT. ON 6 IN. . EITHER SIDE OF CULVERT. 2. TOP SLAB OF CULVERT SHALL BE SLOPE TO 1 ADD I # 4 BARS ADD 1 p 4 BARS MATCH SIDEWALK. SEE D-6. It/zIN. 3. EXPOSED STEEL SHALL BE GALVANIZED IN ACCORDANCE WITH AASHTO M-111• 4. KEY JOINTS WHERE WALLS CONNECT TO TOP SLAB AND BASE. ,yy 6oT WAYS 12 IN. O.C. 5. REINFORCEMENT IN WALLS AND BASE SHALL BE 3 IN. FROM THE SIDE EXPOSED TO EARTH, SECTION C — C REINFORCEMENT IN TOP SLAB SHALL BE 1 1/2 IN CLEAR. CONCRETE CULVERT FOR DRIVE -OVER CURB, GUTTER AND WALK CITY OF FORT COLLINS STORMWATER APPROVED: DETAIL UTILITIES CONSTRUCTION DETAILS DATE: 12/20/00 D-13 ar � wle ems. DRAWN BY: NBJ 0.1 28 1/4 IN. 16 1 /4 IN. A —NO. 12 GRATE AND FRAME BY MOCLEAR OR APPROVED EQUAL A PLAN VIEW 35 3/4 IN. 6 IN. 23 3/4 IN. 1 IN. MIN. INLETET GRATES N. COR. O.F. - J.1 6AR� .4� 2IN. CIR LF. . n 0 12 IN.� '- 12 IN. M • .�' . CTRS. (TYP.) al.~ . LAP T14 OWLINE OFWND I I INLET AND CONDUIT I I O f ..ZX . 0 12 SECTION B-B SECTION A -A GENERAL NOTES: 1. AREA INLETS MAY BE USED FOR DRAINAGEWAY OTHER THAN STREETS. (EXAMPLE, PARKING LOTS, MEDIANDS, SUMP BASINS) AREA INLET PIPE D.D. _ ��, r •. \ q .. A 2IN. dR LFF. CCTTRS. (TM.) I CITY OF FORT COLLINS STORMWATER APPROVED: DETAIL UTILITIES CONSTRUCTION DETAILS DATE: 12/8/00 D - 9 A qh at Fart C49T DRAWN BY: NBJ H r IE FORAGE ' ' 1122I. MAX.SPACING .� I '• F e, — — 6 IN. TYPICAL WALLS AND FLOOR 10 GROUT 24' TRANS. 3'-3" RAIL — EMBED EOUAL LENGTH IN BOTH WALLS #4 ® 12" NOTE 1. TOTAL OPEN AREA IS 336 QofFort 23 1/4• — zz 3/6' ADJ. 9' 1 11/16' TYP. — TO 12 1 /2' --I r 1 3/4' TYP ...�� \ � � %f n1°i�' rnaQr"�r�.AMo aMa n �ouorac�meon• w.m ae A'narm ..'; . %� i I 1/2'_I /.....ro BE xAeat WEND An I4' — 6' — 28 1 /2' a Mrsx e+rts ArtE TO ee Y/.L1rA warts MY" 38 1/2' SOME INCHES. Type 13 Inlet STANDARD NUMBER Detail Type 13 — A CITY OF FORT COLLINS, COLORADO Appmwm ENGINEERING DEPARTMENT a.:.::. NO FLANGE . Y• NOTES• 2'r S' f• wrt srvr r.r .ra+s oau r aewrnwrorm wnr .w woxonv� crMr °ar. I E AYwmw AMw Am mMa• is a67m fGNl.M1' jwsav _ „m„,4 mM aMw btlC NOTE 5 noararo nvm Mnc NAft cr aaEr aontro caw fxA� [[Toni _fs' °. 6XlE/dD R[AVFCgCMa OM SIOC11'AG1' SLCALW A 12iEalaf aF f1' M7/ERS Na STaE7VALK /5 t Au aaer ec°zs suAtt x usr av frtAcr cavae7c rMxcxs omnarou Aunroxfan . • ' or mr awroaix ° -I B" � 30` 6. 72 T5w 3 . 1:2„0 rehar A 1-2.;'zlt?.gyp, Curb, 2- 1/2`p rebar r Gutter r� 3-112 p I s' A 34" PLAN VIEW nts I N_ N 1/4' steel angle Q (welded corners) r 2 1/2' RTab I - — 28 --sl FRAME I•Jlox 112'p renar 4 4 �11� C Normal' grade at 1/2-rcbar anchors 12"OC �L2112' x 21f2�'x`.��1R"'x 92" —Warp inside pputter gqrade 24 /b, each 5ide of inTel to meet grade of inlet 3 3/V -- Normal gutter M grade ar outside back or f Fra�`e L - 31/2" edge. walk. Standard curb al line ;Js. z3„ ie 1*per ft I out let ( I b 11A rcbars 3 - 1/ 2' m rebars 12,0C. �3-112'0 rebars 1ra.C. SECTIQN AA rt s. NOTE: A 12'transition, centered on the C.B, shall be constructed All reinforcing steel s4pll be tirade 40 CATCH RA qw flG TA I I c 000 � 27-------� 4051 J12 qrate- by Macledr or aoprovcd egJal GRATE T— _ SECTION 00615 PAYMENT BOND Bond No. 2188131 KNOW ALL MEN BY THESE PRESENTS: that Northstar Concrete Inc. 1220 S Garfield Ave., Loveland, CO 80537 (an Individual), (a Partnership), ( Corporation , hereinafter referred to as the "Principal' and (Firm) North American Specialty Insurance Company (Address) 475 N Martingale Road, Suite 850, Schaumburg, IL 60173 hereinafter referred to as "the Surety", are held and firmly bound unto the City of Fort Collins 300 Laporte Ave., Fort Collins, Colorado 80522 a (Municipal Corporation) hereinafter referred to as "the OWNER", in the penal sum One Million Seven Hundred Eleven Thousand Two Hundred Fifty -Seven Dollars and Twenty Cents ($1,711.257.20) of in lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, successors and assigns, jointly and severally, firmly by these presents. THE CONDITIONS OF THIS OBLIGATION are such that whereas the Principal entered into a certain Agreement with the OWNER, dated the 9th day of February, 2015, a copy of which is hereto attached and made a part hereof for the performance of The City of Fort Collins project, 7509 Concrete Maintenance Project Phase II — 2015 Renewal. NOW, THEREFORE, if the Principal shall make payment to all persons, firms, subcontractors, and corporations furnishing materials for or performing labor in the prosecution of the Work provided for in such Agreement and any authorized extension or modification thereof, including all amounts due for materials, lubricants, repairs on machinery, equipment and tools, consumed, rented or used in connection with the construction of such Work, and all insurance premiums on said Work, and for all labor, performed in such Work whether by subcontractor or otherwise, then this obligation shall be void; otherwise to remain in full force and effect. PROVIDED, FURTHER, that the said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Agreement or to the Work to be performed thereunder or the Specifications accompanying the same shall in any way affect its obligation on this bond; and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Agreement or to the Work or to the Specifications. PROVIDED, FURTHER, that no final settlement between the OWNER and the CONTRACTOR shall abridge the right of any beneficiary hereunder, whose claim may be unsatisfied. PROVIDED, FURTHER, that the Surety Company must be authorized to transact business in the State of Colorado and be acceptable to the OWNER. Alley Concrete Border Drive -Over or Vertical Curb \ & Gutter /JIB (TYP / I 10X10' 10X10' Construction Joint SIGHT curb AIGHT REA AREA 0' Curb 1.12� Walk I con S' minlmum thick P ° ^ .` Walk e, concrete \1 ., — O'Curb —a Truncated Dome Parkway TIC 6'Curb Warning Detection Parkway Vertical \ — — — _ — — 6' Curb FL---'6' Curb STREET Truncated Dome Warning Detection ALLEY W/ SIDE DRAINAGE Drainage May Cross the Walk Up to a Maximum of 0.5 cfs for the Design 2 Year Storm. Alley \FL-t� / I / Concrete :+ Alley Drainage Inlet or Other Drainage Collection steshll be designed R_O_WqAREA S\AREA (TYP.) = rm minimum. / \ / \ Walk 1:24 I 8' minimum thlck '; Y.; 1.24 Walk `— :• concrete 0' Curb �I� I O'Curb Parkway Parkway 6' Curb FL a- Curb Warning Detection See Tables 8-1 & 8-2 For Radlf STREET Requirements ALLEY W/ CENTER DRAINAGE Drainage May Not Cross the Walk Unless The Water Is Sheet Flow and does not Interfere with pedestrian use of walk_ ALLEY INTERSECTIONS IARIMER COUNTY CONSTRUCTION REVISION NO: 2 :DRAWING URBAN AREA DRAWINGS STREET STANDARDS DATE: 04/01/07 803 Depress ring 1 /4r to 5/8' below adjacent finished street grade Final asphalt lift, overlay or grade adjustment Exlsting base course Suppo,t with Steel Shims and pack with Hlgh Strength Grout Slope up to match finished pavement NOTE: 1. Grout shall be a mixture of 100 Ibs Grout mix, 28 Ibs water (3.12 Gal), and 100 Ibs of sand conforming to ASTM C-35. 2. Manholes shall not be located In crosspans, gutters, or wheel path. 3. Shim and grout to make ring and cover flush with the finished pavement surface. Straight cut around ring Concrete grade ring to match slope or finished grade Shim / Grout Grade ring Manhole STANDARD MANHOLE COVER LARIME=AREA CONSTRUCTION REVISION NO: DRAWING MADRAWINGS STR DATE: 08/07/00 1201 Detached Sidewalk j Driveway Sidewalk J J J Yr Y ♦ J J . Y J ♦ . Y Y Y J J . i ♦ ♦ J Y ♦ J Y Y J .. J . J . . . . . . i . ♦ J ♦ Y ♦ J J . . Y i ♦ ♦ . ♦ ♦ ♦ J ♦ ♦ i . . . . . . . . . . . . . . . . . . ♦ . Y . ♦ . J . . i . . J J . . . . . . . . . . . . . . . . . . . . . . i . . i i J J J ♦ ♦ . . . . . . . . . . . i J . i i ♦ J i i i i J J i . i ♦ J J . ♦ i i i J J ♦ J J i i . Y i . i ♦ . i J J i ♦ i i ♦ ♦ . ♦ ♦ J J J i Y ♦ r . J J i i Y Y Attached Sidewalk T.C. 6'-0" 1 F.L. Min, Lip 6' Commercial 12" Expansion 6" Residential Joint Material 12" Expansion Joint Material Detached Attached 6° : . Sidewalk' Sidewalk SECTION A -A All Sidewalk Thickness Shall Be 6" minimum. NOTE; 1. Sidewalk grade shall remain consistent across driveway 2. For driveway design requirements, see CONST. DWG. Series 706 & 707 3. This detail applies to Residential & Commercial driveways. NOT TO SCALE STANDARD SIDEWALK LARIMER COUNTY CONSTRUCTION REVISION NO: 3 DRAWING URBAN AREA DRAWINGS STREET STANDARDS DATE: 05/O1/13 16�1 Q' • .. :•' Slope sidewalk to curb 1M pertoot. 47 .: 4 d .. e NOTE: Construct siewatk v dth doitte at 10'titarvals and nlklried with scoiiv, on curb. •• • •4 • A. ' •' ATTACHED SIDEWALK DETAIL r Landscaping Slopc: tvLnumum Ma)imum Slope sidewalk to curb 1/r per foc •- .I • 4,. DETACHED SIDEWALK DETAIL R 1 /8' 1/4 SLAB THICKNESS ' !4 ',y .:• 1/41 - .4 i ,• . WEAKENED PLANE JOINT 2- 1 /2' Expansion Joist mateiial • 4 <' 4••.. A • • �< . d.. • . • 4 •" iv • .'AA INSTALL IN LOCATIONS SPECIFIED IN CHAPTER 22 EXPANSION JOINT u r- SIDEWALK DETAIL 2LARIMER COUNTY CONSTRUCTION REVISION N0: 2 DRAWINGURBAN AREA DRAWINGS EET STANDARDS DATE: 04/01/07 1602 Retaining Curb (Optional) to retain ground behind the walk, if needed 2 (Radius varies) Wood float finish thru ramp Transition back of walk (tm) —:7- See Note 6 See Note 5 ,Z Detectable Warning, Walk See Note 4 Broom finish Curb Gutter y` `Curia to match slope safe of sidewalk, Ramp length See Note 6 not to exceed 15'-0' See Note 5 CORNER LOCATION Retaining Curb (Optional) Wood float finish thru ramp Walk Broom finish Curb Gutter i Retaining 3 Curb o (Optional) JJ(( 1 I E L-- r per n.-k 1:12 slope 6' j 5' 1 6' (max.) T T (max.) MID -BLOCK LOCATION 2'-0' _1 4� per ft. . , See note 2 a• SECTION A -A Transition back of walk (typ.) Broom finish Detectable Warning, See Note 4 On a radius hold 6' at the corners of the truncated dome warning. 6' c � N 0 LL v ' a. NOTES: 1 . T = Concrete thickness, 6' minimum for entire ramp area. 2. 1:50 Max unless a landing behind ramp (then ramp can be 1:12 with 1 :20 on the detectable warning). 3. See CONST. DWG. 1606(a) and 1607 for Fort Collins. 4. Detectable Warning to extend the full width of the ramp. Material to be approved by Local Engineer. 5. 0" Curb height, See Section A -A. 6. Standard Curb and Gutter Section , See Standard Drawing 701. NOT TO SCALE ACCESS RAMP DETAILS LARIMER COUNTY CONSTRUCTION REVISION NO: 2 DRAWING URBAN AREA DRAWINGS STREET STANDARDS DATE: O6/26/14 1603 ARTERIAL 0 �o E ROW Line 9, �r ARTERIAL / COLLECTOR J Q Ir R=6' W Zn F-- _ (r Q 9� .�o P° J Q ROW Line cc 10' 6' H 10' 5' (min.) Q 16' 15' ARTERIAL / ARTERIAL ARTERIAL / COLLECTOR For Corner Radius > 35' DETACHED WALK / INTERSECTION DETAIL LARIMER COUNTY CONSTRUCTION REVISION NO: DRAWING UR3AN AREA DRAWINGS STRCI F STANDARDS DATE: 08/07/00 1604 Note: Use of this detail requires special approval In Fort Collins by the Local Entity Engineer. r- DETACHED WALK / INTERSECTION DETAIL LARIMER COUNTY CONSTRUCTION REVISION NO: 2 DRAWING URBAN AREA DRAWINGS STREET STANDARDS DATE: 04/01/07 1605 A� 2' Transition (fYP.) W W W O O°00000°00< U 0000000000 2' (min) W W W W O coo 0°0°0°000 L-F W b W W W W W CUrUareStandard Curband Gutter,See StandardDwg 701 (TYP) Flare table Warning 0' Curb Height,See Section A -A W W WW W (Typ) °0°0 A - 000 °o°° Pedestrian 4' (min) °°o°°o Landing Area, (7yP.))I 0000 Detectable See Note 2 SIDEWALK o°o° Warning 0000 0" Curb o°o° 0 0 W W W Curb Option,' See Note 5 W W W Radius = 8" W W U 2 W W W W W W W W Curb W W W W 1:12 frn W W W W W I' per N 1 .22�0 (max) cp .4. 1/2per ft. a Lip of Gutter r PLAN VIEW T, See Note 8 16" N.T.S. SECTION A —A NOTES: N.T.S. 1. No joints are allowed in the flowline. Six inch wide curb or "dummy joint" may be tooled no closer than 6 inches from flow line as shown. 2. Pedestrian landing area required 4 ft length x 4 ft width, max slope in any direction is 1:50 or Ya' per foot. 3, Joint pattern to be according to intersection gutter detail' or as determined by the local entity. 4. Wood float finish is required over the sloped surface of ramp and flares. 5. A 6" wide curb option may be poured along side of the ramp as shown if required. If curb is used it shall match style of adjacent curb and gutter. 6. Minimum ramp width shall be four feet, or the same as the widest adjacent sidewalk, whichever is greater, up to a maximum width of 8 feet. 7. Detectable warning is to extend full width of the ramp and be a minimum of 2.0' in the direction of travel. Material to be approved by local engineer 8. T = Concrete thickness, 6' minimum for entire ramp area. NOT TO SCALE DIRECTIONAL ACCESS RAMP DETAIL & DETACHED SIDEWALK LARIMER COUNTY CONSTRUCTION REVISION NO: 4 DRAWING URBAN AREA DRAWINGS16 STREET STANDARDS DATE: 06/26/14 06 rR T Gutter or _ Apron m 1:20 l Slope 1:12 Max slope trL Truncate Dome Section A -A Warning Panel NTS Notes: 1. Set ramp slopes using the center of the ramp. Truncated Dome Warning Detection Plan Locations Truncated dome panels: 1-2'x2.5' Ramp 1-2'x2' 4'-6' Flare 2'-6' 2-0' 000000 el ..o..o, 2-0' �'aneis a e0000a oo e' t�l 2. Truncated dome warning panel: Install panels along with the concrete pour for the 5'-6' BOO to walk w/ vertical curb ramp. Specifications for the panel material 5'-T BOO to walk w/ drive over curb will be provided upon request. 3. Each ramp shall align perpendicular to the street in which the ramp is provided to cross. 4. Refer to standard drawing 1606 in the Laimer County urban area street standards for other necessary criteria needed to construct these ramps that is not specified on this drawing. y5. Construct the ramps and walk so the comer area all drains to the street. H 6. If curb and gutter are poured monolithic with n ramp, place dome edge at back of curb as shown. If not poured monolithic, place dome edge 6' from back of curb. R Cn m PT of walk m o Truncated dome m warning detection rn R15.0' RI R & BOW 4.5' Sidewalk B.01 Area to be landscaped \— PT Curb 1.5' 5' 6' Curb LEGEND: PLAN VIEW BOC- Back of curb NTS R Property Line PT - Point of Tangency a M .5' rL PT of curb -n return O Loncrlarav(Typ) 6" Curb -i (TYP) n O 0' Curb r Ramp 4.5' (p onc. are O a e^ z 1z � r 12.0' 12.0' -H ` Full height curb -1.5' (!Center line of ramp -U D BOC-Back of Curb 0 \ FOC -Face of Curb C BOC FL -Flow line r I A og w Flare a' Ramp JR m Ramp Flare Ramp O000000000CDOO Flare AAA Flare0 Panelsu (Panel1 oOPa�els0 0 0 000 000 0 0 0 0 0oBOC 0 0 0 GVrp Flare 0^0. O�O?O 0Oc�00O'Panels 0 o O Panels o�an� lz // ll. 00000 0000o O r' VO00 cn Curb Gutter or A Z n 0 Apron m a; Q Curb W r Case 1-Directional Ramps °' Case 3-Mid-Block Ramps r Case 2-Non-Directional Ramps U) Notes: Ramp Panel Width ZZ r m 1. Truncated dome waming panel: 4.5' 2'+2.5' < m 1 Install panels along with the 5.0' 2.5'+2.5' y N concrete pour for the ramp. 6.0' 2'+2'+2' Specifications for the panel and 7.0' 2.5'+2'+2.5' 1:20 1:12 max slope installation instructions will be 8.0' 2'+2'+2+2 slope provided upon request. 2. This drawing shows vertical curb. Note: HT For Drive Over Curb the warning Truncated dome panels are a o tanels embedded in the detection location shall be placed in available in 2'x2' squares f concrete ramps the same position 6' back from the and 2'x2.5' rectangles. O (D' back of curb. Combine the widths to fit V) O 3. If curb and gutter are poured the ramp. Panels maybe 9 a monolithic with ramp, place dome cut to no less than a 2'x1.5' LrJ edge at back of curb as shown. If size. Section A -A (Center line of ramp) not poured monolithic, place dome NTS edge 6' from back of curb. IN WITNESS WHEREOF, this instrument is executed in three (3) counterparts, each one of which shall be deemed an original, this 13th day of February , 2015. IN PRESENCE OF: Principal Northst4p-Concrete, Inc. 17 (Title) (T le)/ ;Corporate Seal) 122fi South Garfield Loveland (A ress) IN PRESENCE OF: Other Partners M By: IN PRESENCE OF: Surety North American Specialty Insurance Company �� , KVAI By:. Diane F. Clementson, Attorney -in -Fact Witness 475 N Martingale Road, Suite 850, Schaumburg, IL 60173 (Address) (Surety Seal) NOTE: Date of Bond must not be prior to date of Agreement. If CONTRACTOR is Partnership, all partners should execute Bond. 4' Min. Flat Rest Area 4' MIn_ 1 .12 MAX 1:1�X Show street surface SECTION A -A Minimum area of nose Island 50 112 Truncated Dame Warning Detection (Np-) A MIn.4' A OO�p�4 O 0. To e.p. a g Slop Bar at M In. traffic signals Sidewalk width shall conform to width requirements for the street classlllcallon NOTES: 1 _ No storm water shall drain through pedestrian refuge. 2. Pedcstrlan refuge area shall be In line with cross walks. 3. Crosswalk to line up with ramp & Refuge Area. LL MEDIAN ISLANDS & PEDESTRIAN REFUGE AREA LARIMER COUNTY CONSTRUCTION REVISION NO: 2 DRAWING URBAN AREA DRAWINGS STREET STANDARDS DATE: 04/01/07 1608 4'-0f (Min. width) Sidewalk Addition (min.) Existing Sidewalk ADDITION TO EXISTING SIDEWALK NOTES: 1. New walk additions shall be placed to the same line and grade as the existing walk. 2. Match transverse tooled joints to existing tooled joints - EDGE SURFACE 1 Ar R. TOOL JOINT FOR WALKS NOTES: 1. Joint shall be out 1 /4 thickness of Initial concrete; tool joint for walks. r- SIDEWALK WIDENING DETAILS LARIMER COUNTY REVISION NO: DRAWING UR3AN AREA CONSTRUCTION ST STANDARDS DRAWINGS DATE: 08/07/00 2501 STATIONING SMALL BE STAMPED AT 500' INTERVALS ON EACH OUTSIDE MANUME SHOULDER AS SHOWN-� i0�06i�0�1.1� GENERAL NOTES I. THIS STANDARD PUN DOES NOT APPLY TO THIN CONCRETE OVERLAYS (WHDETOPPING). rir 2, LOCATE Q JOINT AT A © JOINT OR A MINIMUM OF 2 F. FROM A © JOINT. 41 3. MIS JOINT LAYOUT 9W1 BE USED AS A STANDARD FOR THE JOINT LAYOUT FOR THE PROJECT. IF THE CONTRACTOR PROPOSES VARMTIONS FROM MIS STANDNW) OR ME PROTECT HAS UNUSUAL OR IRREGULAR CONDTIONS NOT COVERED HEREIN, ME 00"WRA SHALL PREPARE A PAVEMENT JONT XICH LAYOUT FOR APPROVAL BY ME ENGINEER. SLABS 14 FT. IN WIDTH SHALL BE CONSTRUCTED ONLY WHERE NUMEIVIS DESICMIn ON THE PLANS. 4. WHEN A CONTINUOUS WIDTH OF PAVELF�T IS POURED WIDER THAN 40 FT., ME MINT CENIERUNE SHAH BE AN UNTIEDV VIM. 5. ON 4 FILE OMOED HIGHWAYS, THE 2 LANE DIRECTIONAL PAVEMENT AND BOTH? SHOULDERS SHVl BE PLACED WITH CFJ LDNONDINAL SAWED CONTRACTION JOINTS. 6. ON VARMBLE WIDTH SUBS, THE 2 R. DR 4 9.. END OF SLAB WROTH DIMENSION MAY VARY 36 INCHES. ]. iLl M BE USED WHEN TRAFFIC LANE IS MOED SEPARATELY OR FOR TAPERS OR SPEED CWWDE LANES, ALTERNATIVE DIN& JOIN LOCATIONS AT SPEED CHANCE LANE MAY BE USED IF APPROVED. TYPICAL JOINT LAYOUT FOR UNECDON OF MAM JOINT LEGEND ts' rnNCRFTR ROADWAY WITH CONCRETE SHOULDERS (SEE SHEET 5 FOR JOINT DETAILS) C C SHOULDER a 11!e A �� A c � TRANSVERSE CONTRACTION M Y HDRI�� � C�- LONGITUOOb11 CONSTRUCTION m HORIZ. �IpEg 1N �Rppy m a x j� t4' FLOW C I TRANSlATIaN T/2 T/2 VERTICAL SKEW -� Co RACTI TRANSVERSE LONGTU JNL CONSTRUCTION TO DbFt3 i/ 12' L E D�x n a HORZ. SKEW T IS PAVEMENT THICKNESS FROM PLANS c is BER PLAN VIEW SECTION A —A SECTION A —A SHOWING HONIZ., HORIZ. TMNSLATION. SHOWING VERTICAL TOLERANCE SHOWING VERWCAL SKEW TOISPANCE Y DOWEL BAR DETAIL AND HORIZ. SKEW TOLERANCES FOR DC JOINT WITH 14 FT. AND 12 Ff. LANES DETAILS ILLUSTRATING DOWEL PLACEMENT TOLERANCES TIE EARS RAMP AND srEm CHANGE FOR LANE DIDAILY. SEE C SEE SUBSECTION 412.13(a)2 FOR ANIDWED TOLERANCE VAAFS. JOINT ONLY. SEE PLANS LAN FOR STRIPua LOGTDNS. ALTERNATIVE DIMENSIONS (SEE NOTE 3) 000000well NIMILwIMIMlg�3 ' ��lllllli►.�III���� MULTI —LANE WITH SPEED CHANGE LANE AND CONCRETE SHOULDERS ALTERNATIVE DIMENE0% (SEE NOTE 3) SHEXILDER 4 OR 12' 1r r �' Date. "'w" "`•"" " Comment. Colorado Department of Transportation CONCRETE STANDARD PLAN NO. Creation Dote: 07Od O6 Initial.: SJR am 4201 Eat ATkaneae Avenue w,r Al M-412-1 Last Modification Dote: 0]/0{/06 Initials; LTA Full Path: am Denver, Colorado 8022E (30303) PAVEMENT JOINTS w.w.dot.state.co..$/D.stgnsuppvt/ �__ �� Faan )3]sg62003 Drawing File Nome: IS Sool100 CAD v>,: ulwStotian ve scale: Not 1n Smla wltA EnyrRn � Project Development j p ent Branch SRJ/LTA Issued t3y. Project Development Branch on July 04, 2006 Sheet No. 1 of 5 JOINT LEGEND (SEE SHEET 5 FOR JOINT OETALS) u— TiLWS E CONIRSCTiON LONOINDNN. CONSmUCRON .�_ DOWELED TRANSVERSE CONnUlCION LO N NLL CONSTRLcn04 L E CONiMC 01w TRANSYME ,---<D— CDNSERu0ON J (SEE NOTE 3) • •• a•• • • &Z'(0218403115W.• •. Computer File Information I ® ® � I Sheet Revisions I Colorodo Department of Tronsportotion 42 1 East Art nsas Avenue n T Denwr, Colorado 80222 Phone: (303) 757-9003 F.: (303) 757-9820 Project Development Branch SRJ LTA � � � CONCRETE pAVEMENT JOINTS STANDARD PLAN NO. Creation Data: 07/04/06 Wliale: sm Last Yadiamtlon Date: 07/04 06 Initials: LTA Full Path: www.dotstate.co.ue eei nSu ort Drowle Fla Name: 4T2cale Not t CID V,n: YioaStotbn M Scale Nol to Scale Unlis G YN Date: Comment, Ivt-a12-1 laced B Pra Development Branch on Jul 04, 2006 Y � P Y Sheet No. 2 of 5 Litt in..' 0 rWl JYlnl YL11W�) A EXPANSION C TRANSVERSE CONTRACTOR! _ - LONGITUDINAL CDNSIRUCnOW DOWELED TRASID6E CONTRACTION LONGINAL �.J CONTRACTION InCONSIRN=U'C TON O IHIAIVELVVIHVLEVVH � TRANSVERSECONSTRUCTION NOTES I. LONGITUDINAL JOINTS SHML BE PLACID ADJACENT TO LANE MARKINGS WHEN POSSIBLE, AND HAVE A MAXIMUM SPICING OF 12 FT,-e IN. (15 FT. IS PERMITTED WITH MONOLITHIC CURB AND CUTTER). 2. CONSTRUCT TRANSVERSE JOINTS PERPMOICUWi TO THE CENTEIGNE OF PAVD4DT .AND EIIIEND THNOUCH THE CURB OR CURB AND GUTTER K 3. PUCE % N. MEN. EXPANSION JOINT F ER N TOP B IN. OF CURB JOINT AT INTERSECTION REALM! RADIUS POINTS 4. THE CONTACTOR SHALL, UNI.MS ONENWISE SHOWN ON THE PLANS, EELJST AND USE A Bae BRENAM AT IMETS, NµHOIFS AND SNWAR SIZE STRUCTURES. SMAUdH SI UMNES SUCH AS VALVE NCI MONUMENT BOXES SHALL NET REQUIRE A BOND BRFAIRR. 5. WHERE A LONGITUDINAL JOINT PASSES LESS TMN 1 R. FROM A CAST -IN -PAVEMENT MANHOLE OR SIMILAR SIZE STRUCTURE, A TYPICAL 2 FT. PAOML JNNT, AS SHOWN IN THE DETAILS, SHALL BE USED. S. TRANSVERSE JOINTS SHALL ETHER INTERSECT THE CENTER OF CIRCULAR MANHOLES AND INLETS OR BE AT LEAST 4 FT. AWAY FROM ME EDGE OF ORCULµ MANHOLES. SEE CURB INLET BOXOUT DETAIL ON SHEET 5. s PERMISSIBLE ALTUMTNE ON JOINTS WITH JOINT S NOT REQUIRED IF CURB AND MANHOLE SMA11 A/011 < 1e' GUTTER IS POURED MONOUIHICMLY r WITH AOIACENT LANE I8' MINIMUM 12' MAX.. CDNC. 6' THICK OR LESS 2' ! B' TIP. 15' MAX., CONE. OVER B' THICK A E * I A A I INLETLE I I SLAMS AND SHOWSILO CURB MET BOXOUT / ILO MµHOIE a GUTTER INTEGRAL ( DEAR ON D * CURB E YIN SHEET 5) t ► 0 D% - - -- - - -- - E D E CURB WI -ET DOXOUT 2' 4 B' D L L (SEE DErAIL ON TIP. WI EIPµSION 2' 4 CTYP. SHEET 5) // iI ' INTEGRAL At JdM FlLiFR XA E ROUNDING OF ANGLE BY CUM RAFT OR FORMING OR SUPFORM PAVING MANHOLE / PERMISSNE. MY BEALIGRED WITH A FRONT OR BACK OF CURB. INA PAVEMENT HIM PAVEMENT TYPICAL CURBED PAVEMENT JOINT LAYOUT Computer File Information Sheet Revisions Colorado Department of Transportation CONCRETE STANDARD PLAN NO. Creation Dote: 07 04 06 InItlola: SJR Dote: Comment. ® L201 Eae! Arkanaaa Avenue M-412-1 Laa ModlRcatlon Oat.: D7/04/O6 Inl[lols: LTA Full Pam: Denwr, Colomdo 80222 PHone: (303) 757-8083 PAVEMENT JOINTS www.doLstote.co.us/DesignSupport/ Fo.: (303) 757-0820 Name: 412010305.dwa Project Development Branch SRJ /I TA � P Issued B Project Development Branch Jul 04, 2006 Sheet No. 3 of 5 CAD MkrTO. LAD VW.: YWaSNlion M SmIW Not la Scde Unlla En W / � on Y leD P Y JOINT LEGEND NOTES (SEE SHEET 5 FOR JOINT DEALS) 1. LONGITUDINAL JOINTS SHALL BE PLACED ADJACENT TO LANE MARKINGS WHEN POSSIBLE, AND HAVE MAXIMUM SPADING OF 12 FT.-6 IN. (15 FT. IS PERMITTED WITH MONOLITHIC CURB AND GUTTER). A EXPANSION 2. CONSTRUCT TRANSVERSE JOINTS PERPENDICULAR TO THE CENTEr61NE OF PAVEMENT AND EXTEND THROUGH THE CURB OR CURB AND (RIMER. TRANSVERSE CONBDCIION * 3. PLACE h M. MM. EXPANSION Jaw nLLER IN TOP 6 IN. OF CURB JOINT AT INTEImc ION RETURN RADIUS POINTS. LONGITUDINAL JCnQ — OONSnIPIIOOON 4. THE CONTRACTOR STYLI, UNLESS OTHERWISE %KNN a1 THE ROB, SELECT AND USE A BBREAKER BREAK DOWELED TRANSVERSE 9INLETS, MANHOLES AND MILAN SIZE STRUCTURE. SMALLER STRUCTURE SUCH AS VALVE AND MONUMENT BOXES 00 NOT REQUIRE A BOND BREAKER, �a1 CONTRACTION 5. WHERE A LONGITUDINAL JOINT WOULD PASS LESS THAN I Fr. FROM A CAST-M-PAVEMENT MANHOLE OR SIMILAR SIZE LON"I'll. SLRUC URE, A TYPICAL 2 Fr. RMAL JOINT. AS SHORN IN THE DETNLS, SHALL BE USED. E CONTAAVTaN B. TRANSVERSE JONTS S OTHER INTERSECT THE Cs311ER OF CIRCULAR MANKLES AND INLETS OR BE AT LEAST LONGITUDINAL 4 FT, AWAY FROM THE EDGE OF CIRCULAR MANHOLES, SEE CURB INLET EXI DETAIL ON SHEET 3. CONSTRUCTION i TS �H1�w ANSVERSE CONSi0.UCnON ONSTR A ► AN D OR O SHOWS AxD OU L C GOITER SHOULDER DC s Y n' I L T L ■ AN FORA JOINT SHALL BE PLACED HERE (1YPJ, WHEN THERE r C 0 SHOULOEN AN EXTRA JOINT SHALL. BE PLACED HERE M.). WHEN THERE C IS MORE THAN A 12 F. CAP BETWEEN A JOINT LOCATED AT A CURB BREAK POINT AND THE PREVIOUS JOINT S MINE iMAN A 12 FT. 6AP BETWEEN A JOINT LOCATED AT C IN ITS IN IN CURB BREAK PART CURB BRFAN POM AND THE PREVIOUS JOINT SHOULDERA alNB eiFiV( POINT # 112' 1V DC L T sHaRDm N C IN IN IN EXPANSION MATERIAL AT C Von C BREAK IN CURB ALIGNMENT (TYPJ CURB MO CURER D OR OE MULTI —LONE HIM PAVEMENT INTERSECTION WITH SPEED CHANGE LANE AND CONCRETE SHOULDERS Computer File Information ® ® Sheet Revisions Colorado Department of Transportation 4201 East ANaneae Avenue T D.nv.r, Caomdo 80222 Phone. (30) 757-9083 CONCRETE PAVEMENT JOINTS STANDARD PLAN NO. Dote: Comment. Creation Date: 07/04/06 initials: SJR M-412-1 Last Modification Dote: 07/04/06 Initials: LTA Full Pott,: ...d.t.state.co.us/Designsupport/ F.: (303) 757-8820 Issued B Project Devela rant Branch on Jul 04, 2DO6 Y 160 P Y Sheet No. 4 of 5 Drawln Fne Nams: a1201oaos.aw ' Proct Development Branch oP SRJ LTA CAD VN.: WaoStatbn V8 SWc Not to Scale Unitc En IRA APPROACH II I OONCWAYE SLAB JdNT ROADWAY SLAB / NOTE / PAVEMENT THICKNESS (h, SHALL BE AS SHOWN ON THE %ANS 12; T THE TRANSVERSE JONT N PAVrARNI II IN7 NrSS (I) ur PAP 97r DOW PM E MONOLITHIC CURB AND CUTTER DIAM IFP PLAIN FOR SHAL 5. BE SAWED TO THE SANE OEM �3' DEPTH AS THE PAVEMENT. 1 c 8 IN N 4 1 IN 1' BOTTOM OF SAW CUT B IN 3 1 S 10 IN N 5 1 25 IN BRIDGE APPROACH 10 IN > I S 15 IN N W 1 50 IN %' SUM SURFACE REINFORCING SIZE TABLE /2 „ ; $lU E WED T iFAAAR .. tT �'7� 2� rtrtT BRAm BOND BREAKER BRNERM laTHAN TRANSVERSE LONGITUDINAL LONGITUDINAL LONGITUDINAL CONTRACTION JOINT CONTRACTION JOINT CONSTRUCTION JOINT CONSTRUCTION JOINT tY Nx. EXPANSION JOINT t MANTAIME WEAKENEDPLANE WEAKENED USE ONLY IFT2 B WL tw USE ONLY IF i < 9 IN. OB aROO OE PLANE JOINT) PLANEJONT) FORN ONLY FEMLE NEYWO' . .�:. A NEYMM 6 k1wom TO FAORATE IRE OF BENT a a' GRADE 40 THE WARS OR APPROVED TWO PIECE • • ! A T/2 ODMVLIdd le' J1. WE SIRS, o o. 1 LONGITUDINAL TRANSVERSE CONSTRUCTION JOINT CONSTRUCTION JOINT JOW SEALANT � JOIN SEALANT . SE DOWEL SPICING IN TRAVEL LANES ON THE PLANS. A /2 PoAAO WEEDED Y O ce DOWELED TRANSVERSE CONTRACTION JOINT SEAL AT CONSTRUCTION JOINT • T/O MI4 :.2/e' •DUI flAxER INTO • SIV L BE L4T TOR UONG1NBNU. JOWM ALONG S AN 14 FT. IN WORN, SAWED JOINT —1 INLET OR MANHOLE CAST IN PAVEMENT INSTALL TRANMiE J00IT AT D G BORN WONaR WANERS IF B0K0Ur Is e Fr. OR tmm e' NIN. APRON C �. RECESS CURB INLET BOXOUT • INLET OR 4.1•TAPER LLVNIOIE TO NEW APRON 1r T (SEE JOIN QA BETAL) MN BOND BREAKER %' RECESS SECTION A —A m MEEET STRUCTURE SECTION B—B BOND BREAKER SERI WE COP® OF PLASM SHEEP, BUILDING PIPER OR DOER APPROVED NATFTaL ONT PREVENTS BDWM bOm u�r�Ne mTormauon ® ® ZEE) Dote: aneex maymons Comments GOlorado Deportment of Transportation 4201 Emt Ademeawn e Aue T Denwr, Cciamda 80222 Phan: (303) 757-9083 Fox: (303) 757-9620 Project Development Branch SRJ/LTA CONCRETE PAVEMENT JOINTS STANDARD PLAN NO. Creotlon Dot¢ 0704 6 Initlaic SJR Olt ModlRaotion Dote: 07 04 06 Initial.: LTA M412-1 Full Path: www.dot.stote.m.us esi Support Drawing File Name: 412010505.dw CAD Va.: MlcroStotim V6 Scala: Not to Scale unite En,10 Issued By, PrOject Development Bronch on July 04, 2006 Sheet No. 5 of 5 SECTION 03500 PROJECT MAPS Proiect area in alphabetical order: Buckingham Capital Hill City Park Heights 2 Horsetooth Central Horsetooth West McHugh Stover North W Foothills Pkwy Westbrook 1 Note: The areas identified in section 3500 are for the crital path work for the 2015 season. Additional areas may be added once these are completed, in preparation for the 2016 asphalt season. These areas may change due to timelines or unforeseen circumstances. lk Cape Cape Cape Cape 3 Ln m < a CD T ' 1^ `OG (D ` 7 0 3 ~' � CD m cl) O I I W ^_ CD O N N �• ��/� OO N O N L• CD N C CD 3 CD n N m m z D V N � om Z cn D Z v n �m au O O < �fDD n a o 3 c Co ' 0 ^ m a y — cn n A Vl M �/ Fort Collins Streets Legend ZSurface treatment —Reconstruct Overlay ®Concrete pavement STREET MAINTENANCE PROGRAM (SMP) 2015 Maintenance Projects Map 9 of 45 N Revised November 24, 2014 w r s 1 W U' N W C _ Cape Cape Sycamore St rn Beech St c JO � a Z5 Cherry St POL POL n Cherry St m a Y y W a m 3 m a U Go h a .c y Cape Cape Maple St Ct -' -,, Juniper Ct a> U Laporte Ave a a U O C W � m Z Z @ Z Capitol Hill CONTRACT DOCUMENTS TABLE OF CONTENTS Section Pages BID INFORMATION 00300 Bid Form 00300-1 - 00300-3 CONTRACT DOCUMENTS 00500 Agreement Forms 00500-1 00510 Notice of Award 00510-0 00520 Agreement 00520-1 - 00520-6 00530 Notice to Proceed 00530-1 00600 Bonds and Certificates 00600-1 00610 Performance Bond 00610-1 - 00610-2 00615 Payment Bond 00615-1 - 00615-2 00630 Certificate of Insurance 00630-1 00635 Certificate of Substantial Completion 00635-1 00640 Certificate of Final Acceptance 00640-1 00650 Lien Waiver Release (Contractor) 00650-1 - 00650-2 00660 Consent of Surety 00660-1 00670 Application for Exemption Certificate 00670-1 - 00670-2 CONDITIONS OF THE CONTRACT 00700 General Conditions 00700-1 - 00700-34 Exhibit GC -A GC -Al - GC-A2 00800 Supplementary Conditions 00800-1 - 00800-2 00900 Addenda, Modifications, and Payment 00900-1 00950 Contract Change Order 00950-1 - 00950-2 00960 Application for Payment 00960-1 - 00960-4 SPECIFICATIONS NAS SURETY GROUP NORTH AMERICAN SPECIALTY INSURANCE COMPANY WASHINGTON INTERNATIONAL INSURANCE COMPANY GENERAL POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS, THAT North American Specialty Insurance Company, a corporation duly organized and existing under laws of the State of New Hampshire, and having its principal office in the City of Manchester, New Hampshire, and Washington International Insurance Company, a corporation organized and existing under the laws of the State of New Hampshire and having its principal office in the City of Schaumburg, Illinois, each does hereby make, constitute and appoint: RUSSELL D. LEAR, DARLENE KRINGS, K'ANNE E. VOGEL, ROYAL R. LOVELL, KAY DELL, DIANE F. CLEMENTSON, KELLY T. URWILLER, WESLEY J. BUTORAC, and STEVEN J. BLOHM JOINTLY OR SEVERALLY Its true and lawful Attomey(s)-in-Fact, to make, execute, seal and deliver, for and on its behalf and as its act and deed, bonds or other writings obligatory in the nature of a bond on behalf of each of said Companies, as surety, on contracts of suretyship as are or may be required or permitted by law, regulation, contract or otherwise, provided that no bond or undertaking or contract or suretyship executed under this authority shall exceed the amount of: FIFTY MILLION ($50,000,000.00) DOLLARS This Power of Attorney is granted and is signed by facsimile under and by the authority of the following Resolutions adopted by the Boards of Directors of both North American Specialty Insurance Company and Washington International Insurance Company at meetings duly called and held on the 9th of May, 2012: "RESOLVED, that any two of the Presidents, any Managing Director, any Senior Vice President, any Vice President, any Assistant Vice President, the Secretary or any Assistant Secretary be, and each or any of them hereby is authorized to execute a Power of Attorney qualifying the attorney named in the given Power of Attorney to execute on behalf of the Company bonds, undertakings and all contracts of surety, and that each or any of them hereby is authorized to attest to the execution of any such Power of Attorney and to attach therein the seal of the Company; and it is FURTHER RESOLVED, that the signature of such officers and the seal of the Company may be affixed to any such Power of Attorney or to any certificate relating thereto by facsimile, and any such Power of Attorney or certificate bearing such facsimile signatures or facsimile seal shall be binding upon the Company when so affixed and in the future with regard to any bond, undertaking or contract of surety to which it is attached." �lnlltlllll///// LL77 JQ0GtfU7Y/ By e svP: o..Po }2~ �SEAL W% S�`�G�4 a •'' IAi n Steven P. Anderson, Senior Vice President of Washington International Insurance Company ' - %1973L m _ �eWlq � &Senior Vice President of North American Specialty Insurance Company � O: di/O# By David M. Layman. Vice President of Washington International Insumnae Company ory"s11P' & Vice President of North American Specialty Insurance Company IN WITNESS WHEREOF, North American Specialty Insurance Company and Washington International Insurance Company have caused their official seals to be hereunto affixed, and these presents to be signed by their authorized officers this 1 lth day of June 2014 North American Specialty Insurance Company Washington International Insurance Company State of Illinois County of Cook ss: On this 1 lthday of June , 2014 , before me, a Notary Public personally appeared Steven P. Anderson , Senior Vice President of Washington International Insurance Company and Senior Vice President of North American Specialty Insurance Company and David M. Layman , Vice President of Washington International Insurance Company and Vice President of North American Specialty Insurance Company, personally known to me, who being by me duly swom, acknowledged that they signed the above Power of Attorney as officers of and acknowledged said instrument to be the voluntary act and deed of their respective companies. [Notary OFFICIAL SEAL" ONNA D. SKLENS Public, State of Illinois Donna D. Skier, Notary Public y Commission Expires 10 ON2015 I, Jeffrey Goldberg , the duly elected Assistant Secretary of North American Specialty Insurance Company and Washington International Insurance Company, do hereby certify that the above and foregoing is a true and correct copy of a Power of Attorney given by said North American Specialty Insurance Company and Washington International Insurance Company, which is still in full force and effect. IN WITNESS WHEREOF, I have set my hand and affixed the seals of the Companies this 13th day of February 20 15 Jeffrey Goldberg, Vice President & Assistant Secretary of Washington International Insurance Company & North American Specialty Insurance Company W Sheldon Dr I � m � City Park Ave n a d ro s d 3 m ro ti ro m m f m v m J ickso 3 3 A te Miller Dr Cape v m c m CD m 2 m A W Coy Dr Bluebell St Cape Scott Ave Cape Aster St Wagner Dr E Coy Dr Cape IMOD ro S Shields St I CO m c m FT n Del Norte PI 1 t antl e3stA aluoW II O to CD a m 1< m CD m 9 d) II 0 m O CD O OO (D Co y. (D C 0) 0 0) N 3 (D 7 n N m m D z m Z N � CD " Z CYID Z a� n 3m M ;0 sv O m D 0 3 a O O .-. m A O —h �. 0 N 0 'aLrl fA v City of Flirt Collins Streets Legend Surface treatment —Reconstruct Overlay —Concrete pavement STREET MAINTENANCE PROGRAM (SMP) 2015 Maintenance Projects Map 21 of 45 N Revised November 24, 2014 W E S Horsetooth central 0 1< m S9t Nco �� \.O * Cafe Walsh Wa ni �O Horsetooth Ct y 3 ^~'' n (D ` , v Platte .�. c O � v Ct (D � o (D d 0 n N 0 o m (n Platte Dr chi _ < o m Windom St ti 3 Moor Ln Mead St- ----------------- Bronco Lni Silver o Oaks PI n Dalton Dr l M J n Arizona � fl'I &iIverleaOf Ct� ty_ J� r— f z y� °Go + — 0� Z low N � cZ Z -J i E Z a'so m 2 �C? C I � O o O CD Nevada n rt OC S Taft Hill Rd Z 6 D S ,� w 3 N O' ,V ^ Q N N _ ti � F o � o ar � N �~ N (n 0 N �aN 0 O � ¢ d °++' w� Z Q� Z r w C � N Z_ AA` Q zQ�N � 3 w w ix � I,I NI a / W 1 IS Aawoa;uow o" e i Q '------ IS SASH 1S Me9 S` V N` Q IS PJOIIV IS AIW3 O� Q Qr d L W a W m IS upRBd W J'' 0 O 0' a IN IS LPRM 2 II 0 X cn T�T1 N m m y Z N � p m Z �D Z O n �m rt -D OO m a m D 0 0 3 3 0, ��. O^ Cl) A Z O A rt V City of Fit Collins Streets [L":end Surface treatment —Reconstruct Overlay ®Concrete pavement STREET MAINTENANCE PROGRAM (SMP) 2015 Maintenance Projects NN w+ E S Recon /r Recon co Map 41 of 45 Revised November 24. 2014 E Foothills W Foothills Pkwy City of STREET MAINTENANCE PROGRAM (SMP) Fort Collins 2015 Maintenance Projects Streets Map 44 of 45 sgend N Revised November 24, 2014 Surface treatment —Reconstruct w E —Overlay Concrete pavement s Westbrooke 1 Ciof Foort Collins �� Streets Legend Surface treatment —Reconstruct Overlay Concrete pavement STREET MAINTENANCE PROGRAM (SMP) 2015 Maintenance Projects Map 45 of 46 N Revised November 25, 2014 W E s I i t E Oak St J { r' �It 1$k E Olive St c c d 0 U � M 14 E Magnolia St h 0 5 o, e J Cr E Mulberry St m I U c E Myrtle St y {C� G 4 Y _ 55 m U65 G o N fn yy m m: @ m aN � s' a E Laurel St E Laurel St Eastdala Or Whedbee SECTION 04000 EROSION CONTROL AND INLET PROTECTION INDEX OF ENVIRONMENTAL STANDARD OPERATING PROCEEDURES (ESOP) New Construction Activities for Municipalities 1 of 2 Street, Curb, and Gutter Replacement and Construction 1 of 3 Street, Curb, and Gutter Maintenance 1 of 3 Spill Prevention and Response 1 of 4 Utility and Storm Sewer System Maintenance 1 of 4 Utility and Storm Sewer System Replacement and Construction 1 of 3 Power Washing 1 of 3 Vehicle Fueling 1 to 3 Outdoor Fleet Maintenance 1 of 4 Heavy Equipment and Vehicle Maintenance 1 of 4 New Construction Activities for For More Information Name Municipalities Address City, State Description Phone This fact sheet covers new construction activities disturbing less e-mail than one acre not subject to a CDPS Construction permit. New construction includes, but is not limited to buildings, structures, Possible Pollutants capital improvements, roadways, and recreational components Sediment such as trails, restrooms, and other structures. Procedures Chemicals provided are general in nature and can be applied to any scale Organics or type of municipal construction. Trash When services are contracted, this written procedure should be Good Housekeeping provided to the contractor so they have the proper operational Waste Management procedures. In addition, the contract should specify that the contractor is responsible for abiding by all applicable municipal, Employee/Contractor Training state, and federal codes, laws, and regulations. Proper Cleanup and Disposal Procedures Procedures Related Procedures Obtain all applicable federal, state, and local permits for Heavy Equipment and Vehicle construction projects. Maintenance ■ The Colorado Stormwater Construction General Parks and Open Space permit applies to construction sites disturbing one Maintenance acre or more, or less than one acre but part of a larger Spill Prevention and Response common plan of development. Street, Curb, and Gutter Replacement and A larger common plan of development is defined as Construction a contiguous area where multiple separate and Utilities and Storm Sewer distinct construction activities may be taking place at System Replacement and different times on different schedules under one Construction plan. Vehicle Fueling ■ A dewatering permit may be required if construction activities require the removal and discharge of groundwater offsite. , ■ A U.S. Army Corp of Engineers (USAGE) Section 404 Permit may be needed if the work will be conducted in or impact waters of the United States, including wetlands, washes, drainages, ditches, creeks, streams, and rivers. Applicable sediment and erosion controls may be installed, such as inlet protection, silt fence, sediment traps, erosion control logs, check dams, and vehicle tracking control. Sediment and erosion controls will be Page 1 of 2 SECTION 00630 CERTIFICATE OF INSURANCE CONTRACTOR shall insert his own standard form for Certificate of Insurance. • installed and maintained in accordance with approved design criteria and/or industry standards. • Material stockpiles will not be stored in stormwater flow lines. Temporary sediment control will be used during temporary, short-term placement while work is actively occurring. • Where feasible, grading activities should be scheduled during dry weather. • Best management practices will be periodically inspected and maintained as necessary. • Waste containment for concrete washout, masonry, paint, trash and other potential pollutants will be available when these activities are being conducted. • Where practicable, non-structural controls will be used, such as phased construction, dust control, good housekeeping practices, and spill prevention and response. Employee Training • Train applicable employees who perform new construction activities on this written procedure. Information regarding how to avoid and report spills will be presented during the training. Periodically conduct refresher training on the SOP for applicable employees who perform new construction activities. Records The following records could be used to document activities performed: • Records of employee training with sign -in sheet. References City of Centennial SOP: New Construction SOP, August 2007. Mesa County, Municipal Operations and Maintenance Progranz, July 2005. Page 2 of 2 Street, Curb, and Gutter For More Information Name Replacement and Address Construction City, State Phone Description e-mail Procedures involving the replacement and Possible Pollutants construction of streets, curbs, and gutters have the Fine-grained sediment potential to impact stormwater quality. Materials involved in these activities should be used efficiently Organics and disposed of properly. Oil Saw -cut slurry When services are contracted, this written procedure Trash should be provided to the contractor so they have the Good Housekeeping proper operational procedures. In addition, the contract should specify that the contractor is Dumpster/Waste Management responsible for abiding by all applicable municipal, Employee/Contractor Training state, and federal codes, laws, and regulations. Proper cleanup and disposal procedures Procedures Dry cleaning methods General Related Procedures . Obtain all applicable federal, state, and local Spill Prevention and Response permits for construction projects. Street Sweeping The Colorado Stormwater Construction Street Sweeper Cleaning and General permit applies to construction sites Waste disturbing one acre or more, or less than one Street, Curb and Gutter acre but part of a larger common plan of Maintenance development. • A larger common plan of development is defined as a contiguous area where multiple separate and distinct construction activities may be taking place at different times on different schedules under one plan. ■ A dewatering permit may be required if construction activities require the removal and discharge of groundwater offsite. ■ A U.S. Army Corp of Engineers (USACE) Section 404 Permit may be needed if the work will be conducted in or impact waters of the United States, including wetlands, washes, drainages, ditches, creeks, streams, and rivers. • Applicable sediment and erosion controls may be installed, such as inlet protection, silt fence, sediment traps, erosion control logs, check dams, and vehicle tracking control. Sediment and erosion controls will be installed and maintained in accordance with approved design criteria and/or industry standards. • When saw cutting, ensure that no slurry enters the storm drain. Let the slurry dry, sweep it up, and properly dispose of the sweepings or vacuum while saw cutting. • Do not perform concrete or asphalt paving work during wet conditions whenever possible. • Monitor construction equipment for leaks and use drip pans as necessary. • Leaking material containers should be properly discarded and replaced. • Store materials in containers under cover when not in use and away from any storm drain inlet. • Wash out mixers, delivery trucks, or other equipment in the designated concrete washout area only. • Locate concrete washout, portable toilets, and material storage away from storm drain inlets. • Material stockpiles will not be stored in stormwater flow lines. Temporary sediment control will be used during temporary, short-term placement while work is actively occurring. • Sweep or vacuum the roadway as needed, during construction and once construction is complete. • Best management practices will be periodically inspected and maintained as necessary. • Where practicable, non-structural controls will be used, such as phased construction, dust control, good housekeeping practices, and spill prevention and response procedures. • Where practicable, non-structural controls will be used, such as phased construction, dust control, good housekeeping practices, and spill prevention and response. Bridge Construction • Do not transfer or load any materials directly over waterways. • Suspend drop cloths or nets below any bridgework where wastes, scraps, or drips might be spilled into a waterway. Concrete Work • Minimize the drift of chemical cure on windy days by using the curing compound sparingly and applying it close to the concrete surface. • Ensure there is a concrete truck washout area available or require the contractor to wash out at the batch plant. • Whenever possible, recycle concrete rubble; otherwise, dispose of it as solid waste. Asphalt Work Control the placement of road base or asphalt used in embankments or shoulder backing; do not allow these materials to fall into any storm drain or watercourses. Whenever possible, recycle asphalt. If recycling is not possible, dispose of as solid waste. Painting and Striping If possible, schedule painting and striping projects during dry weather. Use thermoplastic or epoxy markings in place of paint whenever feasible. Use care to prevent splashing or spilling of any liquid material. Follow the Spill Prevention and Response procedure should a spill occur. Employee Training • Train applicable employees who perform street, curb, and gutter construction on this written procedure. Information regarding how to avoid and report spills will be presented during the training. Periodically conduct refresher training on the SOP for applicable employees who perform street, curb, and gutter construction. Records The following records could be used to document activities performed: • Records of employee training with sign -in sheet. References City of Centennial, Department of Public Works: Asphalt and Concrete Program, No Date. City of Centennial, Department of Public Works: Asphalt Program, No Date. PACE, Stormwater Best Management Practices: Street Maintenance, No Date. Optional Additional Resources Concrete truck washout BMP specifications. Gravel road maintenance procedures. Street, Curb, and Gutter For More Information Name Maintenance Address City, State Description Phone Street, curb, and gutter activities include concrete and e-mail asphalt installation, maintenance, repair, and replacement; bridge maintenance; and painting and Possible Pollutants striping. Procedures involving the maintenance of Fine-grained sediment streets, curbs, and gutters have