Loading...
HomeMy WebLinkAbout389648 A-1 CHIPSEAL - PURCHASE ORDER - 9135145City of Fort Collins Date: 09119/2013 Vendor: 389648 A-1 CHIPSEAL CO 2001 W 64TH LANE DENVER CO 80221 PURCHASE ORDER PO Number Page 9135145 ' 1 of 2 This number must appear on all invoices, packing slips and labels. Ship To: STREETS DEPARTMENT CITY OF FORT COLLINS 625 NINTH STREET FORT COLLINS CO 80524 Delivery Date: 09/19/2013 Buyer: JOHN STEPHEN Note: Line Description Quantity UOM Unit Price Extended Ordered Price 2013 HACO RENEWAL 1 LOT LS 704,350.00 PER TERMS AND CONDITIONS OF BID #7256 AND AGREEMENT DATED AUGUST 22, 2013 City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by Gerry S. Paul City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax:970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Purchase Order Terms and Conditions Page 2 of 2 1. COMMERCIAL DETAILS. Tax exemptions. By statute the City of Fort Collins is exempt from state and local taxes. Our Exemption Number is 11. NONWAIVER. 98-04502. Federal Excise Tax Exemption Certificate of Registry 84-6000587 is registered with the Collector of Failure of the Purchaser to insist upon strict performance of the terms and conditions hereof, failure or delay to Internal Revenue, Denver, Colorado (Ref. Colorado Revised Statutes 1973, Chapter 39-26, 114 (a). exercise any rights or remedies provided herein or by law, failure to promptly notify the Seller in the event of a breach, the acceptance of or payment for goods hereunder or approval of the design, shall not release the Seller of Goods Rejected. GOODS REJECTED due to failure to meet specifications, either when shipped or due to defects of any of the warranties or obligations of this purchase order and shall not be deemed a waiver of any right of the damage in transit, may be returned to you for credit and are not to be replaced except upon receipt of written purchaser to insist upon strict performance hereof or any of its rights or remedies as to my such goods, regardless instructions from the City of Fort Collins. of when shipped, received or accepted, as to my prior or subsequent default hereunder, not shall my purported oral modification or rescission of this purchase order by the Purchaser operate as a waiver of any of the terms Inspection. GOODS are subject to the City of Fort Collins inspection on arrival. hereof. Final Acceptance. Receipt of the merchandise, services or equipment in response to this order can result in 12. ASSIGNMENT OF ANTITRUST CLAIMS. authorized payment on the part of the City of Fort Collins. However, it is to be understood that FINAL Seller and the Purchaser recognize that in actual economic practice, overcharges resulting from md=t ACCEPTANCE is dependent upon completion of all applicable required inspection procedures. violations are in fact home by the Purchaser. Theretofore, for good cause and as consideration for executing this purchase order the Seller hereby assigns to the Purchaser any and all claims it may now have or hereafter Freight Terms. Shipments most be F.O.B., City of Fort Collins, 700 Wood St, Fort Collins, CO 80522, unless otherwise specified on this order. Upermission is given to prepay freight and charge separately, the original freight bill most accompany invoice. Additional charges for packing will not be accepted Shipment Distance. Where manufacturers have distributing points in various pans of the country, shipment is expected from the nearest distribution point to destination, and excess freight will be deducted from Invoice when shipments am made from greater distance. Permits. Seller shall procure at sellers sole cost all necessary permits, certificates and licenses required by all applicable laws, regulations, ordinances and rules of the state, municipality, territory or political subdivision where the work is performed, or required by any other duly constituted public authority having jurisdiction over the work of vendor. Seller further agrees to hold the City of Fort Collins harmless from and against all liability and loss incurred by them by reason of an asserted or established violation of my such laws, regulations, ordinances, mles and requirement. Authorization. All parties to this contract agree that the representatives are, in fact, bona fide and possess full and complete authority to bind said parties. LIMITATION OF TERMS. This Purchase Order expressly limits acceptance to the terms and conditions stated herein set forth and my supplementary or additional terms and conditions annexed hereto or incorporated herein by reference. Any additional or different terms and conditions proposed by seller we objected to and hereby rejected. 