the potential to impact Organics stormwater quality. Materials involved in these Oil activities should be used efficiently and disposed of Saw -cut slurry properly. Trash When services are contracted, this written procedure Good Housekeeping should be provided to the contractor so they have the Dumpster/Waste Management proper operational procedures. In addition, the Employee/Contractor Training contract should specify that the contractor is Proper cleanup and disposal responsible for abiding by all applicable municipal, procedures state, and federal codes, laws, and regulations. Dry cleaning methods Procedures Related Procedures General Spill Prevention and Response • Protect storm drain inlets and drains with curb Street Sweeping socks, rock berms, inlet protection, or drain Street Sweeper Cleaning and covers/mats prior to any maintenance activity. Waste • When saw cutting ensure that no slurry enters the storm drain, let the slurry dry, sweep it up, and properly dispose of the sweepings. • Do not perform concrete or asphalt patch work during wet conditions whenever possible. • Leaking material containers should be properly discarded and replaced. • Store materials in containers under cover when not in use and away from any storm drain inlet. • Monitor equipment for leaks and use drip pans as necessary. • Sweep or vacuum the roadway once maintenance activities are complete. Bridge Maintenance • Do not transfer or load any materials directly over waterways. • Secure lids and caps on all containers when on bridges. • Suspend drop cloths or nets below any bridgework where wastes, scraps, or drips might be spilled into a waterway. Concrete Maintenance Minimize the drift of chemical cure on windy days by using the curing compound sparingly and applying it close to the concrete surface. • Ensure there is a concrete truck washout area available or require the contractor to wash out at the batch plant. • Whenever possible, recycle concrete rubble; otherwise, dispose of it as solid waste. Asphalt Maintenance Sweep to minimize sand and gravel from new asphalt from getting into storm drains, streets, and creeks. Do not allow asphaltic concrete grindings, pieces, or chunks used in embankments or shoulder backing to enter any storm drain or watercourses. Apply temporary perimeter controls. Install silt fence until the structure is stabilized or permanent controls are in place. Whenever possible, recycle broken asphalt. If impossible, dispose of as solid waste. Drainage inlet structures shall be covered with inlet protection during application of seal coat, tack coat, slurry seal, and/or fog seal. Painting and Striping • If possible, schedule painting and striping projects during dry weather. • Use thermoplastic or epoxy markings in place of paint whenever feasible. • The pre -heater for thermoplastic striping and the melting tanks used during pavement marking must be filled carefully to prevent splashing or spilling of materials. Leave 6 inches at the top of pre -heater and the melting tanks to allow room for material to move and splash when vehicles are deadheaded. Employee Training Train applicable employees who perform street, curb, and gutter maintenance on this written procedure. Information regarding how to avoid and report spills will be presented during the training. Periodically conduct refresher training on the SOP for applicable employees who perform street, curb, and gutter maintenance. Records The following records could be used to document activities performed: • Records of employee training with sign -in sheet. References City of Centennial, Department of Public Works: Asphalt and Concrete Program, No Date. City of Centennial, Department of Public Works: Asphalt Program, No Date. PACE, Stormwater Best Management Practices: Street Maintenance, No Date. Optional Additional Resources Concrete truck washout BMP specifications. Gravel road maintenance procedures. Spill Prevention and For More Information Name Response Address City, State Description Phone Due to the type of work and the materials involved, many e-mail activities that occur either at a municipal facility or as part of municipal operations have the potential for accidental Possible Pollutants spills. Some municipal facilities operate under Spill Chemicals Prevention Control and Countermeasures (SPCC) plans Toxics that include procedures for spill response. Proper spill oil response planning and preparation enables employees and Paint contractors to effectively respond to problems and Fuel minimize the discharge of pollutants to the storm sewer system. Good Housekeeping Waste Management When services are contracted, this written procedure should be provided to the contractor so they have the Employee/Contractor Training proper operational procedures. In addition, the contract Proper cleanup and disposal should specify that the contractor is responsible for procedures abiding by all applicable municipal, state, and federal Related Procedures codes, laws, and regulations. Fertilizer, Pesticide, and Herbicide Application Procedures Heavy Equipment and Vehicle Spill Prevention Maintenance • Keep work areas neat and well organized. Material Storage • Maintain a Material Safety Data Sheet (MSDS) for Materials Management each hazardous chemical. Follow the Outdoor Outdoor Vehicle Maintenance Material Storage procedures. Vehicle Fueling Provide tight fitting lids for all containers. • Keep containers clearly labeled. Labels should provide name and type of substance, stock number, expiration date, health hazards, handling suggestions, and first aid information. • Store containers, drums, and bags away from direct traffic routes to prevent accidental spills. • Inspect storage containers regularly for signs of leaking or deterioration. • Replace or repair leaking storage containers. • Use care to avoid spills when transferring materials from one container to another. Page 1 of 4 • Use powered equipment or get assistance when moving materials to and from a storage area. Use care to prevent puncturing containers with the equipment. • Do not wash down or hose down any outdoor work areas or trash/waste container storage areas except where wash water is captured and discharged into the sanitary sewer (if approved). • Conduct periodic inspections to ensure that materials and equipment are being handled, disposed/recycled, and stored correctly. • Provide adequate spill kits or lockers with sufficient equipment and supplies necessary for each work area where the potential for spills or leaks exists. • Inspect each spill kit or locker regularly and after each spill response. Replace any spent supplies or repair any equipment that is worn or not suitable for service. • Stock adequate personal protective equipment. Spill Response Safety Consider safety at all times. Anticipate and avoid all likely hazards. Never approach, contact, or sample an unknown substance. If a highly toxic or flammable substance is discovered, staff should leave the immediate area and contact the appropriate identified response authority, such as the fire department. If there is any question about a substance, contact the appropriate identified response authority or other designated representative. Procedures • Stop the leading edge of the spill. Block or divert the spill to avoid discharge to the storm sewer system and to minimize the area requiring cleanup. • Determine the source of the spill and stop the spill at its source by closing a valve, plugging a leak, or setting a container upright. Transfer material from a damaged container. • Identify the material and volume spilled. Contact the appropriate identified response authority or other designated representative if you cannot identify the material and its properties. • Refer to the MSDS to determine appropriate personal protective equipment, such as gloves and safety glasses and appropriate cleanup methods. • Clean up spills immediately to prevent spreading of wastes by wind, rain, and vehicle traffic and potential safety hazards. • Use sand absorbents or socks, pillows, or pads to quickly capture spilled liquid and properly dispose of all clean-up materials. Use dry clean-up methods only. • Complete all necessary reports. Spill Reporting • A spill of any chemical, oil, petroleum product, or sewage that enters waters of the state of Colorado (that include surface water, ground water, and dry gullies and storm sewers leading to surface water) must be reported immediately to the Colorado Department of Public Health and Environment. • Release of a substance into a storm drain, or onto a parking lot or roadway as part of a storm sewer leading to surface water, is reportable. However, if the material can be contained and cleaned within the storm sewer system to the degree that a subsequent flow in the storm sewer will not flush the substance to waters of the State, it may not need to be reported. • Contact the appropriate identified response authority within the municipality or other designated representative and be prepared to provide details needed to report the spill to the necessary agencies. • Detailed spill reporting guidance can be found at hu: / /w-ww.cdl2he.state.co.us/op/wgcc/Resources/Guidance/sl2illguidance.12df andft://www.cdphe.state.co.us/hm/si2illsandreleases.htm Employee Training Train applicable employees who perform spill prevention and response on this written procedure. Information regarding how to avoid and report spills will be presented during the training. • Periodically conduct refresher training on the SOP for applicable employees who perform spill prevention and response activities. Records The following records could be used to document activities performed: • Records of any major spills and the action taken. • Records of employee training with signAn sheet. References City of Centennial, Department of Public Works: Good Housekeeping, No Date. City of Centennial, Department of Public Works: Materials Management, No Date. City of Centennial, Department of Public Works: Spill Prevention and Control, No Date. City of Golden, Stormwater Quality Pollution Prevention Guide for Municipal Operations: Parks Department Golf Course, January 2004. City of Lafayette, Spill Clean Up, No Date. Colorado Department of Public Health and Environment, Environmental Spill Reporting, January 2009. r`lianHF ARgAq NORRTI ACORD.CERTIFICATE OF LIABILITY INSURANCE DATEuz/2o1s4/2015YYY) THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER & Peterson Ins., Inc. P. O. BOX 578 NAME, Jennifer Winter E 970 506-3206 970 506 6846Flood PONNoEa[ : NC No E-MAIL ADDRESS: JWinter oodPe terson.com Greeley, CO 80632 970 356-0123 INSURER(S) AFFORDING COVERAGE NAIC # INSURER A: Bituminous Casualty Corporation 20095 INSURED INSURERB: Pinnacol Assurance 41190 Northstar Concrete, Inc. 1220 S. Garfield Avenue INSURER C Loveland, CO 80537 INSURER D : INSURER E INSURER F : COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDLSUBR MR WVD POLICY NUMBER POLICY EFF MMIDDNYYY POLICY EXP MM/DD LIMITS A GENERAL LIABILITY X COMMERCIAL GENERAL LIABILITY CLAIMS -MADE a OCCUR X PD Ded:1,000 i CLP3603459 4/26/2014 04/2612011 EACHOCCURRENCE$1 000,000 s300000 PREMISES Eenence MED EXP (Any one person) a 1 O 000 PERSONAL & ADV INJURY $1 000 000 GENERAL AGGREGATE s2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: POLICY X PEO- LOC PRODUCTS -COMPIOP AGG E2000,000 $ \ AUTOMOBILE LIABILITY JANY AUTOBODILY ALL OWNED SCHEDULED AUTOSAUTOSHIRED AUTOS X NON -OWNED AUTOS oth Car CAP3603460 /26/2014 0*261201 COBINEDaccidenSINGLE LIMIT 1,000,000 INJURY(Per person) S BODILY INJURY (Per accident) S S $ PROPERTY DAMAGE Per accident'We A X UMBRELLA As EXCESS LIAB �( OCCUR CLAIMS -MADE CUP2804943 26/2014 04/26/201 EACH OCCURRENCE $1 000 000 AGGREGATE $1 o00000 DED I X RETENTION$10000 E B WORKERS COMPENSATION AND EMPLOYERS' LIABILITYER ANY PROPRIETOR/PARTNER/EXECUTIVE YI N OFFICERIMEMBER EXCLUDED? � (Mandatory in NH) H yes, describe under DESCRIPTION OF OPERATIONS below NIA 4108060 7/01/2014 07/01/201 U- X T STATOTH- E.L. EACH ACCIDENT E7 OOO OOO EL. DISEASE - EA EMPLOYEE $1 000 000 E.L. DISEASE - POLICY LIMIT $1 000,000 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (Attach ACORD 101, Additional Remarks Schedule, If more space is required) RE: Concrete Maintenance Project, Phase II; 2015 Renewal Bid No. 7509 City of Fort Collins listed as an Additional Insured as respects General Liability, including completed operations, and Auto Liability. Insurance is primary and non-contributory. City of Fort Collins 281 N. College Avenue Fort Collins, CO 80524 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE ©1988.2010 ACORD CORPORATION. All rights reserved. ACORD 25 (2010105) 1 of 1 The ACORD name and logo are registered marks of ACORD #S974743/M901770 JZS Mesa County, Municipal Operation and Maintenance Program, July 4, 2005. USEPA Menu of BMP: Spill Response and Prevention, cfpub.epa.gov/npdes/stormwater/menuofbmps/, accessed July 5, 2009. For More Information Utility and Storm Sewer Name System Maintenance Address City, State Phone Description This procedure addresses utility and storm sewer system e-mail maintenance. Utilities include power, sanitary sewer, Possible Pollutants water conveyance systems, and the storm sewer system. Sediment Power includes electrical and gas utilities. Maintenance Nutrients of power may require excavation and reinstallation of Metals lines including open cut trenching or directional boring Hydrocarbons in landscaped areas or street right of way. Electrical and Trash gas line maintenance ensures services are provided to Good Housekeeping businesses and households without interruption. Waste Management The sanitary sewer system is cleaned as part of routine Employee/Contractor Training maintenance and on an emergency basis. Without proper maintenance, sanitary sewer back-ups and Proper Cleanup and Disposal overflows may occur and can result in potential property Procedures damage and significant health concerns if not properly Related Procedures managed. Heavy Equipment and Vehicle Maintenance Water conveyance systems are flushed and pressure tested as part of routine maintenance. Potable water Parks and Open Space Maintenance systems must be properly maintained to ensure delivery of water that meets State and Federal health standards. Spill Prevention and Response Failures result in water main breaks that can cause Street, Curb, and Gutter property damage including erosion. Replacement and Construction The storm sewer system is cleaned as part of routine Utilities and Storm Sewer maintenance and on an emergency basis in the event of System Replacement and flooding. Maintenance will remove pollutants and Construction ensure the system functions properly to avoid flooding. Vehicle Fueling Flooding, ponding, and uncontrolled sheet flow can result in property damage and increased soil erosion. When services are contracted, this written procedure should be provided to the contractor so they have the proper operational procedures. In addition, the contract should specify that the contractor is responsible for abiding by all applicable municipal, state, and federal codes, laws, and regulations. Page 1 of 4 Procedures General • Conduct routine inspection and maintenance on utility and storm sewer systems. • Where feasible, schedule maintenance activities during dry weather. • Monitor the jet/vacuum truck closely for leaks and use a drip pan as needed. • Wash and fuel the jet/vacuum truck per the Heavy quil2ment/Vehicle Maintenance procedure. • Properly dispose of vac truck contents. • Stay alert for any signs of illicit discharges. This includes "dry weather' flows or pipes or hoses emptying directly into waterways or the storm sewer system. • Report any suspicious discharges or dumping to your supervisor. Electrical and Gas Utility Maintenance • To prevent sediment, mud and particles generated by power utility maintenance from entering the stormwater system implement inlet protection, perimeter control, street sweeping, vehicle tracking control, stockpile management and material management BMPs. • Restore landscaped or hardscaped areas promptly. Potable Water Line Flushing • Remove any debris from the gutter that could wash away with the water. If possible, sweep the flow line before flushing the line. • Direct the water so that it is not flowing over exposed soil areas in order to minimize erosion. Water Line Breaks • Contain spoils by building berms or installing rock socks around the area of disturbance. • Dewater the excavation by using a vac truck. • Discharge high chlorine water to the sanitary sewer via the nearest manhole, to a water truck, through a dechlorinating diffuser, or other method of dechlorination. • Remove sediment from the street, curb, gutter and storm inlets as needed immediately following the repair. • Where needed, install a temporary patch or repave as soon as practicable following the repair. • If necessary, revegetate areas as soon as practicable following the repair. Sanitary Sewer Backup Clear line stoppage to prevent backup into house basements and manhole overflows. Page 2 of 4 Contain overflows by using emergency generator, pump and/or a vac truck to intercept flows. It may be necessary to construct additional containment. Clean up spills by washing and vacuuming the affected areas. Lime may need to be applied for disinfection of affected areas. Lime must be removed once disinfection is complete. Storm Sewer System Pipes, Catch Basins, Inlet and Outlet Structures, and Culverts Clean storm sewer system by manual cleaning or jetting the pipes using a jet/vacuum truck to remove the material. Do not temporarily store collected storm system cleaning debris adjacent to any surface water, storm drain inlet, or drainageway. Storm sewer system maintenance wastes may be either non -hazardous or hazardous. Solid non -hazardous waste may be disposed in a sanitary landfill or recycled. Liquid non -hazardous waste must be evaporated before disposing of it into the landfill or discharged to the sanitary sewer system with the approval of the local wastewater treatment plant. Hazardous waste, as defined under Colorado Hazardous Waste Regulations (6 CCR 1007-3), must be transported and disposed of at a permitted disposal or treatment facility. Replace or maintain "no dumping' stencils or plaques as necessary. Remove trash from trash racks and grated openings. Detention and Retention Ponds Inspect the outlet works and remove trash or vegetation from the trash racks and grates. • Inspect side slopes of the pond for erosion and reestablish vegetation as needed. • Remove and service fountains and aerator motors as recommended. • Report any suspected water quality problems such as a change in growth or appearance of vegetation. • Report excessive sediment accumulation, standing water beyond the designed drain down time or damage requiring additional maintenance. Drainageways Drainageways include drainage channels, ditches, grass swales, and washes. Inspect drainageways for erosion and repair if necessary. Remove and properly dispose of trash and debris from the drainageways. Remove sediment which could impede flow in drainageways. Leave an unmown buffer when mowing adjacent to drainageways to filter pollutants. Do not leave grass clippings in or next to the drainageway. Do not apply landscape chemicals in the buffer area. Page 3 of 4 Employee Training • Train applicable employees who perform utility and storm sewer system activities on this written procedure. Information regarding how to avoid and report spills will be presented during the training. • Periodically conduct refresher training on the SOP for applicable employees who perform utility and storm sewer system activities. Records The following records could be used to document activities performed: • Records of employee training with sign -in sheet. References Center for Watershed Protection, Municipal Pollution Prevention/Good Housekeeping Practices: Version 1.0, September 2008. City of Centennial SOP: Detention Pond Maintenance SOP, August 2007. City of Centennial SOP: Inlet, Pipe, and Vault Cleaning and Disposal SOP, August 2007. City of Centennial SOP: Drainageway Maintenance SOP, August 2007. City of Golden Stormwater Drainage Maintenance Plan, February 2008. City of Greeley, Department of Public Works: Storm Water Drainage Program, January 2008. City of Greeley, Department of Public Works: Ditch Program, No Date. City of Lafayette Standard Operating Procedure: Ditch Cleaning, March 2009. City of Lafayette Standard Operating Procedure: Cleaning Storm Drain System, March 2009. City of Lafayette Standard Operating Procedure: Manhole Cleaning, March 2009. City of Lafayette Standard Operating Procedure: Potable Line Flushing, March 2009. City of Lafayette Standard Operating Procedure: Sanitary sewer Backup, March 2009. City of Lafayette Standard Operating Procedure: Waterline Breaks, March 2009. Mesa County, Municipal Operations and Maintenance Program, July 2005. Partners for a Clean Environment, Storm Drain Maintenance, No date. Optional Additional Resources Municipal codes and ordinances that relate to utility or storm sewer system maintenance. Inspection and maintenance frequency plan for the storm sewer system. Specific instructions on how to operate applicable equipment. Instructions on how to track the amount of debris collected. Treated Water Discharge Plans for potable water maintenance. Page 4 of 4 Utility and Storm Sewer For More Information Name System Replacement and Address Construction City, State Phone e-mail Description This procedure covers utility and storm sewer system Possible Pollutants replacement and construction. Utilities include power, Sediment storm sewer, sanitary sewer, water conveyance systems. Chemicals When services are contracted, this written procedure Organics should be provided to the contractor so they have the Trash proper operational procedures. In addition, the contract Good Housekeeping should specify that the contractor is responsible for abiding by all applicable municipal, state, and federal Waste Management codes, laws, and regulations. Employee/Contractor Training Proper Cleanup and Disposal Procedures Procedures General Related Procedures Obtain all applicable federal, state, and local Heavy Equipment and Vehicle permits for construction projects. Maintenance Parks and Open Space The Colorado Stormwater Construction Maintenance General permit applies to construction sites Spill Prevention and Response disturbing one acre or more, or less than one acre but part of a larger common plan of Street, Curb, and Gutter development. Replacement and Construction A larger common plan of development is Utilities and Storm Sewer defined as a contiguous area where multiple System Replacement and separate and distinct construction activities Construction may be taking place at different times on Vehicle Fueling different schedules under one plan. ■ A dewatering permit may be required if construction activities require the removal and discharge of groundwater offsite. ■ A U.S. Army Corp of Engineers (USACE) Section 404 Permit may be needed if the work will be conducted in or impact waters of the United States, including wetlands, washes, drainages, ditches, creeks, streams, and rivers. Page 1 of 3 • Applicable sediment and erosion controls may be installed, such as inlet protection, silt fence, sediment traps, sediment control logs, check dams and vehicle tracking control. Sediment and erosion controls will be installed and maintained in accordance with approved design criteria and / or industry standards. • When saw cutting, ensure that no slurry enters the storm drain. Let the slurry dry, sweep it up, and properly dispose of the sweepings or vacuum while saw cutting. • Where feasible, grading activities will be scheduled during dry weather. • Do not perform concrete or asphalt paving work during wet conditions whenever possible. • Monitor construction equipment for leaks and use drip pans as necessary. Leaking material containers should be properly discarded and replaced. • Store materials in containers under cover when not in use and away from any storm drain inlet. Wash out mixers, delivery trucks, or other equipment in the designated concrete washout area only. Locate concrete washout, portable toilets, and material storage away from storm drain inlets. Material stockpiles will not be stored in stormwater flow lines. Temporary sediment control will be used during temporary, short-term placement while work is actively occurring. Sweep or vacuum the roadway as needed, during construction and once construction is complete. • Best management practices will be periodically inspected and maintained as necessary. • Where practicable, non-structural controls will be used, such as phased construction, dust control, good housekeeping practices, and spill prevention and response procedures. Emergency Repair and Replacement Emergency Discharges are defined as situations in which it is not possible to implement all of the available BMPs due to the uncontrolled nature of the discharge. The primary focus during these events is to identify and mitigate the cause as soon as possible. Clean up of resulting sediment or other pollutants will be performed as soon as practicable following the emergency. Refer to the mill Prevention and Response procedure for reporting requirements. Page 2 of 3 Employee Training • Train applicable employees who perform utility replacement and construction activities on this written procedure. Information regarding how to avoid and report spills will be presented during the training. • Periodically conduct refresher training on the SOP for applicable employees who perform utility replacement and construction activities. Records The following records could be used to document activities performed: • Records of employee training with sign -in sheet. References Center for Watershed Protection, Municipal Pollution Prevention,/Good Housekeeping Practices: Version 1.0, September 2008. City of Centennial SOP: Detention Pond Maintenance SOP, August 2007. City of Centennial SOP: Inlet, Pipe, and Vault Cleaning and Disposal SOP, August 2007. City of Centennial SOP: Drainageway Maintenance SOP, August 2007. City of Golden Stormwater Drainage Maintenance Plan, February 2008. City of Greeley, Department of Public Works: Storm Water Drainage Program, January 2008. City of Greeley, Department of Public Works: Ditch Program, No Date. City of Lafayette Standard Operating Procedure: Ditch Cleaning, March 2009. City of Lafayette Standard Operating Procedure: Cleaning Storm Drain System, March 2009. City of Lafayette Standard Operating Procedure: Manhole Cleaning, March 2009. City of Lafayette Standard Operating Procedure: Potable Line Flushing, March 2009. City of Lafayette Standard Operating Procedure: Sanitary sewer Backup, March 2009. City of Lafayette Standard Operating Procedure: Waterline Breaks, March 2009. Mesa County, Municipal Operations and Maintenance Program, July 2005. Partners for a Clean Environment, Storm Drain Maintenance, No date. Page 3 of 3 City of Fort Collins Regulatory and Government Affairs Division City of F6rt`�S Verification Originator Revised Approved Issued Initials Date LR Oct.09 ss 10/19109 Environmental Standard Operating Procedure (ESOP) ESOP —Power Washing (Pressure Washing) wastewater Persons who will City staff who perform power washing, and their supervisor/manager. use this ESOP: A variety of City departments perform power washing. The employee Area of who power washes, and his/her supervisor/manager, will use the application: information in this SOP to guide their power washing, and supply purchasing, activities. Document l:\RGA Division\SOPs\ESOPs location: Revisions Rev. Date Description No. 001 002 Procedure Index 1.0 Purpose 2.0 Scope 3.0 Process 4.0 Training Requirements 5.0 References/Related Documents 6.0 Records Revision date: 10/19/2009 Page 1 of 3 City of Fort Collins Regulatory and Government Affairs Division City of Fort Collins Verification Originator Revised Approved Issued Initials Date LR Oct.09 ss 10/19109 Environmental Standard Operating Procedure (ESOP) ESOP —Power Washing (Pressure Washing) wastewater 1.0 Purpose 1.1 The purpose of this ESOP is to describe the appropriate methods of handling power washing wastewater. 2.0 Scope 2.1 The scope of this ESOP is limited to the description of the allowable methods of the disposal of power washing wastewater and the protection of the storm drainage system; the scope does not include specifics on how to power wash. 3.0 Process 3.1 Power washing wastewater must be prevented from running uncontrolled in the City's storm water system. The system includes streets, inlets, gutters, ponds, creeks, ditches, and the Poudre River. During the power washing activity, ensure the wastewater is controlled by the utilization of the natural slope of the land, or barriers such as inlet covers. Use of barriers on an impermeable surface also requires that the wastewater be vacuumed, collected, and disposed of properly. 3.2 General pollution prevention procedures: A. Use dry methods for surface pre -cleaning, such as using absorbent on small oil spots and sweeping up trash, debris, dirt, and used absorbent before power washing. B. Minimize the amount of water used during power washing activities. C. Avoid using cleaning products that contain hazardous substances (e.g., hydrofluoric acid, muriatic acid, sodium hydroxide, bleach) that can turn wastewater into hazardous waste. 3.3 Prior to power washing, decide on one of the following methods of disposal: D. Landscape --power washing wastewater may be discharged to landscaped areas if the materials used and the material removed are not harmful to vegetation, there is no ponding, and there is no uncontrolled runoff to the stormwater system. E. Wastewater treatment system-- As long as the collected wastewater does not have an oil sheen, has a pH between 5 and 11, and does not contain any hazardous or toxic substances, the wastewater may be disposed of into the City's wastewater treatment system. x If you add anything to the wash water (ie—a cleaning agent) or if you have questions about the content of your power washing wastewater, Revision date: 10/19/2009 Page 2 of 3 This page has been left blank intentionally. City of Fort Collins Regulatory and Government Affairs Division of ,, Fort Colons Verification Originator Revised Approved Issued Initials Date LR Oct.09 ss 10/19/09 Environmental Standard Operating Procedure (ESOP) ESOP —Power Washing (Pressure Washing) wastewater please contact the industrial pretreatment office at 221-6938. Disposal into the City's wastewater treatment system may be done either by discharging directly to an inside drain, or by pump truck at the Drake wastewater treatment facility. Disposing by pump truck requires a waste hauler's permit, and a 5 cent/gallon fee will be charged. For fee information, or to obtain a permit, contact the industrial pretreatment office at 221-6938. F. Truck the waste to a different waste disposal facility. 3.4 Once wastewater has been collected, visible solids remaining in the collection area must be swept up to prevent future discharges to the storm drain. 3.5 A sewer manhole cover may not be removed for disposal to the wastewater system. 3.6 If you are working in an area that is serviced by a neighboring wastewater district, such as South Fort Collins Sanitation or Boxelder, it is necessary to contact that district's industrial pretreatment coordinator before discharging to their system. 4.0 Training Requirements 4.1 The training requirement associated with this procedure is knowledge of the proper management of power washing wastewater. 5.0 References / Related Documents 5.1 http://www.cdphe.state.co.us/wq/PermitsUnit/PolicyandGuidance/powerwash.pdf 5.2 I:\RGA division\I[licit Discharge Program\Complaint Calls\pressure washinq\City power washing guidance.pdf 6.0 Records 6.1 The following records could be used to document activities performed: • Records of employee training with sign -in sheet. • List of power washing activities and departments responsible for conducting power washing. Revision date: 10/19/2009 Page 3 of 3 For More Information Vehicle Fueling Name Description Address Spills of gasoline and diesel fuel on the ground or on vehicles City, State during fueling can wash into a storm drain and cause water Phone pollution. e-mail When services are contracted, this written procedure should be Possible Pollutants provided to the contractor so they have the proper operational Metals procedures. In addition, the contract should specify that the Hydrocarbons contractor is responsible for abiding by all applicable municipal, Toxins state and federal codes, laws, and regulations. Good Housekeeping Procedures Drip pans General Secondary containment . Fuel vehicles at approved locations (municipal fueling Automatic shutoff nozzles station or offsite fueling station). Signs Provide spill kits near the municipal fueling location. Spill response plans Spill cleanup materials • If fuel is stored in an above -ground tank, store fuel in enclosed, covered tanks with secondary containment Dry cleanup methods (e.g., concrete barrier or double -walled tanks). Employee training ■ All fuel tanks will be inspected per State and Federal Related Procedures regulations. Heavy Equipment/Vehicle Maintenance • Periodically inspect municipal fueling locations for the Outdoor Fleet Maintenance following: Spill Prevention and Response For above -ground tanks, inspect tank foundations, connections, coatings, tank walls, and piping systems. Look for corrosion, leaks, cracks, scratches, and other physical damage that may weaken the tank. ■ Check for spills and fuel tank overfills due to operator error. Clean up any leaks or drips. Clean up is not completed until the absorbent is swept up and disposed of properly. Report leaking vehicles to fleet maintenance. Page 1 of 3 Vehicle Fueling • Follow all posted warnings. • Ensure that the nozzle is properly inserted in the filler neck of the vehicle before dispensing any fuel. • Remain by the fill nozzle while fueling to ensure the nozzle stays in place. • Do not top off the tank of the vehicle once the nozzle has shut off the fuel. • Follow the procedures outlined in the Spill Prevention and Response Procedure to respond to any leaks or spills. • Clean fuel dispensing areas with absorbent material. • Never use water to clean up a spill. Mobile Fuel Truck • Provide inlet protection (e.g., berms, weighted inlet covers) for nearby storm drain inlets when transferring fuel and fueling a vehicle. • Use secondary containment when transferring fuel from the tank truck to the fuel tank. All gas cans must be placed in the secondary containment box/ pan and remain on the ground when fueling. • Use a funnel to transfer fuel to vehicles and equipment. After the transfer is complete, the funnel should be dried with a rag or placed in a container to avoid dripping fuel on the ground. Employee Training • Train applicable employees who fuel vehicles on this written procedure. Information regarding how to avoid and report spills will be presented during the training. • Periodically conduct refresher training on the SOP for applicable employees who fuel vehicles. Records The following records could be used to document activities performed: • Records of employee training with sign -in sheet. References Center for Watershed Protection, Municipal Pollution Prevention/Good Housekeeping Practices: Version 1.0, September 2008. City of Centennial SOP: Vehicle Fueling, August 2007. City of Lafayette Standard Operating Procedure: Vehicle and Equipment Fueling, March 2009. Mesa County, Municipal Operation and Maintenance Program, July 4, 2005. USEPA Menu of BMPs: Municipal Vehicle Fueling, cfpub.epa.gov/npdes/stormwater/menuofbmps/, accessed June 18, 2009. Page 2 of 3 Optional Additional Resources Municipal codes and ordinances that relate to vehicle fueling. Locations of approved offsite fueling stations. Locations of nearby spill kits. Spill Prevention Control and Countermeasures Plan. Page 3 of 3 Outdoor Fleet Maintenance For More Information Name Description Address Although it is recommended that fleet maintenance City, State activities be conducted indoors or under cover, it is Phone sometimes necessary to perform fleet maintenance e-mail outdoors (e.g., equipment is too large to fit inside the Possible Pollutants maintenance building, temporary repairs need to be made before the equipment can be moved to the maintenance Metals building, breakdowns, service calls). Toxins Solvents (degreasers, paint Some potential pollutants typically associated with outdoor thinners, etc.) fleet maintenance activities include oil, antifreeze, brake Antifreeze fluid and cleaner, solvents, batteries, and fuels. Consult the Brake fluid and brake pad dust Spill Prevention and Response procedure and the Vehicle Fueling procedure for additional information on those Battery acid topics. Motor oil Fuel (gasoline, diesel, kerosene) When services are contracted, this written procedure should be provided to the contractor so they have the Lubricating grease proper operational procedures. In addition, the contract Good Housekeeping should specify that the contractor is responsible for abiding Drip pans by all applicable municipal, state, and federal codes, laws, Tarps and regulations. Covered outdoor storage areas procedures Secondary containment Fleet Maintenance Proper disposal of used fluids • Fleet maintenance should be performed inside Spill cleanup materials whenever possible. Dry cleanup methods • If indoor maintenance is not possible, ensure Employee training maintenance is performed in a location where Related Procedures contact with stormwater is minimized, through Heavy Equipment and Vehicle berming and appropriate routing of drainage. Maintenance . Provide inlet protection (berms, weighted inlet Material Storage covers, etc.) for all adjacent inlets when work is Spill Prevention and Response occurring in close proximity to a storm drain Vehicle Fueling inlet. Have absorbent pads and drip pans accessible to capture leaks and spills during maintenance activities. Keep equipment clean and do not allow excessive build-up of oil and grease. Page 1 of 4 • Perform regular preventative maintenance to minimize the occurrence of leaks and major repairs. • Recycle and/or dispose of all wastes properly and promptly. • Do not dump any liquids or other materials outside, especially near or in storm drains or ditches. Sweep and pick up trash and debris as needed. • Clean up spills promptly using dry methods (do not hose down). Consult the Spill Prevention and Resl2onse procedure for more information. Cleanup is completed only after absorbent and rags are disposed of properly. Body Repair and Painting Whenever possible, conduct all body repair and painting work indoors. • Use dry cleanup methods such as vacuuming or sweeping to clean up all metal filings, dust, and paint chips from grinding, shaving, and sanding. Dispose of the waste properly. Debris from wet sanding can be allowed to dry overnight, then swept and vacuumed. Liquid from wet sanding should not be allowed to enter the storm drain. Never discharge these wastes to the storm or sanitary sewer systems. • Minimize waste from paints and thinners by carefully calculating paint needs based on surface area and using the proper sprayer cup size. • Clean spray guns in a self-contained cleaner. Do not dispose of cleaner waste in the storm drain. • Use sanding tools equipped with vacuum capability (if available) to pick up debris and dust. Material Management Store maintenance materials and waste containers (e.g., used oil and antifreeze) in labeled containers under cover or in secondary containment (e.g., double -walled tanks). Chemicals should not be combined in containers. • All hazardous wastes must be labeled and stored according to hazardous waste regulations. • Carefully transfer fluids from collection devices to designated storage areas as soon as possible. Do not store the transferred fluids adjacent to the containers. • Store new batteries securely to avoid breakage and acid spills. • Store used batteries indoors or in secondary containment to contain potential leaks. Recycle used batteries. • Conduct periodic inspections of storage areas to detect possible leaks. Page 2 of 4 • Do not wash or hose down the storage area except in areas where the wash water will only enter the sanitary sewer drain as an approved discharge. Use dry clean-up methods as often as possible. Keep lids on waste barrels and containers, and store them indoors or under cover to reduce exposure to rain. Periodically inspect and maintain all pretreatment equipment, including sumps, separators, and grease traps to ensure proper functioning. Parts Cleaning Use designated areas for engine, parts, or radiator cleaning. Do not wash or rinse parts outdoors. If parts cleaning equipment is not available, use drip pans or other containment to capture parts cleaning fluids. • Use steam cleaning or pressure washing of parts whenever possible instead of solvent cleaning. • When steam cleaning or pressure washing is used, only discharge wastewater to an oil/water separator connected to the sanitary sewer. When using solvents, rinse and drain parts over the designated solvent tank so that fluids will not drip or spill onto the floor. Use drip boards or pans to catch excess solutions and divert them back to the tank. Allow parts to dry over the hot tank. • Recycle cleaning solution when it becomes too dirty to use. Never discharge cleaning waste to the storm or sanitary sewer systems. Vehicle and Equipment Washing Vehicles should be washed, whenever possible, in the municipality's vehicle and equipment wash area/bay or taken to a commercial car wash. Employee Training • Train applicable employees on this written procedure. Information regarding how to avoid and report spills will be presented during the training. Periodically conduct refresher training on the SOP for applicable employees who perform outdoor vehicle maintenance. Records The following records could be used to document activities performed: • Record of any major spills and the action taken. • Records of employee training with sign -in sheet. • Heavy equipment and vehicle maintenance logs. Page 3 of 4 References Center for Watershed Protection, Municipal Pollution Prevention/Good Housekeeping Practices: Version 1.0, September 2008. City of Centennial SOP: Vehicle and Equipment Storage SOP, August 2007. City of Centennial SOP: Vehicle Maintenance SOP, August 2007. City of Centennial SOP: Vehicle Washing SOP, August 2007. City of Golden. Fleet Maintenance Standard Operating Procedure, July 29, 2007. City of Lafayette Standard Operating Procedure: Vehicle and Equipment Maintenance Repair, March 2009. City of Lafayette Standard Operating Procedure: Vehicle and Equipment Washing, March 2009. Mesa County, Municipal Operation and Maintenance Program, July 4, 2005. Partners for a Clean Environment Stormwater Protection: Vehicle Repair. Spring 2009. USEPA Menu of BMP: Municipal Vehicle and Equipment Maintenance, cfpub.epa.gov/npdes/stormwater/menuofbmps/, accessed May 27, 2009. USEPA Menu of BMP: Municipal Vehicle and Equipment Washing, cfpub.epa.gov/npdes/stormwater/menuofbmps/, accessed May 27, 2009. Optional Additional Resources Municipal codes and ordinances that relate to fleet maintenance. Chemical purchasing policies. Guidelines for staff to dedicate a percentage of their time to vehicle and equipment maintenance. Specific directions on how to use the municipality's vehicle wash area. Spill Prevention Control and Countermeasures Plan. Page 4 of 4 For More Information Heavy Equipment and Vehicle Name Maintenance Address City, state Description Phone Regular maintenance of municipal vehicles and equipment, or e-mail municipality -contracted vehicles and equipment prolongs the life Possible Pollutants of the municipality's assets and prevents the leaking of hazardous fluids commonly associated with normal wear and tear of vehicles Metals and equipment. Toxins Potential pollutants generated at vehicle maintenance facilities Solvents (degreasers, paint thinners, etc.) include oil, antifreeze, brake fluid and cleaner, solvents, batteries and fuels. Antifreeze Brake fluid and brake pad dust When services are contracted, this written procedure should be Battery acid provided to the contractor so they have the proper operational procedures. In addition, the contract should specify that the Motor oil contractor is responsible for abiding by all applicable municipal, Fuel (gasoline, diesel, kerosene) state, and federal codes, laws, and regulations. Lubricating grease Good Housekeeping Procedures Maintenance activities should be performed inside a maintenance Drip pans building unless the equipment is too large to fit inside or Tarps temporary repairs need to be made before the equipment can be Covered outdoor storage areas moved to the maintenance building. Consult the Outdoor Fleet Secondary containment Maintenance procedure when it is necessary to perform repairs Proper disposal of used fluids outside of the facility (breakdowns, service calls, etc.). Spill cleanup materials Vehicle Storage Dry cleanup methods . Monitor vehicles and equipment closely for leaks and Employee training use drip pans as needed until repairs can be Related Procedures performed. Material Storage • When drip pans are used, check frequently to avoid Outdoor Fleet Maintenance overtopping and properly dispose of fluids. Spill Prevention and Response • Drain fluids from leaking or wrecked vehicles and Street Sweeper Cleaning and from motor parts as soon as possible. Dispose of fluids Waste properly. Vehicle Fueling Vehicle Washing Page 1 of 4 Vehicle Maintenance • Conduct routine inspections of heavy equipment and vehicles to proactively identify potential maintenance needs. • Perform routine preventive maintenance to ensure heavy equipment and vehicles are operating optimally. • Recycle or dispose of all wastes properly and promptly. • Do not dump any liquids or other materials outside, especially near or in storm drains or ditches. Sweep and pick up trash and debris as needed. Body Repair and Painting • Whenever possible, conduct all body repair and painting work indoors. • Use dry cleanup methods such as vacuuming or sweeping to clean up all metal filings, dust, and paint chips from grinding, shaving, and sanding, and dispose of the waste properly. Debris from wet sanding can be allowed to dry overnight on the shop floor, then swept or vacuumed. Never discharge these wastes to the storm or sanitary sewer system. • Minimize waste from paints and thinners by carefully calculating paint needs based on surface area and using the proper sprayer cup size. Do not use water to control over -spray or dust in the paint booth unless this wastewater is collected. This water should be treated and permission granted by the wastewater treatment plant prior to discharge into the sanitary sewer system. Do not dispose of spray gun cleaner waste in the storm drain. Use sanding tools equipped with vacuum capability (if available) to pick up debris and dust. Material Management • Store maintenance materials and waste containers (e.g., used oil and antifreeze) in labeled containers under cover or in secondary containment (e.g., double -walled tanks). Chemicals should not be combined in containers. • All hazardous wastes must be labeled and stored according to hazardous waste regulations. • Carefully transfer fluids from collection devices to designated storage areas as soon as possible. Do not store the transferred fluids adjacent to the containers (for example, oil drip pans with used oil in them should not be placed next to the used oil tank). • Store new batteries securely to avoid breakage and acid spills. • Store used batteries indoors or in secondary containment to contain potential leaks. Recycle used batteries. • Conduct periodic inspections of storage areas to detect possible leaks. Page 2 of 4 SECTION 00635 CERTIFICATE OF SUBSTANTIAL COMPLETION TO: CITY OF FORT COLLINS (OWNER) DATE OF SUBSTANTIAL COMPLETION: PROJECT OR SPECIFIED PART SHALL INCLUDE: PROJECT TITLE: 7509 Concrete Maintenance Project Phase II — 2015 Renewal LOCATION: Fort Collins, Colorado OWNER: City of Fort Collins CONTRACTOR: Northstar Concrete Inc. CONTRACT DATE: February 9, 2015 The Work performed under this contract has been inspected by authorized representatives of the OWNER, CONTRACTOR, and the ENGINEER and the project or specified part of the project, as indicated above) is hereby declared to be substantially completed on the above date. A tentative list of items to be completed or corrected is appended hereto. This list may not be exhaustive, and the failure to include an item on it does not alter the responsibility of the CONTRACTOR to complete all the Work in accordance with the Contract Documents. ENGINEER AUTHORIZED REPRESENTATIVE DATE The CONTRACTOR accepts the above Certificate of Substantial Completion and agrees to complete and correct the items on the tentative list within the time indicated. CONTRACTOR AUTHORIZED REPRESENTATIVE DATE The OWNER accepts the project or specified area of the project as substantially complete and will assume full possession of the project or specified area of the project at 12:01 a.m., on . The responsibility for heat, utilities, security, and insurance under the Contract Documents shall be as set forth under "Remarks" below. CITY OF FORT COLLINS, COLORADO By: OWNER DA REMARKS: AUTHORIZED REPRESENTATIVE • Do not wash or hose down storage areas except where wash water will enter the sanitary sewer as an approved discharge. Use dry clean-up methods whenever possible. Keep lids on waste barrels and containers, and store them indoors or under cover to reduce exposure to rain. Periodically inspect and maintain all pretreatment equipment, including sumps, separators, and grease traps to ensure proper functioning. Parts Cleaning • Use designated areas for engine, parts, or radiator cleaning. Do not wash or rinse parts outdoors. If parts cleaning equipment is not available, use drip pans or other containment to capture parts cleaning fluids. • Use steam cleaning or pressure washing of parts whenever possible instead of solvent cleaning. • When steam cleaning or pressure washing, only discharge wastewater to an oil/water separator connected to the sanitary sewer. • When using solvents to clean parts, rinse and drain parts over the designated solvent tank so that fluids will not drip or spill onto the floor. Use drip boards or pans to catch excess solutions and divert them back to the tank. Allow parts to dry over the hot tank. • Recycle cleaning solution when it becomes too dirty to use. Never discharge cleaning waste to the sanitary sewer or storm sewer. Vehicle and Equipment Washing Vehicles should be washed in the municipality's vehicle and equipment wash area/bay or taken to a commercial car wash. Employee Training Train applicable employees who perform heavy equipment and vehicle maintenance on this written procedure. Information regarding how to avoid and report spills will be presented during the training. • Periodically conduct refresher training on the SOP for applicable employees who perform heavy equipment and vehicle maintenance. Records The following records could be used to document activities performed: • Record of any major spills and the action taken. • Records of employee training with sign -in sheet. 0 Heavy equipment and vehicle maintenance logs References Center for Watershed Protection, Municipal Pollution Prevention/Good Housekeeping Practices: Version 1.0, September 2008. City of Centennial SOP: Vehicle and Equipment Storage SOP, August 2007. City of Centennial SOP: Vehicle Maintenance SOP, August 2007. City of Centennial SOP: Vehicle Washing SOP, August 2007. City of Golden. Fleet Maintenance Standard Operating Procedure, July 29, 2007. City of Lafayette Standard Operating Procedure: Vehicle and Equipment Maintenance Repair, March 2009. City of Lafayette Standard Operating Procedure: Vehicle and Equipment Washing, March 2009. Mesa County, Municipal Operation and Maintenance Program, July 4, 2005. Partners for a Clean Environment. Stormwater Protection: Vehicle Repair. Spring 2009. USEPA Menu of BMP: Municipal Vehicle and Equipment Maintenance, cfpub.epa.gov/npdes/stormwater/menuofbmps/, accessed May 27, 2009. USEPA Menu of BMP: Municipal Vehicle and Equipment Washing, cfpub.epa.gov/npdes/stormwater/menuofbmps/, accessed May 27, 2009. Optional Additional Resources Municipal codes and ordinances that relate to vehicle and equipment maintenance. Chemical purchasing policies. Loading and unloading bulk materials. Guidelines for staff to dedicate a percentage of their time to vehicle and equipment maintenance. Specific directions on how to use the municipality's vehicle wash area. Spill Prevention Control and Countermeasures Plan. Page 4 of 4 SECTION 00640 CERTIFICATE OF FINAL ACCEPTANCE 20 TO: Northstar Concrete Inc. Gentlemen: You are hereby notified that on the day of , 20_, the City of Fort Collins, Colorado, has accepted the Work completed by Northstar Concrete Inc. for the City of Fort Collins project, 7509 Concrete Maintenance Proiect Phase II — 2015 Renewal. A check is attached hereto in the amount of $ as Final Payment for all Work done, subject to the terms of the Contract Documents which are dated February 9, 2015. In conformance with the Contract Documents for this project, your obligations and guarantees will continue for the specified time from the following date: 20_ Sincerely, OWNER: City of Fort Collins By: Title: ATTEST: Title: SECTION 00650 LIEN WAIVER RELEASE (CONTRACTOR) TO: CitV of Fort Collins. Colorado (OWNER) FROM: Northstar Concrete Inc. (CONTRACTOR) PROJECT: 7509 Concrete Maintenance Project Phase II — 2015 Renewal 1. The CONTRACTOR acknowledges having received payment, except retainage from the OWNER for all work, labor, skill and material furnished, delivered and performed by the CONTRACTOR for the OWNER or for anyone in the construction, design, improvement, alteration, addition or repair of the above described project. 2. In consideration of such payment and other good and valuable consideration, the receipt and adequacy of which are hereby acknowledged, the CONTRACTOR voluntarily waives all rights, claims and liens, including but not limited to, mechanic's liens, Miller Act claims (40 U.S.C.A. 270 a and b), stop notices, equitable liens and labor and material bond rights which the CONTRACTOR may now or may afterward have, claim or assert for all and any work, labor, skill or materials furnished, delivered or performed for the construction, design, improvement, alteration, addition or repair of the above described project, against the OWNER or its officers, agents, employees or assigns, against any fund of or in the possession or control of the OWNER, against the project or against all land and the buildings on and appurtenances to the land improved by the project. 3. The CONTRACTOR affirms that all work, labor and materials, furnished, delivered or performed to or for the construction, design, improvement, alteration, addition or repair of the project were furnished, delivered or performed by the CONTRACTOR or its agents, employees, and servants, or by and through the CONTRACTOR by various Subcontractors or materialmen or their agents, employees and servants and further affirms the same have been paid in full and have released in full any and all existing or possible future mechanic's liens or rights or claims against the project or any funds in the OWNER'S possession or control concerning the project or against the OWNER or its officers, agents, employees or assigns arising out of the project. 4. The CONTRACTOR agrees to defend and hold harmless the OWNER, the lender, if any, and the Surety on the project against and from any claim hereinafter made by the CONTRACTOR'S Subcontractors, materialmen, employees, servants, agents or assigns against the project or against the OWNER or its officers, employees, agents or assigns arising out of the project for all loss, damage and costs, including reasonable attorneys fees, incurred as a result of such claims. 5. The parties acknowledge that the description of the project set forth above constitutes and adequate description of the property and improvements to which this Lien Waiver Release pertains. It is further acknowledged that this Lien Waiver Release is for the benefit of and may be relied upon by the OWNER, the lender, if any, and Surety on any labor and material bonds for the project. Signed this day of 20_ CONTRACTOR: Northstar Concrete Inc. By: Title: ATTEST: Secretary STATE OF COLORADO ) )ss. COUNTY OF LARIMER ) Subscribed and sworn to before me this day of 20_, by Witness my hand and official seal. Notary Public My Commission Expires: SECTION 00660 CONSENT OF SURETY TO: City of Fort Collins, Colorado (hereinafter referred to as the "OWNER") CONTRACTOR: Northstar Concrete Inc. PROJECT: 7509 Concrete Maintenance Project Phase II — 2015 Renewal CONTRACT DATE: February 9, 2015 In accordance with the provisions of the Contract between the OWNER and the CONTRACTOR as indicated above, for (Surety) on bond of hereby approves of the Final Payment to the CONTRACTOR, and agrees that Final Payment to the CONTRACTOR shall not relieve the Surety Company of any of its obligations to the OWNER, as set forth in the said Surety Company's Bond. IN WITNESS WHEREOF, the Surety Company has hereunto set its hand this day of , 20 (Surety Company) M ATTACH: Power of Attorney and Certificate of Authority of Attorney(s)-in-Fact. SECTION 00670 APPLICATION FOR EXEMPTION CERTIFICATE DR 0172 (12/98) COLORADO DEPARTMENT OF REVENUE DENVER CO 80261 (303)232-2416 CONTRACTOR APPLICATION FOR EXEMPTION CERTIFICATE Pursuant to Statute Section 39-26.114(1)(a)(XIX) 0 DO NOT WRITE IN THIS SPACE The exemption certificate for which you are applying must be used only for the purpose of purchasing construction and building materials for the exempt project described below. This exemption does not include or apply to the purchase or rental of equipment, supplies, and materials which are purchased, rented, or consumed by the contractor and which do not become part of the structure, highway, road, street, or other public works owned and used by the exempt organization. Any unauthorized use of the exemption certificate will result in revocation of your exemption certificate and other penalties provided by law. A separate certificate is required for each contract. Subcontractors will not be issued Certificates of Exemption by the Department of Revenue. It is the responsibility of the prime contractor to issue certificates to each of the subcontractors. (See reverse side). FAILURE TO ACCURATELY COMPLETE ALL BOXES WILL CAUSE THE APPLICATION TO BE DENIED. Registration/Account No. (to be assigned by OOR) Period 0170-750 (999) $0.00 89 - CONTRACTOR INFORMATION Trade name/DBA: Owner, partner, or corporate name Mailing address (City, State, Zip). Contact Person E-Mail address: Federal Employer's Identification Number: Bid amount for your contract: Fax Number. Business telephone number: Colorado withholding tax account number: Copies of contract or agreement pages (1) identifying the contracting parties EXEMPTION INFORMATION and (2) containing signatures of contracting parties must be attached. Name of exempt organization (as shown on contract): Exempt organization's number: 98 - Address of exempt organization (City, State, Zip): Principal contact at exempt organization: Principal contact's telephone number: Physical location of project site (give actual address when applicable and Cities and/or County lies) where project is located) Scheduled Month Day Year Estimated Month Day Year construction start date: completion date: I declare under penalty of perjury in the second degree that the statements made in this application are true and complete to the best of my knowledge. Signature of owner, partner or corporate officer: Title of corporate officer: Date. DO NOT WRITE BELOW THIS LINE SECTION 00300 BID FORM Special Notice Contractors who have completed this application in the past, please note the following changes in procedure: The Department will no longer issue individual Certificates of exemption to subcontractors. Only prime contractors will receive a Contractor's Exemption Certificate on exempt projects. Upon receipt of the Certificate, the prime contractor should make a copy for each subcontractor involved in the project and complete it by filling in the subcontractor's name and address and signing it. The original Certificate should always be retained by the prime contractor. Copies of all Certificates that the prime contractor issued to subcontractors should be kept at the prime contractor's place of business for a minimum of three years and be available for inspection in the event of an audit. Once an 89# has been assigned to you, please use the next five numbers following it for any applications submitted for future projects. This should be your permanent number. For instance, if you were assigned 89-12345-0001, every application submitted thereafter should contain 89-12345 on the application. The succeeding numbers will be issued by the Department of Revenue. DO NOT enter what you believe to be the next in sequence as this may delay processing of your application. SECTION 00700 GENERAL CONDITIONS GENERAL CONDITIONS CONSTRUCTION CONTRACT These GENERAL CONDITIONS have been developed by using the STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT prepared by the Engineers Joint Contract Documents Committee, EJCLXJ No, 1910-8 (1990 Edition), as a base. Changes to that document are shown by underlining text that has been added and striking through text that has been deleted. EJCDC GENERAL CONDITIONS 1910-8 (1990 EDITION) WITH CITY OF FORT COLLINS MODIFICATIONS (REV 9/99) Article or Paragraph Number & Title TABLE OF CONTENTS OF GENERAL CONDITIONS Page Article or Paragraph Number Number & Title DEFINITIONS ......................................................1 1.1 Addenda ........................... 1.2 Agreement . ......................................... 1.3 Application for Payment ...................... 1.4 Asbestos ........ 1.5 Did 1.6 Bidding Documents ............................. 1 1.7 Bidding Requirements, ........................ I 1.8 Bonds ................................................1 1.9 Change Order .... .......................... ....... I 1.10 Contract Documents 1 1.11 Contract Prict.....................................1 1.12 Contract Times ..................................1.1 1.13 CONTRACTOR ..................................1 1.14 defe, h ve .............................................1 1,15 Drawingk .................................... ...... 1 1.16 Effective Date of the Agreement .... _ ..... 1 1.17 ENGINEER ......................................... I 1.18 ENGINEERS Consultant-„.................. 1 1.19 Field Order .........................................1 1.20 General Requirements,_...................... ;Z L21 Hazardous Waste.. ............ ___...... 2 1.22.a Laws and Regulations; Laws or Regulations ...................................... 1.22,b Lao Holidays .................................... :2 1.23 Liens ............................ .... ................ 2 1.24 Milestorilk ........................................... 2 1.125 Notice of Award ............... __ ......... .... 2 1.26 Notice to Proceed.................................2 1.27 OWNER .................. .......................... 1.28 Partial Utilization ................................2 1.29 PCBs..................................................2 1.30 Petroleum ...........................................2 1.31 Project .... ...... .................. _ .............. 1.32.a Radioactive Nfitterial, ....................... __2 1.32.b Regular Working Hours ... ................... 1.33 Resident Project Representative ........... 1.34 Samples..............................................2 1.35 Shop Drawings ....................................2 1.36 Specifications ...................................... 2 1.37 Subcontractor ..................................... :2 1.38 Substantial Completion ........................ 2 1.39 Supplementary Conditions ............ ..... 2 1.40 Supplier .............................................7 1.41 Underground Facilities ..................... 2-3 1.42 Unit Price Work ................................... 3 1.43 Work ..................................................3 1.44 Work Change Directive ........................3 1.45 Written Amendment ...........................3 Page Number PRELIMINARY MATTERS ................................3 2.1 Delivery of Bono ............................ 2.2 Copies of Documents ....................... 2.3 Commencement of Contract Times; Notice to Proceed ............. 2.4 Starting the Work.............................3 2.5-2.7 Before Starting Construction', CONTRACTORs Responsibility to Report; Preliminary Schediles; Delivery of Certificates of Insuramcq-, .... ........................... 34 2.8 Preconstruction Conferencq ..............4 2.9 Initially Acceptable Schedules......... 4 'VoInk-My- �R.@ to AMENDING, REUSE ...................................._...A 3.1-3.2 Intent........._.........-- -- ..............A 3.3 Reference to Standards and Speci- fications of Technical Societies!, Reporting and Resolving Dis- crepancies ................................. 4.5 3.4 Intent of Certain Terms or Adjectives .................................... 5 3.5 Amending Contract Docuncrits ........ 5 3.6 Supplementing Contract Documents ................................... 5 3.7 Rouse of Documents .........................5 AVAILABILITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS; REFERENCE POINTS ........................................15 4.1 Availability of Lands .....................5-6 4.2 Subsurface and Physical Conditions 6 4.2.1 Reports and Drawings ......................6 4.2.2 Limited Reliance by CONTRAC- TOR Authorized: Technical Data_ ........................................... 6 4.2.3 Notice of Differing Subsurface or Physical ConditionA ..................6 4.2.4 ENGINEER!s Review ....................... 4.2.5 Possible Contract Documents Change......................................... 6 4.2.6 Possible Price and Times Adjustments... ...... ............ ........ 15-7 4.3 Physical Conditions -Underground Facilities ............................. ......... 7 4.1.1 Shown or Indicated ..........................7 4.3.2 Not Shown or Indicate4.................7 4.4 Reference Points ..............................7 EXDC GENULAL COMTION31910-8(IM ED1110N) v/aTY OFFORT COUINS MODIFICATIONS (REV 91") Article or Paragraph Page Article or Paragraph Page Number & Title Number Number & Title Number 4.5 Asbestos, PCBs, Petroleum, 6.25 Submittal Proccedures; CON - Hazardous Waste or TRACTOR's Review Prior Radioactive Material_ ..................7-8 to Shop Drawing or Sample Subm ittal....................................16 5. BONDS AND INSURANCE ................................ 8 6.26 Shop Drawing & Sample Submit- 5.1-5.2 Performance, Payment and Other tale Review by ENGINEER. _..,16-17 Bonds .............................................. 8 6.27 Responsibility for Variations 5.3 Licensed Sureties and Insurers; From Contract Documents.,,,,,......17 Certificates of Insurance....................8 6.28 Related Work Performed Prior 5A CONTRACTOR's Liability to ENGINEER's Review and Insurance..........................................9 Approval of Required 5.5 OWNERsLiability Insurance ..............9 Submittals ................................ _„17 5.6 Property Insurance ..........................Q40 629 Continuing the Wor$.... ................. I7 5.7 Boiler and Machinery or Addi- 6.30 CONTRACTOR's General tional Property Insurance ................. 10 Warranty and Guarantee ............... 17 5.8 Notice of Cancellation Provision....... 10 6.31-6.33 Indemnification._..................17-18 5.9 CONTRACTOR'sResponsibility 6.34 Survival of Obligations ...................38 for Deductible Amounts...................JO 5.10 Other Special Insurance .....................10 7. OTHER WORK,......,.. ......18 5.11 Waiver ofRights................................11 7.1-7.3 Related Work at Site, ...................... )8 5.12-5.13 Receipt and Application of 7.4 Coordination .................. ,.,........... _ 18 Insurance Proceeds,,,,,,,,,,,,,,,,,,,,, to -I I 5.14 Acceptance of Bonds and Insa- 8, OWNER'S RESPONSIBILITIES ......................... ) 8 ance; Option to Replace,,,,,,,,,,,,,,, 11 8.1 Communications to CON- 5.15 Partial Utilization --Property TRACTOR.................................18 Insurance........................................11 8.2 Replacement of ENGINEER, ........... I S 8.3 Furnish Data andPay Promptly 6. CONTRACTOR'S RESPONSIBILITIES ...............I I When Due ... ...............................18 6.1.6.2 Supervision and Superintendeno; ....... 11 8.4 Lands and Easements; Reports 6.3.6.5 Labor, Materials and Equipment... 11-12 and Tests................__._...,------ 6.6 Progress Schedule ..................... ....)2 8.5 Insurance..... ....19 6.7 Substitutes and "Or -Equal" Items; 8.6 Change Orders..............................19 CONTRACTOR's Expense; 8.7 Inspections, Tests and Substitute Construction Approvals...................................19 Methods or Procedures; 8.8 Stop or Suspend Work; ENGINEER's Evaluation........... _ 12-13 Terminate CONTRACTOR's 6.8-6.11 Concerning Subcontractors, Services......................................19 Suppliers and Others; 8.9 Limitations on OWNER'S Waiver of Rights .... ......... ........... 13-14 Responsibilities ................. ........... 19 6.12 Patent Fees and Royalties..................14 9.10 Asbestos, PCBs, Petroleum, 6.13 Permits............................................14 Hazardous Waste or 6.14 Laws and Regulations ........................ J4 Radioactive Material ............ ....... 19 6.15 Taxes...........................................14-15 8.11 Evidence of Financil 6.16 Use of Promises.................................15 Arrangements .................. ............ 19 6.17 Site Cleanlmess................................ 15 6.18 Safe Structural Loading.....................35 9. ENGINEER'S STATUS DURING 6.19 Record Documents .............................is CONSTRUCTION... .................... ...................... 19 6.20 Safety and Protection., ........ ...... .1546 9.1 OWNERsRepresentative ................ 19 6.21 Safety Representative ......................_J6 9.2 Visits to Site. ................................. 19 6.22 Hazard Communication Program; .....16 9.3 Project Representative ...............)9-21 6.23 Emergencies. .................................... 16 9.4 Clarifications and Interpre- 6.24 Shop Drawings and Sample*..............16 tations........................................ 21 9.5 Authorized Variations in Vibrk........ 1 EJCDC GENERAL CONDMONS 191M (1990 EDITION) w/ aTv OF FORT OOLUNS MODMCATTONS (REV 9l99) Article or Paragraph Page Article or paragraph Number & Title Number Number & Title 9.6 Rejecting Defective Work ...................71 9,7-9.9 Shop Drawings, Change Orders and Payments ........ ... _ ..................... 21 9.10 Determinatims for Unit Prices„.... 21-22 9,11-9.12 Decisions on Disputes, ENGI- NEER as Initial lntcrprctet..............22 9.13 Limitations on HNG]N[EEWs Authority and Responsibilities.... 22-23 CHANGES IN THE WORK ....................................... 23 MI OWNEWs Ordered Change ................23 14. 10.2 Claim for Adjustment ....................... 23 10.3 Work Not Required by Contract Documents 23 10.4 Change Orders .................................. 23 10.5 Notification of Surety---_ .................23 CHANGE OF CONTRACT PRICE .............................7..3 11.1-11.3 Contract Price: Claim for Adjustment; Value of the Work_ ............................. .... 23-24 11.4 Cost of the Work .......................... 24-25 11.5 Exclusions to Cog of the Work .......... 25 11.6 CONTRACTORs Fee,,,,,,,,,,,,,,,,,,,,,,,, 25 11.7 Cost Records ................................. 25-26 it's Cash Allowances...............................20 11,9 Unit Price Work .... _ ......................... 26 CHANGE OF CONTRACT TIMES ............................26 12.1 Claim for Adjustmen........................26 12.2 Time of the Essencq ..........................26 12.3 Delays Beyond CONTRACTORs Control 26-27 12.4 Delays Beyond OWNEWs and CONTRACTOWs Control ................27 TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFEC71YE WORK ..................................................77 13.1 Notice of Defects ...............................27 13.2 Access to the Work ...........................27 13.3 Tests and Inspections; CONTRACTOR% Cooperation,,,,,,,,, 27 13.4 OWNERS Responsibilities; Independent Testing Laboratory,,,,,,, 27 13.5 CONTRACTORs Responsibilities ........ .....................27 13.6-13.7 Covering Work Prior to lnspec- tion. Testing or Approval .................27 13.8-13.9 Uncovering Work at ENGI- par Number NEER's Request ..................... 77-28 13.10 OWNER May Stop the Wotik .......... 28 13.11 Correction or Removal of Defective Work ...........................28 13.12 Correction Period...........................28 13.13 Acceptance of Defective Work ......... 28 13.14 OWNER May Correct Defective Work ................. 28-29 PAYMENTS TO CONTRACTOR AND COMPLETION ................................................. 29 14.1 Schedule of Values.........................29 14.2 Application for Progress Paym ent .......... _ . .............. ....... 29 14.3 CONTRACTOR's Warranty of Title ........................................... 29 144-14.7 Review of Applications for Progress Payment; ................. 29-30 14,8-14,9 Substantial Completion....._............ 14.10 Partial Utilization., ................... 30-31 14.11 Final Inspection .............................31 14.12 Final Application for Payment,...,,. 31 14.13-14.14 Final Payment and Acceptance ...... 31 14.15 Waiver of Claims ...................... 31-32 15. SUSPENSION OF WORK AND TERMINATION ....... ........................................ 32 15.1 OWNER May Suspend Work .......... 32 15.2-15.4 OWNER May Terminate,,,,,,,,,,,,,,,, 32 15.5 CONTRACTOR May Stop Work or Terminate .................. IM3 16. DISPUTE RESOLUTION .................................. 33 17. MISCELLANEOUS 33 17.1 Giving Notice................................33 17.2 Computation of Tim cs....................33 17.3 Notice of Claim ..............................33 17.4 Cumulative Remedies .....................33 17.5 Professional Fees and Court Costs Included .............................33 17.6 Applicable State Laws ................ 33-34 Intentionally left blank .......................................35 FXMIT GC -A: (Optional) Dispute Resolution Agreement .................... Al 16.1-16.6 Arbitration 163 Mediation ............................... PC -Al LJC.DC (MNOLAL C01,UTIONS 1910 -9 (1990 EDITION) WICITY OF FORT COLUNS MODIRCAIIONS (REV 9/951) INDEX TO GENERAL CONDITIONS City of Fort Collins modifications to the General Conditions of the Construction Contract are not shown in this index Article or Paragraph Number Acceptance of — Bonds and Insurance ........................................5.14 defective Work.._........._.............. 10.4.1, 13.5, 13.13 final payment .......................... ......... 9.12, 14,15 insurance 5.14 other Work by CONTRACTOR ........... ..... �7_3 Substitutes and 'Or -Equal" Item* ......................C.Tl Work- by OWNER ..............................2.5, 6.30, 6.34 Access to the -- Lands, OWNER and CONTRACTOR responsibilities............ ................................. 4.1 site, related Work........__ __ ................... ........... 7.2 Work . ....................... ............... _13.2,13.14,14.9 Acts or Omissions-, Acts and Omissions — CONTRACTOR.... ......... __ ........ ......... 6-9,11.9.133 ENGINEER ..... ....... ..... _ ................ j5.20, 9.13.3 OWNER.................................................... 0.20,8.9 Addenda --definition of (also see definition of Specifications) .......(L6,1.10,6.19). 11 Additional Property Insurance* ................................. 5.7 Adjustments — Contract Price or Contract Times ........................ _13.3.5, 4.1, 4.3.2,4.5.2. ..............................4..5.3, 9.4. 9.5. 10.2-10.4, ...................I.....................11. 12.14.8,15.1 progress schedule ............................... _ .............6.6 Agreement— definition of ...................................................... J.2 'All -Risk" Insurance, policy form, ...........................5.42 Allowances, Cash ....................................................11.8 Amending Contract Documents ................................3.5 Amendment, Written -- in general , ... _ .......... 1. 10. 1.45, 3.5, 5,10, 5, 12, 6.6.2 ........................... 0.8.2, 6.19.10.1. 10.4,11.2 ..........................I.........12.1, 13,112,14,72 Appeal. OWNER or CONTRACTOR intent to ............ ............. 9.10, 9.11, 10.4,16.2. 16,5 Application for Payment -- definition of ....................................................... 1,3 ENGINFERs Responsibility .............................. 9.9 final payment, ..... ........ _ 9.13.4, 9.13.5, 14.12-14.15 in general ..........................2.8, 2.9,544, 9.10. 15.5 progress Payment ..................... I ................ 14.1-14.7 review of ............ ................................ _.,14.4-14.7 Arbitration ... .............................................. Asbestos ... 16.1-16.6 -- claims pursuant theretq__., ......... _ ......... 43.2,43.3 CONTRACTOR authorized to stop Work ... ..... 4.5.2 definition of ...... .............. ............ ................. . .. 1.4 Article or Paragraph Number OWNER responsibility for ............................. 4-54, 8.10 possible price and times change ............. ..........4.5.2 Authorized Variations in Work........, 3.6, 6.25, 6.27, 9.5 Availability of Lands ............. ............................ 4.1. 8A Award, Notice of --defined ....................................... 125 Before Starting Constructiork .............................. Z5-2.8 Bid --definition of ......... ...... _ 1.5 (). 1, 1. 10, 13, 3.3, I .......................4.2.6.4, 6.13, IL4.3,11.9.1) Bidding Documents —definition of .............................1.6(6.8.2) Bidding Requirements --definition of .......................................... 1.7(l.1,4.2.6.2) Bonds -- acceptanceof .. ....... .....................................5.14 additional bonds ................ Cost of the ............... 11.5.4 definition of .......................................................1.8 deliveryof ...................................................2.1, final Application for Payment ................. 14,12-14.14 general ....................................... 1.10,5.1-5.3.5.13, ... I ............. .......... ­1 ..... 9.13,10.5.14.7.6 Performance, Payment and OtheT ........ ......... 5.1-5.2 Bonds and Insurance --in genera) .................................5 Builder's risk 'all-risk" policy form, ....... .............. _�.6.2 Cancellation Provisions, Insurance_ ...... 5.411, 5.8, 5.15 Cash Allowances . .................... .............................. JL8 Certificate of Substantial Completion ........ 1.38, 6.30.2.3, .............. ___ .................... ... 14.8,14-10 Certificates of Inspection, ................... 9.13.4,13.5,14.12 Certificates of Insurance„_......... 2.7, 5.3. 5.4.11, 5.4.13, I ..................... 5,635.8, 5,14,9.13.4,14.12 Change in Contract Price.. Cash Allowances J1.8 claim for price adjustment ............. 4.1.4.2.6. 4.5. 5.15,6.81.9.4 ...................9.5, 9.11. 10.2, 10,5, 1 I,Z 13.9. ....................... 13.13.13.14.14.7.15.1,15.5 CONTRACTOR!s fee .........................................11.6 Cost of the Work general ......... ...................................... 11.4-11.7 Exclusions to 11.5 Cost Records _.... .............................................. J 1.7 in general ............. J,19,1.44,9.11. 10.4.2,10.4.3. 11 Lump Sum Pricing ..........................................11.3.2 Notification of Surety., ......................... __ ......... 10.5 Scope of__ . . .............. ................... .......... JO.3-10.4 Testing and Inspection, Uncovering the Work ..................................13.9 EJCDC GENERAL CONDITIONS 1910.5 (1990 EDMON) W/ CITY OF FORT COLLINS MODMCAMM (REV 9" Unit Price Work......._..._.........._...............11.9 CONTRACTOR's Fee ............. ................. . _ --- 11.6 Article or Paragraph Number Value of Work .................................................11.3 Change in Contract Times — Claim for times adjustment .......4.1, 4.2.6, 4.5, 5.15, ....... 6.9.2, 9.4, 9.5. 9.11, 10.2, 10.5. 12.1, ' * ....... 13.9. 13.13. 13.14, 14.7, 15.1. 15.5 tr Conactual time limits ..................................... 12.2 Delays beyond CONTRACT03ts control. ................................................... _12.3 Delays beyond OWNERs and CONTRACTOKs control ............................. 12.4 Notification of surety ........................... ......... _M5 Scope of change ......................... .............. 10.3-10.4 Change Orders -- Acceptance of Defective Work..,_ ..................._13,13 Amending Contract Documcnq .........................3.5 Cash Allowances jL8 Change of Contract Priop............................. ....... I I Change of Contract Time; ...................................12 Changes in the Work ..........................................10 CONTRACTOWs fee ....................................... 11.6 Cost of the Work ......... __ ...................... -.11.4.113 Cost Records ...... ............ ........ ___ ............ J1.7 definition of .......................................................1.9 emergencies .....................................................0.23 ENGINEERS responsibility ....... 9.8.10.4. 1 LZ 12.1 execution of .....................................................10.4 Indemnifictior4 ............ ...... 15.12,6.16, 6.31-6.33 Insurance, Bonds and ...... ............... 5.10,533,10.5 OWNER may tcrminalq, ........................... 152-15.4 OWNERs Responsibility ............................ $.6,10.4 Physical Conditions — Subsurface and .............................. .............. 4-2 Underground Facilities ..............................4.3.2 Record Docurn crits ......... ........................ ......... 619 Scope of Change ....................................... 10.3-10.4 Substitutes ............................................. �6.7.3.6.9.2 Unit Price Work ...............................................11.9 value of Work, covered by .................................11.3 Changes in the Work .................... ......................... _10 Notification of surety ...... __ .................... _ ....... 10.5 OWNEWs and CONTRACTOks responsibilities............................................10.4 Right to an adjustment......................................10.2 Scope of change ........................................ 10.3-10A Claims -- against CONTRACTOR......:.....- ...................... 6.16 against ENGINEER ......................................... 6.32 against OWNER . ............................... .............. k32 Change of Contract Price ......................... _9.4,11.2 Change of Contract TinM ..........................9.4, 12.1 CONTRACTORs .............4, 7.1. 9.4. 9.5. 9.11. 10.2. ...........................I I.Z 11.9,12.1, 13.9,14.8, .......................... __­­ ........ 15.1,15.5,17.3 Article or Paragraph Number CONTRACTORs liability,,,....... 5.4, 6. 1 Z 636, 6.31 Cost of the Work .......................................11.4,11.5 Decisions on Disputes,.............................9.11,9.12 Dispute Resolution ............................................16.1 Dispute Resolution Agreement ................... 16.1-16.6 ENGINEER as initial interpretar .......................9.11 Lump Surn Pricing ......................................... j 1.3.2 Noticeof . ..... ....... ................ __ ....................... )Y.3 OWNER'S....................9.4, 9.5, 9.11, 10.2, ILZ 11.9 ..................... _12.1,13.9,13.13.13.14,17.3 OWNER!s liability ...............................................5.5 OWNER may refuse to make payment .............. _14.7 Professional Fees and Court Costs Included........... .. .......... __ ........... _ .......... 17.5 request for formal decision oQ ........................... 9,11 Substitute Items 0-7.1.2 Time Extension.................................................12.1 Time requirements ...................................9.11, 12.1 Unit Price Work ......... .................... ............. 1t.9.3 Valueof ................. ......................................... 1,13 Waiver of --an Final Payment .................. 14.14,14.15 Work Change Directivt% ........... I ..... I ... written notice require4 ......................9.11, I1.:4 12.1 Clarifications and Interpretations.......,.... �3.6.3,9.4,9.11 Clean Site .................... ....... ................. 0.17 Codes of Technical Society, Organization or Association..................................................3.3.3 Commencement of Contract Times ...........................2.3 Communications-- general..............................................6.2, 6.9.2, 8.1 Hazard Communication Programs ...................... 0,22 Completion — Final Application for Payment ..........................14.12 Final Inspection....,,,..... . * ..... - "*"*"..........................14.11 ........... J4.11 Final Payment and Acceptance ............ _14.13-14.14 Partial Utilization...........................................14.10 Substantial Completion ......... ............ 1.38.14.8-14.9 Waiver of Claims ............................................14.15 Computation of Times ., ............................. 17.2.1-17.12 Concerning Subcontractors, Suppliers andOthers .................................................6.8.6.11 Conferences -- initially acceptable schedules ..............................2.9 preconsiructiork ..................................................2.8 Conflict, Error, Ambiguity. Discrepancy — CONTRACTOR to Report ........................... �.5. 3.3.2 Construction, before starting by CONTRACTOR., ............................. ........... :2.5-2.7 Construction Machinery. Equipment. etc ..................AA Continuing the Work .................................... §29, 10.4 Contract Documents — Amending..........................................................3.5 Bonds __.5A EJCDC GENERAL CONDITIONS 1910.9 (IM EDITION) w/ CITY OF FORT COLLINS MODIFICATIONS (REV 91") Cash Allowances...._........................................11.8 Article or Paragraph Number Change of Contract Prioq .................................... I I Change of Contract Times ..................................12 Changes in the Work ........ ............. ......... 10.4-10,5 check and verify .................. ....... 2.5 Clarifications and Interpretations .............. ...........$.2, 3.6, 9.4, 9.11 definition of .....................................................1.10 ENGINEER as initial interpreter of .......... ........9.11 ENGINEER as OWNEWs representative. .... ........ 9.1 gen=13 Insa."mee...........................................................5.3 Intent 3.1-3.4 minor variations in the Work .............................. 3,6 OWNERs responsibility to furnish data...............93 OWNER's responsibility to make prompt payment ......... ...... .... 1...-8.3,14,4,14,13 precedence ................................................ 3.1,3.3.3 RecordDocuments ............................................0.19 Reference to Standards and Specifications of Technical Societie4 ................................... 3.3 Related Work .................................................... 72 Reporting and Resolving Discrepancies,,,,,,,, 2.5, 3.3 Reuse of 33 Supplem enting ..................................................3.6 Termination of ENGINEEKs Employment ...... _ 8.2 Unit Price Work ....... ....................................... 11.9 variations. . ........................................ 3.6, 6.23, 6.27 Visits to Site, ENGINEEKil ............................... 9.2 Contract Price — adjustment of ............... 3.5, 4.1, 9.4. 10.3. 11.2-11.3 ChangeOf...........................................................I I Decision on Disputes ........................................9.11 definition Of Contract Times — adjustment of ...... ............ 3.5.4,1.9.4,10.3,12 Change ot, ............................................... J2.1-12.4 Commencement definitionof.....................................................1.12 CONTRACTOR — Acceptance of Insurance ...................................5.14 Comm unications ......................................6.2.6.9.2 Continue Work, ... 11.4 ................................ j6.29,10.4 coordination and scheduling ................. _ ........ 6,92 definition of .....................................................1.13 Limited Reliance on Technical Data Authorized- .....................................4.2.2 May Stop Work or Term irate............................15.5 provide site access to others,,,,,,,,,,,,,,,,,,,,,,, :7.2,112 Safety and Protection.. ............ .... 4.3.1.2,6,16, 6.18. .................................. ......... * ........ * ... * .......... ­­ 6,21-6.23, 7.2, 13.2 Shop Drawing and Sample Review Prior to Subm ittak .......................................6.25 Vii Stop Work requirements ..................................4.5.2 CONTRACTOR's— Article or Paragraph Number Compensation.. . ....... _ ................ .......... _.11.1_11.2 Continuing Obligation .....................................14.15 Defective Work ...... ............ .......... _9.6, 13.10-13.14 Duty to correct defective Work ..........................13.11 Duty to Report -- Changes in the Work caused by Em agency.. _ ..... ........ __ ................ 6.23 Defects in Work of Others, ............................. 7.3 Differing condition$ ...................................4.2.3 Discrepancy in Documents ..... _.", 3.32, 6.14.2 Underground Facilities not indicato ........... 4.3-2 Emergencies ......................... _ .................... .... 0,23 Equipment and Machinery Rental, Con of the Work .................... 11.4.5.3 Fee --Cost Phiq..........................11.4.5.6, IL5.1, 11.6 General Warranty and GuanmW ................. ..... 030 Hazard Communication Program4 ....................0.22 Indemnification ......................... 6.1Z 6.16.6.31-6.33 Inspection of the Work ............... ............... 7.3,13.4 Labor, Materials and Equipment .............. ..... 0.3-6.5 Laws and Regulations, Compliance by,,,,,,,,.,,, 6.14A Liability Insurance ..............................................5.4 Notice of Intent to Appeal ......................... 9.10,10.4 obligation to perform and complete theWork....................................................0.30 Patent Fees and Royalties, paid for by,,,,,,,,,,,,,,,,, . 6.12 Performance and Other Bonds 5.1 Permits, obtained and paid for by .............. ........ 0.13 Progress Schedule ........................... 2.6,18,19, 66, .......................................6.29. 10.4,15.2-1 Request for formal decisionon disputes, .............. 9,11 Responsibilities -- Changes in the Work -------- "' 10.1 Concerning Subcontractors, Suppliers andOthers 6.8-6.11 Continuing the Work 10.4 CONTRACTOR's expense ...........................0.7.1 CONTRACTOR's General Warranty and Guarantee.... ................. _ ............... 6.30 CONTRACTOR's review prior to Shop Drawing cr Sample submittal ................. 6.25 Coordination of Work ................................6.9.2 Emergencies, ............................................... 6.23 ENGINEERs evaluation, Substitutes or "Or -Equal" ............. 03.3 For Acts and Omissions of Others ........... ....... ....... _0.9.149.2.9.13 for deductible amounts. insurance ......... ......... 6_9 general ........................................0, TZ 7.3, 89 Hazardous Communication Programs.......... 6.22 IndemnificatioR ....................... .......... 6.31-6.33 EJ(-W. OENLP AL CONDITIOM 1910-8 (IM MITIOM wi aTY OF FORT COLLINS MODMCA71ONS 0MV91M Labor, Materials and Equipment .... ......... 6.3-6.5 Laws and Regulations.................................6.14 Liability Insurance ........................................ 5.4 Article or Paragraph Number Notice of variation from Contract Documents ........................................... 6.27 Patent Fees and Royalties..............................0.12 Permits.......................................................0.13 Progress Schedule ..................... ......... ...........6.6 Record Documents..: .................. ......... __..... 6.19 related Work performed prior to ENGINEER s approval of required submittals ..... ........................................ 0,28 safe structural loading.................................6.18 Safety and Protection_..................6.20, 7.2. 13.2 Safety Representative,...., ......_..................621 Scheduling the Work..................................6.9.2 Shop Drawings and Samples ........................0.24 Shop Drawings and Samples Review by ENGINEER ..................................... 6.26 Site Cleanliness_ ........................................ 6.17 Submittal Procedures .................................. 6,25 Substitute Construction Methods and Procedures .................................... 6.7,2 Substitutes and "Or -Equal" Items................0.7.1 Superintendencq...........................................6.2 Supervision...................................................0.1 Survival of Obligations,,,,,,,,,,,,,,,,,,,,,„_.6.34 Taxes........_................................................0.15 Tests and Inspections .................. ...............13.5 ToReport ........................... .._...................... 2.5 Use of Premises .....................6.16,6.18, 6.30.2.4 Review Prior to Shop Drawing or Sample Submittal........................................6.25 Right to adjustment for changes in the Work ..... 10.2 right to claim............ 4, 7.1, 9.4, 9.5, 9.11, 1022,11.2, ,...,,,.,,11.9, 12.1, 13.9, 14.8, 15.1, 15.5. 17.3 Safety and Praecticq................. 6.20-6.22, 7.2, 13.2 Safety Representative .... .................................... .21 Shop Drawings and Samples Submittal*.,,, 6.24-6.28 Special Consultants........................................11.4.4 Substitute Construction Methods and Procedure*..6.7 Substitutes and "Or -Equal" Items, Expense .......................................... 6.7.1, 6.7.2 Subcontractors, Suppliers and Others........., 6.8-6.11 Supervision and Superintendencq ......... 6.1, 6.2, 6.21 Taxes. Payment by............................................615 Use of Premises... .................... .................6.16-6.18 Warranties and guarantees ..........................0.5. 6.30 Warranty of Title..............................................14.3 Written Notice Required -- CONTRACTOR stop Work or terminate ,....... 15.5 Reports of Differing Subsurface and Physical Condition*........................4.2.3 Substantial Completion„..............................14.8 Viii CONTRACTORS —other... -------------- ..................... 7 Contractual Liability Insurance ................ _......... _5.4.10 Contractual Time Limits........................................12.2 Article or Paragraph Number Coordination— CONTRACTORs responsibility .................... _ _ 6.9.2 Copies of Documents...............................................?.2 Correction Period..................................................13.12 Correction. Removal or Acceptance of Defective Work-- in general...................................10.4.1. 13.10-13.14 Acceptance ofDejective Work., ......................... 13.13 Correction or Removal of Defective Work ................................. 6.30, 13.11 Correction Period............................................13.12 OWNER May Correct Defective Work ............ .13.14 OWNER May Stop Work............................._..13.10 Cost -- of Tests and Inspections.....................................13.4 Records11.7 Cast of the Work — Bonds and insurance, additional ...................11.4.5.9 Cash Discounts..............................................11.4.2 CONTRACTORs Fee.......................................11.6 Employee Expenses, ..................................... 11.4.5.1 Exclusions tq....................................................11.5 Generall 1.4-11.5 Home office and overhead expenses ....................11.5 Losses and damages .................................... 11.4.5.6 Materials and equipment................................11.4.2 Minor expenses...........................................11.4.5.8 Payroll costs on changes.................................11.4.1 performed by Subcontractors... _......................11.4.3 Recordsl l.7 Rentals of construction equipment and machinery.... ......... _ ....................11.4.5.3 Royalty payments, permits and license fees............................................11.4.5.5 Site office and temporary facilities ...............11.4.5.2 Special Consultants, CONTRACTORa............ 31.4.4 Supplemental.................................................)1.4.5 Taxes related to the Work ..................... ........11.4.5.4 Tests and Inspection, ......................................... J3.4 Trade Discounts.............................................11.4.2 Utilities, fuel and sanitary facilities..............11.4.5.7 Work after regular hours.................................11A.1 Covering Work...............................................13.6-13.7 Cumulative Remedies ............... .................. ..... 17.4.17.5 Cutting, fitting and patching ................................... 7.2 Data, to be furnished by OWNER ............................. 8.3 Day --definition of..............................................J7.12 Decisions on Disputes ................................... 9.11, 9.12 defective --definition of........................................_.1.14 defective Work -- Acceptance of..................................._..10.4.1,13.13 EX= OENMAL CONDMO S 1910-8 (1990 EDIT ON) wi aTY of FORT co uNs mach ICA ms (REV 9m) Item No. Item Description Unit Quantity Costlunit Total 202.01 Sawcutting 4" Lineal Foot 200 $325 $ 650.00 203.01 General Excavation Cubic Yard 200 $35.00 $ 7,000.00 203.02 Borrow Ton 50 $27.00 $ 1,350.00 207.01 Imported Topsoil Cubic Yard 50 $52.50 $ 2,625.00 208.01 Stormwater Protection - CDOT Gravel Bag (Rock Sock) Lineal Foot 400 $11.25 $ 4,500.00 208.02 Stormwater Protection - Recycled Rubber Filled Wattle Lineal Foot 20 $15.00 $ 300.00 208.03 Stormwater Protection - COOT Gravel Bag Inlet Fitter Each 10 $100.00 $ 1,000.00 212.01 Sod Square Foot 100 $3.00 $ 300.00 212.02 Landscapellrrigation Labor Flour 30 $32.00 $ 960.00 304.01 Aggregate Base Course Ton 2,000 $27.25 $ 54,500.00 403.01 Temporary Patching Ton 300 $200.00 $ 60,000.00 601.01 Exposed Sand Finish - Up Charge Square Foot 500 $2.25 $ 1,125.00 604.01 Type R Inlet - Remove & Replace (5' Opening, 5' max depth, COOT) Each 2 $4,300.00 $ 8,600.00 604.03 Type R Inlet - Reconstruct Inlet Deck (5' Opening, COOT) Each 5 $1,150.00 $ 5,750.00 604.05 TypeRInlet- MaterialOny(CDOT) Each 2 $600.00 $ 1,200.00 604.06A Area Inlet - Remow & Replace (5' Max depth) Detail D-9A Each 2 $4,000.00 $ 8,000.00 604.08A Area Inlet - Reconstruct Inlet Deck (4' Opening) Detail 0.9A Each 2 $1,100.00 $ 2,200.00 604.1DA Area Inlet- Materials Only ( D-9A) Each 2 $550.00 $ 1,100.00 604.11 Catch Basin - Remove & Replace (5'max depth, D-1313) Each 2 $2,750.00 $ 5,500.00 604.13 Catch Basin -Reconstruct Inlet Deck (D-13B) Each 2 $700.00 $ 1,400.00 604.15 Catch Basin - Material Only (D-1313) Each 2 $850.00 $ 1,700.00 604.16 Modified Type 13 Curb Inlet - Remove & Replace (5' Max Depth, D-13A) Each 2 $3,100.00 $ 6,200.00 604.18 Modified Type 13 Curb Inlet- Reconstruct Inlet Deck ( D-13A) Each 2 $900.00 $ 1,800.00 604.20 Modified Type 13 Curb Inlet- Materials Only (D-13A) Each 2 $750.00 $ 1,500.00 604.21 Concrete Sidewalk Culvert - Remove & Replace (D-12, D- Each 3 $1,700.00 $ 5,100.00 604.22 Metal Sidewalk Culvert - Salvaged Material (D10, D11) Each 5 $800.00 $ 4,000.00 604.23 Metal Sidewalk Culvert - Material Only (D-10,D-11) Each 5 $1,200.00 $ 6,000.00 604.24 Metal Sidewalk Culvert - Additional 5/8" Plate (D-10, D-11) Square Foot 15 $115.00 $ 1,725.00 608.01 Remove Concrete Square Foot 500 $3.00 $ 1,500.00 608.02 Remove and Haul Fillet Each 4 $50.00 $ 200.00 608.03 Apron 8" - Remove & Replace Square Foot 8,000 $8.15 $ 65,200.00 608.04 Crosspan - 8" Remove & Replace Square Foot 5,000 $8.15 $ 40,750.00 608.05 Driveover Curb, Gutter & 6" Sidewalk - Remove & Replace Lineal Foot 8,000 $40.75 $ 326,000.00 608.06 Driveover Curb, Gutter, No Sidewalk - Remove & Replace Lineal Foot 1,000 $23.75 $ 23,750.00 608.07 Vertical Curb, Gutter and 6" Sidewalk - Remove & Replace Lineal Foot 2,000 $42.25 $ 84,500.00 608.08 Vertical Curb, Gutter, No Sidewalk - Remove & Replace Lineal Foot 100 $26.00 $ 2,600.00 608.09 Vertical Outfall Curb, Gutter - Remove & Replace Lineal Foot 50 $23.50 $ 1,175.00 Correction or Removal of 10.4.1, 13.11 OWNERsRepresentative.............................._,. 9.1 Correction Period ......... ......,,J3.12 Payments to the CONTRACTOR in general ........................... ........... _ 13, 14.7. 14.11 Responsibility for,,,,.. ................ ..... .-..... 9.9, 14 Recommendation of Payment,,,,,,,,,,, .... 144,1413 Article or Paragraph Number Article or Paragraph Number Observation by ENGINEER ................................ 9.2 OWNER May Stop Work .................... ............. 13.10 Prompt Notice of Defects..................................13.1 Rejecting.................................................. 9.6 Uncovering the Work .................... ................... J3.8 Definitions................................::..............................1 Delays.....................................4.1.6.29, 12.3-12.4 Delivery of Bonds.....................................................2.1 Delivery of certificates of insurance, .......... ................ 2.7 Determinations for Unit Prices ................................ 9.10 Differing Subsurface or Physical Conditions — Notice of ................--..... ................ ....,,4.2.3 ENGINEER's Review ...................................... 4.2.4 Possible Contract Documents Change,,., ... ......4.2.5 Possible Price and Times Adjustments,,,,,,,,,,,,, 42.6 Discrepancies -Reporting and Resolving ......... :........ ............. 2.5. 3.3.2, 6,14.2 Dispute Resolution — Agreement ...............................................16.1-16.6 Arbitration ...............................................16.1-16.5 general16 Mediation........................................................ J,6.6 Dispute Resolution Agreement ............... .- ....... .16.1-16.6 Disputes, Decisions by ENGINEER...................9A 19.12 Doc =ents-- Copiesof...........................................................7.2 Record 6.19 Reuseof.............................................................33 Drawings -definition of ................. .................... .. ...J.15 Easements.............................................................4.1 Effective date of Agreement -- definition qt ............. J.16 Emergencies......_ ..................._..........._ _....... ....... ,23 ENGINEER — as initial interpreter on disputes .................9.11-9.12 definition of, -1...- .................................. ....... 1.17 Limitations on authority and responsibilitigg,,,,, ,13 Replacement of ...................... 8.2 Resident Project Representative ...........................9.3 ENGINEER's Consultant -- definition of_ ...............1.18 ENGINEER's-- authority and responsibility, limitations on ....... ,9.13 Authorized Variations in the Work ...................9.5 Change Orders, responsibility for ....... .7. 10, 11, 12 Clarifications and Interpretations .............. 3.6:3, 9.4 Decisions on Disputes .............................. 9.11-9.12 defective Work, notice of ........... ........................ 13-1 Evaluation of Substitute Items .........................0.7.3 Liability ...................................................6.32, 9.12 Notice Work is Acceptable..............................14.13 Observations, ..........................................6.30.2, 9.2 Responsibilities --Limitations oil................9,11-9.13 Review of Reports on Differing Subsurface and Physical Conditions.............................4.2.4 Shop Drawings and Samples, review responsibility ............................. _ _............ 6.26 Status During Construction -- authorized variations in the Work..................9.5 Clarifications and InlerpretationA ..................9.4 Decisions on Disputes, ... ........ ........ .. 9.11-9.12 Determinations on Unit Price., .. .......... _.I...9.10 ENGINEER as Initial Interpreter_-------- 9.11-9.12 ENGINEER's Responsibilities ................9.1.9.12 Limitations on ENGINEER's Authority and Responsibilities..............................9.13 OWNER's Representative............................1.9.1 Project Representative................................9.3 Rejecting Defective Work..............................9..6 Shop Drawings, Change Orders and Payments,,,,,,,,,,,,,,...................... 9.7-9.9 Visits to Site ....... ...................... _..................9.2 Unit Price determinations.................................9.10 Visits to Site. .............9.2 Written consent require4..............................7.2, 9.1 Equipment, Labor, Materials and ........................0.3.6.5 Equipment rental, Cost of the Work .... __,.......... 1.4.5.3 Equivalent Materials andEquipment ........................0.7 error or missions ................ .... 6.33 Evidence of Financial Arrangement$ ........ ............. PAI Explorations of physical conditions ....................... 4.2.1 Fee, CONTRACTOR's--Costs Plus, .......................... 11.6 Field Order -- definition of... J.19 issued by ENGINEER, ....................... ....... 3.6.1, 9.5 Final Application for Payment..............................14A2 Final Inspection .......................... ............. . .. ....J4.11 Final Payment — and Acceptance ................ ....... ......... _14.13-14.14 Prior to, for cash allovarecs...............................11.8 General Provisions..........................................17.3-17.4 General Requirements— defmition ot......................................................J,20 principal references t9..............2.6, 6.4, 6.6.6.7, 6,24 Giving Notice ...... ............ ........ ..... _......... ............... 17.1 Guarantee of Work —by CONTRACTOR........6.30, 14.12 Hazard Communication Program; .......................... b.22 Hazardous Waste -- definition of....................................................1.21 general............................................................. 4.5 OWNER's responsibility for..............................8.10 WMC GUMM& cortomONS 1910-8 (1990 EDIII0M w7 MY OF FORT COLLIM MODMCA170M (REV 9l" Indemnification._ ..... ____,_.... ------ 412, 6.16, 6.31-6.33 Initially Acceptable Schedules,,,,,,,,,,,,,,,,,,,,,,;,2.9 Inspection -- Certificates of.............................9.13.4, 135, 14.12 Final...........................................................14.11 Article or Paragraph Number Special, required byENGINEER .........................9.6 Tests and Approval.............................$.7, 13.3-13.4 Insurance — Acceptance of, by OWNER ............ .............. .... 5.14 Additional, required by changes in the Work............................................11.4.5.9 Before starting the Work .................................... 2.7 Bonds and --in general..........................................5 Cancellation Provisions ..................................... 5.8 Certificates of . ...... -7, 5, 5.3, 5.4.11, 5.4.13, ........................5.6.5, 5.8. 5.14, 9.13.4, 14.12 completed operations.....................................5 4.13 CONTRACTOR's Liability ..................................5.4 CONTRACTOR's objection to coverage.............5.14 Contractual Liability._...................................5AA0 deductible amounts, CONTRACTOR's responsibility ................................................5.9 Final Application for Payment ....................... 14.12 Licensed Insurers...............................................5.3 Notice requirements material changes,,,,,,, 5.8, 10.5 Option to Replace.............................................5.14 other special insurances .............................._.... 5.10 OWNER as fiduciary for insureds..............5.12-5.13 01ANER's Liability ............................................5.5 OWNER's Responsibility .................................... 8.5 Partial Utilization, Properly Insurance...............5.15 Property... ...................................... ............5.6-5.10 Receipt and Application of Insurance Proceeds ..... .......................... ............... 5.12-5.13 Special Insurance.-- . ....................... _... -....... ..5.10 Waiver of Rights..............................................5.11 Intent of Contract Document; .............. .......3.1-3.4 Interpretations and Clariticationi;..................... 3-6.3, 9.4 Investigations of physical condition;.........................4.2 Labor, Materials and Equipment ..........................6.35 Lands -- and Easements...................................................$.4 Availability of.............................................4.1. 8.4 Reports and Tests...............................................$.4 Laws and Regulations --Laws or Regulations-- Bonds........................................................5.1-5.2 Changes in the Work ..... ......... ........... ............10.4 Contract Documents...........................................33 CONTRACTOR's ResponsibiliRies,,,,,,,,,,,,,,,,,,,, 6.14 Correction Period, defective Work ........... .........13,12 Cost of the Work, taxes...............................11.4.5.4 definition of...................................................1.22 general6.14 Indemnification ..... ................................. 6.31-6.33 Insurance ..............-................................. ­­'­5.3 Precedence...............................................3.1, 3.3.3 Reference to....................................................3.3.1 Safety and Protection ............................. 6.20. 13.2 Subcontractors, Suppliers and Other§,,,,,,,,,. 6.8-6.1 I Article or Paragraph Number Tests and Inspections.................................13.5 Use of Premises................................................6.16 Visits to site ........................... _.........................9.2 Liability Insurance-- CONTRACTOR's................................................ .4 OWNER's...........................................................5.5 Licensed Sureties and Insurers ................................. 5.3 Liens -- Application for Progress Payment .......................14.2 CONTRACTOR's Warranty of Title _ .............. ...)4.3 Final Application for Payment, ........................14.12 definition of... .......... .......................... ....... __'J.23 Waiver of Claims... ......................................... ) 4.15 Limitations on ENGINEER's authority and responsibilities..................................................9.13 Limited Reliance by CONTRACTOR Authorized ...................................................... 4.2.2 Maintenance and Operating Manuals -- Final Application for Payment .........................14.12 Manuals (of others) -- Precedence ...................... ........ 3.3.3.1 Reference to in Contract Documents._...............3.3.1 Materials and equipment — furnished by CONTRACTOR ............................. 6.3 not incorporated in Work...................................14.2 Materials or equipment --equivalent ...........................0.7 Mediation (Optional) ................................... Milestones --definition of........................................3.24 Miscellaneous -- Computation of Times ................................. _..._17.2 Cumulative Remedies....................................._J7.4 Giving Notice...................................................J7.1 Notice of Claim................................................17.3 Professional Fees and Court Costs Included,,,,-„_17.5 Multi -prime contracts..._............................................7 Not Shown or Indicated, .......... ...... ................ __4.3.2 Notice of — Acceptability of Project....................................14.13 Award, definition of, ........................................ J.25 Claim............................................................17.3 Defects,13.1 Differing Subsurface or Physical Condition; ..... 4.2.3 Giving.......................................... :...:............. 1.7.1 Tests and Inspections........................................13.3 Variation, Shop Drawing and Sampl4.................0.27 Notice to Proceed -- definition of.....................................................1.26 givingof ....... ....................... _............. _............ 2.3 E1CDC OENfltAL CONDITIONS 1910.8 0990/EpDryIT�ION) w/ QTY OF FORT COUINS MODIRCATIONS OMV 9/99) Notification to Surety _....................... ......................10.5 Observations, by ENGINEER..........................6.30, 9.2 Occupancy of the Work,,,,,,,,.„_„....5.15, 6,30.2.4, 14.10 Omissions or acts by CONTRACTOR : .............. 6.9, 9.13 Open Peril policy form, Insuraneq ..........................5.6.2 Option to Replace....................................................$.14 Article or Paragraph Number "Or Equal" Items .... ..................................................b-7 Other work 7 Overtime Work —prohibition of ................................. 6.3 OWNER — Acceptance of defective Work............................3.13 appoint an ENGINEER......................................8.2 as fiduciary ................... ............................ 5.12-5.13 Availability of Land;, responsibility .................... 4.1 definition of.....................................................1.27 data, furnish ...... ............ ............ .................. ....,8.3 May Correct Defective Work „ ..........................13.14 May refuse to make payment.............................a4.7 May Stop the Work ,,,,,,,..................... .-.......... .13.10 May Suspend Work, Terminate.........................„8.8. I3.10, 15.1-15.4 Payment, make prompt,,,,,,,,,,,,,,,,,,,„$.3, 14.4, 14.13 performance of other work ................................. T1 permits and licenses, requiremen.....................0.13 purchased insurance requirement;,,,,,,,,,,,,,, .............. OWNER's-- Acceptance of the Work.. ............................ 0.30.15 Change Orders, obligation to executq,,,,;.....8.6, 10.4 Comm unications................................................8.1 Coordination of the Work................................... 7.4 Disputes, request for decision ....... .................... 911 Inspections, tests and approval§ .................. $.7, 13.4 Liability Insurance ...................... ....................... 5.5 Notice of Defects..............................................13.1 Representative --During Construction, ENGINEER's Status ..... ........ — .....................9.1 Responsibilities — Asbestos, PCBs, Petroleum, Hazardous Waste or Radioactive Material................F.10 Change Orders, ................... _ ...................... 8.6 Changes in the Work..................................10.1 communications .......................................... ..8.1 CONTRACTOR's responsibiliti................... 8,9 evidence of financial arrangements..............8.11 inspections, tests and approval* .................... J9.7 insurance...................................................... $.5 lands and easements- ................................... 8.4 prompt payment by., ............................. ........ 8.3 replacement of ENGINEER .......................... 8.2 reports and tests ........................................... 8.4 stop or suspend Work,. ................ A.8,13.10,15.1 terminate CONTRACDORs services- .......................... ............. 8.8. 15,2 separate representative at site.............................Q.3 testing, independent ........ ,- use or occupancy of the Work,,,,,,,,,,,,,,,,,,, written consent or approval required ....................... _..........................13.4 ..... 5.15. 6.30.2.4, 14.10 .............. —9.1, 6.3, 11.4 EJCOC OGNERAL CONDITIONS 1910•8 (1990 ED1110M w/ CITY OF FORT COLLINS MODITICATiONS ptEV 9199) Article or Paragraph Number written notice required........................7.1, 9.4, 9.11, ....................................I1.2, ­* ............... ­1 .......... I 1.',) 11 -9, 14-7, 15.4 PCBs -- definition of ......................... .................. 1-29 general............ ................................................. 4.5 OWNER!s responsibility far . .............................. $.10 Partial Utilization - definition of .................... ........ . ...................... 1.28 general 6.30.2.4. 14.10 Property Insurance .......... .............. ....... ...... 515 Patent Fees and Royalties ........................................ 6.12 Payment Bands .................. ................................ 5.1-5.2 Payments. Recommendation of .............. 14.4-143, 14.13 Payments to CONTRACTOR anCompletion- Application for ProgressPayments ......................14.2 CONTRACTOR!s Warranty of Title,,.,,,__-.-.... - J 4.3 Final Application for Payment .........................14.12 Final Inspectio..............................................14.11 . Final Payment and Acceptance ....... ........ 14.13-14.14 general... ...... .­ ...... * ....... ................ I .... Partial Utilization ...............................4...........14.10 Rerainagc..........................................................14.2 Review of Applications for Progress Payments ................. 4 ............. j 44-143 prompt payment ................................ ............. _P.3 Schedule of Valuak ............................................ 14.1 Substantial Completion-........ ....... ........... 141,8-149 Waiver of Claims .............................................14.15 when payments due., .............................. 14.4,14.13 withholding payment . ...... ......................... ....... 14-7 Performance Bands , ......... ..... 4_4 .............. 4 ......... 541-5.2 Permits_ .............................................4...........0.13 Petroleum -- definition of .................... ........ . . . ...... . ........... 1.30 general..................... 44 ................... ......... ......... 4.5 OWN M-'s responsibility far� .............................. A.10 Physical Conditions -- Drawings of in or relating to ........................ 4.2.1.2 ENGrKEER!s review .........................................4.24 existing structures...... _........ ... __ ............. ..... 4.2,2 general4.2.1.2 . ... ................... __ ----- ....................... Notice of Differing Subsurface or...................... 4,23 Possible Contract Documents Change ...............4.2.5 Possible Rice and Times Adjustments ..... - ........ 4.2.6 Reports and Drawings ............ ......................... 4.23 Subsurface and ....................................................4.2 Subsurface Conditions ...................................4.2.1.1 Technical Data, Limited Reliance by CONTRACTOR Authorized ........................ 4.2.2 Underground Facilities -- general.................... ................................... 4.3 Not Shown or Indicated .............................. 4.3.2 Protection of......................................4.3.6.20 xii Article or Paragraph Number Shown or Indicated ...............................................4.3.1 Technical Date ................................. 4.2.2 Preconstruction Confereneq .......................................2.8 Preliminary Matters ........ __ ....... _ .... ............... ......... 2 Preliminary Schedulq ........................... ................ _2.6 Premises, Use of_..........................................b.16-6.18 Price, Change of Contract ..........................................I I Price, Contract -definition of ................................ _ 1.11 Progress Payment. Applications for ..... . __ .............. J4.2 Progress Payment--retainagq ........ ........ .......... ____ 14.2 Progress schedule, OONTRACTOR!s, ....... ... 2.6,2.8.2.9, ................................. 6.6.6.29,10.4, I5.2I Project --definition of...............................................1.31 Project Representative— ENGINEERs Status DuringConsavotiorl ............ 9.3 Project Representative, Resident -definition of ......... 1.33 prompt payment by OWNER .....................................8.3 Property Insurance -- Additional.........................................................53 gencra15.6-5.10 Partial Utilization ............ ...... 5.15.14.10.2 receipt and application of proce"k ............ 5.12-5.13 Protection, Safety and ........................... _0 20-6.21, 13.2 Punchlist ..........................................................14.11 Radioactive Material­- defintionof .....................................................1.32 gencra14.5 OWNER's responsibility for ............. _ ............... ?. 10 Recommendation of Payment, ................ J4,4,14.5,14.13 Record Documents........................................ j6.19,14.12 Records, procedures for maintaining..........................2.8 Reference Points ....................................................... 4.4 Reference to Standards and Specifications of Technical Societies,,,,,,,,,,,,,,,,,,,„_................. 3.3 Regulations, Laws and (or) ......................................6.14 Rejecting Defechve Work_ ............ ........................... 9.6 Related Work -- atSite ..... ..................................... ............ 7.1-7.3 Performed prior to Shop Drawings and Samples submittals review .................... A28 Remedies. cumulative ......... ....... ................... )7.4,17.5 Removal or Correction ofDofeefive Work................13.11 rental agreements, OWNER approval required,,., 11.4.5.3 replacement of ENGINEER, by OWNER,, .................. t2 Reporting and Resolving Discrepancies .................................2.5, 3.3,2, 6.14.2 Reports -- and Drawings .................................................4.2.1 and Tests. OWNERS responsibility ............ ........ $.4 Resident and Project Represeritative­ definition of .................................................... ).33 provision for ................. ........................................... 9.3 EJCW GENERAL CONDITIONS 1910.8 (1990 EDITION) W1 CITY OF FORT COLUNS MODIFICATIONS (REV 91") Article or Paragraph Number Resident Superintendent. CONTRACTOX;.. ......... , �62 Responsibilities-- CONTRACTORs-in general ..................................6 ENGINEWs4n general ................. ....................... 9 Limitations on .............................................9.13 OWNEWs-in general ................................ ........ 8 Retainage. .......................... .......... __ ....... __ ...... 14.2 Reuse of Documents Review by CONTRACTOR; Shop Drawings and Samples Prior to Submittal .............. ........... §.25 Review of Applications for Progress Payments .............. __ ................... 14.4-14.7 Right to an adjustmetA ...........................................10.2 Rightsof Way....---- ......................... .......... ........... 4.1 Royalties, Patent Fees and......................................6.12 Safe Structural Leading......_.................................om Safety -- and Protection ........................... ... 4.3.Z 6.16, 6.18, .....I ....... ........................ 6.2".21. 7.2, 13.2 general.................................................... §20.6,23 Representative, CONTRACTORs .......................6.21 Samples -- definition of .....................................................1.34 1.34 general..................................................... 4.24-6.28 Review by ODNTRACTOR ................................6.25 Review by ENGINEER .............................. 6.26,6.27 related Work ....................................................0.28 submittal of ......................... ........................... 0.24.2 submittal procedureit .........................................0.25 Schedule of progress ........ .................... 2.6,2.8-2.9, 6.6, .........................................6.N, 10.4.15.2.1 Schedule of Shop Drawing and Sample Subm inals .............. ............... 2.6. 2.8-2.9. 6,24-6.28 Schedule of Values,,,,_ ........... 2.6,18.2.9,14.1 Schedules -- Adherence to AdJusting................... ...... ........................ Change of Contract Timcq .................................10.4 Initially Acceptable ........ ............. 2.8.2.9 Prelim Scope of Changcs ....................................... 10.3-10.4 Subsurface Conditions Shop Drawings -- and Samples, general ................................ 6.24-6.28 Change Orders & Applications for Payments, and...._............_ ... _ ........ 9.7-9, 9 definition of ..................... ................................ 1.35 ENGINEER's approval of ................................. 16.2 ENGINEEWs responsibility for review.....................................9.7, 6.2".28 related Work .............. ...... ............................... 0.28 review procedures ............................... 2.8,624-628 Article or Paragraph Number submittal required ............................... . ............. _624.1 Submittal Procedures ......................................... 6.25 use to approve substitutions ............................. 63.3 Shown or Indicated _43,1 Site Access ...................................................... 7.2. 13.2 Site Cleanliness......................................................0.17 Site, Visits to — by ENGINEER ...................... .................... 9Z 13.2 byothers ........................................._.:.............13.2 "special causes of lose policy form, insurance ........................................................5.6.2 * .......... * ............ *i*. .... ................ �.6.2 de ""*.." definition 0 ... Specifications— defination of ............................ ...... . ............... J.36 of Technical Societies, reference t9 _33.1 precedence ......................................................3.3.3 Standards and Specifications of Technical Societies ........................ ................. 3.3 Starting Construction, Before ... __ ....................... 2.5-2.8 SWLMBthe Work .....................................................2.4 Stop or Suspend Work — by CONTRACTOR ............................. . ........... 15.5 by OWNER . .......... .......................... 8.8.13.10,15.1 Storage of materials and equipment ............. ...... 4.1.7.2 Structural Loading, Safety,,,,,,,,,,,,,,, 6.18 Subcontractor — Concerning ................................................ &8-6.11 definition of.....................................................1.37 delays.. ........ .............................. ------- 12.3 waiver of rights .......... ................. .................. 6. 11 Subcontracturs--in general ......................... ....... 6.9-6.11 Subcontracts --required Provisiorw.. ...... 5.11. 6.11,11.4.3 Subm ittals— Applications for Payment..................................14.2 Maintenance and Operation Manuals,,,,,,,,,,,,,, 14.12 Procedures.......................................................6.25 Progress Schedules ... ................................... 2,6, 2.9 Samples .......................... ........... ......... 0.24-6.28 Schedule of Values 2.6,14.1 Schedule of Shop Drawings and Samples Submissions .... ....................... ___.2.6, 2.8-19 Shop Drawings ............................... �6.2".28 Substantial Completion -- certification o(........... ................ 6.30,2.3,14.8-14.9 definition of ),39 Substitute Construction Methods or Procedures....,.. 63.2 Substitutes and "Or Equal" Items..... ....... .............. _63 CONTRACTOR's ExpenK ....... ................... §3.13 ENGINEEks Evaluation........ I........................6.7.3 "Or -Equal. ............. ......................... .......... Substitute Construction Methods EJCDC GENERAL CONDITIONS 1910.8 (3990 EDI nc" w/ CITY OF FORT COLLINS MODTICATIONS MV 9199) Article or Paragraph Number or Procedures.............................................6.7.2 Substitute Items......._.._............................_15.7.1.2 Subsurface and Physical Conditions — Drawings of, in or relatitg to,,,,,,,,,,,,,,,,,,,,,,,,1.2.1.2 ENGINEER's Review.......................................4.2.4 general..............................................................4.2 Limited Reliance by CONTRACTOR Authorized ................................................ 4.2.2 Notice of Differing Subsurface or Physical Conditions..........................................4.2 3 Physical Conditions ......... .............................4.2.1.2 Passible Contract Documents Change...............4.2.5 Possible Price andTimes Adjustments...............4.2.6 Reports and Drawings_ .................................... 4.2.1 Subsurface and, .................................................. 4.2 Subsurface Conditions at the Site,,,,,,,,,,,,,,,,,, 4.2.1.1 Technical Data................................................4.12 Supervision— CONTRACTORs responsibility ...........................01 OWNER shall not supervise................................8.9 ENGINEER shall not supervise................92, 9.132 Superintendence .......................................................0.2 Superintendent, CONTRACTOR's resident,... ........... 0.2 Supplementalcosts...............................................11.4.5 Supplementary Conditions — definition of .............................. ...................... 139 principal references tq,,,,,,,,,,,,,,,,,1.10, 1.I S. 2.2, 2.7. ........... ............ 4,2, 4.3, S.I, 5.3, 5.4, 5.6-5.9, ,,,.... ,.. —.. 5.11, 6.8. 6.13, 7.4. 8.11, 9.3, 9.10 Supplementing Contract Documents., ....................... . .6 Supplier -- definition of......................................................1.40 principal references tq........... 3.7. 6.5, 6.8-6.11, 6.20. ...__...............................6.24.9,13, 14.12 Waiver of Rights...............................................0.11 Surety -- consent to final payment ........................J4.12, 14.14 ENGINEER has no duty to................................9.13 Notification of ............... .............. --10.1. 10.5. 15.2 qualification of ............. ................................ 5.1-5.3 Survival of Obligations, .......................................... 6.34 Suspend Work, OWNER May ........ ................ 13.10. 15.1 Suspension of Work and Termination .......................15 CONTRACTOR May Stop Work or Tam inate...............................................15.5 OWNER May Suspend Work..............................15.1 OWNER May Terminatq............................15.2-15.4 Taxes --Payment by CONTRACTOR ........................4.15 Technical Data -- Limited Reliance by CONTRACTOR.................4.22 Possible Price and Times Adjustments,,,,,,,,,,,,,, 4.2.6 Reports of Differing Subsurface and Physical Conditions ................................... 4.23 xiv Temporary construction facilities _. _... _„_,,,_,...... _,_ 4.1 Article or Paragraph Number Termination — by CONTRACTOR...........................................15.5 by OWNER........................................8.8, 15.1-15.4 of ENGINEER's employment., ............................. ?.2 Suspension of Work-in general, ............................ 15 Terms and Adjectives.......................................-......3.4 Tests and Inspections - Access to the Work, by others ...........................13.2 CONTRACTOfes responsibilities ......................13.5 cost of 13.4 covering Work prior to ........................... .13.6-13.7 Laws and Regulations(or)................................ 13.5 Notice of Defects. ..................... ..................... 13.1 OWNER May Stop Work,.... ................ ...... -_13.10 OWNER's independent testing ..........................)3.4 special, required by ENGINEER ..........................9.6 timely notice required.......................................13.4 Uncovering the Work, at ENGINEER's request.. _.............................................13.8-13.9 Times-- Adjusting......................................_...................0.6 Change of Cont aq............................................12 Computation of................................................17.2 Contract Times -definition of ...........................j.12 day....... ............ _...... ...... ____ ............ 1,7.2.2 Milestones.......................................................... ) 2 Requirements — appeals....... I ........................... . ............. 9.10. 16 clarifications, claims and disputes : ................. 9.11, 1 LZ 12 Commencement of Contract Times ,,,,,,,,,,,,,,,, 23 Preconstruction Conference ............................7.8 schedules.........................................2.6, 2.9, 6.6 Starting the Work ....................................... 2.4 Title, Warranty of. ................ ........... ......... __J4.3 Uncovering Work ................................. .......... .13.8-13.9 Underground Facilities, Physical Conditions — definition of.....................................................1.41 Not Shown or Indicated ................. ................. 4.3.2 protection of— .................... ........ --- ........ .3, 6.20 Shown or Indicated.........................................4.3.1 Unit Price Work — claims.........................................................1.1.9.3 definition of....................................................1.42 general] 1.9.14.1. 14.5 Unit Prices-- generdll.3.1 Determination for ............................................ 9.10 Use of Premises................................6.16, 6.18. 6,30.2.4 Utility owners.............................6.13, 620. 7.1-7.3, 13.2 URilization, Partial...................1,28, 5.15. 6.30.2.4. 14.10 Value of the Work..................................................11.3 Values, Schedule of ........ ....... ...............7-6, 2.8-2.9, 14.1 EICDC GENERAL co minoxs 1910-9 0990 EDITION) cal CITY OF FORT COLLINS MODIFICATIONS (REV 9199) Variations in Work --Minor Authorized ...................................... 6.25, 6.27, 9.5 Artiole or Paragraph Number Visits to Site --by ENGINEER, .......... ........................ 9.2 Waiver of Claims --on Final Payment ...................„ 14.15 Waiver of Rights by insured partiee.................. 5,11, 6.11 Warranty and Guarantee, General --by CONTRACTOR................................................0.30 Warranty of Title, CONTRACTOR's........................14.3 Work -- Accessto..........................................................13.2 byothers............................................................... 7 Changes in the....................................................10 Continuing the :........... .......... ............. ............... 6.29 CONTRACTOR May Stop Work or Terminate..............................................:15.5 Coordination of ..... ........ ...................... ..............7.4 Cast of the........._......................................11.4.11.5 definition of ......... ,,.-........................................ .1.43 neglected by CONTRACTOR............................13.14 other Work ................. . OWNER May Stop Work ................... .............. 13,10 OWNER May Suspend Work...................13.10, 15.1 Related, Work at Site ............................ ........ 7.1-7.3 Starting the .............. ......._: A ................................. Stopping by CONTRACTOR.............................15.5 Stopping by OWNER.................................15.1-15.4 Variation and deviation authorized, miw........... 3.6 Work Change Directive — claims pursuant to.............................................10.2 definition of .... ..................... ............................ 1,44 principal references tq......................3.5.3. 10.1-10.2 Written Amendment -- definition of......................................................1.45 principal references tq..............1.10, 3.5, 5.10,15.12, ........................4.6.2, 6.8.2, 6.19, 10.1, 10.4, .... ...._..................11.2,12.1,13.12.2,14.7.2 Written Clarifications and Interpretations...................................3.6.3, 9.4, 9.11 Written Notice Required — by CONTRACTOR............................7:1, 9.10.9,11, .......................................... 10.4, 11.2. 12.1 by OWNER....................9.10.9.11, 10.4, IL2, 13.14 X' EICDC GENERAL. CONDITIONS 1910-5 (1990 EDITION) W/ CITY OF FORT COLLINS MODIFICATIONS (REV 9199) (This page left blank intentionally) EJCW GENT AL CON"TIOM 191o•s (1990 FUITION) W1 CITY OF FORT COLUNS MOATFICATIOM (REV 9199) GENERAL CONDITIONS ARTICLE 1—DEFINITIONS Wherever used in these General Conditions or in the other Contract Documents the following terms have the meanings indicated which are applicable to both the singular and plural thereof 1.1. Addenda —Written or graphic instruments issued prior to the opening of Bids which clarify, corned or change the Bidding Requirements or the. Contract Documents 1.2. Agreement —The written contract between OWNER and CONTRACTOR covering the Work to be performed; other Contract Documents are ar ached to the Agreement and made a part thereof as provided therein. 1.3. Apppplication for Pavn�ent—The form accepted by ENGiT1FER which is to be used by CONTRACTOR in requesting progress or final payments and which is to be accompaniedby such supporting documentation as is required by the Contract Documents. 1 A. Asbestos -.Any material that contains more than one percent asbestos and is friable or is releasing asbestos fibers into the air above currant action levels established by the United States Occupational Safety and 1-1calth Administration. 1.5. Bid -The offer or proposal of the bidder submitted on the prescribed form setting forth the pries for the Work to be performed. 1.6. Biddi $ Documents —The advertisement or invitation to Bid, instructions to bidders, the Bid form, and the proposed Contract Documents (including all Addenda issued prior to receipt of Bids). 1.7. Bidding Requirements —The advertisement or invitation to Bid, instructions to bidders, and the Bid farm. 1.8. Bondr—Performance and Payment bonds and other instruments of security. 1.9. Change Omer —A document recommended by IMINEEI, which is signed by CONTRACTOR and OWNER and authorizes an addition, deletion or revision in the Work, or an adjustment in the Contract Rice or the Contract Times, issued on or after the Effective Date of the Agreement 1.10. Contract Documents —The Agreement Addenda (which pertain to the Contract Documents), CONTRACTOR's Bid (inner documentatot accompanying the Bid and any post Bit documentation submitted prior to tine Notice of Award) when attached as an exhibit to the Agreement, the Notice to Proceed, the Bonds, these General Conditions, the Supplementary Conditions, the Specifications and the Drawings as the MM OENSM CONMIONS 1910-8 (1990 E(iticn) tv/ CITY OF FORT COLUM MODIFICATIONS (REV 412000) same are more specifically identified in the Agreement, together with all Written Amendments, Change Orders, Work Change Directives, Field Orders and ENGINEHR's wrinen interpretations and clarifications issued pursuant to paragrapbs3.5, 3.6.1 and 3.6.3 on or after the Effective Date of the Agreement. Shop Drawing submittals approved pursuant to paragraphs 6.26 and 6.27 and the reports and drawings referred to in paragraphs 4,2.1 and 4.2.2 are not Contract Documents. 1.11. Contract Price —Tire moneys payable by OWNER to CONTRACTOR for completion of the Work in accordance with the Contract Documents as stated in the Agreement (subject to the provisions of paragraph t 1.9.1 in the case of Unit Rice Work). 1.12. Contract Times —The numbers of days or the dates stated in the Agreement: (i) to achieve Substantial Completion, and (ii)to complete the Work so that it is ready for final payment as evidenced by ENGINEER's written recommendation of final payment in accordance with paragraph 14.13. 1.13. CONTRACTOR --The person, firm or corporation with whom OWNER has entered into the Agreement 1.14. defective —An adjective which when modifying the word Work refers to Wok that is unsatisfactory, faulty or deficient in that it does not conform to the Contract Documents, or does not meet the requirements of any inspection, reference standard, test or approval referred to in the Contract Documents, or has been damaged prior to ENGINEER'S recommendation of final payment (unless responsibility, for the protection thereof has been assumed by OWNER at Substantial Completion in accordance with paragraph 14.8 or 14.10). 1.15. Drawings --The drawings which show the scope, extent and character of the Work to be furnished and performed by CONTRACTOR and which have been prepared or approved by ENGINEER and are referral to in the Contract Documents. Shop drawings are not Drawings as so defined 1.16. Effective Date of the Agreement —The date indicated in the Agreement on which it becomes effective, but if no such date is indicated it means the date on which the Agreement is signed and delivered by the last of the two parties to sign and deliver. 1.17. ENGINEER —The person, firm or corporation named as such in the Agreement. 1.18. ENGMEER's Constubam--A person, firm or corporation having a contract with ENGINEER to furnish services as ENGINEER'S independent professional associate or consultant with respect to the Pitied and who is identified as such in the Supplementary Conditions. 1.19. Field Order —A written order issued by ENGINEER which orders mirror changes in die Work in accordance with paragra�rnIhn 9.5 but which does not involve a change in the Contract re or the Contract Times. 120. General Requirements —Sections of Division 1 of the Specifications. 1.21. Hazardous Waste —The term Hazardous Waste shall have the meaning provided in Section 1004 of the Solid Waste Disposal Act (42 USC Section 6903) as amended from time to time. 1 22.a. Laws and Regulations; Laws or Regulations —Any and all applicable laws, rules, regulations, ordinances, codes and orders of any and all governmental bodies, agencies, authorities and courts having Jurisdiction. 1.22.b. Leral Holidays -shall be those holidays observed by the City of Fort Collins 1.23. Liens --Liens, charges, security interests or encumbrances upon real properly or personal property. 1.24. Milestone --A principal event specified in the Contract Documents rc attng to an intermediate completion date or time prim to Substantial Completion of all the W C& 1.25. Notice of Award —A written notice by OWNER to the apparent successful bidder stating that upon compliance by the apparent successful bidder with the conditions precedent enumerated therein, within the time specified, OWNER will sign and deliver the Agreement. 116- Motive to Proceed —A written notice given by OWNER to CONTRACTOR (with a copy to ENGINEER) fixing the date on which the Contract Times will commence to non and on which CONTRACTOR shall start to perform CONTRACTOR'S obligations under the Contract Documents. 1.27. OWNER —The public body or authority, corporation, association, firm or person with whom CONTRACTOR has entered into the Agreement and for whom the Work is to be provided L28. Partial Utilization —Use by OWNER of a substantially completed part of the Work for the purpose for which it is intended (or a related purpose) prior to Substantial Completion of all the Work 1.29. PCB.v—Polychlorinated biphenyls. 1.30. Petroktan--Petroleum, including crude oil or any fraction thereof which is liquid at standard conditions of temperature and pressure (60 degrees Fahrenheit and 14.7 pounds per square inch absolute), such as oil, petroleum, fuel oil, oil sludge, oil refuse, gasoline, kerosene and oil mixed with other non -hazardous Wastes and crude oils. 131. Project —The total construction of which the Work to be provided under the Contract Documents may be the whole, or a part as indicated elsewhere in the Contract Documents. 1.32.a Radioactive Alaterial—Source, special nuclear, or byproduct material as defined by the Atomic Energy Act of EtcDC GENERAL COMMONS IIONS 191" OM Ectition) w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4r2000) 1954 (42 USC Sectiooi 2011 et seq.) as amended from time to time. 132.b. Regular Working Hours -Regular working hours are defined as 7 00am to 6:00om unless otherwise specified in the General Requirements. 1.33. Resident Projeet Represenlativv—The authorized representative of ENGINEER who may be assignced to the site or arty part thereof. 1.34. Samples —Physical examples of materials, equipment, or workmanshi that are representative of some portion of the Work and which establish the standards by which such portion of the Work will be judged 1.35. Shop Dmwings-AII drawings, diagrams, illustrations, schedules and other data or infommetion which are specifically prepared or assembled by or for CONTRACTOR and submitted by CONTRACTOR to illustrate some portion of the Work. 1.36. Spec cations —Those portions of the Contract Documcnts consisting of written technical descriptions of materials, equipment, construction systems, standards and workmanship as applied to the Work and certain administrative details applicable thereto. 1.37. Subcontractor --An individual, firm or corporation having a direct contract with CONTRACTOR or with any other Subcontractor for the performance of a part of the Work at the site. 1.38. Substantial Completion —The Work (or a specified par thereof) has progressed to the point where, in the opinion of ENGINEER as evidenced by ENGINEER's definitive cutificate of Substantial Completion, it is sufficiently complete, in accordance with the Contract Documents, so that the Work (or specified part) can be utilized for the purposes for which it is intended; or if no such certificate is issued, when the Work is complete and ready for final payment as evidenced by ENGINEER's written recommendation of final payment in accordance with paragraph 14.13. The terms "substantially complete" and "substantially completed" as applied to all or part of the Work refer to Subs1amial Completion thereof. 1.39. Supplementary Conditions —The par of the Contract Documents which amends or supplements these General Conditions. 1.40. Supplier —A manufacturer, fabricator, supplier, distributor, materialman or vendor having a direct contract with CONTRACTOR or with any Subcontractor to turnish materials or equipment to be incorporated in the Work by CONTRACTOR or any Subcontractor. 1.41, Underground Facilities —All pipelines, conduits, ducts, cables, wires, manholes, vaults, tanks, tunnels or other such facilities or attachments, and any encasements containing such facilities which have been installed mndergrotn d to furnish may of the following services or 608.10 Barrier Curb 12" - Remove & Replace Lineal Foot 5,000 $31.00 $ 155,000.00 608.11 Hollywood Curb, Gutter and 6" Sidewalk - Remove & Replace Lineal Foot 400 $41.50 $ 16,600.00 608.12 Hollywood Curb, Gutter, No Sidewalk - Remove & Replace Lineal Foot 1,000 $25.75 $ 25,750.00 608.13 Highback Curb, Gutter, No Sidewalk - Remove & Replace Lineal Foot 6,000 $33.00 $ 198,000.00 608.14 Pedestrian Access Ramp - Remove & Replace Square Foot 1,000 $8.25 $ 8,250.00 608.15 Pedestrian Access Ramp Highback Curb - Remove & Replace Square Foot 600 $10.00 $ 6,000.00 608.16 Truncated Dome Panel Square Foot 1,000 $40.00 $ 40,000.00 608.17 Flatwork 4" - Remove & Replace Square Foot 1,000 $5.50 $ 5,500.00 608.18 Flatwork 6" - Remove & Replace Square Foot 20,000 $6.75 $ 135,000.00 608.19 Replace Flatwork -1"Additional Depth Square Fool 2,500 $1.20 $ 3,000.00 608.20 Colored Concrete 4" San Diego Buff - Up Charge Square Foot 1,000 $2.50 $ 2,500.00 608.21 4' Valley Pan 6" - Remove & Replace Square Foot 500 $6.50 $ 3,250.00 608.22 Concrete Pavement 8" - Remove & Replace Square Foot 500 $12.00 $ 6,000.00 608.23 Alley Approach 8" - Remove & Replace Square Foot 6,000 $8.15 $ 48,900.00 608.24 Expansion Lineal Foot 1,000 $2.00 $ 2,000.00 608.25 Splashblock 4" - Remove & Replace Square Foot 500 $8.00 $ 4,000.00 608.26 Exposed Aggregate 4" - Up Charge Square Foot 500 $3.50 $ 1,750.00 608.27 Reset Flagstone Square Foot 500 $11.00 $ 5,500.00 608.28 Haul & Dispose Concrete with Wire/Rebar Ton 500 $30.00 $ 15,000.00 608.29 Asphalt Pavement Preservation Lineal Foot 4,000 $2.25 $ 9,000.00 623.01 Irrigation Sleeving 3" PVC Lineal Foot 100 $5.50 $ 550.00 630.20 Traffic Control Percentage 1.00 12% $ 171,997.20 630.30 Variable Message Board Per Each Per Day 100.00 $200.00 $ 20,000.00 630.40 Flagging Hour 4,000.00 $23.00 $ 92,000.00 630.50 Advance Warning Arrow Board Per Each Per Day 70.00 $75.00 $ 5,250.00 630.60 ART -Small Area Up -Charge $0 to $1000 Lump ea Sum/Per 1.00 $1,500.00 $ 1,500.00 630.61 ART - Small Area Up -Charge $1001 to $5000 Lump Suam/Per Are 1.00 $1,000.00 $ 1,000.00 630.62 ART - Small Area Up- Charge $5001 to $10000 Lump ea /Per 1.00 $750.00 $ 750.00 630.63 ART - Small Area Up- Charge $10001415000 Lump Suam/Per Are 1.00 $500.00 $ 500.00 630.64 RES/COL - Small Area Up -Charge $0 to $1000 Lump SumlPerArea 1.00 $1,000.00 $ 1,000.00 630.65 RES/COL - Small Area Up -Charge $1001 to $5000 Lump Sum/PerArea 1.00 $750.00 $ 750.00 630.66 RES/COL - Small Area Up -Charge $5001 to $10000 Lump Sum/PerArea 1.00 $500.00 $ 500.00 630.67 RES/COL - Small Area Up-Charge$10001-$15000 um Suuam/Per Lump 1.00 $250.00 $ 250.00 TOTAL BASE BID $ 1,711,257.20 IN WORDS One Million Seven Hundred Eleven Thousand Two Hundred Fifty -Seven Dollars and Twenty Cents materials: electricity, gases, steam, liquid petroleum products, telephone or other commuracatioM cable television, sewage and drainage removal, traffic or other control systems or water. 1.42. Unit Price Work —Work to be paid for on the basis of tint prices. 1.43. Wont. -The entire completed construction or the various separately identifiable parts thereof required to be furnished under the Contract Documents Work includes and is the result of performing or furnishing labor and furnshing and incorporating materials and equipment into the construction, and performing or furnishing services and furnishing documents, all as required by the Contract Documents, 1.44. Wort: Change Directive —A written directive to CONTRACTOR, issued on or after the Effective Date of the Agreement and signed by OWNER and recommended by ENGINEER, ordering an addition, deletion or revision in the Work, or responding to differing or unforeseen physical conditions under which the Work is to be performed as prcMded in paragraph 4.2 or 43 or to emergencies under paragraph 6.23. A Work Change Directive will not change the Contract Price or the Contract Times, but is evidence that the parties expect that the change directed or documented by a Work Change Directive will be incorporated in a subsequently issued Change Order following negotiations by the parties as to its effect, if any, on the Contract Price or Contract Times as provided in paragraph 10.2 1.45. Written Amenc6nem—A written amendment of the Contract Documents, signed by OWNER and CONTRACTOR on or after the Effective Date of the Agreement and normally dealing with the noncnginecring or nontechnical rather than strictly construction -related aspects of the Contract Documents. ARTICLE 2—PRE11 IINARY MATTERS Dedvery of Bond*: 21 When CONTRACTOR delivers the executed Agreements to OWNER., CONTRACTOR shag also deliver to OWNER such Bonds as CONTRACTOR may be required to furnish in accordance with paragraph 5.1. Copies ofDoeirments: '_'? OWNER shall furnish to CONTRACTOR up to ten copies (unless otherwise specified in the Supplementary Conditions) of the Contract Documents as are reasonably necessary for the execution of the Work. Additional copies will be furnished, upon request, at the cost of reproduction. Commencement ofConb»d Times; Notice to Proceed- 2.3. The Contract Times will commence to tun on the thirtieth day after the Effective Date of the Agreement, or, EXDC OENEM COMMOM 1910.8 (1990 Edlion) cat C1TY OF FORT COLLINS MODIFICATIONS (REV 42000) if a Notice to Proceed is given, on the day indicated in the Notice to Proceed. A Notice to Proceed may be given at any time wither t}h rty days atier the Effective Date of the Agreement _ _ _ ..:n .t n....«AOt r:_ffi of -Rid -opening -or the thirtieth dayeftertha-EfteattVe Bete of die Agreement,-whichemer dite-is-earlier, Storting the Work: 2.4. CONTRACTOR shall start to perform the Work on the date when the Contract Times commence to nut, but no Work shall be done at the site prior to the date on which the Contract Times commence to run. Before Starting Construction: 235 Before undertaking each part of the Work, CONTRACTOR shall carefully study and compare the Contract Documents and check and verify pertinent figures shown thereon and all applicable field measurements. CONTRACTOR shall promptly report in writing to ENGINEER any conflict, error, ambiguity or discrepancy which CONTRACTOR may discover and shall obtain a written interpretation or clarification from ENGINEER before proceeding with any Work affected thereby; however, CONTRACTOR shall not be liable to OWNER or ENGINEER for failure to report any conflict, error, ambiguity or discrepancy in the Contract Documents, unless CONTRACTOR knew or reasonably should have known thereof. 2.6. Within ten days after the Effective Date of the Agreement (unless otherwise specified in the General Requirements), CONTRACTOR shall submit to ENGINEER for review: 2.6.1. a preliminary progress schedule indicating the times (numbers of days or dates) for starting and completing the various stages of the Work, including any Milestones specified in the Contract Documents; 2.6.1 a preliminary schedule of Shop Drawing and Sample submittals which will list each required submittal and the times for submitting, reviewing and processing such submittal; 2.6.2.1. In no caw will a schedule be acceptable which allows lass than 21 calendar cars for each review by Enginxer 2.6.3. A preliminary schedule of values for all of the Wait which will include quantities and prices of items aggregating the Contract Price and will subdivide the Work into component parts in sufficient detail to serve as the psis for progress payments during construction Such prices will include an appropriate amount of overhead and profit applicable to each item of Work. 2.7. Before any Work at the site is started, CONTRACTOR and 03A9 F shall each deliver to the o9w OWI,E with copies to ident ftad-in-thezCupplementary-£otdinans ENGINEER, certificates of insurance (and other evidence of insurance reasonably request retuested by OWNER) which CONTRACTOR an' nno sp,0^oa:--1 = - is rcquued to purchase and maintain in accordance with paragraphs 5.4 5Aan -5-7. Preconstruction Conference: 2.8. Within twenty days after the Contract Times start to rurt but before any Work at the site is siarted, a conference attended by CONTRACTOR ENGINEER and others as appropriate will be. held to establish a working understanding among the parties as to the Work and to discuss the schedules referred to in paragraph 2.6, procedures for handling Shot Drawings and other submittals processing Applications for Payment and maintaining required records. Initially Acceptable Schedules: 2.9. Unless otherwise provided in the Contract Documents Applioatiron4i,4arrtent before any work at the site begins a conference attended by CONTRACTOR, ENGINEER and others as appropriate dent ated byOWNER will be held m review for acceptalnlity to ENGINEER as provided below the schedules submitted in accordance with parasmph2.6. f1flSl_�ivi�A4n_�Gsnera.!_ ess!u� tint : CONTRACTOR shall have an additional ten days to make corrections and adjustments and to complete and resubmit the schedules No progress payment shall be made to CONTRACTOR until the schedules are submitted to and acceptable to ENGINEER as provided below. The progress schedule will be acceptable to ENGINEER as providing an orderly progression of the Work to completion within any specified Milestones and the Contract Times, but such acceptance will neither impose on ENGINEER responsibility for the sequencing• scheduling or progress of the Work nor interfere with or relieve CONTRACTOR from CONTRACTOR's full responsibility therefor. CONTRACTOR'S schedule of Shop Drawing and Sample submissions will be acceptable to I•NGTNEER as providing a workable arrangement for reviewing and processing the required submittals CONTRACTOR's schedule of values will be acceptable to ENGINEER as to form and substance. ARTICLE 3--CONTRACT DOCUMENTS: INTENT, AMENDING, REUSE Intent: 3.1. The Contract Documents comprise the entire agreement between OWNER and CONTRACTOR concemirtg the Work The Contract Documents are complementary; what is called for by one is as binding as if called fur by all. The Contract Documents will be construed in accordance with the law of the place of the Project. 32 It is the intent of the Contract Documents to EJ=OENERAL CONIXTI0M 1910-8 (t990 Ediitim) WICITY OF FORT 0OLLINS MODIFICATIONS OEV 4n000) describe a functionally complete Project (or part thereof) to be constructed in accordance with the Contract Documents. Any Work materials or equipment that may reasonably be inferred from the Contract Documents or from prevailing custom or trade usage as being required to produce the intended result will be furnished and performed whether or not specifically called for. When words or phrases which have a well-known technical or construction industry or track meaning are used to describe Work, materials or equipment, such words or phrases shall be interpreted in accordance with that meaning. Clarifications and interpretations of the Contract Documents shall be issued by ENGINEER as provided in paragraph 9.4. 3.3. Reference to Standards and Specifications of Technical Societies; Reporting and Resohing Discrepancies., 3.3.1. Reference to standards, specifications, manuals or codes of arty technical society, organization or association, or to the Laws or Regulation of any governmental authority, whether such reference be specific or by implication, shall mean the latest standard, sp ocificatron, manual, code or Laws or Regulations in effect at the time of opening of Bids (or, on the Effective Date of the Agreement of there were no Bits), except as may be otherwise specifically stated in the Contract Documents. 3.3.2. If; during the performance of the Work, CONTRACTOR discovers any conflict, error, ambiguity or discrepancy within the Contract Documents or between the Contract Documents and any provision of any such Law or Regulation applicable to the performance of the Work or of any such standard, specification, manual or code or of any instruction of any Supplier referred to in paragraph 6.5, CONTRACTOR shall report it to ENGINEER in writing at once, and, CONTRACTOR shall not proceed with the Work affected thereby (except in an emergency as authorized by paragraph 6.23) until an amendment or supplement to the Contract Documents has loon issued by one of the methods indicated in paragraph 3.5 or 3.6provided, however, that CONTRACTOR shall not be liable to OWNER or ENGINEER for failure to report any such conflict, error, ambiguity or discrepancy unless CONTRACTOR knew or reasonably should have known thereof. 3.3.3. Except as otherwise specifically stated in the Contract Documents or as may be provided by amendment or supplement thereto issued by one of the methods indicated in paragraph 3.5 or 3.6. the provisions of the Contract Documents shall take precedence in resolving any conflict, error, ambiguity or discrepancy between the provisions of the Contract Docwnerts and: 3.3.3.1. the provisions of any such standard specification, manual, code or instruction (whether or riot specifically incorporated by reference in the Contract Documents); or 3.3.3.2. the provisions of any such Laws or Regulations applicable to the performance of the Work (unless such an interpretation of the provisions of the Contract Documens would result in violation of such Law or Regulation). No provision of any such standard, specification, manual, code or i nsrttetion shall be effective to change the duties and responsibilities of OWNER, CONTRACTOR or ENGINEER, or any of their subcontractors, consultants, agents or employees from those set forth in the Contract Documents nor shall it be effective to assign to OWNER, ENGrN'EFR or any of ENGINEER's Consultants, agents or employees any duty or authority to supervise or direct the furnishing or performance of the Work or any duty or authority to undertake responsibility inconsistent with the provisions of paragraph 9.13 or any other provision of the Contract Documents. 3A. Whenever in the Contract Documents the terms "as ordered", "as directed", "as required", "as allowed", "as approved" or terms of like effect or import are uses( or the adjectives "reasonable% 'suitable',"acceptable", "proper" or "satisfactory" or adjectives of like effect or import are used to describe a requirement, direction, review or judgment of ENGINEER as to the Work, it is intended that such requirement, direction, review or judgment will be solely to evaluate, in general, the completed Work for compliance with the requirements of and information in the Contract Documents and conformance with the design concept of the completed Project as a functioning whole as shown or indicated in the Contract Documents (unless there is a specific statement indicating otherwise)- The use of any such term or adjective shall not be effective to assign to ENGINEER any duty or authority to supervise or direct the furnishing -or performance of the Wank or any duty or authority to undertake responsibility contrary to the provisions of paragraph 9.13 or any other provision of the Contract Documents, Amending and Supplementing Contract Documents 3.5. The Contract Documents may be amended to provide for additions, deletions and revisions in the Work or to modify the terms and conditions thereof in one or more of the following ways: 3.5.1. a formal Written Amendment, 3.5.2. a Change Order (pursuant to paragraph 10.4), or E1CDC GEMM CONDITIOM 1910-8 (1990 Edtio n) w/CITY OF FORT COLLIM MODIFICATIONS OLEV 417_000) 3.5.3. a Work Change Directive (pursuant to paragraph 10.1). 3.6. In addition, the requirements of the Contract Documents may be supplemented, and minor variations and deviations in the Work may he authorimd, in one or more of the following ways: 3.61. A Field Order (pursuant to paragraph 9.5), 3.6.2. ENG114EER's approval of a Shop Drawing or Sample (puisuarit to paragraphs 6.26 and 6.27), or 3.6.3. ENGINEER's written interpretation or clarification (putstiant to paragraph 9.4). Reuse ofDocumena 3.7. CONTRACTOR, and any Subcontractor or Supplier or other person or organiratian performing or furnishing any of the Work under a direct or indirect contract with OWNER (i) shall not have or acquire any title to or ownership rights in any of the Drawings, Specifications or other documents (or copies of any thereof) prepared by or bearing the seal of ENGINEER or ENGTNEER's Consultant, and (ni) shall not reuse airy of such Drawings, Specifications, other documents or copies on exumsions of the Project or any other project without written consent of OWNER and ENGINEER and specific written verification or adaptation by ENGINEER ARTICLE 4-AVAMABILITY OF LANDS, SUBSURFACE AND PHYSICAL CONDITIONS; REFERENCE POINTS Availability ofLandk. 4.1. OWNER shall furnish, as indicated in the Contract Documents, the lands upon which the Work is to be performed, rights -of -way and easements for access thereto, and such other lands which are designated for the use of CONTRACTOR i4pon-rswsoaebk writterrrequesi, OkWiF AAH ftma GONTR GTO with .. eamee statement ofrecord-le��ritleand-legal deseriptiotro€the lands -upon -which Hnd 91WIdERLs-interest-therein-es-medxsary {orgiring-no4iee of --or -filing a -mealieetic's- Iiet einst-atteli- lands --in eeeerdence—with appheable Laws and Ragulatiorts. OWNER shall ideritifY any encumbrances or restrictions not of general application but specifically related to use of lands so furnished with which CONTRACTOR will have to comply in performing the Work. Easements for permanent structures or permanent changes in existing facilities will be obtained and paid for by OWNER, unless otherwise provided in the Contract Documents, If CONTRACTOR and OWNER are unable to agree on entitlement to or the amount or extent of any adjustments in the Contract Rice or the Contract Times as a result of any delay in OWNER's furnishing these lands, rights -of - way or easements, CONTRACTOR may make a claim therefor as provided in Articles 11 and 12. CONTRACTOR shall provide for all additional lands and access thereto that may be required for temporary construction facilities or storage of materials and equipment. 4..2. Subsurface and Phy:deal Conditions: 4.2.1, Reports and Drawings. Reference is made to the Supplementary Conditions for identification of: 4.2.1_1. Subsurface Coubtions: Those reports of explorations and tests of subsurface conditions at or contiguous to the site that have been utilized by ENGINEER in preparing the Contract Documents; and 4.2.1.2. Physical Conditions- Those drawings of physical conditions in or relating to existing surface or subsurface structures at or contiguous to the site (except Underground Facilities) that have been utilized by ENGINEER in preparing the Contract Documents. 4.2.2. Limited Reliance by CONTRACTOR Authorized - Technical Data: CONTRACTOR may rely upon the general accuracy of the "technical data" contained in such reports and drawings, but such reports and drawings are not Contract Documents Such "technical data" is identified in the Supplementary Conditions. Except for such reliance on such "technical data", CONTRACTOR may not rely upon or make any claim against OWNER, ENGINEER or any of ENGINEER's Consultants with respect to: 42.2.1. the completeness of such repots and drawings for CONTRACIORs purposes, including but net limited to, any aspects of the means, methods, techniques, sequences and procedures of construction to be employed by CONTRACTOR and safety precautions and programs incident thereto, or 42.2.2. other data, interpretations, opinions and information contained in such reports or shown or indicated in such drawings, or 4.2.23. any CONTRACTOR interpretation of or conclusion drawn from any "technical data" or any such data, interpretations, opinions or information 4.2.3. Notice of Differing Subsurface or Physical Conditions: If CONTRACTOR believes that any subsurface or physical condition at or contiguous to the site that is uncovered or revealed either: 42.3.1. is of such a nature as to establish that any "technical data' on which CONTRACTOR is entitled to rely as provided in paragraphs 4.2.1 and 4 22 is materially inaccurate, or 42.3.2. is of such a nature as to require a change in the Contract Documents, or 4.2.33. differs materially from that shown or EXM GEHaViL CONpilON3191"(1990 Eckkn) wl CITY OF FORT COUJt S MODIFICATIONS (REV 42000) indicated in the Contract Documents, or 4.2.3.4. is of an unusual nature, and differs materially from conditions ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract Documents; then CONTRACTOR shall, pwreptly immediate after becoming aware thereof and before further disturbing conditions affected thereby or performing any Work in connection therewith (except in an emergency as m fitted by Paragraph 6.23J notify OWNER and ENGINEER in writing about such condition. CONTRACTOR shall not further disturb such conditions or perform any Work in connection therewith (except as aforesaid) until receipt of wtiuen order to do so. 4.2.4. ENGINEER's Review: ENGINUR will promptly review the pertinent renditions, determine the necessity of OWNER's obtaining additional exploration or tests with respect thereto and advise OWNER in writing (with a copy to CONTRACTOR) of ENGINEERS findings and conclusions. 4.2.5. Possibk Contract Doctanenb Change: If ENGINEER concludes that a change in the Contract Documents is required as a result of a condition that meets one or more of the categories in paragraph 4.2.3. a Work Change Directive or a Change Order wdl be issued as provided in Article 10 to reflect and document the eonsequerees of such change. 4.2.6. Posdbk Price and Tuner At¢tcsbnenu: An equitable adjustment in the Contract Price or in the Contract Times, or both, will be allowed to the extent that the existence of such uncovered or revealed condition causes an increase or decrease in CONTRACTORS cost of, or time required for performance of the Work, subject, however, to the following: 4.2.6.1. such condition must meet any one or more of the categories described in paragraphs 4.2.3.1 through 4.2.3.4, inclusive, 4.2.6.2. a change in the Contract Documents pursuant to paragraph 42.5 will not be an automatic authorization of nett a condition precedent to entitlement to any such adjustor ent; 4.2.6.3. with respect to Work that is paid for on a Unit Price Basis, any adjustment in Contract Price will be subject to the provisions of paragraphs 9.10 and 11.9. and 4.2.6.4. CONTRACTOR shall not be entitled to any adjustment in the Contract Price or Times if; 4.2.6.4.1. CONTRACTOR knew of the existence of such conditions at the time CONTRACTOR made a final commitment to OWNER in respect of Commct Price and Contract Times by the submission of a bid or becoming bound under a negotiated contract, or 4.2.6.4.2. the existence of such condition could reasonably have been discovered or revealed as a result of any examination, investigation, exploration, test or study of the site and contiguous areas required by the Bidding Requirements or Contract Documents to be conducted by or for CONTRACTOR prior to CONTRACTOR's making such final commitment; or 4.2.6.4.3. CONTRA(:I'OR failed to give the written notice within the time and as required by paragraph 4.2.3. If OWNER and CONTRACTOR are unable to agree on entitlement to or as to the amount or length of any such equitable Ausunent in the Contract Price or Contract Times, a claim may be made therefor as provided in Articles I and 12. However, OWNER, ENGINEER and lNGINEER's Consultants shall not be liable to CONTRACTOR for any claims, costs, losses or damages sustained by CONTRACTOR on or in connection with any other project or anticipated project 4.3. Physical Conditions —Underground Facilities. 4.3.1. Shown orhndlcated• The information and data shown or indicated in the Contract Documents with respect to existing Underground Facilities at or contiguous to the site is based on information and data furnished to OWNER or ENGINEER by the owners of such Underground Facilities or by others. Unless it is otherwise expressly provided in the Supplementary Conditions: 4.3.1.1. OWNER and ENGIIM shall not be responsible for the accuracy or completeness of any such information or data; and 4.3.1.2. The cost of all of the following will N included in the Contract Price and CONTRACTOR shall have full responsibility for: (i) reviewing and checking all such information and data, (ii) locating all Underground Facilities shown or indicated in the Contract Documents,(iii) coordination of the Work with the owners of such Underground Facilities during construction, and (iv) the safety and protection of all such Underground Facilities as provided in paragaph6.20 and repairing arty damage thereto resulting from the Work. 4.32. Not Shown or for icated• If an Underground Facility is uncovered or revealed at or contiguous to the site which was not shown or indicated in the Ccnbwt Documents, CONTRACTOR shall, promptly immediately after becoming aware thereof and before further disturbing conditions affected thereby or pmformiirg any Work in connection therewith (except in an emergency as required by paragaph6.23), identify the owner of such Underground Facility and EKDC GENERAL CONDITIONS 1910-8 (1990 Edition) w/CITY OF FORT COLLINS MODIFICATIONS (RSV 42000) give written notice to that owner and to OWNER and ENGINEER ENGWEER will promptly review the Underground Facility and determine the extend, if any, to which a change is required in the Contract Documents to reflect and document the consequences of the existence of the Underground Facility. if ENGINEER concludes that a change in the Contract Documents is required, a Work Change Directive or a Change Order will be issued as provided in Article 10 to reflect and document such consequences. During such time, CONTRACTOR shall be responsible for the safety and protection of such Underground Facility as provided in ra&raph 620. CONTRACTOR dell may be allowed an increase in the Contract Price or an extension of the Cwntrnct Times, or both, to the extent that they are attributable to the existence of any Underground Facility that was not shown or indicated in the Contract Documents and that CONTRACTOR slid not know of and could not reasonably have been ea•pce to be aware of or to have anticipated If OWNER anndCONTRACTOR are unable to agree on entitlement to or the amount or length of any such adiustmerd in Contract Price or Contract Times, CONTRACTOR may make a claim therefor as provided in Articles I i and 12. Hawaver, OWNER, ENGINEER and ENGTNEER's Consultants shall not be 1 iable to CONTRACTOR for any claims, costs, losses or damages incurred or sustained by CONTRACTOR on or in connection with any other project or anticipated project Reference Points: 4A. OWNER shall provide engineering surveys to establish reference points for construction which in ENGINEER's judgment are necessary to enable CONTRACTOR to proceed with the Work. CONTRACTOR shall be responsible for laying out the Work shall Protect and preserve the established reference points and shall make no changes or relocations without the prior written approval of OWNER. CONTRACTOR shall report to ENGINEER whenever any reference point is lost or destroyed or requires relocation because of necessary changes in grades or locations, and shall be responsible for the accurate replacement or relocation of such reference points by professionally qualified personnel. 4.5. Asbestos, PCBs, Petroleum, Hazardous Waste or Radioact„•e Material. 4.5.1. OWNER shall be responsible for any Asbestos, PCBs, Petroleum, Hazardous Waste or Radioactive Material unccaered or revealed at the site which was not shown or indicated in Drawings or Specifications or identified in the Contract Documents to be within the scope of the Work and which may present a substantial danger to persons or property, exposed thereto in connection with the Work at the site. OWNER shall not be responsible for any such materials brought to the site by CONTRACTOR, Subcontractors, Suppppliers or anyone else for whom CONTRACTOR is responsible. 4-51-CONTRACTOR shall immediately: +)-stop all sitaly-notice-4n-writi-0-AVNER--she4I-promlttly consult with ENGI'NTE Rcbneemitg-Ate-neeessity-for OWNER to -retain a qualified-expett-to-evaluate such CONTRACTOR shall not be required -te resumeWork env nired-permits-ula.ted-thereto-and-de{ivereel ro kC� thatsuelrcendianyafteetedareo-is o has-bent rendered safe for "lode leeadivax:+suth ^�9A CSC--FOR-carin -agree as tL te-or the amount or extent of an adjustotem, if ftny� . 00atold Price OF Work -stoppage or�shspecial-eandmen. ender -which either- pe aftx nfprc;vided-in 04 Z if after receipt..f ..,,eI---:.,i .. .v,-Reuae CONTRACTOR. does -riot-agree-to-resurae such -work based on it reasemble i! lief it is m er does no Fffiume m.e. rkrprl..0 oonditiett ,then-F3WN);R may order I^ 1mrttontf 4,54 To the fullest am Regulatiorn-OWNER-sMR-indamnify _ and-_aYs-hold hartaless—C1�"rT�GFOR: - Subcomtactors: o!&cars—aiiswtors�- _employres. _organic: --other ccansalkiMr,-arid--rubix�MmGeas--r�C each-rmct--artyrot them -from -ern{- against -94-claims. toA%-k+ases-arid Cast, loss or including-the--lass-of -use --resulting--theraGan; -and (ii}tnotlni»g-inn-iltis-subparagraph 4.5.4 shall obligate OWNER -to -indemnify .any.. person -or entity -from -anal against the conse-p-mas _r m'senttty's own neghgenoe: lle�rf{e is �l actor oi-R ed of FXDCoENatet. corm(MOM 1910.8 (1990 Edtim) ad aTY OF FORT cote rs.MODIFICATIONS OCIEV 4R00a) ARTICLE S-BONDS AM llvSQRANCE Peryarmance, Payment and DeherBondr: 5.1. CONTRACTOR shall furnish performance and Payment Bonds, each in an amount at least equal to the Contract Price as security for the faithful performance and payment of all CONTRACfOR's obligations under the Contract Documents. These Bonds shall remain in effect at least until ate year after the date when final payment becomes due, except as provided otherwise byy Laws or Regulations or by the Contract Ducuments. CONTRACTOR shall also furnish such other Bads as are required by the Supplementary Conditions. All Bonds shall be in the form presunbed by the Contract Documents except as provided otherwise by Laws or Regulations and shall be executal by such sureties as are named in the current list of "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Companies" as published in Circular SI(t (amended) by the Audit Staff, Bureau of Government Financial Operations, U.S. Treasury Department All Bonds signed by an agent must be accompanied by a certified copy of such agent's authority to act. 5.2. If the surety on any Bond furnished by CONTRACTOR is declared a bankrupt or becomes insolvent or its right to do business is terminated in any state where arty part of the Project is located or it ceases to meet the requirements of paragraph 5.1, CONTRACTOR shall within ten days thereafter substitute another Bond and surety, both of which must be acceptable to OWNER 5.3. Licensed Sureties and Insurers; Certificates of Insurance: 5.3.1. All Bonds and insurance required by the Contract Documents to be purobased and maintained by OWNER or CONTRACTOR shall be obtained from surety or insurance companies that are duly licensed or authorized in the jurisdiction in which the Project is located to issue Bonds or insurance policies for the limits and covera&es so required Such surety and insurance companies shall also meet such additional requirements and qualifications as may be provided in the Supplementary Conditiois. 5.3.2. CONTRACTOR shall deliver to OWNER, with copies to each additional insured identified m the Supplementary Conditions, certificates of mstaance (and other evidence of insurance requested by OWNER or any other additional insured) which CONTRACTOR is required to purchase and maintain in accordance with paragraph 5.4. OWNER shall addawnal--insured--idententary eviienee of regkttred{o�ay.+v�85Pandit3atnt8ln'in-al>FiMR-'Wiilt pamgmphs 5:6-and Sa }wreof CONMCTOR's Liability Insurance: 5.4. CONTRACTOR shall purchase and maintain such liability and other insurance as is appropriate for the Work being performed and furnished and as will provide protection from claims set forth below which may arise out of or result from CONTRACTOR's performance and furnishing of the Work and CONTRACTOR's oiler obligations under the Contract Docwneras, whether it is to be performed or banished by CONTRACTOR any Subcontractor or Supplier, or by anyone directly or indirectly employed by any of them to perform or furnish any of the Work, or by anyone for whose acts any of them may be Gable 5.4.1. claims under workers compensation, disability benefits and other similar employee bcnefit acts; 5.4.2. claims for damages because of bodily injury, occupational sickness or disease, or death of CONTRACTOR's employees; 5.4.3. claims for damages because of bodily injury, sickness or disease, or death of any person other than CONTRACTOR's employees; 5 4.4.-,claims-for--damages -insured by --customary eavef age w)tieh are sustained! 5.4.5. claims for damages, other than to the Work itself, because of injury to or destruction of tangible property wherever located, including loss of use resulting therefrom; and 5.4.6. claims for damages because of bodily injury or death of any person or property, damage arising out of the ownership, maintenance or use of any motor vehicle. The policies of irisurance so required by this paragraph 5.4 to be purchased and maintained shall: 5.4.7with respect to insurance required by paragraphs 5.4.3 through 5.4.6 inclusive and 5.4.9, include as additional insureds (subject to any customary exclusion in expect of professional liability), OWNER. ENGINEER. ENGINEER's Consultants and any other persons or entities identified in the Supplementary Conditions, all of whom shall be listed as additional insureds, and include covenrge for the respective officers and employees of all such additional insiacdds; 5.4.8. include the specific coverages and be written for not less than the limits of liability provided in the Supplementary Conditions or required by Laws or Regulations, whichever is greater, 5.4.9. include completed opemtmns insurance; EXDC GENERAL CONDITIONS 1910-8 (1990 Edition) w/CITY Of FORT COt.UM MOMICATIONS (REV 420aa) 5.4.10. include contractual liability insurance covering CONTRACTOR's indemnity obhgeuas under paragraphs 6.12. 6.16 and 6.31 through 6.33; 5.4.11. contain a provision or endorsement that the coverage afforded will not be cancelled, materially changed or renewal refiused until at least thirty days' prior written notice has been given to OWNER and CONTRACTOR and to each other additional insured identified in the Supplementary Conditions to whom a certificate of insurance has been issued (and the certificates of insurance furnished by the CONTRACTOR pursuant to paragraph 5.3 2 will so provide); 5.4.12. remain in effect at least until final payment and at all times thereafter when CONTRACTOR may be correcting, removing or replacing *feclive Work in accordance with paragraph 13.12; and 5.4.13. with respect to completed operations insurance, and any, insurance coverage written on a claims -made basis, remain in effect for at least two years after final payment (and CONTRACTOR shall furnish OWNER and each other additional insured identified in the Supplementary Conditions to whom a certificate of insurance; has been issued evidence satisfactory to OWNER and any such additional insured of continuation of such insurance at final pa)mem and one year thereafter). OA'NIF-R's Liability Insurance: 55. In addition to insurance required to be provided by CONTRACTOR under paragraph 5.4, OWNER, at OWNEWs oplioq may purchase and maintain at OWNER's expense OWNER's own liability insurance as will protect OWNER against claims which may arise from operations under the Contract Documents Property Insurance: 3-6--Unless-0therwisa frra'+� +n-��Pt�nry C�itiarss� (3W%11:SR--Shill--pufGier<�aHr of -ilia -fall-fepla cmtrfrt--cast-Unefeof�subject-to-suede ded ctiblo-amounts.--es--'may-- ba prov clan]-e}--the Supplementary- fiorne4EEiorts-ear--mquieed by-� ews-aml RegulaWm)-T'his romiwe iaW 56.4- inaladc---t#w---vntnre�s-�f-9W�FfiR: mrtities-identifted-in-the-Supplementary-6c:.nditicx�; each of whom -is -deemed to have an insurable-intern-t andslatll-be-tvAedasarmrssaw -invaanrl: 3b:2:-be-written- cuu,-a.-Buiidet's...Rell-risk-"-<u shwill At le -All inel—le less OF the-fallowing-1'er+L=-fire, �-lr�ttntng,-exter+ded cov age: thefi.-+sndelism--snd ttrabcious-mischief. 5.63.---include-experms -incurred-m--the-repair -or replAcementof-any-insured property-(mdudiry but twA t:...:l.d in m. and ,.t.,... _r ---a .. Nq---and erehiteots} �44, cover Brij equipm eat stored Ell' he Nit orat-another-looaticxs that was agreed to inwvritutg by flravidad that suchmaterinls and equipment-hav4-been iteluded ended 1�I6 atd 4 c-oTR-me,==ta;i. min niTeat-unt. rc�m PQyment is *wLy--day? mitten notiaNto--each-nther-additional nee-Fxs.-Freer+ isslred Si.7:—OWNFEf�haH purchase -and maintain -each -be ler -additioRRI prepefty insurame as-may-be-required--by-the Supplementary (' wAttore-cw I�fiws and Re Ide Ate im�efesw of ! ln.ii'D /`nAi•1'D A!•'i nD r..1.-.._.... _...._.5 CTi(SrTfCL•1G #i;�l<r4'E>zE(3RsCo:vit}I7atu� A tie6 ,dImIlifiRd -he . -eneh of whm deerned to Etlt-Mi$E1Fl81-w♦SFFiAd:••• •••. maimained by Pli4vER-4n Accordance -with paragraphs 54 auemge-afforded- w H-+tot-be-canorlkd-or ntatariaAy changed or -renewal refused -untifatleast-thirty-days-prior written-netiee-has-boert-given-ie---OWn3ER---- end E'Fy—IR{1��( lid to whom a oertifieate of-ifewranoe-ins been iz,ved and-WiH conjoin ---Waiver --- provisiom—il7-- BGC�7rdanC4.__wK}i paragmh 5.1 1, 5.9, OWNER shall not be responsible for purchasing and maintain env property imurance to protect the interests of CONTRACTOR Subcontractors cc others in theme'ale-totkaextem-ef�+ny-rlacktctibla-atttotatts-t}a:terra Wentilied-m-fho-SsppkemaNary.Fo xlitiore:-Thor risk -of such -loss -and -if -any -of -them w:isIw& prapdriy--irwumnt:e arvverage- wit}urrthr limitsof suafrsrm ones -each -may placheseand-maintain-itat-the purchasets<»vnnM wISe 5 G--= CONTRACTOR-Ftque96-in-wr 4W-dint-ether �.�:a..a nd _....,......a.,. c 6 ... c a nrunrca tlttROVt�Fd' 1 be �Fc a.,. f�f1P L.., .......dale C fkOhnn^enre Order--or-�vrittem Am�ndmentt --Prior--to E)CDCGENERALCONDIUONS191"41990Edkim) 10 w/ CITY OF FORT COUINS MODIFICATIONS tREV 42000) rommencement-ofthe Work-at-the-site.-OWNBR-&Adl-tn rr11- 9Vl>fR and [>�Icte�ptvc)lerad-itt ascerdaxcetvidrperagFephs3G .r <o wig protect nn n.sD GQ.9 errnD Subuentractom—..&NG&`I£Bk'.—FiNGFYFEEf2% 111 insureds-tx-add tional4nsure&-irr-suet-pofiaies-And :n .,_ .:,I_ primary _ _ r . ,.n 1,.....v and damages-rsased- by-the-perils-mvered--thereby-.-,411 In or -damage --the lvmws ihc_II,_.,��� "' 1--insureds therenndt�: payable under-any-pelmy-w isauetf C 111 in „Aa:.:__ n11fl.TCD .. ,.. all fights eSall�t—£Q43i�i�0il. C `".-VaCierS: efTeers direaAe�etnpleyees And Agent"f-any-of titan; ter: of-uso--err--A---- nl� _�+znding beyond-direct-#thystoal-lessor--+ ttaage---to eau9ed @321 nsiag'fkitEfOF-Y6SaiEHigtf9m-fffet{14iM)r-perll; whe[1wr-0rncat-inured-by F3�V Nf'sR; And 54-f33—lass-or- damsga-to-the- comtplewd l ojest-oFisart'tham af'saused'by:-ntiawrg out Elf reanhlrlg-from-fire 9 -eihITYFLSHCed per -A covered during- -partial --- -vtili;mtion--pursuant—to paragraph f4.l(t.-after -Substantial--Completion pursuant to {MtrAgr:rplr-14.F-or-alter-final-p<lyment parruanKopata�t+ph-14:1; al-t consequential-kxs-insureds ill have-no-rights--nf reecrvai9' -agaatst-any' ef-GONTRf1Ef ©R-Subeoturector& r�..rn.rrr-o rnrrnrrrn r r i L n' Receipt and Appfiwdon of lnsxmnce Proceeds: 5.12. Any insured loss under the policies of insurance required by paragraphs 5.6 and 5.7 will be adjusted with OWNER and made payable to OWNER as fiduciary for the insureds, as their interests may appear, subject to the requirements of any applicable mortgage clause and of paragraph 5.13. OWNER shall deposit in a separate account any money, so received, and shall distribute it in accordance with such agreement as the parties in interest may reach if no other special agreement is reached the damaged Work shall be repaired or replaced, the moneys so received applied on account thereof and the Work and the cost thereof covered by an appropriate Change Order or Written Amendment. 5.13. OWNER as fiduciary shall have power to adjust and settle any loss with the insurers unless one of the parties in interest shall object in writing within fifteen days after the occurrence of loss to OWNER's exercise of this power. If such objection be made OWNER as fiduciary shall make settlement with the insurers in accordance with such agreement as the parties in interest may reach If no such agreement among the parties in interest is reached, OWNER as fiduciary shall adjust and settle the loss with the insurers �^ zR uc malt-gtva� forti Acceptance of 13&ndr and Imutmisce; Option to Replace: 5.14. If eit}xr OWNER has any objection to the coverage afforded or other provisions of the Bonds -or insurance required to be purchased and maintained by the ether patA CONTRACTOR in accordance with Article 5 on of non-conformance with the Contract Documents, the otjjeet sig pet#y s}mll so nati{y 419rc FlrerpeMy OWNER will I141j�Y CQNI��OR in wntutg with n ten fLtgM days after reeeipt deliver of the certificates (or--odw-evidenoe redglested) to OWNER az required by paragraph 2.7. other such additior�Iattid�rrttetiCrr ut -respectt of-instrattse Partial Ul izadon-Property Insurance: 5.15. If OWNER Grads it necessary to occupy or use a potion or portions of the Work prior to Substantial EJCDC GENERAL CONDIMON5191" (1990 Edtiaa) w/ aTY OF FORT COLLINS MODIFICATIONS OLEV 42000) Completion of all the Work, such use or occupancy may be accomplished in accordance with paragraph 14.10; provided that no such use or occupancy shall commence before the insurers providing the property insurance have acknowledged notice thereof and in writing effected any charges in coverage necessitated thereby. The insurers providing the property insurance shall consent by endorsement on the policy or pohcies, but the property insurance shall not be cancelled or permitted to lapse on account of any such partial use or occupancy. ARTICLE 6-CONTRACTOR'S RESPON5IBIMUES 5ulmrvison and SitperWendence• 6.1. CONTRACTOR shill supervise, inspect and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. CONTRACTOR shall be solely responsible for the means, methods, techniques, sequences and procedures of construction, but CONTRACTOR shall not be responsible for the negligence of others in the design or specification of a specific means, method, technique, sequence or procedure of construction which is shown or radiated in and expressly required by the Contract Documents. CONTRACTOR shall be responsible to see that the completed Work complies accurately with the Contract Documents 6.2. CONTRACTOR shall keep on the Work at all times during its progress a competent resident superintendent, who shall not be replaced without written notice to OWNER and ENGINEER except under extraordinary circumstances. The superintwdem will be CONTRACTORS representative at the site and shall have authority to act on behalf of CONTRACTOR All communications to the superintendent shall be as binding as if given to CONTRACTOR Labor, bfaterialc and Equipment: 63. CONTRACTOR shall provide competent, suitably qualified personnel to survey, lay out and corAnict the Work as required by the Contract Document& CONTRACTOR shall at all times maintain good discipline and order at the site. Except as otherwise required for the safety or protection of persona or the Work or property at the site or adjacent thereto, and except as otherwise indicated in the Contract Documents, all Work at the site shall be performed during regular working hours and CONTRACTOR will not permit overtime work or the performance of Work on Saturday, Sunday or any legal holiday without OWNER's written consent given after prior written notice to ENGINEER. CONTRACTOR shall submit requests to the ENGINEER no less than 48 hours in advance of an r)_Work to be performed on Saturday. Sunday. Holidays or outside the Regular Workirig Hors, 6.4. Unless otherwise specified in the General Requirements, CONTRACTOR shall furnish and assume full responsibility for all materials, equipment, labor. transportation, construction equipment and machinery, tools, appliances, fuel. power, light, heat, telephone, water, sanitary facilities, temporary facilities and all other facilities and incidentals necessary for the furnishing, performance, testing, start-up and completion of the Work. 641 purchasing Restrictions: CONTRACTOR must comply with the CiN's purchasing restrictions. A copy of the resolutions are available for review in the offices of the purchasing and Risk Management Division or the City Clerk's office. 64.2. Cement Restrictions: City of Fort Collins Resolution 91-121 requires that sutialiers and Rmphicers of -cement or products containing cement m certity that the cement was not made in cement kibrs that bum hazardous waste as a fuel 6.5. All materials and equipment shall be of good quality aril new, except as otherwise provided in the Contract Documents. All warranties and guarantees specifically called for by the Specifications shall expressly run to the benefit of OWNER if required by ENGINEER, CONTRACTOR shall furnish satisfactory evidence (including reports of required tests) as to the kind and quality of materials and equ pment. All materials and equipment shall be applied, installed, connected, erected, used cleaned and conditioned in accordance with instructions of the applicable Supplier, except as otherwise provided in the Contract Documents. Progress So6edule: 6.6, CONT24(TOR shall adhere to the progress schedule established in accordance with paragraph 2.9 as it may be adjusted from time to time as provided below: 6.6.1. CONTRACTOR shall submit to ENGE4EERR for acceptance (to the edent indicated in paragraph 29) proposed adjustments in the progress schedule that will not change the Contract Times (or Milestones). Such adjustments will cWorgenerally to the progress schedule then in effect and additionally will comply with any provisions of the General Requirements applicable thereto. 6.6.2. proposed adjustments in the progress schedule that will change the Contract Times (or Milestones) shall be submitted in accordance with the requirements of paragraph 12.1. Such adjustments may only be made by a Change Order or Written Amendment in accordance with Article 12. 6.7. Substituiesand "Or -Equal" Items: 6.7.1. Whenever an item of material or equipment is specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular Supplier, the specification or description is intended to establish the type, function and quality required. Unless the specification or description EJCDC OENFRAI, CONDITIOM 1910,8 (1990 Etfition) 12 w/ CITY OF FORT COLLINS MOMICATIONS(MV412000) contains or is followed by words reading that no like, equivalent or "or -equal" item or no substitution is permitted, other items of material or equipment or material or equipment of other Suppliers may be accepted by ENGINEER under the following circumstances: 6.7.1.1. Vr-Equal'. If in ENGINTEER's sole discretion an item of material or equipment proposed by CONTRACTOR is functionally equal to that named and sufficiently similar so that no charge in related Work will be required, it may he considered by ENGINEER as an "or al" item, in which case review and approval of the proposed item may, in ENGINF.ER's sole discretion, be accomplished without compliance with sonic or all of the requirements for acceptance of proposed substitute items. 6.7.1.2. Substitute Items: If in ENGINEER's sole discretion an item of material or equipment proposed by CONTRACTOR does not qualify as an "or -equal" item under subparagraph 6.7.1.1, it will be considered a proposed substitute item. CONTRACTOR stall submit sufficient information as provided below to allow ENGINEER to determine that the item of material or equipment proposed is essentially equivalent to that named and an acceptable substitute therefor. The procedure for review by the ENGINEER will include the following as supplemented in the General Requirements and as ENGINEER may decide is appropriate under the circumstances. Requests for review of proposed substitute items of material or equipment will not be accepted by FNGTNEER from anyone other than CONTRACTOR If CONTRACTOR wishes to famish or use a substitute item of material or equipment. CONTRACTOR shall first make written application to ENGINEER for acceptance thereof, certifying that the proposed substitute will perform adequately the functions and achieve the results called for by the general design, be similar in substance to that specified and be suited to the same use as that specified The application will state the extent. if any. to which the evaluation and acceptance of the proposed substitute will prejudice CONTRACTOR's achievement of Substantial Completion on time, whether or not acceptance of the substitute for use in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with OWNER for work on the Project) to adopt the design to the proposed substitute and whether or not incorporation or use of the substitute in connection with the Work is subject to payment of any license fee or royalty. All variations of the proposed substitute from that specified will be identified in the application and available maintenance, repair and replacement service will be indicated The application will also contain an itemized estimate of all costs or credits that will result directly or indirectly from acceptance of such substitute, including costs of redesign and claims of other conrct= affected SECTION 00500 AGREEMENTFORMS 00510 Notice of Award 00520 Agreement 00530 Notice to Proceed by the resultirig cllmngk all of which will be CONTRACTOR shall perform not less than 20 considered by ENGINEER in evaluating the gercent of the Work wither own forces (that is proposed substitute. ENGINEER may requue CONTRACTOR furnish without subcontracting). The 20 percent requirement to additional data about shall be understood to refer to the Work the value of the proposed substitute, which totals nut less than 20 percent of the Contract Price. 6.7.1.3. CONIRACTOR'sExpense: All data to be provided by CONTRACTOR in support of any 6.8.2. If—tha Sltpplantec&ary-( onditions Biddine proposed "orequal• or substitute item will be at Documents require the identity of certain CONTRACTOR's expense. Subcontractors Suppliers or other persons or organizations (including those who are to furnish the 6.7.2. Substitute Construction Methods or principal items of materials or equipmem) to be Procedures: If a specific means, method, technique, submitted to OWNER in-advarwe-ofthe-4aaeified sequence or procedure of construction is shown or date prior to the Effective Date of the Agreement for indicated in and expressly required by the Contract acceptance by OWNER and F..NGINEFR -and- if Documents, CONTRACTOR may famish or utilize a G0?R'RAGT0R has submitted _ list .c____c :_ substitute means, method technique, sequence or procedure of construction acceptable to ENGINEER. CONTRACTOR information OWNER's or, ENGINBER's acceptance (either in shall submit sufficient to writing or by failing to make written objection thereto allow IsNGINEFR, in ENGINEER's sole discretion, to by the date indicated for acceptance or objection in determine that the substitute proposed is equivalent to the bidding documents or the Contract Documents) of that expressly called for by the Contract Documents. any such-Subaontrac�at;otlter I at on -or The procedure for review by ENGINEER will be similar to that provided in subparegraph 6.7.1.2. ba fFF I. aaa'a rsaM-r QR shall si "it 6.7.3. Enginee✓s Evaluation: ENGINEER will be aeeeptable-- substitute;--the--Contreet_ .Price -will- be allowed a reasonable time within which to evaluate by the ditties each proposal or submittal made pursuant to suoh-subs6uitkm and an appropriate Change -Order paragraphs 6.7.1.2 and 6.7.2. ENGINEER will be the sole judge of acceptability. No "or -equal" or constitute a condition of the Contract requir�th substitute wil I be ordered, installed or utilized without use of the named subcontractors, suppliers o other h'NGINEER's prior written acceptance which will be persons or organization cm the Work unless prior evidenced by either a Change Order or an approved written amxoval is obtained front OWNER and Shop Drawing. OWNER may require ENGINEER No acceptance by OWNER or CONTRACTOR to famish at CONTRACTOR's ENGINEER of any such Subcontractor, Supplier or expense a special performance guarantee or other other person or organization shall constitute a waiver surety with respect to any "or -equal" or substitute, of any right of OWNER or ENGINEER to reject ENGINEER will record time required by defective Wok ENGINEER mad INGINEER's Consultants in evaluating substitutes proposed or submitted by 6.9. CONTRACTOR pursuant to paragraphs 6.7,1 2 and 6.7.2 and in making changes in the Contract 6.9.1. CONTRACTOR shall be fully responsible to Documents (or in the provisions of any other direct OWNER and ENGINEER for all acts and omissions contract with OWNER for work on the Project) of the Subcontractors, Suppliers and other persons occasioned thereby. Whether or not ENGINEER and organizations performing or furnishing any of the accepts a substitute item so proposed or submitted by Word; under a direct or indirect contract with CONTRACTOR CONTRACTOR shall reimburse CONTRACTOR just as CONTRACTOR is OWNER for the charges of ENGINEER and responsible for CONTRACTOR's own acts and ENGINEMs Consultants for evaluating each such omissions. Nothing in the Contract Documents shall proposal substitute item. create for the benefit of any such Subcontractor. Supplier or other person or organization any 6.8. Concerning Subcontractors, Suppliers and *59ers. eontractual relationship between OWNER or ENGINEER and any such Subcontractor. Supplier or other nor shall it create spat 6.8.1. CONTRACTOR shall not employ any obligation on of OIINER. or ENGINEER w Subcontractor, Supplier or other person or organization pay or to see to the payment of any moneys due any (including those acceptable to OWNER and such Subcontractor, Supplier or other person or ENGINEER as indicated in paragraph 6.8.2), whether organization except as may otherwise be required by initially or as a substitute, against whom OWNER or Laws and Regulations. OWNER or ENGINEER may ENGINEER may have reasonable objection. farm sh to any subcontractor, supplier or other person CONTRACTOR shall not be required to employ any or evidence of amounts paid to Subcontractor, Supplier or other person or orgamrtion CONTRACTOR in accordance with to furnish or perform arty of the Work against whom CONTRACTOR'S "Applications for Payment" CONTRACTOR has reasonable objection. FJCDC al•"NFRAL CONDITIONS 191" 0990 edtio l 13 w/ (7 TY OF FORT (X)LLINS MODIFICATIONS (P1:V 4r1000) 6.9.2. CONTRACTOR shall be solely responsible for scheduling and coordinating the Work of Subcontractors. Suppliers and other persons and organizations performing or furnishing any of the Work under a direct or indirect contract with CONTRACTOR. CONTRACTOR shall require all Subcontractors, Suppliers and such other persons and organizations performing or furnishing any of the Work to communicate with the ENGINEER through CONTRACTOR. 6.10. The divisions and sections of the Specifications and the identifications of any Draw mks shall not control CONTRACTOR in dividing the Work among Subcontractors or Suppliers or delineating the Work to be performed by any specific trade. 6.11 All Work performed for CONTRACTOR by a Subcontractor or Supplier will be pursuant to an apptt�pnate agreement between CONTRACTOR and the Subcontractor or Supplier which specifically binds the Subcontractor or Supplier to the applicable terms and conditions of the Contract Documents for the benefit of OWNER and ENMTEER WFteneveFanysuslaagrennentt additional -insured on-the--prelh�imursnee-provided-in pamgFaphs§.6 eF 5.7, the agreement between the GONfRAC-TOR -anti- the �uhaontrnotor-trr-Supplier-w i l I 1�OG .-If, lznts awn 6e�r>y*frecaany fkeperd ieehleto the4er1F if -the -insurers -on arty -such -policies -require forms te be signed by r,_ nn�rrn nnrno , a � _bug i . the same Patent Fees and Royaldes: 6.12. CONTRACTOR shall pay all license fees and royalties and assume all costs incident to the use in the performance of the Work or the incorporation in the Work of any invention, design, process, product or devicewhich is the subject of patent rights or copyrights held by others. If a particular invention, design, process, product or device is specified in the Contract Documents for use in the performance of the Work kind if to the actual knowledge of OWNER or ENGINEER its use is subject to patent rights or copyrights calling for the payment of any license fee or royalty to others, the existence of such rights shall be disclosed by OWNER in the Contract Documents. To the fui]est extent permitted by Laws and Regulations. CONTRACTOR shall indemnify and hold harmless OWNER, ENGINEHR, ENGLNEER's Consultants and the officers, directors, employees, agents and other consultants of each and any of them from and against all claims, casts losses and damages arising out of or resulting from any infringement of patent rights or oopyrights incident to the use in the performance of the Work or resulting fron the incorporation in the Work of any invention, design, process, product or device not specified in the Contract Documents EKDC GENERAL CONIXTION31910.8 0990 Edition) 14 w/ CITY OF FORT COLLINS MODIFICATIONS (REV 42000) Permits: 6.13. Unless otherwise provided in the Supplementary Conditions, CONTRACTOR shall obtain and pay for all construction permits and licenses. OWNER shall assist CONTRACTOR, when necessary, in obtaining such permits and licenses. CONTRACTOR shall pay all governmental charges and inspection fees necessary for the prosecution of the Work, which are applicable at the time of opening of Bids, or, if there are no Bids, on the Effective Date of the Agreement. CONTRACTOR shall pay all charges of utility owners for corrections to the Work, and OWNER shall pay all charges of such utility owners for capital costs related thereto such as plant investment fees 6.14. LaraandReguladons. 6.14.1. CONTRACTOR shall give all notices and comply with all Laws aid Regulations applicable to furnishing and performance of the Work. Except where otherwise expressly required by applicable Laws and Regulations, neither OWNER nor ENGINEER shall be responsible for monitoring CONTRACTOR's compliance with any Laws or Regulations. 6,14.2. If CONTRACTOR performs any Work knowing or having reason to know that it is contrary to Laws or Rcgulaum% CONTRACTOR shall bear all claims costs, losses and damages caused by, arising out of or resulting therefrom; however, it shall not be CONTRACTOR's primary responsibility to make certain that the Specifications; and Drawings are in accordance with Laws and Regulations, but this shall not relieve CONTRACTOR of CONTRACTOR's obligations under paragraph 3.3 2. Taxes: 6.15. CONTRACTOR shall pay all sales, consumer, use and other similar taxes required to be paid by CONTRACTOR in accordance with the Laws and Regulations of the place of the project which are applicable during the performance of the Work. 6.15 1 OWNER is exempt from Colorado State and loeal�gnd use tars on materiaN to be oermanently ireoroorated into Lhe�proiecL Said taxes shall riot be included in the Contract Price. Address: Colorado Decertment of Revenue State Capital Amex 1375 Sherman Street Denver. Colorado 802n Sales and Use Taxes for the State of Colorado. Regional T_ ramortation District (RTD) and certain Colorado counties are collected by the State of Colorado and are it eluded in the Certificaon_ of Exemption. All applicable Sales and Use Tags (including State collected takes), on any items other than contraction and building materials phvsically incorporated into the project are to be paid by CONTRACTOR and me to be included in anp[oo ate bid items. Use of Premiser 6.16. CONTRACTOR shall confine construction equipment, the storage of materials and equipment and the oopperaaations of workers to the site and land and areas idrntified in and permitted by the Contact Documents and other land and areas permitted by Laws and Regulations, rights^of-way, permits and easements, and shall not unreasonably encumber the premises with construction equipment or other materials or equipment. CONTRACTOR shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof or of any adjacent land or areas, resulting from the performance of the Won}. Should any claim be made by any such owner or ax upon bemuse of the performance of the Work, CONTRACTOR shall promptly settle with such other party by negotiation or otherwise resolve the claim by arbitration or other dispute resolution proceeding or at law. CONTRACTOR shall, to the fullest Went permitted by Laws and Regulations, indemnify and hold harmless OWNER ENGINEER, ENGINEER's Consultant and anyone directly or indirectly employed by any of them from and against all claims, costs, losses and damages arising out of or resulting Iron any claim or action, legal or equitable, brought by any such owner or occupant against OWNER ENGINEER or any other party indemnified hereunder to the extent caused by or based upon CONTRACTOR's performance of the Work. 6.17. During the progress of the Work, CONTRACTOR shall keep the premises free from accumulations of waste materials, rubbish and other debris resulting Jron the Work At the completion of the Work CONTRACTOR shall remove all waste materials, rubbish and debris from and about the premises as well as all tools, appliances, construction equipment and machinery and surplus materials. CONTRACTOR shall leave the site clean and ready for occupancy by OWNER at Substantial Completion of the Work. CONTRACTOR shall restore to original condition all property net designated for alteration by the Contract Documents. 6.18. CONTRACTOR shall net load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall CONTRACTOR subject any part of the Work or adjacent property to stresses or pressures that will endanger it. Record Documents EJMC OENERA CONDITIONS I910-8 (1999 Editim) w/CITY OF FORT CDLUN4 MODIFICATIONS WXV 4R000) 6.19. CONTRACTOR shall maintain in a safe place at the site one record copy of all Drawings, Specifications, Addenda, Written Amendments, Change Orders, Work Change Drectives, Field Orders and written interpretations and clarifications (issued pursuant to paragraph 9.4) in good order and annotated to show all changes made during construction These record docutnerrts together with all approved Samples and a counterpart of all approved Shop Drawings will be available to ENGINEER for reference. Upon completion of the Work, and rrior to release of firarl payment these record documents. Samples grid Shop Drawings will be delivered to ENGINEER for OWNER. Safety and Protection 6.20. CONTRACTOR shell be responsible for initiating; maintaining and supervising all safety precautions and programs in connection with the Wok. CONTRACTOR shall take all necessary precautions for the safety ot; and shall provide the necessary protection to prevent damage, injury or loss to: 6.20.1. all persons on the Work site or who may be affected by the Work; 6.20.2. all the Work and materials and equipment to be incorporated therein, whether in storage on or off the site; and 6.20.1 other property at the site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures, utilities and Underground Facilities not designated for removal, relocation or replacement in the course of construction. CONTRACTOR shall comply with all applicable Laws and Regulations of any public body having jurisdiction for safety of persons or property or to protect them from damage, injury or loss; and shall erect and maintain all necessary safeguards for such safety and protection. CONTRACTOR shall notify owners of adjacent property and of Underground Facilities and utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation and replacement of their property. All damage, injury or loss to any property referred to in paragraphs 6.20.2 or 6.20.3 rausPA directly or indirectly, in whole or in part, by CONTRACTOR, any Subcontractor, Supplier or any other person or organization directly or indirectly employed by any of them to perform or fu nrM any of the Work or anyone for whose acts any of them may be liable, shall be remedied by CONTRACTOR (e.Nccept damage or loss attributable to the fault of Drawings or Specifications or to the acts or omissions of OWNER or ENGINEER or ENGINEER's Consultant or anyone employed by any of them or anyone fig whose acts any of them may be liable, and not attributable, directly or indirectly, in whole or in part• to the fault or negligence of CONTRACTOR or any Subcontractor, Supplier or other person or organization directly or indirectly employed by any of them). CONTRACTOR's duties and responsibilities for the safety and protection of the Work shall continue until such time as all the Work is completed and FNGiNFER has issued a 15 notice to OWNER and CONTRACTOR in accordance with paragraph 14.13 that the Work is acceptable (except as otherwise expressly provided in connection with Substantial Completion). 6.21. SafdyRepreserrfa&e: CONTRACTOR shall designate a qualified and experienced safety representative at the site whose duties and responsibilities shall be the prevention of accidents and the maintaining and supervising of safety precautions and programs. Hazard Communication Programs: 6.22. CONTRACTOR shall be resporsible for cattduating arty exchange of material safety data sheets or other hazard communication information required to be made available to or exchanged between or among employers at the site in accordance with Laws or Regulations. Fmergencies: 6.2;. In emergencies affecting the safety or protection of persons or the Work or property at the site or adjacent thereto, CONTRACTOR, without special instruction or authorization from OWNER or ENGINEER, is obligated to act to prevent threatened damage, injury or loss. CONTRACTOR shall give ENGINEER prompt written notice if CONTRACTOR believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby. If ENGINEER determines that a change in the Contract Documents is required because of the action taken by CONTRACTOR in response to such an emergency, a Work Change Directive ur Change Order will be issued to document the consequences of such action 6.24. ShopDrmsingsandSamples: 6.24.1. CONTRACTOR shall submit Shop Drawings to ENGINEER for review and approval in accordance with the accepted schedule of Shop Drawings and Sample submittals (see paragraph 2.9). All submittals will be identified as ENGINEER may rcgs re and in the number of copies specified intla General Requirements. The data shown on the Shop Drawings will be complete with respect to quantities, dimensions, specified performance and design criteria, materials and similar data to slow ENGINEER the materials and equipment CONTRACTOR proposes to provide and to enable ENGINEER to review the information for the limited purposes required by paragraph 6.26. 624.2. CONTRACTOR shall also submit Samples to ENGINEER for review and approval in accordance with said accepted schedule of Shop Drawings and Sample submittals. Each Sample will be identified dearly as to material, Supplier, pertinent data such as catalog numbers and the use for which intended and otherwise as ENGINEER may requite to enable ENGINEER to review the submittal for the limited EJCDCOEK IM CONDITIOM 1910-8 (1990 Emtim) 16 w1 CITY OF FORT COI.WNS MOMICATIONS ft-V 412000) purposes required by paragmph6.26. The numbers of each Sample to be submittal will be as specified in the Specifications. 6.25. Submittal Psoeedures. 6.25.1. Before submitting each Shop Drawing or Sample. CONTRACTOR shall have determined and verified: 6.25.1.1. all field measurements, quantities, dimensions, specified performance criteria. installation requirements, materials, catalog numbers and similar information with respect thereto, 6.25.1.2. all materials with respect to intended use, fabrication, shippppii�ng, handling, storage, assembly acid installation pertai to the performance of the Work and 6.25.1.3. all information relative to CONTRACTOR's sole responsibilities in respect of means, methods, techniques, sequences and procedures of construction and safety precautions and programs incident thereto. CONTRACTOR shall also have reviewed and coordinated each Shop Drawing or Sample with other Shop Drawings and Samples and with the requirements of the Work and the Contract Documents. 6.25.2. Each submittal will bear a stamp or specific written indication that CONTRACTOR has satisfied CONTRACTOR's obligations under the Contract Documents with respect to CONTRACTOR's review and approval of that submittal. 6.25.3. At the time of each submission, CONTRACTOR shall give ENGINEER specific written notice of such variations, if any, that the Shop Drawing or Sample submitted may have from the requirements of the Contract Documents, such notice to be in a written communication separate from the submittal; and, in addition, shall cause a specific notation to be made on each Shop Drawing and Sample su(anitted to iNGTNTTR for review and approval of each such variation. 6.26, ENGINEER will review and approve Slop Drawings and Samples in accordance with the schedule of Shop Drawings and Sample submittals accepted by ENGINEER as required by paragraph 2.9. ENGINEERs review and approval will be only to determine if the items covered by the submittals will, after installation or incorporation in the Work conform to the information given in the Contract Documents and be compatible with the design concept of the completed project as a functioning whole as indicated p by the Contract Documents. ENGLNEER's review and approval will not extend to means, methods, techniques, sequences or procedures of construction (except where a particular means, method, technique, sequence or procedure of construction is specifically and expressly called for by the Contract Documents) or to safety precautions or programs incident thereto. The review and approval of a to item as such will not indicate approval of the assembly in which the item functions. CONTRACTOR shall make corrections required by ENGINEER and shall return the required number of corrected copics of Shop Drawings and submit as required new Samples for review and approval. CONTRACTOR shall direct specific attention in writing to revisions other than the corrections called for by ENGINEER on previous submittals 627. ENGINEER's review and approval of Shop Drawmp or Samples shall not relieve CONTRACTOR from responsibility for any variation from the requirements of the Contract Documents unless CONTRACTOR has in writing called ENGA'EER's attention to each such variation at the time of submission as required by paragraph 6.25.3 and ENGINEER has given written approval of each such variation by a specific written notation thereof incorporated in or accompanying the Shop !hawing or Sample approval; nor will any approval by ENGINEER relieve CONTRACTOR from responsibility for complying with the requirements of paragraph 6.25.1. 6.28. Where a Shop Drawing or Sample is required by the Contract Documents or the schedule of Shop Drawing and Sample submissions accepted by ENGINEER as required by paragmph2.9, any related Wok performed Wto ENGINEER'S review and approval of the ppeertinent nitW will be at the sole expense and responibility of CONTRACTOR ConIInuing the Work: 6.29. CONTRACTOR shall carry on the Work and adhere to the progress schedule during all disputes or disagreements with OWNER. No Work shall be delayed or postponed pending resolution of any disputes or disagreements, except as permitted by paragraph 15.5 or as OWNER and CONTRACTOR may otherwise agree in writing. 630. COAMCTOR's General Warranty and Guarantee: 6.30.1. CONTRACTOR warrants and guarantees to OWNER, ENGINEER and ENGINEER'S Consultants that all Work will be in accordance with the Contract Documents and will not be defective. CONTRACTOR's warranty and guarantee hereunder excludes defects or damage caused by; 630.1.1. abuse, modification or improper maintenance or operation by persons other than CONTRACTOR Subcaaractors or Suppliers; or 630.1.2. normal wear and tear under normal usage. 6.30.2. CONTRACTOR's obligation to perform and complete the Work in accordance with the Contract Documents shall be absolute. None of the following will Mute an acceptance of Work that is not in E1CDC GENERAL CONDITIONS 1910-8 (1990 En9tim) w/CITY OF FORT COLLINS MODIFICATIONS (REV 42000) accordance with the Contract Documents or a release of CONTRACTOR's obligation to perform the Work in accordance with the Contract Documents: 6.30.2.1. observations by ENGINEER; 6.30.2.2. recommendation of any progress or final payment by ENGINEER; 6.30.2.3, the issuance of a certificate of Substantial Completion or any payment by OWNER to CONTRACTOR under the Contract Documents; 6.30.2.4. use or occupancy of the Work orany part thereof by OWNER; 6:30.2.5. any acceptance by OWNER or any failure to do so; 6.30.2.6. any review and approval of a Shop Drawing or Sample submittal or the issuance of a notice of acceptability by ENGINEER pursuant to paragraph 14.13, 6.30.2.7. any inspection, test or approval by others; or 6.30.2.8. any correction of defective Work by OWNER Indemnifcadan. 6.31. To the fullest extent permitted by Laws and Regulations, CONTRACTOR shall indemnify and hold harmless OWNER ENGINEER, ENGINEER's Consultants and the officers, directors, employees, agents and other consultants of each and any of them from and against all claims, costs, losses and damages (including but not limited to, all fees and charges of engincers, architects, attorneys and other professionals and all court or arbitration or other dispute resolution costs) caused by, arising out of or resulting from the performance of the Work, provided that any such claim, cost, loss or damage: (i) is attributable to bodily injury, sickness, disease or death, or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom, and (a) is caused in whole or in part by any negligent act or omission of CONTRACTOR any Subcontractor, any Supplier, any person or organization directly or indirectly employed by any of them to perform or furnish any of the Wok or anyone for whose acts any of them may be liable, regardless of whether or not caused in part by any negligence or omission of a person or entity indemnified hereunder or whether liability is imposed upon such indemnified party by Laws and Regulations regardless of the negligence of any such person or entity. 6.32. In any and all claims against OWNER or ENGINEER or any of their respective consultants, agents, officers, directors or employees by any employee (or the survivor or personal representative of such employee) of CONTRACTOR any Subcontractor, any Supplier, any person or organization directly or indirectly employed by 17 any of them to perform or furnish arty of the Work or anyone for whose acts any of them may be liable, the indemnification obligation under paragraph6.31 shall not be limited in any way by any limitation on the amount or type of damages, compensation or benefits payable by or for CONTRACTOR or any such Subcontmctor, Supplier or other person or organization under workers' compensation acts, disability benefit ads or other employee benefit acts. 6.33. The indemnification obltgalions of CONTRACTOR under paragraph 6.31 shall nil extend to the liability of ENGINEER and ENGINEER's Consultants, officers, directors, employees or agents caused by the professional negligence, errors or omissions of any of them. Sunival ofObhgations: 634. All representations, indemnifications, warranties and guarantees made in required by or given in accordance with the Coraract Documents, as well as all continuing obligations indicated in the Contrail Documents, will survive final payment, completion and acceptance of the Work and termination or completion of the Agreement. ARTICLE 7-OTHER WORK Relied Work at Site: 71. OWNER may perform other work related to the Project at the site by OWNERSs own forces, or let other direct contracts therefor which shall contain General Conditions similar to these, or have other work performed by utility owners. If the fact that such other work is to be performed was not noted in the Contract Documents, then: (i) written notice thereof will be given to CONTRACTOR prior to starting any such other work and (6) CONTRACTOR may make a claim therefor as provided in Articles I 1 and 12 if CONTRACTOR believes that such performance will involve additional expense to CONTRACTOR or requires additional time and the parties are unable to agree as to the amount or extent thereof 7.1 CONTRACTOR shall afford each other contractor who is a party to such a direct contract and each utility owner (and OWNER, if OWNER is performing the additional work with OWNERSs employees) proper and safe access to the site and a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such other work and shall properly connect and coordinate the Work with theirs. Unless otherwise provided in the Contract Documents, CONTRACTOR shall do all cutting fitting and patching of the Work that may be required to make its several parts come together properly and integrate with such other work. CONTRACTOR shall not endanger any work of others by cutting, excavating or otherwise altering thew work and will only cut or alter their work with the written consent of ENGINEER and the others whose work will be affected. The duties and r onsibilitics of CONTRACTOR under this paragraph are for the benefit of such utility owners and other contractors to the extent that there are compamble EJCDCOENERAL COMXUOFS 1910-8 6990 Edlim) 18 wf CITY OF FORT COWNS MODIFICATIONS (REV 4n000) provisions for the benefit of CONTRACTOR in said direct contracts between OWNER and such utility owners and other contractors. 7.3. If the proper execution or results of any part of CONTRACIOR's Work depends upon ORshall by others under this Article 7, CONTRACTOR inspect such other work and promptly report to ENGINEER in writing any delays, defects or deficiencies in such doer work that render it unavailable or unsuitable for the proper execution and results of CONTRACTOR's Work. CONTRACTOR's failure so to report will constitute an acceptance of such other work as fit and proper for integration with CONTRACTOR'S Work except for Intent or nonapparent defects and deficiencies in such other work. Coordination: 7.4. If OWNER contracts with others for the performance of other work on the Project at the site, the following will be set forth in Supplementary Conditions: 7.4.1. the person, firm or corporation who will have authority and responsibility for coordination of the activities among the various prime contractors will be identified; 7.4.2. the specific matters to be covered by such authority and responsibility will be itemized; and 7.4.3. the extent of such authority and responsibilities will be provided. Unless otherwise provided in the Supplementary Condition OWNER shall have sole authority and responsibility in respect of such coordination ARTICLE 8-OWNER'S RESPONSIBILITIES 8.1. Except as otherwise provided in these General Conditions, OWNER shall issue all communications to CONTRACTOR throughENGIIVEER. 8.2. In case of termination of the employment of ENGINEER, OWNER shall appoint an engineer againd whom-EON�fR�4C-T'9R-maktr-no-reesaneble-ebjecticxk whose status under the Contract Documents shall be that of the former ENGINEER 8.3. OWNER shall furnish the data required of OWNER under the Contract Documents promptly and shall make payments to CONTRACTOR promptly when they are due as provided in paragraphs 14.4 and 14.13. 8.4. OWNERs duties in respect of providing lands and easements and providing engineering surveys to establish reference points are set forth in paragraphs 4.1 and 4.4. Paragraph4.2 refers to OWNERSs identifying and making available to CONTRACTOR copies of reports of explorations and tests of subsurface conditions at the site and drawings of physical conditions in existing structures at or contiguous to the site that have been utilized by ENGINEER in preparing the Contract Documents_ R.S. E�iUI ll iF�rUspensibilitins i�i peet: g forth-in-pamgrsphs33through 5:10: 8.6. OWNER is obligated to execute Change Orders as indicated in paragraph 10.4. 81. OWNERs responsibility in respect of certain inspections, tests and approvals is set forth in paragraph 13.4. 8.8. In connection with OWNER's right to stop Work or suspend Work, see pa hs 13.10 and 15.1. Paragraph 15.2 deals with O)MR's right to terminate services of CONTRACTOR under certain circumstances. 8.9. The OWNER shall not supervise, direct or have control or authority over, nor be responsible for, CONTRACTOR's means, methods, techniques, sequences or procedures of construction or the safety precautions and programs incident thereto, or for any failure of CONTRACTOR to comply with Laws and Regulations applicable to the furnishing or performance of the Work. OWNER will not be responsible for CONTRACTOR's failure to perform or furnish the Work in accordance with the Contract Documents. "0 OWI,z�Ws rasp, sibili:i R rEspeat4wAselesed Asbestes; Pf Rs; Petreletan llasrdaus Waste er Radieeetive ?,later ials urieevered or revealed is set forth paragraph 43. lVlArt'b Al�l'!1D ....61_ :d_!.._ .M. arfangemertts—live--leen—made to satisfy BWNTRs re9partstbtlity-in-ras]xef L#leree£will bP as -set-forth-jr, the Supplaatertiatl`.<attdrttets- ARTICLE 9—ENGINEER'S STATUS DURING CONSMUCTION OWNER's Representative: 9.L ENGINEER will be OWNER's representative during the construction period. The duties and responsibilities and the limitations of authority of ENGINEER as OW NER's representative during construction are set forth in the Contract Documents and shall not be extended without written consent of OWNER and ENGINEER. lrtsits to b9te: 9.2. ENGINEER will make visits to the site at intervals appropnate to the various stages of construction as ENGINEER deems necessary in order to observe as an experienced and qualified design professional the progress E1CDC OENE' CONWTIONS 1910-8(1990 Editim) wr aTY Or roar COt.UM MOD1r7CA11ONS (REV 42000) that has been made and the quality of the various aspects of CONTRACTOR's executed Work. Based at information obtained during such visits and observations, ENGINEER will endeavor for the benefit of OWNER to determine, in general, if the Work is proceeding in accordance with the Contract Documents. ENGINEER will not be required to make exhaustive or continuous on - site inspections to check the quality or quantity of the Work. ENGINEER's efforts will be directed toward providing for OWNER a Beater degree of confidence that the completed Work will conform generally to the Contract Documents. On the basis of such visits and on - site observations, ENGINEER will kae OWNER informed of the progress of the Work and will endeavorto guard OWNER against defective Work. ENGINEER's visits and on site observations are subject to all the limitations on ENGINEER's authority and responsibility set forth in paragraph 9.13, and particularly, but without limitation. during or as a result of ENGINEER's on site visits or observations of CONTRACfOWs Work ENGINEER will not supervise, clirect. control or have authority over or be responsible for CONTRACTOR's means, methods, techniques, sequences or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of CONTRACTOR to comply with Laws and Regulations applicable to the furnishing or performance of the Work. Project Representative: 93 1f OWNER and ENGINEER agree, ENGINEER will furnish a Resident Project Representative to assist ENGINEER in providing more continuous observation of the Work. The responsibilities and authority and limitations thereon of any such Resident Project Representative and assistants will be as provided in paragraphs 9.3 and 9.13 001 Conditions of these General Conditiot . If OWNER designates another representative or agent to represent OWNER at the site who is not ENGINEER' Consultsm, agent or employee, the responsibilities and authority and limitations thereon of such other person will be as provided in oaraeraoh 9.3 9.3.1. The Representative's dealings in matters Veertaining m the on -site wod will, in eateral, be with the E -GG DEER and CONTRACTOR But, the R�,pe reseniative will keep the OWNER �rocerly advised about such matters. The Rgxesmtative's deal' with subcontractors will and be [hrou or with the full knowledge and Approval o the CONTRACTOR 9.3.2. Duties and Respxsibilities Representative will: 9.3.2.I.Schedules - Review the nrotrress 19 schedule and other schedules prepared by the CONTRACTOR and consult with the ENGINEER concerning acceptability. 9.3.2 2 Conferences and Mcetitm - Attend meeting with the CONTRACTOR such as pr construction conferences. Diogrps mCetinRa and other nob conferences and Prepare and arculate conies of minutes of meetings. 93.2.3. Liaison 9.32.3.1. Serve as ENGINEERS liaison with CONTRACTOR vvorkum Principally through CONTRACTORS §Wgr ntendem to assist the CONTRACTOR in understanding the Contract Documents 9.3.2.3.2. Assist in obtainine diom OWNER additional details or information when required for Proper execution of the Work. 9 3.2 3.3. Advise the ENGINEER and CONTRACTOR of the commencement of env Work rer�iirirg a Shop Drawing or sample submission if the submission has not been MMved by the ENGINEER 9.3 2 4 Review of Work. Re §dgp of Defective Work Inspections and Test - 9.3.2.4.1. Conduct on -site observations of to assist the ENGINEER in determining the Work is proceeding in a000rdarlce with the Contract Documers 9.3.2A.3. livsttM=msyectors representngobcpother agencies having jurisdiction over the Project, record the results of these inspections and report to the ENGINEER. 9325. Wetpretation of Contract Documents. RWort to ENGINEER when clarifications and interpretations of the Contract Documents are needed and transmit to CONTRACTOR clarification and inteilretation of the Contract Documents as issued by the It11�it341�71 t7 93.2.6. Modification. Consider and evaluate CONTRACTORS suggestions fur EJCDC GEtgRAL CONDiT IOR5191"(1 "0 Editim) 70 w1 CITY OF FORT 001.11MMODIF)CATIOM QtEV 412000) modification in Drawines or Specifications and report these recommendeLom to L2�?GINCER, Accurately Jtiarnsoit to CONTRACTOR decisions wuerl by the ENGINEER 9.3.2.7. Records. MIPWIlt :ML_ 9,3.2.8.1 Famish ENGINF a—peiodic Tr as req of the prgpM of the Work and of the CONTRACTORS cannlitutcc wilhsbs pfcess schedule and sd=dale of shop Drawing and sample s ftitle s 9 �;�$,ffi_ �,}u t with INGIldEER in advance of scheduling mayor yNgF inspections or start of important phases of the Wcrk. 9.3.2.8.3. Drain propesed Change Orders and W k Dvechve Charge�olxaining backup material from the CONTRACTOR and recommennd to the Change Orders. Work Directive Changes ard- of !d orders, 93.2.8.4. Repot immediately to ENGINEER OWNER occ arrnce of any accident 9 3 2 9 Payment Rec uueests. Review applications for payment with CONIIRACTOR for compliance with the established oracedure for their submission and forward with recommendation to ENGINEER noting particularly the relationship of th�xment tecgusted to the schedule of values, work completed and materials and eettipanent delivered at the site but not incorporated m the Work. 9.3.2.10. Commotion, 9.3.2.10.1. Before ENGINEER issues a Certificate of Substantial Completion submit to CONTRACTOR a lisl of observed items =uiuirina correction or completion 9.3.2.10.2. Conduct final inspection in the company of the HNGINFF,R. OWNFR and CONTRACTOR and prepare a final list of items to be corrected or completed 9.3.2.10.3. Observe that all items on tag final list have been carreded or comconspletrd�and make recommertdalions to ENGNEER concerning acceotance. 93.3. Limitation of Authority- The Representative shall not 93.3.1_Authorize arw deviations from the Contract Documents or accept any substitute materials or eauipmentygt less authgg7¢y ENGINEER 93.3.2. Exceed limitations of ENGINEERS authority as set forth in the Contract Documons, 9.3.3.3. Undertake any of the responsibilities of the CONTRACTOR Subcontractors or CONTRACTOR'S supMatmdent 93.3.4. Advise 9A issue direction relan esstmre control over many pceothe trod rbyes for construction unless such is specifically called for in the Contract Documents. 9.3.3.5. Advise on or issue directions reaardine a assume oontrQl aver safetw precautions and programs in connections with the Wok. 93.3.6. Accept Shop Draw r or_sample submittals from anyone other than the CONTRACTOR 9.3.3.7. Authorize OWNER to occupy the Work in whole or inpart. 9.3.3.8. Participate in specialized field or laboratory tests or mistmotions conducted by others except as specifically authonzed by the I_�►Ce3ix_I,h�^� Clarifications and Interpretations: 9.4. ENGINEER will issue with reasonable promptness such written clarifications or interpretations of the EJCDC GENERAL CONIATI ONS 191" (1990 Edtim) w/CITY OF FORT COLUM MODIFICATIONS (HEV 42a0a) requirements of the Contract Documens (in the form of Drawings or otherwise) as ENGINEER may determine necessary, which shall be consistent with the intent of and reasonably inferable from the Contract Documents. Such written clarifications and interpretations will be binding on OWNER and CONTRACTOR If OWNER or CONTRACTOR believes that a written clarification or interpretation justifies an adjustment in the Contract Price or the Contract Times and the parties are unable to agree to the amount or extent thereof, if any, OWNER or CONTRACTOR may make a written claim therefor as provided in Article 11 or Article 12. Authorized Variations in Work: 9.5. ENGINEER may authorize minor variations in the Work from the requirements of the Contract Documents which do not involve an adjustment in the Contract Price or the Contract Times and are compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. These may be accomplished by a Field Order and will be binding on OWNER and also on CONTRACTOR who shall perform the Work involved promptly. If OWNER or CONTRACTOR believes that a Field Order justifies an adjustment in the Contract Price or the Contract Times and the parties are unable to agree as to the amount or eAcnt thereof, OWNER or CONTRACTOR may make a written claim therefor as provided in Article 1 I or 12. Rejecting Defective Work 9A ENGINEER will have authority to disapprove or reject Work which ENGINEER believes to be defective, or that ENGINEER believes will not produce a completed Project that conforms to the Contract Documents or that will prejudice the integrity of the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. ENGINEER will also have authority to require special inspection or testing of the Work as provided in paragraph 13.9. whether or not the Work is fabricated, installed or completed. Shop Drawings, Change Orders and Payments: 9.7, In connection with ENGINEERS authority as to Shop Drawings and Samples, see paragraphs 6.24 through 6.28 inclusive. 9.8. In connection with ENGINEERS authority as to Change Orders, see Articles 10.11. and 12. 9.9, In connection with ENGINEER's authority as w Applications for Puymem, see Article 14. Determinations for Unit Prices 9.10. ENGINEER will determine the actual quantities and classifications of Unit Price Work performed by CONTRACTOR. ENGINEER will review with CONTRACTOR the ENGINEER's preliminary determinations on such matters before rendering a written decision thereon (by recommendation of an Application 'I for payment or otherwise). ENGLNEER's written decision thereat will be final and binding upon OWNER and CONTRACTOR, unless, within ten days after the date of any such decision, either OWNER or CONTRACTOR delivers to the other and to ENGINEER written notice of intention to appeal from ENGINEER' s decision and: (i) an appeal from ENGINEER's decision is taken within the time limits and in accordance with the procedures set forth in Exhibit GC -A, "Dispute Resolution Agreement", entered into between OWNER and CONTRACTOR pursuam to Article 16, or (ii) if no such Dispute Resolution Agreement has been entered intct a formal proceeding is instituted by the appealing party in a foram of competent jurisdiction to cxcretse such rights or remedies as the appealing party may have with respect to ENGLNEER's decision, unless otherwise agreed an writing by OWNER and CONTRACTOR Such appeal will not be subject to the procedures of paragraph 9.11. Decisions an Disputes: 9.11. ENGINEER will be the initial interpreter of the requirements of the Contract Documents and judge of the acceptability of the Work thereunder. Claims disputes and other matters relating to the acceptability of the Work or the interpretation of the requirements of the Contract Documents perta fining to the performance and furnishing of the Work and claims under Articles i I and 12 in respect of changes in the Contract Price or Contract Times will be referred initially to ENGINEER in writing with a request for a formal ion in accordance with this paragraph. Written notice of each such claim, dispute or other matter will be delivered by the claimant to ENGINEER and the other party to the Agreement promptly (but in no event later than thirty days) after the start of the occurrence or event giving rise thereto, and written supporting data will be submitted to ENGINEER and the other party within sixty days after the start of such occurrence or event unless ENGINEER allows an additional period of time for the submission of additional or more accurate data in support of such claim, dispute or other matter. The opposing }Tarty shall submit any response to ENGINEER and the claimant within thirty days after receipt of the claimant's last submittal (unless ENGINEER allows additional time). ENGINEER will render a formal decision in writing within thirty days after receipt of the opposing parry's submittal, if any, in accordance with this paragraph. ENGINEERS written decision on such claim, dispute or other matter will be final and binding upon OWNER and CONTRACTOR unless: (i) an appeal from ENGINIER's decision is taken within the time limits and in accordance with the procedures set forth in EXHIBIT GC -A, "Dispute Resolution Agreement", entered into between OWNER and CONTRACTOR pursuant to Article 16, or (ii) if no such Dispute Resolution Agreement has been entered into, a written notice of intention to appeal from ENGINEER's written decision is delivered by OWNER or CONTRACTOR to the other and to ENGINEER within thirty days after the date of such decision and a formal proceeding is instituted by the appealing party in a forum of competent jurisdiction to exercise such rights or remedies as the appealing party may have with respect to such claim, dispute or other matter in accordance with applicable Laws and Regulations within sixty days of the date of such EJC.DC GENERAL CONDITIONS 191"(1990 Editim) 22 wf CITY OF FORT COLLINS MODIFICATIONS (REV 412000) decision, unless otherwise agreed in writing by OWNER and CONTRACTOR 9.12. When fnmetioning as interpreter and judge under paragni*9.10 and 9.11, ENGINEER will not show partiality to OWNER or CONTRACTOR and will not be 'liable in connection with any interpretation or decision rendered in good faith in such capacity. The rendering of a decision by ENG INEER pursuant to paragraphs 9.10 or 9.11 with respect to an), such claim, dispute or other matter (except arry which have been waivedby the making or acceptance of final payment as provided in Paragraph 14.15) will be a condition precedent to any exercise by OWNER or CONTRACTOR of such rights or remedies as either may otherwise have tinder the Contract Documents or by laws or Regulations in respect of any such claim, dispute or other matter-ptavantiia-ArUele46. 9.13, Limitations on CNGINEER's Authority and Responsibilities: 9.13.1. Neither ENGMEER's authority or responsibility under this Article 9 or under arty other provision of the Contract Documents nor any decision made by ENGINEER in good faith either to exercise or not exercise such authority or responsibility or the undertaking, exorcise or performance of any authority or responsibility by ENGINFER shall create, impose or give rise to any duty owed by ENGINEER to CONTRACTOR, any Subcontractor, any Supplier, any other person or organization, or to any surety for or employee or agent of any of them. 9.13.2. ENGINEER will not supervise, direct, control or have authority over or be responsible for CONTRACTOR's means, methods, techniques, sequences or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of CONTRACTOR to comply with Laws and Regulations applicable to the furnishing or performance of the Work. ENGINEER will not be responsible for CONTRACTOR's failure to perform or furnish the Work in accordance with the Contract Documents. 9.13.3. ENGINEER will not be responsible for the acts or omissions of CONTRACTOR or of any Sulx:onvacior, a+ry Supplier. or of any other person or organization performing or furnishing any of the Work. 9.13.4. ENGINEER's review of the final Application for Payment and accompanying documentation and all maintenance and operating instructions, schedules, guarantees, Bonds and certificates of inspection, tests and approvals and other documentation required to be delivered by pamgmph 14.12 will only be to determine generally that their content complies with the requirements of, and in the case of certificates of inspections, tests and approvals that the results certified indicate compliance with, the Contract Documents 913.5. The limitations upon authority and SECTION 00510 NOTICE OF AWARD DATE: February 9, 2015 TO: Northstar Concrete Inc PROJECT: 7509 Concrete Maintenance Project Phase II — 2015 Renewal OWNER: CITY OF FORT COLLINS (hereinafter referred to as "the OWNER") You are hereby notified that your Bid for the above project has been considered. You are the apparent successful Bidder and have been awarded an Agreement for 7509 Concrete Maintenance Project Phase II — 2015 Renewal. The Price of your Agreement is One Million Seven Hundred Eleven Thousand Two Hundred Fifty -Seven Dollars and Twenty Cents ($1 711 257.20). Three (3) copies of each of the proposed Contract Documents (except Drawings) accompany this Notice of Award. Three (3) sets of the Drawings will be delivered separately or otherwise made available to you immediately. You must comply with the following conditions precedent within fifteen (15) days of the date of this Notice of Award, that is by February 24, 2015. 1. You must deliver to the OWNER three (3) fully executed counterparts of the Agreement including all the Contract Documents. Each of the Contract Documents must bear your signature on the cover of the page. 2. You must deliver with the executed Agreement the Contract Security (Bonds) as specified in the Instructions to Bidders, General Conditions (Article 5.1) and Supplementary Conditions. Failure to comply with these conditions within the time specified will entitle OWNER to consider your Bid abandoned, to annul this Notice of Award and to declare your Bid Security forfeited. Within ten (10) days after you comply with those conditions, OWNER will return to you one (1) fully -signed counterpart of the Agreement with the Contract Documents att ched. City of Fo lins OWNER By: Gerry Paul Director of Purchasing & Risk Management responsibility set forth in this paragraph 9.13 shall also apply, to ENGINEER's Consultants, Resident Project Representative and assistants. ARTICLE 10—CHANGES IN THE WORK 10.1. Without invalidating the Agreement and without notice to any surety, OWNER may, at any time or from time to time, order additions, deletions or revisions in the Work. Such additions, deletions or revisions will be authorized by a Written Amendment, a Change Order, or a Work Change Directive. Upon receipt of any such dcctmtent, CONTRACTOR shall promptly proceed with the Work involved which will be performed under the applicable conditions of the Contract Documents (except as otherwise specifically provided). 10.2. If OWNER and CONTRACTOR are unable to agree as to the extern, if any, of an adjustment in the Contract Price or an adjustment of the Contract Times that should be allowed as a result of a Wok Change Directive, a claim may be made therefor as provided in Article 1 I or Article 12. 10.3. CONTRACTOR shall not be entitled to an increase in the Contract Price or an extension of the Contract Times with respect to arry Work performed that is not required by the Contract Documents as amended, modified and supplemented as provided in paragraphs 3.5 and 3.6, except in the case of an emergency as provided in paragraph 6.23 or in the case of uncovering Work as provided in paragraph 13.9. 10.4. OWNER and CONTRACTOR shall execute appropriate Change Orders recommended by ENGINEER (or Written Amendments) covering: 10.4.1. changes in the Work which are (i) ordered by OWNER pursuant to paragraph 10.1, (ii) required because of acceptance of defective Work under paragraph 13.13 or correcting defective Work under paragraph 13.14. or (ih) agreed to by the parties; 10.4.2. changes in the Contract Price or Contract Times which are agreed to by the parties; and 10.4.3. changes in the Contract Price or Contract Times which embody the substance of any written decision rendered by ENGINEER pursuant to paragraph 9-11; provided that, in heu of executing any such Change Order, an appeal may be taken from any such decision in accordance with the provisions of the Contract Documents and applicable Laws and Regulations, but during any such appeal, CONTRACTOR shall carry on the Weak and adhere to the progress schedule as provided in paragraph 6.29. 10.5. If notice of arty change atfeaing the general scope of the Work or the provisions of the Contract Documents EJCOC GENERAL COMMIONS 191" (1990 Eddon) WIC ITY OF FORT COLLINS MODIFICATIONS (REV 412(W) (including, but not limited M Contract Price or Contract Times) is required by the provisions of any Bond to be given to a sure, the givirtp� of any such notice will be CONTRACTOR's responsibility, and the amount of each applicable Bond will be adjusted accordingly. ARTICLE II —CHANGE OF CONTRACT PRICE 11.1. The Contract Price constitutes the total compensation (subject to authorized adjustments) payable to CONTRACTOR for performing the Work. All duties, nxprins bilities and obligations assigned to or undertaken by CONTRACTOR shall be at CONTRACTOR's expense without change in the Contract Price, 11 The Contract Price may only be changed by a Change Order or by a Written Amendment Any claim for an adjustment in the Comuact Price shall be based on written notice delivered by the party making the claim to the other party and to ENGINEER promptly (tut in no event later than thirty days) after the start of the occurrence or event giving rise to the claim and stating the general nature of the claim. Notice of the amount of the claim with supporting data shall be delivered within sixty days after the start of such occurrence or event (unless ENGINEER allows additional time for claimant to submit additional or more accurate data in support of The claim) and shall be accompanied by claimant's written statement that the adjustment claimed covers all known amounts to which the claimant is entitled as a result of said occurrence or event. All claims for adjustment in the Contract Price shall be determined by ENGINEER in accordance with paragraph 9.11 if OWNER and CONTRACTOR cannot otherwise agree on the amount involved. No claim for an Austmem in the Contract Price will be valid if not submitted in accordance with this paragraph 11.2. 113. The value of any Work covered by a Change Order or of any claim for an adjustment in the Contract Price will be determined as follows: 11.3.1. where the Work involved is covered by unit prices contained in the Contract Doctmtents, by application of such unit prices to the quantities of the items involved (subject to the provisions of 23 paragraphs 11.9.1 through 11.93, inclusive): 11.3.2. where the Work involved is not covered by unit prices contained in the Contract Documents, by a mutually agreed payment basis, including lump sum (which may include an allowance for overhead and profit not necessarily in accordance with paragraph 11.62); 11.3.3. where the Work involved is not covered by unit prices contained in the Contract Documents and agreement to a lump sum is not reached under paragraph 11.3.2, on the basis of the Cos of the Work - (determined as provided in paragraphs 11.4 and 11.5) plus a CONTRACTOR's fee for overhead and profit (determined as provided in paragraph 11.6). Cost of Me li%ork- 11R. The term Coat of the Work means the sum of all mstss necessarily incurred and paid by CONTRACTOR in the proper performance of the Work. Except as otherwise may be agreed to in writing by OWNER such coats shall be in amounts no higher than those prevailing in the locality of the Project, shall include only the following items and shall not include any of the casts itemised in Paragraph 11.5- 11.4.1.Payroll costs for employees in the direct employ, of CONTRACTOR in the performance of the Work under schedules of job classifications agreed upon by OWNER and CONTRACTOR. Such employees shall include without limitation superintendents, foremen and other personnel employed full-time at the site. Payroll costs for employees not employed full-time on the Work shall be apportioned on the basis of their time spent on the Work. Payroll costs shall kcltuk->x*4xx be limited to; salaries and wages plus the cost of fringe benefits which shall include social security contributions, unemployment, excise and payroll taxes, workers' compensation, health andreti ement benefits; -bonuses; applicable thereto. The e;penses of performing Work after regular working hours. on Saturday, Sunday or legal holidays, shall be included in the above to the extent authorized by OWNER. 11.4.2. Cost of all materials and equipment furnished and incorporated in the Work including costs of transportation and storage thereof, and Suppliers' field services required in mraecuon therewith All cash discounts shall accrue to CONTRACTOR unless OWNER deposits funds with CONTRACTOR with which to make payments, in which case the cash discounts shall am -rue to OWNER. All trade discounts. rebates and refunds and returns from sale of surplus materials and equipment shall accrue to OWNER and CONTRACTOR shall make provisions so that they may be obtained 11.4.3. Payments made by CONTRACTOR to the Subcontractors for Work performed or furnished by Subcontractors if required by OWNW E)CtK OENNIRAL COMMONS 19104 (1990 E(Gtim) 24 wlaTYOFFORT 00t.UNSM0OIFICATI0NS(REV4)2000) CONTRACTOR shall obtain competitive bids from Subcontractors acceptable to OWNER and CONTRACTOR and shall deliver such bids to OWNER who will then determine, with the advice or ENGINEER, which bids, if any, will be accepted. If any subcontract provides that the Subcontractor is to be paid on the basis of Cost of the Work plus a fee, the Subcontractors Cost of the Work and fee shall be determined in the same manner as CONTRACTOR's Cost of the Work and fee as provided in paragraphs l 1.4, 11.5, I L6 and 11.7. All subcontracts shall be subject to the other provisions of the Contract Documents insofar as applicable. 11.4.4. Costs of special consultants (including but not limited to engineers, architects, testing laboratories, surveyors, attorneys and accountants) employed for services specifically related to the Work. 11.4.5. Supplemental costs including the following: 11.4.5.1. The proportion of necessary Irtraantusppoottatian, traveland subsistence expenses of CONTRACTOR's employees incurred in discharge of duties connected with the Work. 11.4.5.2. Cash, including transportation and maintenance, of all materials• supplies, equipment, machinery, appliances, office and temporary facilities at the site and hand tools not owned by the workers, which are consumed in the performance of the Work and cos less market value of such items used but not consumed which remain the property of CONTRACTOR 11.4.5.3. Rentals of all construction equipment and machinery and the parts thereof whether rented from CONTRACTOR or others in accordance with rental agreements approved by OWNER with the advice of ENGINEER and the casts of transportation, loading, unloading, installation, dismantling and removal thereof —all in accordance with tcnns of said rental agreements. The rental of any such equipment, machinery or parts shall cease when the use thereof is no longer necessary for the Work. 11.4.5.4. Sales, consumer, use or similar taxes related to the Work, and for which CONTRACTOR is liable, imposed by Laws and Regulations. 11.4.5.5. Deposits lost for causes other than negligence of CONTRACTOR, any Subcontractor or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, and royalty payments and fees for permits and licenses. 11.4.5.6. Losses and damages (and related cxpetses) caused by damage to the Work, not compensated by insurance or otherwise, sustained by CONTRACTOR in connection with the performance and furnishing of the Work (except losses and damages within the deductible amounts of property insurance established by OWNER in accordance with paragraph 59), provided they have resulted froin causes other than the ne Ig Tence of CONfRAC'fOR, any Subbccxormuractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable. Such losses shall include settlements made with the written consent and approval of OW1NMR- No such losses, damages and expenses shall be included in the Cost of the Work for the p of determining CONTRACTOR'S fee. It however, any such loss or damage requires reconstruction and CONTRACTOR is laced in charge thaeot CONTRACTOR shallbepaid for services a fee Proportionate to that stated in paragraph 11.6.1 11A.5.7. The cost of utilities, fuel and sanitary facilities at the site. 11.4.5.8. Minor expenses such as telegrams, long distance telephone calls, telephone service at the site, expressage and similar petty cash items in connection with the Work. 11.4.5.9. Cost of premiums for additional Bonds and insurance required because of changes in the Work. 11.5. The term Cost of the Work shall not include any of the following: 11.5.1. Payroll costs and other compensation of CONTRACTOR's officers, executives. principals (of partnership and sole proprietorships), general managers, engineers, architects. estimators, attorneys, auditors, acwtwants, purchasing and contracting agents, expediters, timekeepers, clerks and other personnel employed by CONTRACTOR whether at the site or in CONTRACTOR's principal or a branch office for general administration of the Work and not specificallS, included in the agreed upon schedule of job classifications referred to in paragraph 11.43 or specifically covered by paragraph 11.4.4--all of which are to be considered administrative costs covered by the CONTRACTOWs fee. 115.2. Expenses of CONTRACTORS principal and branch offices other than CONTRACTORSs office at the site. 115.3. Any part of CONTRACTORSs capital expenses, including interest on CONTRACTOR'S capital employed for the Work and charges against CONTRACTOR for delinquent payments. 11.5.4. Cost of premiums for all Bonds and for all insurance whether or not CONTRACTOR is required by the Contract Documents to purchase and maintain the same (except for the cost of premiums covered by subparagraph 11.4.5.9 above). UCDC GENERAL COMMONS 191" (199a Edtion) Wf U rY OF FORT COLUNS MODIFICATIONS (REV 4/20aa) 11.5.5. Costs due to the negligence of CONTRACTOR, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose axis any of them may be liable, including but not limited to, the correction of defective Work disposal of materials or equipment wrongly supplied aril making good any damage to property. 11.5.6_ Other overhead or general expense costs of arty kind and the costs of any item not specifically and expressly included in paragraph 11 A 116. The CON1'RACTOR's fee allowed to CONTRACTOR for overhead and profit shall be determined as follows 11.6.1, a mutually acceptable fixed fee; or 11,6.2. if a fixed ke is not agreed upon, then a fee based on the following percentages of the various portions of the Cost of the Work: 11.6.2.1. for costs incurred under paragraphs 11.4.1 and 11.4.2. the CONTRAC:TOR's fee shall be fifteen percent; 11.6.22, for casts incurred under paragraph 11.4.3, the CONTRACTOR's fee shall be five percent: 11.6.2.3. where one or more tiers of subcontracts are on the basis of Cost of the Work plus a fee and no fixed fee is agreed upon, the lntcnt of paragraphs 11.4.1, 11.4.2, 11.4.3 and 11.6.2 is that the Subcontractor who actually performs or furnishes the Work, at whatever tier, will be paid a fee of fifteen percent of the costs incurred by such Subcontractor under paragraphs 11.4.1 and 11.42 and that any higher tier Subcontractor and CONTRACTOR will each be paid a fee-o€-€ *-percent oftha amount paid to the-nda}4awertier-gube.onntrecter, to h neeg6aled Y) good-ffiLh_wA the OWNER but not to exceed five percent of the amount paid to the next lower UPF 534_�9gtd : 11.6.2.4, no fee shall be payable on the basis of costs itemized under paragraphs 11.4.4, 11.4.5 and 11.5; 11.6.2S. the amount of credit to be allowed by CONTRACTOR to OWNER for any change which results in a net decrease in cost will be the amount of the actual net decrease in cost plus a deduction in CONTRACTOR's fee by an amount equal to Eve percent of such net decrease; and 11.6.2.6. when both additions and credits are involved in any one change, the adjustment in CONTRACTOR's fee shall be compared on the basis of the net charge in accordance with paragraphs 11.6.2.1 through 11.6.25, inclusive. 11.7. Whenever the cast of arty Work is to he 25 determined pursuant to paragraphs 11.4 and 11.5. CONTRACTOR will establish and maintain records thereof in accordance with generally accepted accounting practices and submit in form acccptable to ENGINEER an itemized cost breakdown together with supporting data. Cash Allowances: i I.S. It is understood that CONTRACTOR has included in the Contract Price all allowances so named in the Contract Documents and shall cause the Work so covered to be furnished and performed for such sums as may be acceptable to OWNER and ENGINEER. CONTRACTOR agrees that: 11.8.1, the allowances include the cost to CONTRACTOR (less any applicable trade discounts) of materials and equipment required by the allowances to be delivered at the site, and all applicable taxes, and 11.8.2. CONfRACTOR's costs for unloading and handling on the site, labor, installation costs, overhead, profit and other expenses contemplated for the allowances have been included in the Contract Price and not in the allowances and no demand for additional payment on account of any of the foregoing will be valid. Prior to final payment, an appropriate Change Order will be issued as recommended by ENGINEER to reflect actual amounts due CONTRACTOR on account of Work covered by allowances, and the Contract Price shall be correspondingly adjusted. 11.9. Unit Price Norte 11.9.1. Who the Contract Documents provide that all or pan of the Work is to be Unit Price Work, initially the Contract Price will be deemed to include for all Unit Price Work an amount equal to the sum of the established unit prices for each separately identified item of Unit Price Work limes the estimated quantity of each item as indicated in the Agreement. The estimated quantities of items of Unit Price Work are not guaranteed and are solely for the purpose of comparison of Bits and determining an initia 1 Contract Price. Determinations of the actual quantities and classifications of Unit Rice Wick performed by CONTRACTOR will be made by ENGINEER in accordance with paragraph 9.10. 11.9.2. Each unit price will be deemed to include an amount considered by CONTRACTOR to be adequate to cover CONTRACTOR's overhead and profit for each separately identified item. 11.9.1OWNER or CONTRACTOR may make a claim for an adjustment in the Contract price in accordance with Article 11 if: 11.9.3.1. the quantity of any item of Unit Price Work performed by CONTRACTOR differs materially end significantly from the estimated quantity of such item indicated in the Agreement; EK DCOENERAL CONDITIONS 19105 0990 Ed itim) �6 wI CITY OF FORT COLLINS MODIFICATIONS(REV 40000) and 11.9.3.2. there is no corresponding adjustment with respect to arty other item of Work; and 11.9.33. if CONTRACTOR believes that CONTRACTOR is entitled to an increase in Contract Price as a result of having incurred additional expense or OWNER believes that OWNER is entitled to a decrease in Contract Price and the parties are unable to agree as to the amount of any such increase or decrease. 11.9.3.4. CONTRACTOR acknowledecs that the OWNER has the ri¢ht to add or delete items in the Bid or chap e c artn" at OWNER'S sole discrelion without nmr the Contract Price of any remaininy, item so long as the deletion or addition does not exceed twenty-five reticent of the original total Contract Price. ARTICLE IZ—CHANGE OF CONTRACT TIMES 121. The Contract Times (or Milestones) may only be changed by a Change Order or a Written Amendment. Any claim for an adjustment of the Contract Times (or Milestones) shall be based on written notice delivered by the party making the claim to the other party and to ENGINEER promptly (but in no event later than thirty days) after the occurrence of the event giving rise to the claim and stating the general nature of the claim. Notice of the extent of the claim with supporting data shall be delivered within sixty days after such occurrence (unless ENGINEER allows additional time to ascertain more accurate data in support of the claim) and shall be a cornpanied by the claimant's written statement that the adjustment claimed is the entire adjustment to which the claimant has reason to believe it is entitled as a result of the occurrence of said event. All claims for adjustment in the Contract Times (or Milestones) shall be determined by ENGINEER in accordance with paragraph 9.11 if OWNER and CONTRACTOR cannot otherwise agree. No claim for an adjustment in the Contract Times (or Milestones) will be valid if not submitted in accordance with the requirements of this pamsraph 12.1. 12.2. All time limits stated in the Contract Documents are of the essence of the Agreement. 12.3_ Where CONTRACTOR is prevented from completing any pan of the Work within the Contract Times (or Milestones) due to delay beyond the control of CONTRACTOR, the Contract Times (or Milestones) will be extended in an amount equal to time lost due to such delay if a claim is made therefor as provided in pa ph 12.1. Delays beyond the control of CORACTOR shall include, but not be limited to, acts or neglect by OWNER, acts or neglect of utility owners or other contractors performing other work as contemplated by Article 7, fires, floods, epidemics, abnormal weather conditions or acts of God. Delays attributable to and within the control of a Subcontractor or Supplier shall be deemed to be delays within the control of CONTRACTOR. 12.4. Where CONTRACTOR is prevented from completing any pan of the Work within the Contract Times (or Milestones) due to delay beyond the control of both OWNER and CONTRACTOR, an extension of the Contract Times (or Milestones) in an amount equal to the time last due to such delay shall be CONTRACTOR's sole and exclusive remedy for such delay. In no event shall OWNER be liable to CONTRACTOR, arty Subcontractor, any Supplier, any other person or organization, or to any surety for or employee or agent of an of them, for damages arising out of or resulting from i) delays caused by or within the control of the CONTRACTOR or (ii) delays beyond the control of both parties including, but not limited to, fires, floods, epidemics, abnormal weather conditions, acts of God or acts or negloct by utility owners or other contractors perform ing other work as contemplated by Article 7_ ARTICLE 13—TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIIiE W ORK 13.1, Notice ofDefeoxs• Prompt notice of all defective Work of which OWNER or ENGINEER have actual knowledge will be given to CONTRACTOR All defective Work may be rejected, corrected or accepted as provided in this Article 13, Access to Work• 13.2. OWNER ENGINEER, ENGINEER's Consultants, other representatives and personnel of OWNER, independent testing laboratories and governmental agencies with jurisdictional interests will have access to the Work at reasenable times for their observation, inspecting and testing. CONTRACTOR shall provide them proper and safe conditions for such access and advise them of CONTRACTOR's site safety procedures and programs so that they may comply therewith as applicable. Tests and Inspections 13.3. CONTRACTOR shall give ENGINEER timely notice of readiness of the Work for all required inspections, tests or approvals, and shall cooperate with inspection and testing personnel to facilitate required inspections or tests 13.4. OWNER shall employ and pay for the services of an independent testing laboratory to perform all mspectim& tests, or approvals required by the Contract Documents except: 13.4.1. for inspectiors, tests or approvals covered by paragraph 13.5 below; 13.4.1 that costs incurred in connection with tests or inspections conducted pursuant to paragraph 13.9 EICDC OENERAL CONDITIONS 191" (1990 Ex5tim) w/ C1TY OF FORT COL11M MODIFICATIONS (REV M_aDe) below shall be paid as provided in said paragraph 13.9; and 13.4.3. as otherwise specifically provided in the Contact Documents. 135. If Laws or Regulations of any public body having jurisdiction require any Work (or part thereof) specifically to be inspected tested or approved by an employee or other representative of such public body, CONTRACTOR shall assume full responsibility for arranging and obtaining such inspections, tests or approvals, pay all costs in connection therewith, and furnish ENGINEER the required certificates of inspcction or approval. CONTRACTOR stall also be responsible for atrmtging and obtaining and shall pay all costs in connection with any inspections, tests or approvals required for OWNER's and ENGINEER's acceptance of materials or equipment to be incorporated in the Work, or of materials, mix designs, or a pmcnt submitted for approval prior to CONTrCTOR's purchase thereof fa incorporation in the Work. 13.6, If any Work (or the work of others) that is to be inspected, tested or approved is covered by CONTRACTOR without written concurrence of ENGINEER, it must, if requested by ENGINEER, he uncovered for observation. 133' Uncovering Work as provided in paragraph 13.6 shall be at CONTRACTOR's expense unless CONTRACTOR has given ENGINEER timely notice of CONTRACTOR's intention to cover the same and ENGINEER has not acted with reasonable promptness in response to such notice. Uncovering Work: 13.8. If any Work is covered contray to the written request of ENGINEER, it must, if requested by ENGINEER, be uncovered for ENGINEER's observation and replaced at CONTRACTOR's expense. 13.9. If ENGINEER considers it necessary or advisable that covered Work be observed by ENGINEER or aa��ccled or tested by others, CONTRACTOR, at ENGINEF.R's request, shall uncover, expose or otherwise make available for observation, inspection or testing as 24GINEER may require, that portion of the Work in question, furnishing all necessary labor, material and equipment, If it is found that such Work is ekfecrrve, CONTRACTOR shall pay all claims, costs, losses and damages caused by, arising out of or resulting from such uncovering, expo=, observation, inspection and testing and of satisfactory replacement or reconstruction, (including but not limited to all costs of repair or replacement of work of others); and OWNER shall be entitled to an appropriate decrease in the Contract Rice, and, if the panics are unable to agree as to the amount thereof may make a claim therefor as provided in Article 11. If, however, such Work is not found to be &fective, CONTRACTOR shall be allowed an inarase in the Contract Price or an extension of the Contract Times (or Milestones), or both, directly attributable to such 27 uncovering exposure, observation, inspection, testing, replacement and reconstruction; arxi if the parties are unable to agree as to the amount or extent thereof, CONTRACTOR may make a claim therefor as provided in Articles 1 I and 12. OWNER May Stop the Work: 13.10. If the Work is defective, or CONTRACTOR fails to supply sufficient skilled workers or suitable materials or equipment, or fails to furnish or perform the Work in such a way that the completed Work will conform to the Contract Documents, OWNER may order CONTRACTOR to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of OWNER to stop the Work shall not give rise to any duty on the part of OWNER to exercise dus right for the benefit of CONTRACTOR or any surety or other parry. Correction or Removal of Defective Work., 13.11. If required by ENGINEER, CONTRACTOR shall promptly, as directed, either correct all defective Work, whether or not fabricated, installed or completed, or, if the Work has been rejected by ENGINEER, remove it from the site and replace it with Work that is not defective. CONTRACTOR shall pay all claims, torts, lasses and damage., caused by or resulting from such correction or removal (including but not limited to all costs of repair or replacement of work of others). IML Correction Period: 13.12.1. If within aria year two yeeats after the date of Substantial Completion or such longer period of time as may be prescribed by Laws or Regulations or by the terms of any applicable special guarantee required by the Contract Documents or by any specific provision of the Contract Documents, any Work is found to be defective, CONTRACTOR shall promptly, without cost to OWNER and in accordance with OWNER's written instructions: (i) correct such defective Work, or, if it has been rejected by OWNER, remove it from the site and replace it with Work that is not defective, and (ii) satisfactorily correct or remove and replace any damage to other Work or the work of others resulting therefrom. If CONTRACTOR does not promptly comply with the terms of such instructions, or in an emergency where delay would cause serious risk of loss or damage, OWNER may have the defective Work corrected or the rejected Work removed and replaced, and all claims, costs, losses and damages caused by or resulting from such removal and replacement (including but not limited to all costs of repair or replacement of work of others) will be paid by CONTRACTOR 13.122.In special circumstances where a particular item of equipment is placed in continuous service before Substantial Completion of all the Work, the correction period for that item may start to run from an earlier date if so provided in the Specifications or by Written Amendment. 13.12.3. Where defective Work (and damage to other EXVCGENERAL CONDITIONS 191" (1990 Editim) 28 wI CITY OFFORT COL11M MODIRCATIONS(REV4r1000) Work resulting therefrom) has been corrected, removed or replaced under this paragraph 13.12, the correction period hereunder with respect to such Work will be extended for an additional period of aria year two years after such correction or removal and replacement has been satisfactorily completed. Acceptance of Defective Work. 13.13. If, instead of requiring correction or removal and replacement of defective Work, OWNER (and, prior to ENGMEER's recommendation of final payment, also ENGINEER) }refers to accept it, OWNER may do so. CONTRACTOR shall pay all claims, costs, losses and damages attributable to OWNER's evaluation of and determination to accept such defective Work (such costs to be approved by ENGINEER as to reasonableness). If any such acceptance occurs prior to FN I ER's recommendation of final payment, a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work; and OWNER shall be entitled to an appropriate decrease in the Contract Rice, and, if the parties are unable to agree as to the amount thereof, OWNER may make a claim therefor as provided in Article 11. if the acceptance occurs after such recommendatiort an appropriate amount will be paid by CONTRACTOR to OWNER. OWNER May Correct Defee6ve Work: 13.14 If CONTRACTOR fails within a reasonable time after written notice from ENGINEER to correct defective Work or to remove and replace re�Jected Work as required by ENGINEER in accordance Z' paragraph 13.11, or if CONTRACTOR fails to perform the Work in accordance with the Contract Documents, or if CONTRACTOR fails to comply with any other provision of the Contract Documents, OWNER may, after seven days' written notice to CONTRACTOR, correct and remedy any such deficiency. In eicercis4 the rights and remedies under this paragraph OWNER shall proceed expeditiously. In connection with such corrective and remedial action, OWNER may exclude CONTRACTOR from all or part of the site, take possession of all or part of the Work, and suspend CONTRACIOR's services related thereto, take possession of CONTRACTOR's tools, appliances, construction equipment and machinery at the site and incorporate in the Work all materials and equipment stored at the site or for which OWNER has paid CONTRACTOR but which are stored elsewhere. CONTRACTOR shall allow OWNER, OWNERS representatives, agents and employees, OWNER's other contractors and ENGINEER and ENGINEER's Consultants access to the site to enable OWNER to exercise the ri�hls and remedies ureter this paragraph. All claims, coats, lotwes and damages incurred or sustained by OWNER in exercising such rights and remedies will be charged against CONTRACTOR and a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work; and OWNER shall be entitled to an appropriate decrease in the Contract Price, and, if the parties are unable to agree as to the amount thereof. OWNER may make a claim therefor as provided in Article 11. Such claims, cectn, losses and damages will include but not be limited to all costs of repair or replacement of work of others destroyed or damaged by currection removal or replacement of CONTRACTOR defective Work CONTRACTOR shall not be allowed an mention of the Contract Tunes (or Milestones) because of any delay in performance of the Work attributable to the exercise by OWNER of OWNER's rights and remedies hereunder. ARTICLE 14--PAY NfENTS TO CONTRACTOR AND COMPLETION Schedule of Malues. 14.1. The schedule of values established as provided in paragraph 2.9 will serve as the basis for progress payments and will be incorporated into a form of Application for Payment acceptable to ENGINEER. Progress payments on account of Unit Price Work will be based on the number of units completed. Afflicadon for Progress Payment 14.2. At least twenty days before the date established for each progress payment (but not more often than once a month), CONTRACTOR shall submit to ENGINEER for review an Application fur Payment filled out and signed by CONTRACTOR covering the Work completed as of the date of the Application and accompanied by such supporting documentation as is required by the Contact Documenm If payment is requested on the basis of materials and equipment not incorporated in the Work but delivered and suitably stored at the site or at another location agreed to in writing, the Application for Payment shallalso be accompaned by a bill of sale, invoice or other documentation warranting that OWNER has received the materials and equipment free and clear of all Liens and evidence that the materials and equipment are covered by appropriate property insurance and other arrangements to protect OWNER'S interest therein, all of which will be satisfactory to OWNER. The amount of retainagc with respect to progress payments will be as stipulated in the Agreement. Ari - funds that are withheld by the OWNER shall not be subject to substitution by the CONTRACTOR with securities n in aarrangments involvir e�vtrow or custodianslr}pp. By executing the application for payment form the CONTRACTOR expressly waives his rigt to the benefits of Colorado Revised Statutes Section 24- ]alb] et sett. CONTRACTOR s Warranty of Title. 14.3. CONTRACTOR warrants and guarantees that title to all Work, materials and equipment covered by any Application for Payment, whether Incorporated in the Project or not, will pass to OWNER no later than the time of payment free and clear of all Liens. Review of.4pplicafions for Progress Payment 14.4. ENGINEER will, within ten days after receipt of each Application for Payment, either indicate in writing a SrCDCOENUAL CONDITIONS lytoa (1990 E(Iticu) w/CITY OF FORT COLLINS MODIFICATIONS ftN 42000) recommendation of payment and pt'asmtt the Application to OWNER, or return the Application to CONTRACTOR indicating in writing ENGINEER's reasons for refusing to recommend payment. In the latter case, CONTRACTOR may make the necessary corrections and resubmit the zApplication. Ten days after presentation of the hcation for Payment to OWNER with ENGINEEIts recommendation the amount recommended will (subject to the provisions of the last sentence of paragraph 14.7) become due and when due will be paid by OWNER to CONTRACTOR 14.5. ENGINEER's recommendation of any payment requested in an Application for Payment will constitute a representation by ENGINEER to OWNER, based on ENGINEEWs on -site observations of the executed Work as an experienced and qualified design professional and on ENGINEFR'sreview of the Apppplication for Payment and the accompanying data and schedules, that to the best of ENGINEEWs knowledge, information and belief: 14.5.1. the Work has progressed to the point indicated., 14.5Z the quality of the Work is generally in accordance with the Contract Documents (subject to an evaluation of the Work as a functioning whole prior to or upon Substantial Completion, to the results of any subsequent tests called for in the Contact Documents, to a final determination of qquanuLim and classifications for Unit Price Wok under paragraph 9.10. and to any other qualifications stated in the recommendation), and 14.53, the conditions precedent to CONTRACTOR's being entitled to such payment appear to have been fulfilled insofar as it is ENGINEER's responsibility to observe the Work. However, by recommending any such payment ENGINEER will not thereby be deemed to have represented that: (i) exhaustive or continuous on -site inspections have been made to check the quality or the quantity of the Work beyond the responsibilities specifically assigned to INGEdEER in the Contact Documents or (ii) that there may not be other matters or issues between the parties that might entitle CONTRACTOR to be paid additionally by OWNER or entitle OWNER to withhold payment to CONTRACTOR FNGINEFR's recommendation of any payment, including final payment, shall not mean that ENGINEER is responsible for CONTRACTOR's means, methods, techniques, sequences or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of CONTRACTOR to comply with Laws and Regulations applicable to the famishing or performance of Work, or for any failure of CONTRACTOR to perform or furnish Work in accordance with. the Contract Documents. 14.7. ENGINEER may refine to recomnmend the whole or any part of any payment iL in ENGINEER's opinion it would be incorrect to make the representations to 29 OWNER referred to in paragraph 14.5. ENGINEER may also refuse to recommend any such payment, or, because of subsNuentiy discovered evidence or the results of subsequent inspections or tests, nullify any such payment previously recommended, to such extent as may be necessary in ENGiNEER's opinion to protect OWNER from loss because: 14.7.1. the Work is defecGre, or completed Work has been damaged requiring correction or replacemem, 14.7.2. the Contract Price has been reduced by Written Amendment or Charge Order, 14.7.3. OWNER has been required to correct defecme Work or complete Work in accordance with paragraph 13.14, or 14.7.4. ENGINEER has actual knowledge of the occurrence of any of the events cnumcrated in paragraphs 15.2.1 through 15.2.4 inclusive. OWNER may refuse to make payment of the full amount recommended by ENGINEER because: 14.7.5. claims have been made against OWNER on account of CONTRACTOR's performance or fumishirg of the Work, 14.7.6. Liens have been filed in connection with the Work, except where CONTRACTOR has delivered a specific Bond satisfactory to OWNER to see= the satisfaction and discharge of such Lime, 14.7.7. there are other items entitling OWNER to a sd- off against the amount recommended or 14.7.8. OWNER has actual knowledge of the occurrence of any of the events enumerated in paragraphs 14.7.1 through 14.7.3 or paragrapbs 15.2.1 through 15.2.4 inclusive, but OWNER must give CONTRACTOR immediate written notice (with a cgry to ENGINEER) stating the reasons for such action and promptly pay CONTRACTOR the amount so withheld, or any adjustment thereto agreed to by OWNER and CONTRACTOR when CONTRACTOR carrects to OWNM- 's sdisfaction the reasons for such action Sabman" completion: 14.8. When CONTRACTOR considers the entire Work ready for its intended use CONTRACTOR shall notify OWNER and ENGINEER in writing that the entire Work is substantially complete (except for items specifically listed by CONTRACTOR as incomplete) and request that ENGINEER issue a certificate of Substantial Completion. Within a reasonable time thc=ftcr, OWNER, CONTRACTOR and ENGINEER shall make an inspection of the Work to determine the status of completion. If ENGINEER does not consider the Work substantially complete, ENGINEER will notify CONTRACTOR in writing giving the reasons therefor. If ENGINEER EJCDC GENERAL CONDITIOM 1910-9 (1990 Emtim) 30 wtCITY OF FORT OOLLINS MODIFICATIONS(REV 42000) considers the Work substantially complete. ENGINEER will prepare and deliver to OWNER a tentative certificate of Substantial Completion which shall fix the date of Substantial Completion. There shall be attached to the certificate a tentative list of items to be completed or corrected before final payment OWNER shall have seven days after receipt of the tentative certificate during which to make written objection to ENGINEER as to any provisions of the certificate or attached list If, after considering such objections, ENGINEER concludes that the Work is not substantially complete, ENGINEER will within fourteen days after submission of the tentative certificate to OWNER notify CONTRACTOR in writing, stattrig the reasons therefor. I& after consideration of OWNER's objections, ENGINEER considers the Work substantially complete, ENGINEER will within said fourteen days execute and deliver to OWNER and CONTRACTOR a definitive certificate of Substantial Completion (with a revised tentative list of items to be completed or corrected) reflecting such changes from the tentative certificate as ENGINEER believes justified after consideration of any objections from OWNER. At the time of delivery of the tentative certificate of Substantial Completion ENGINEER will deliver to OWNER and CONTRACTOR a written recommendation as to division of responsibilities pending final payment between OWNER and CONTRACTOR with respect to security, operation safety, maintenance, heat, utilities, insurance and warranties and guarantees. Unless OWNER and CONTRACTOR agree otherwise in writing and so inform ENGINEER in writing prior to ENGiNEER's issuing the definitive certificate of Substantial Completion, ENGINEER'S aforesaid recommendation will be binding on OWNER and CONTRACTOR until final payment 14.9. OWNER shall have the right to exclude CONTRACTOR from the Wok after the date of Substantial Completion, but OWNER shall allow CONTRACTOR reasonable access to complete or correct items on the tentative list Partial Uli&urdon: 14.10. Use by OWNER at OWNER's option of any substantially completed pan of the Work, which: (i) has specifically been identified in the Contract Documents, or (d)OWNER, ENGINEER and CONTRACTOR agree conditutes a separately functioning and usable part of the Work that can be used by OWNER for its intended purpose without significant interference with CONTRACTOR's performance of the remainder of the Work, may be accomplished prior to Substantial Completion of all the Work subject to the following: 14.10.1.OWNER at any time may request CONTRACTOR in writing to permit OWNER to use any such part of the Work which OWNER believes to be ready for its intended use and substantially coonppfete. if CONTRACTOR agrees that sudi pan of the Vold is substantially complete, CONTRACTOR will certify to OWNER and ENGINEER that such part of the Work is substantially complete and request ENGINEER to issue a certificate of Substantial Completion for that part of the Work, CONTRACTOR at any time may notify OWNER and ENGINEER in writing that CONTRACTOR considers any such part of the Work ready for its intended use and substantially complete and request ENGINEER to issue a certificate of Substantial Completion for that part of the Work. Within a reasonable time after either such request, OWNER, CONTRACTOR and ENGINEER shall make an inspection of that pari of the Work to determine its status of completion If ENGINEER does not consider that part of the Work to be substantially complete, ENGINEER will notify OWNER and CONTRACTOR in writing giving the reasons therefor If ENGINEER considers that part of the Wok to be substantially complete, the provisions of paragraphs 14.8 and 14.9 will apply with respect to ccrtificrtion of Substantial Completion of that part of the Work and the division of responsibility in respect thereof and access thereto. 14.10.2. No occupancy, or separate operation of part of the Work will be accomplished prior to compliance with the requirements of paragraph 5.15 in respect of property insurance. Final Inspection: 14.11. Upon written notice from CONTRACTOR that the entire Work or an agreed portion thereof is complete, ENGINEER will make a final inspection with OWNER and CONTRACTOR and will ratify CONTRACTOR in writing of all particulars in which this inspection reveals that the Work is incomplete or defective. CONTRACTOR. shall immediately take such measures as are necessary to complete such work or rem edy such deficiencies Final Application for Payment. 14.12. After CONTRACTOR has completed all such corrections to the satisfaction of ENGINEER and delivered in accordance with the Contract Documents all maintenance and operating instructions, schedules, guarantees, Bones, certificates or other evidence of insurance required by paragraph 5.4, certificates of inspection, marked -up record documents (as provided in pamgraph6.19) and other documents, CONTRACTOR may make application for final payment following the procedure for progress payments. The final Application for Payment shall be accompanied (except as previously delivered) by: (i) all documentation called for in the Contract Documents, including but not limited to die evidence of insurance required by subpamgraph5A 13, (u)consent of the surety, if any, to final payment, and (iii) complete and legally effective releases or waivers (satisfactory to OWNER) of all Liens arising out of or filed in connection with the Work In lieu of such releases or waivers of Liens and as approved by OWNER, CONTRACTOR may furnish receipts or releases in full and affidavit of CONTRACTOR that: (i) the releases and receipts include all labor, services, material and equipment for which a Lien could be filed, and (i) all payrolls, material and equipment bills, and other indebtedness connoded with the Work for which OWNER or OWNER's property might in any way be responsible have been paid or otherwise satisfied If any Subcontractor or Supplier fails E)cDc 004B L CONXTIOM 191" (I"o B itku) wlCITY OF FORT COLUM MODIFICATIONS (PRV 42000) to furnish such a release or receipt in full, CONTRACTOR may haaish a Bond or other collateral satisfactory to OWNER to indemnify OWNER against any Lien Releases or waivers of liens and the consent of the surety to finalize p_oyinem are to be submitted on forms conform ing to the format of the O WNF.R'S standard forms bound in th„ a PrQkct manual Final Payment and Acceptance: 14.13. If, on the basis of rNGINEER's observation of the Work during construction and final inspection, and ENGINEER's review of the final Application for Payment and accompanying documentation as required by the Contract Documents, ENGINEER is satisfied that the Work has been completed and CONTRACTOR's other obligations under the Contract Documents have been fulfilled, ENGiNNEER will, within ten days after receipt of the final Application for Payment, indicate in writing ENGINEER's recommendation of payment and present the Application to OWNER for payment. At the same time ENGINEER will also give written notice to OWNER and CONTRACTOR that the Work is acceptable subject to the provisions of paragraph 14.15. Otherwise, ENGINEER will return the Application to CONTRACTOR, indicating in writing the reasons for refusing to recommend final payment, in which case CONTRACTOR shall make the necessary corrections and resubmit the Application. Thirty days after presentation to OWNER of the Application and acaimpranying documentation, in appropriate form and substance and with ENGINEER's recommendation and notice of acceptability, the amount recommended by ENGINEER will become due and will be paid by OWNER to CONTRACTOR suhiect to paragraph 176.2 of those Tely ILCon"t a5 14.14 If: through no fault of CONTRACTOR final completion of the Work is significamly delayed anti if ENGINEER so confirms, OWNER shall, upon receipt of CONTRACTOR's final Application for Payment and recommendation of ENGINEER, and without terminating the Agreement, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance to be held by OWNER for Work no fully completed or corrected is less than the retainage stipulated in the Agreement, and if Bonds have been furnished as required in paragraph 5.1. the written consent of the surety to the payment of the balance clue for that portion of the Work fully completed and accepted shall be submitted by CONTRACTOR to ENGINEER with the Application for such poyment Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of claims Waiver of Claims: 14.15. The making amp acceptance of final payment will constitute; 14.15.1. a waiver of all claims by OWNER against CONTRACTOR except claims arising from unsettled Liens, from defective Work appearing after 31 final inspection pursuant to paragraph 14.11, from failure to comply with the Contract Documents or the terms of aarrtyry special guarantees specified therein, or from CONTRACTOR's continuing obligations under the Contract Documents; and 14.15.2. A waiver of all claims by CONTRACTOR against OWNER other than those previously made in writing and still unsettled. ARTICLE 15-SUSPENSION OF WORK AND TERMINATION OWNER May Suspend Work: 15.1. At any time and without cause, OWNER may suspend the Work or any portion thereof for a period of not more than ninety days by notice in writing to CONTRACTOR and ENGINEER which will fix the date on which Work will be resumed. CONTRACTOR shall resume the Work on the date so fund CONTRACTOR shall be allowed an adjustment in the Contract Price or an cdcrrmon of the Contract Times, or both directly attributable to any such suspension if CONTRACTOR makes an approved claim therefor as provided in Articles 11 and 12. OWNER May Terminate: 15.2. Upon the occurrence of any one or more of the following events: 15.2.1. if CONTRACTOR persistently fads to perform the Work in accordance with the Contract Documents (including but not limited to, failure to supply sufficient skilled workers or suitable materials or equipment or failure to adhere to the progress schedule established under paragmpb2.9 as adjusted from time to time pursuant to paragraph 6.6); 15.2.2, if CONTRACTOR disregards Laws or Regulations of any public body having jurisdiction; 15.23, if CONTRACTOR disregards the authority of ENGINEER; or 15.2.4. if CONTRACTOR otherwise violates in any substantial way any provisions of the Contract Documents; OWNER may, after giving CONTRACTOR (and the surety, if any) seven days written notice and to the extent permitted by Laws and Regulations, terminate the services of CONTRACTOR exclude CONTRACTOR Goo the site and take possession of the Work and of all CONTRACTOR's tools, appliances, construction equipment and machinery at the site and use the same to the full extent they could be used by CONTRACTOR (without liability to CONTRACTOR for trcs)tass or conversion), incorporate in the Work all materials and equipment stored at the site or for which OWNER has paid VCDC GENEK01 COMTlora 1910-8 (1990 E&M) 32 col CITY OF FORT COLLINS MODIFICATIONS OLEV 42000) CONTRACTOR but which are stored elsewhere, and finish the Work as OWNER may deem expedient In such case CONTRACTOR shall not be entitled to receive any further payment until the Work is finished If the unpaid balance of the Contract Price exceeds all claims, cc" losses and damages sustained by OWNER arising out of or resulting from completing the Work such excess will be paid to CONTRACTOR If such claims, costs, lasses and damages exceed such unpaid balance, CONTRACTOR shall pay the difference to OWNER. Such claims, costs, losses and damages incurred by OWNER will be reviewed by ENGINEER as to their reasonableness and when so approved by ENGINEER incorporated in a Change Order, provided that when exercising any rights or remedies under this paragaph OWNER shall not be required to obtain the lowest price for the Work perforated 15.3. Where CONTRACTOR's services have Ixeen sn terminated by OWNER, the termination will not affect any rights or remedies of OWNER against CONTRACTOR then existing or which may thereafter accrue. Any retention or payment of moneys due CONTRACTOR by OWNER will not release CONTRACTOR from liability. 15.4. upon seven days' written notice to CONTRACTOR and ENGINEER, OWNER may, without cause and without prejudice to any other right or remedy of OWNER, elect to terminate the Agreement. In such case, CONTRACTOR shall be paid (without duplication of any items): 15.4.1, for completed and acceptable Work executed in accordance with the Contract Documents prior to the effective date of termination, including fair and reasorable sums for overhead and profit on such Work; 15.4.2. for expenses sustained prior to the effective date of termination in performing services and furnishing labor, materials or equipment as required by the Contract Documents in connection with uncompleted Work, plus fair and reasonable sums for overhead and profit on such expenses; 15.4.3. for all claims, costs, losses and damages insured in settlement of terminated contracts with Subcontractors• Suppliers and others; and 15.4.4. for reasonable expenses directly attributable to termination. CONTRACTOR shall not be paid on account of loss of anticipated profits or revenue or other economic loss arising out of or resulting from such termination. CONTRACTOR May Map Work or Terminate: 153. IC thtrout lhno actor fault of CONTRACTOR, the Work is suspendrd for a period of more than ninety days by OWNER or under an order of court or other public authority, or ENGINEER fails to act on any Application for Payment within thirty days after it is submitted or OWNER fails for thirty days to pay CONTRACTOR any SECTION 00520 AGREEMENT THIS AGREEMENT is dated as of the gth day of February in the year of 2015 and shall be effective on the date this AGREEMENT is signed by the City. The City of Fort Collins (hereinafter called OWNER) and Northstar Concrete Inc (hereinafter called CONTRACTOR) OWNER and CONTRACTOR, in consideration of the mutual covenants hereinafter set forth, agree as follows: ARTICLE 1. AGREEMENT RENEWAL AND WORK 1.1 Renewal. This Agreement is a renewal of the Agreement entered into between the parties on the 28T" day of May, 2013, entitled Concrete Maintenance Project —Phase II, Bid No. 7509. CONTRACTOR shall complete all Work as specified or indicated in the Contract Documents. The Project for which the Work under the Contract Documents may be the whole or only a part is defined as the construction of the 7509 Concrete Maintenance Project Phase II — 2015 Renewal. ARTICLE 2. ENGINEER The Project has been designed by the City of Fort Collins Streets Department, who is hereinafter called ENGINEER and who will assume all duties and responsibilities and will have the rights and authority assigned to.ENGINEER in the Contract Documents in connection with completion of the Work in accordance with the Contract Documents. ARTICLE 3. CONTRACT TIMES 3.1 Contract Period. This agreement shall commence upon signing and shall continue in full force until March 1, 2016 unless terminated as herein provided. In addition at the option of the City, the agreement may be extended for additional one (1) year period not to exceed two (2) additional one (1) year periods. Pricing changes, if any, shall be negotiated by and agreed to by both parties in writing. 3.2 The Work shall be Substantially Complete within one hundred forty (140) calendar days after the date when the Contract Times commence to run as provided in the General Conditions and completed and ready for Final Payment and Acceptance in accordance with the General Conditions within forty-five (45) calendar days after the date when the Contract Times commence to run. 3.3. Liquidated Damages. OWNER and CONTRACTOR recognize that time is of the essence of this Agreement and that OWNER will suffer financial loss if the Work is not completed within the times specified in paragraph 3.1. above, plus any extensions thereof allowed in accordance with Article 12 of the General Conditions. sum finally determined to be due, then CONTRACTOR may, upon seven days' written notice to OWNER and ENGINEER, and provided OWNER or ENGINEER do not remedy such suspension or failure within that time, terminate the Agreement and recover from OWNER payment on the same terms as provided in paragraph 15.4. n lieu of terminating the Agreement and without prejudice to any other right or remedy, if ENGINEER has failed to act on an Application for Payment within thirty days after it is submitted, or OWNER has failed for thirty days to pay CONTRACTOR any sum finally determined to be due, CONTRACTOR may upon seven days' written notice to OWNER and ENGINEER s[ the Work until payment of all such amounts due CONTRACTOR. inclut ui i interest thereon. The provisions of this paragraph 15.5 are not intended to preclude CONTRACTOR from making claim under Articles 1 I and 12 for an increase in Contract Price or Contract Times or otherwise for expenses or damage directly attributable to CONTRACTOR's stopping Work as pmmitW by this paragraph. ARTICLE 16—DISPUTE RESOLUTION if and to the extent that OWNER and CONTRACTOR have agreed on the method and procedure for resolving disputes between them that may arise under this Agreement, such dispute resolution method and procedure, if any, shall be as set forth in ExhibitOC-A, "Dispute Resolution Agreement", to be attached hereto and made a part hereof. If no such agreement on the method and procedure for resolving such disputes has been reached, and subject to the provisions of paragraphs9.10, 9.11 and 9.12, OWNER and CONTRACTOR may exercise such rights or remedies as either may otherwise have under the Contract Documents or by Laws or Regulations in respect of any dispute. ARTICLE 17—NIISCELLANEOUS Ghing Notice: 17.1. Whenever any provision of the Contract Documents requires the giving of written notice, it will be deemed to have been validly given if delivered in person to the individual or to a member of the from, or to an officer of the corporation for whom it is intended, or if delivered at or sent by registered or certified mail, postage prepaid, to the last business address known to the giver of the notice. 17.2. Computation of Time: 17.2.1. When any period of time is referred to in the Contract Documents by days, it will be computed to exclude the first and include the last day of such period If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction. such day will be omitted from the computation. EJCDC GENERAL COMMONS 191" 099Q EC16M) w/(I TY OF FORT COLLIMS MODIFICATIONS (REV 42000) 17.22. A calendar clay of twenty-four hours measured from midnight to the next midnight will comtitute a day. Notice of Claim: 17.3. Should OWNER or CONTRACTOR suffer injury or damage to person or property because of any error, omission or act of the other party or of any of the other party's employees or agents or others for whose acts the other party is legally liable, claim will be made in writing to the other party within a reasonable time of the. first observance of such injury or damage. The provisions of this paragraph 17.3 shall not be construed as a substitute for or a waiver of the provisions of any applicable statute of limitations or repose.Cuntulatn a Remedies: 17.4. The duties and obligations imposed by these General Conditions and the rights and remedies available hereunder to the parties hereto, and, in particular but without limitation, the warranties, guarantees and obligations imposed upon CONTRACTOR by paragmphs 6.12, 6.16, 6.30, 6.31, 6.32,13.1,13.12, 13.14, 14.3 and 15.2 and all of the rights and remedies available to OWNER and ENGINEER thereunder, are in addition to, and are not to be construed in any way as a limitation of, any rights and remedies available to any or all of them which are otherwise imposed or available by Laws or Regulations by special warranty or guarantee or by other provisions of the Contract Documents„ and the provisions of this paragraph will be as effective as if repeated specifically in the Contract Documents in connection with each particular duty, obligation right and remedy to which they apply. Professional Fees and Court Costs Inclueled• 17.5. Whenever reference is made to "claims, costs, losses and damages°, it shall include in each case, but not be limited to, all fees and charges of engineers, architects, attorneys and other professionals and all court or arbitration or other dispute resolution costs. 1Z<�—The taws of the State of Colorado,�gpjy_>�� Aerelsnent Reference to two pertinent Colorado statutes are as follows 17.6.2, If a claim is filet OWNER is required by law (CRS 38 26-107) to withhold from all payments to CONTRACTOR sufficient funds to insure the payment of all claims for labor, material4 team hire, sustenance. provisionm trovender or other supplies used er consumed by CONTRACTOR or his 33 EXDcGDr coNDITIOs1910$(1990E&kn) 34 WICITY of FORT OOLLI s MOMICAnoHs (REV 4n000) (This page left blank intentionally.) EICDC GENERAL CONDITIONS 19108 (1990 EChtim) 35 W CITY Of FORT COLLINS MODIFICATIONS (REV 4I2000) EJCDC OHNHRAL CONDITIONS 1910-5 (1990 HditiaU 36 WiCITY OFFORT COLLINS MODIFICATIONS M-V4n000> EXHIBIT GC -A to General Conditions of the Construction Contract Between OWNER and CONTRACTOR DISPUTE RESOLUTION AGREEMENT OWNER and CONTRACTOR hereby agree that Article 16 of the General Conditions of the Construction Contract between OWNER and CONTRACTOR is amended to include the following agreement of the parties: 16.1. All claims, disputes and otter matters in question between OWNER and CONTRACTOR arising out of or relating to the Contract Documents or the breach thereof (except for claims which have been waived by the making or acceptance of final payment as provided by paragraph 1415) will be decided by arbitration v1 accordance with the Ccristruction Industry Arbitration Rules of the American Arbitration Association then obtairiM subject to the limitations of the Article I& This agreement so to arbitrate and any other agreement or consent to arbitrate entered into in accordance herewith as provided in this Article 16 will be specifically enforceable under the prevailing law of any court having jurisdiction. 16.2. No demand for arbitration of any claim, dispute or other matter that is required to be referred to ENGINEER initially for decision in accordance with paragraph 9.11 will be made until the earlier of (a) the date on which ENGINEER has rendered a written decision or (b) the thirty -fist day after the parties have presented their evidence to ENGINEER if a written decision has not been rendered by ENGINEER before that date. No demand for arbitration of any such claim, dispute or other matter will be made later than thirty days after the date on which ENGINEER has rendered a written decision in respect thereof in accordance with paragraph 9.11; and the failure to demand arbitration within said thirty days' period will result in ENGINEL^R's decision being final and binding upon OWNER and CONTRACTOR If ENGINEER renders a decision after arbitration proceedings have been initiated, such decision may be entered as evidence but will not supersede the arbitration proceedings, except where the decision is acceptable to the parties concerned. No demand for arbitration of any written decision of ENGINEER rendered in accordance with paragraph 9.10 will be made later than ten days after the party making such demand has delivered written notice of intention to appeal as provided in paragraph 9.10. 16.3. Notice of the demand for arbitration will be filed in writing with the other party to the Agreement and with the American Arbitration Association, and a copy will be sent to ENGINEER for information. The demand for arbitration will be made within the thirty -day or ten day period specified in paragraph 16.2 as applicable, and in all other cases within a reasonable time after the claim, dispute or other matter in question has arisen, and in no event shall any such demand be made after the date when institution of legal or equitable proceedings based on such claim, dispute or other matter in question would be barred by the applicable statute of limitations. FJCDC GENERAL CONDIAONS 191M (1990 Mum) w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9/99) 16.4. Except as provided in paragraph 16.5 below, no arbitration arising out of or relating to the Contract Documents shall include by consolidation, joinder or in any other manner any other person or entity (including ENGINEER, ENGINEER's Consultant and the officers, directors, agents, employees or consultants of any of them) Who is not a party to this contract unless: 16.4.1. the inclusion of such other person or entity is necessary if complete relief is to be afforded among those who am already parties to the arbitration, and 16.4.2. such other person or entity is substantially involved in a question of law or fact which is common to those who are already parties to the arbitration and which will arise in such proceedings, and 16.4.1 the written consent of the other person or entity sought to be included and of OWNER and CONTRACTOR has been obtained for such inclusion, which consent shall make specific reference to this paragraph; but no such consent shall constitute consent to arbitration of any dispute not specifically described in such consent or to arbitration with any party not specifically identified in such consent. 16.5. Notwithstanding paragraph 16.4, if a claim, dispute or other matter in question between OWNER and CONTRACTOR involves the Work of a Subcontractor, either OWNER or CONTRACTOR may join such Subcontractor as a party to the arbitration between OWNER and CONTRACTOR hereunder. CONTRACTOR shall include in all subcontracts required by paragraph 6.11 a specific provision whereby the Subcontractor consents to being joined in an arbitration between OWNER and CONTRACTOR involving the Work of such Subcontractor, Nothing in this paragraph 16.5 nor in the provision of such subcontract consenting to joinder shall create any claim, right or cause of action in favor of Subcontractor and against OWNER ENGINEER or ENGINEER's Consultants that does not otherwise exist. 16.6. The award rendered by the arbitrators will be final, judgment may be entered upon it in any court having jurisdiction thereoC and it will not be subject to modification or appeal. 16.7. OWNER and CONTRACTOR agree that they shall first submit any and all unsettled claims, counterclaims, disputes and other matters in question between them arising out of or relating to the Contract Documents or the breach thereof ("disputes"), to mediation by the American Arbitration Association under the Construction Industry Mediation Rules of the American Arbitration Association prior to either of them imitating against the otter a demand for arbitration pursuant to paragraphs 16.1 through 16.6, unless delay in initiating arbitration would irrevocably prejudice one of the parties. The respective thirty and ten day time limits within which to File a demand for arbitration as provided in paragraphs 16.2 and 16.3 above shall be suspended with respect to a dispute submitted to mediation within those same applicable time limits and shall remain suspended until ten days after the termination of the mediation. The mediator of any dispute submitted to mediation trader this Agreement shall not serve as arbitrator of such dispute unless otherwise agreed GC -Al E)CDC GENERAL CONDITIONS 1910-8 (1990 E(i6m) GC•AI a/ CITY OF FORT COLLINS MODIFICATIONS (REV 9/94) SECTION 00800 SUPPLEMENTARY CONDITIONS SECTION 00800 SUPPLEMENTARY CONDITIONS Conditions of the Contract These Supplementary Conditions amend or supplement the General Conditions of the Construction Contract (EJCDC General Conditions 1910-8, 1990 edition with City of Fort Collins modifications) and other provisions of the Contract Documents as indicated below. SC-5.4.8 Limits of Liability A. Add the following language at the end of paragraph 5.4.8. The limits of liability for the insurance required by the paragraph numbers of the General Conditions listed below are as follows: 5.4.1 and 5.4.2 Coverage A - Statutory Limits Coverage B - $100,000/$100,000/$500,000 5.4.3 and 5.4.5 Commercial General Liability policy will have limits of $1,000,000 combined single limits (CSL). This policy will include coverage for Explosion, Collapse, and Underground coverage unless waived by the Owner. 5.4.6 The Comprehensive Automobile Liability Insurance policy will have limits of $1,000,000 combined single limits (CSL). 5.4.9 This policy will include completed operations coverage/product liability coverage with limits of $1,000,000 combined single limits (CSL). SC-12.3 Add the following language to the end of paragraph 12.3. Contractor will include in the project schedule zero 0 days lost due to abnormal weather conditions. SECTION 00900 ADDENDA, MODIFICATIONS AND PAYMENT 00950 Contract Change Order 00960 Application for Payment SECTION 00950 CHANGE ORDER NO. PROJECT TITLE: Concrete Maintenance Project Phase II — 2015 Renewal CONTRACTOR: Northstar Concrete Inc PROJECT NUMBER: 7509 DESCRIPTION: 1. Reason for change: 2. Description of Change: 3. Change in Contract Cost: 4. Change in Contract Time: ORIGINAL CONTRACT COST $ .00 TOTAL APPROVED CHANGE ORDER .00 TOTAL PENDING CHANGE ORDER .00 TOTAL THIS CHANGE ORDER .00 TOTAL % OF THIS CHANGE ORDER % TOTAL C.O.% OF ORIGNINAL CONTRACT % ADJUSTED CONTRACT COST $ .00 (Assuming all change orders approved) ACCEPTED BY: DATE: Contractor's Representative ACCEPTED BY: DATE: Project Manager REVIEWED BY: DATE: Title: APPROVED BY: DATE: Title: APPROVED BY: DATE: cc: City Clerk Contractor Project File Architect Engineer Purchasing They also recognize the delays, expenses and difficulties involved in proving in a legal preceding the actual loss suffered by OWNER if the Work is not completed on time. Accordingly, instead of requiring any such proof, OWNER and CONTRACTOR agree that as Liquidated damages for delay (but not as penalty) CONTRACTOR shall pay OWNER the amounts set forth hereafter. 1) Substantial Completion: One Thousand Dollars ($1,000.00) for each calendar day or fraction thereof that expires after the one hundred forty (140) calendar day period for Substantial Completion of the Work until the Work is Substantially Complete. 2) Final Acceptance: After Substantial Completion, Five Hundred Dollars ($500.00) for each calendar day or fraction thereof that expires after the forty-five (45) calendar day period for Final Payment and Acceptance until the Work is ready for Final Payment and Acceptance. ARTICLE 4. CONTRACT PRICE 4.1 OWNER shall pay CONTRACTOR for performance of the Work in accordance with the Contract Documents in current funds as follows: One Million Seven Hundred Eleven Thousand Two Hundred Fifty -Seven Dollars and Twenty Cents ($1,711,257.20), in accordance with Section 00300, attached and incorporated herein by this reference. ARTICLE 5. PAYMENT PROCEDURES CONTRACTOR shall submit Applications for Payment in accordance with Article 14 of the General Conditions. Applications for Payment will be processed by ENGINEER as provided in the General Conditions. 5.1. PROGRESS PAYMENTS. OWNER shall make progress payments on account of the Contract Price on the basis of CONTRACTOR's Application for Payment as recommended by ENGINEER, once each month during construction as provided below. All progress payments will be on the basis of the progress of the Work measured by the schedule of values established in paragraph 2.6 of the General Conditions and in the case of Unit Price Work based on the number of units completed, and in accordance with the General Requirements concerning Unit Price Work. 5.1.1. Prior to Substantial Completion, Owner will be entitled to withhold as contract retainage five percent (5%) of each progress payment, but, in each case, less the aggregate of payments previously made and less such amounts as ENGINEER shall determine, or OWNER may withhold, in accordance with paragraph 14.7 of the General Conditions. If, in the sole discretion of Owner, on recommendation of Engineer, Owner determines that the character and progress of the Work have been satisfactory to OWNER and ENGINEER, OWNER may determine that as long as the character and progress of the Work remain satisfactory to them, there will be no additional retainage on account of Work completed in which case the remaining progress payments prior to Substantial Completion will be in an Section 00960 APPLICATION FOR PAYMENT PAGE 1 OF 4 OWNER: City of Fort Collins PROJECT: APPLICATION NUMBER: APPLICATION DATE: PERIOD BEGINNING: ENGINEER: CONTRACTOR: PERIOD ENDING: PROJECT NUMBER: CHANGE ORDERS Application is made for Payment as shown below in connection with Contract The present status of the account for this Contract is as NUMBER DATE AMOUNT follows: 1 2 Original Contract Amount: 3 Net Change by Change Order: Current contract Amount: $0.00 Total Completed and Stored to Date: Less Previous Applications: Amount Due this Application - Before Retainage: $0.00 Less Retainage: Net Change by Change Order $0.00 AMOUNT DUE THIS APPLICATION: $0.00 CERTIFICATION: The undersigned CONTRACTOR certifies that all obligations of CONTRACTOR incurred in connection with the Work have been satisfied as required in Paragraph 14.3. of the General Conditions of the Contract. The above Amount Due This Application is requested by the CONTRACTOR. Date: By: Payment of the above Amount Due This Application is recommended by the ENGINEER. Date: By: Payment of the above Amount Due This Application has been reviewed by the OWNER'S Project Manager. Date: By: Payment of the above Amount Due This Application is approved by the OWNER. Date: APPLICATION FOR CONTRACT AMOUNTS PAYMENT PAGE 2 OF 4 Work Work Work Completed Completed Completed Stored This Previous To Bid Month Periods Date Materials Total Item This Earned Percent Unit To Number Description Quantity Units Price Amount Qty. Amount Qty. Amount Qty. Amount Period Date Billed $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 TOTALS $0.00 $0.00 $0.00 $0.00 $0.00 CHANGE ORDERS APPLICATION FOR PAYMENT PAGE 3 OF 4 Work Work Work Completed Completed Completed Stored This Previous To Bid Month Periods Date Materials Total Item This Earned Percent Unit To Number Description Quantity Units Price Amount Qty. Amount Qty. Amount Qty. Amount Period Date Billed $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 TOTALS CHANGE ORDERS $0.00 $0.00 $0.00 $0.00 $0.00 PROJECT TOTALS $0.00 $0.00 $0.00 $0.00 $0.00 No Text 2015 CONCRETE MAINTENANCE PROJECT — PHASE I GENERAL REQUIREMENTS INDEX SECTION 01010 Summaryof Work 01040 Coordination 01310 Construction Schedules 01330 Survey Data 01340 Shop Drawings 01410 Testing 01510 Temporary Utilities 01560 Temporary Controls 01700 Contract Closeout 01800 Method of Measurement and Basis of Payment PAGE NUMBERS General Requirements 2-3 General Requirements 4-5 General Requirements 6-7 General Requirements 8 General Requirements 9-11 General Requirements 12-13 General Requirements 14 General Requirements 15-16 General Requirements 17 General Requirements 18 SECTION 01010 SUMMARY OF WORK 1.1 DESCRIPTION OF WORK This work shall consist of the removal and/or installation of concrete curbs, gutters, sidewalks, crosspans, aprons, drive approaches, inlets, concrete pavement, and pedestrian access ramps and placement of temporary asphalt patching adjacent to new concrete on designated streets in the City of Fort Collins. Specific locations are described in Section 3500, Project Map. A. Protection and Restoration. 1. Replace to equal or better conditions all items removed and replaced or damaged during construction. Restore all areas disturbed to match surrounding surface conditions. Also see tree protection standards. B. Construction Hours 1. Construction hours, except for emergencies, shall be limited to 7:00 a.m. to 6:00 p.m., Monday through Friday, unless otherwise authorized in writing by the Engineer. After hour equipment operation shall be in accordance with Section 1560. 2. Any work performed by the Contractor outside of the construction hours, whether or not authorized by the Engineer, shall entitle the Owner to deduct from compensation due to the Contractor sufficient funds to cover the Owner's costs in providing field engineering and/or inspection services because of such work. The cost for field engineering and inspection shall be $50.00 per hour. 1.2 NOTICES TO PRIVATE OWNERS AND AUTHORITIES A. Notify private owners of adjacent property, utilities, irrigation canal, and affected governmental agencies when prosecution of the Work may affect them. B. Give notification 48 hours in advance to enable affected persons to provide for their needs when it is necessary to temporarily deny access or services. C. Contact utilities at least 48 hours prior excavating near underground utilities. D. Contact all agencies at least 72 hours prior to start of construction. Notify all agencies of the proposed scope of work schedule and any items which would affect their daily operation. E. Darren Moritz/Tom Knostman will be the Program Manager/Project Engineer Darren Moritz 970-221-6618 Office 970-556-1495 cell Tom Knostman 970-221-6576 Office 970-679-7947 cell F. Names and telephone numbers of affected agencies and utilities in the area are listed below for Contractor's convenience. General Requirements - Page 2 of 18 SECTION 01010 SUMMARY OF WORK UTILITIES Water: City of Fort Collins, Colorado 221-6700, Meter Shop 221-6759 Storm Sewer: City of Fort Collins, Colorado 221-6700 Sanitary Sewer: City of Fort Collins, Colorado 221-6700 Electrical: City of Fort Collins, Colorado 221-6700 Gas: Xcel Energy Emergency 1-800-895-2999 Local Contact: Pat Kreager 970-566-4416 Telephone: UNCC / 1-800-922-1987 Local Contact: Debbie Kautz 970-689-0635 Traffic Operations: City of Ft. Collins, Colorado 221-6630 Cable Television: Comcast 493-7400 *Utility Notification Center of Colorado (UNCC) - 811 1-800-922-1987 AGENCIES Safety: Larimer County Sheriffs Department: Non -Emergency: 221-7177 Occupational Safety and Health Administration (OSHA): 844-3061 Fire: Poudre Fire Authority Poudre Valley Hospital Emergency: 911 Non -Emergency: 221-6581 Non -Emergency: 484-1227 Police: City of Fort Collins Police Department Non -Emergency: 221-6540 Emergency: 911 Postmaster: US Postal Service: 225-4111 Transportation: Transfort: 221-6620 Traffic Engineering: 221-6630 END OF SECTION General Requirements — page 3 of 18 SECTION 01040 COORDINATION 1.1 GENERAL CONTRACTOR RESPONSIBILITIES A. Coordinate operations under contract in a manner which will facilitate progress of the Work. The Contractor shall also coordinate with the Landscape Contractor whose Work is separate from the General Contractor' s contract. B. Conform to the requirements of public utilities and concerned public agencies in respect to the timing and manner of performance of operations which affect the service of such utilities, agencies, or public safety. C. Coordinate operations under contract with utility work to allow for efficient completion of the Work. D. Coordinate all operations with the adjoining property owners, business owners, and surrounding neighborhoods to provide satisfactory access at all times and keep them informed at all times. E. The Contractor shall ensure that Subcontractors shall have visible company names on all vehicles that enter the work zone. 1.2 CONFERENCES A. A Pre -construction Conference will be held prior to the start of construction. 1. Contractor shall participate in the conference accompanied by all major Subcontractors, including the Traffic Control Supervisor assigned to the project. 2. Contractor shall designate/introduce Superintendent, and major Subcontractors' supervisors assigned to project. 3. The Engineer shall invite all utility companies involved. 4. The Utilities will be asked to designate their coordination person, provide utility plans, and their anticipated schedules. 5. The Engineer shall introduce the Project Representatives. B. Additional project coordination conferences will be held prior to start of construction for coordination of the Work, refining project schedules, and utility coordination. C. Engineer may hold coordination conferences to be attended by all involved when Contractor's operations affects, or is affected by, the work of others. 1. Contractor shall participate in such conferences accompanied by Subcontractors as required by the Engineer. 1.3 PROGRESS MEETINGS A. Contractor and Engineer shall schedule and hold regular progress meetings at least weekly and at other times as requested by the Engineer or required by the progress of the Work. B. Attendance shall include: 1. Contractor and Superintendent. 2. Owner's Representatives. 3. Engineer and Project Representative. 4. Traffic Control Supervisor 5. Others as may be requested by Contractor, Engineer or Owner. Geneml Requirements— page 4 of 18 SECTION 01040 COORDINATION C. Minimum agenda shall include: 1. Review of work progress since last meeting. 2. Identification and discussion of problems affecting progress. 3. Review of any pending change orders. 4. Revision of Construction Schedule anticipated two weeks in advance. D. The Engineer and Contractor shall agree to weekly quantities at the progress meetings. The weekly quantity sheets shall be signed by both parties. These quantity sheets, when signed, shall be final and shall be the basis for the monthly progress estimates. This process ensures accurate monthly project pay estimates. END OF SECTION General Requirements - Page 5 of 18 SECTION 01310 CONSTRUCTION SCHEDULE 1.1 GENERAL A. The contractor shall prepare a detailed schedule of all construction operations and procurement after review of tentative schedule by parties attending the pre -construction conference. This schedule will show how the contractor intends to meet the milestones set forth. 1. No work is to begin at the site until Owner's acceptance of the Construction Progress Schedule and Report of delivery of equipment and materials. 1.2 FORMAT AND SUBMISSIONS A. Prepare construction and procure schedules in a graphic format suitable for displaying scheduled and actual progress. B. Submit two copies of each schedule to Owner for review. 1. Owner will return one copy to Contractor with revisions suggested or necessary for coordination of the Work with the needs of Owner or others. C. The schedule must show how the street, landscaping, and various utility work will be coordinated. 1.3 CONTENT A. Construction Progress Schedule. 1. Show complete work sequence of construction by activity and location for the upcoming two week period. 2. Show changes to traffic control. 3. Show project milestones. B. Report of delivery of equipment and materials. 1. Show delivery status of critical and major items of equipment and materials. 2. Provide a schedule which includes the critical path for Shop Drawings, tests, and other submittal requirements for equipment and materials; reference Section 01340. 1.4 PROGRESS REVISIONS A. Submit revised schedules and reports at weekly project coordination meetings when changes are foreseen, when requested by Owner or Engineer, and with each application for progress payment. B. Show changes occurring since previous submission. 1. Actual progress of each item to date. 2. Revised projections of progress and completion. C. Provide a narrative report as needed to define: 1. Anticipated problems, recommended actions, and their effects on the schedule. 2. The effect of changes on schedules of others. General Requirements - Page 6 of 18