2. DELIVERY. PLEASE ADVISE PURCHASING AGENT immediately if you cannot make complete shipment to arrive on your promised delivery date as noted. Time is ofthe essence. Delivery and perfommnce must be effected within the time stated on the purchase order and the document attached hereto. No act of the Purchasers including, without limitation, acceptance ofpartial late deliveries, shall operate as a waiver of this provision. In the event ofany delay, the Purchaser shall have, in addition to other legal and equitable remedies, the option ofplacing this order elsewhere and holding the Seller liable for damnges. However, the Seller shall not be liable for damages as a result of delays due to causes not reasonably foreseeable which are beyond its reasonable control and without its fault of negligence, such acts of God, acts ofcivil or military authorities, governmental priorities, fires, strikes, Rood, epidemics, wars or riots provided that notice of the conditions causing such delay is given to the Purchaser within five (5) days of the time when the Seller first received knowledge thereof. In the event of any such delay, the date of delivery shall be extended for the period equal to the time actually lost by reason of the delay. 3. WARRANTY. The Seiler warrants that all goods, articles, materials and work covered by Nis order will conform with applicable drawings, specifications, samples and/or other descriptions given, will be fit for the purposes intended, and performed with the highest degree of care and competence in accordance with accepted standards for work of a similar nature. The Seller agrees to hold the purchaser harmless from my loss, damage or expense which the Purchaser may suffer or incur on account of the Sellers breach of war inty. The Seller shall replace, repair or make good, without cost to the purchaser, any defect or faults arising within one (1) year or within such longer period of time as may be prescribed by law or by the terns of any applicable warranty provided by the Seller after the date of acceptance of the goods furnished hereunder (acceptance not to be unreasonably delayed), resulting from imperfect or defective work done or materials famished by the Seller. Acceptance or use of goods by the Purchaser shall not constitute a waiver of any claim under this warranty. Except as otherwise provided in this purchase order, the Sellers liability hereunder shall extend to all damages proximately caused by the breach of any of the foregoing warranties or guarantees, but such liability shall in no event include loss of profits or loss of use. NO IMPLIED WARRANTY OR MERCHANTABILITY OR OF FITNESS FOR PURPOSE SHALL APPLY. 4. CHANGES IN LEGAL TERMS. The Purchaser may make changes to legal terns by written change order. 5. CHANGES IN COMMERCIAL TERMS. The Purchaser may make any changes to the terms, other than legal terms, including additions to or deletions from the quantities originally ordered in the specifications or drawings, by verbal or written change order. If any such change effects the mount due or the time ofperformance hereunder, an equitable adjustment shall be made. 6. TERMINATIONS. The Purchaser may at any time by written change order, terminate this agreement m to any or all portions of the goods then not shipped, subject to my equitable adjustment between the parties as to any work or materials then in progress provided that the Purchaser shall not be liable for any claims for anticipated profits on the uncompleted portion of the goods and/or work, for incidental or consequential damages, and that no such adjustment be made in favor of the Seller with respect to any goods which are the Sellers standard stock. No such termination shall relieve the Purchaser or the Seller of any of their obligations as to any goods delivered hereunder. 7. CLAIMS FOR ADJUSTMENT. Any claim for adjustment most be asserted within thirty (30) days from the dale the change or termination is ordered. S. COMPLIANCE WITH LAW. The Seller warrant that all goods sold hereunder shall have been produced, sold, delivered and famished in strict compliance with all applicable laws and regulations to which the goods are subject. The Seller shall execute and deliver such documents as may be required to effect or evidence compliance. All laws and regulations required to be incorporated in agreements of this character are hereby incorporated herein by this reference. The Seller agrees to indemnify and hold the Purchaser harmless from all cost and damages suffered by the Purchaser as a result of die Sellers failure to comply with such law. 9. ASSIGNMENT. Neither party shall assign, transfer, or convey this order, or any monies due or to become due hereunder without the prior written consent of the other party. 10. TITLE. The Seller warrants full, clear and unrestricted title to the Purchaser for all equipment, materials, and items fumished in performance of this agreement, free and clear of any and all liens, restrictions, reservations, security interest encumbrances and claims ofothers. acquired under federal or stale antitrust laws for such overcharges relating to the particular goods or services purchased or acquired by the Purchaser pursuant to this purchase order. 13. PURCHASERS PERFORMANCE OF SELLERS OBLIGATIONS. If the Purchaser direct the Seller to correct nonconforming or defective goods by a date to be agreed upon by the Purchaser and the Seller, and the Seller thereafter indicates its inability or unwillingness to comply, the Purchaser may cause the work to be performed by the most expeditious mean available to it, and the Seller shall pay all costs associated with such work. The Seller shall release the Purchaser and its contractors of my tier from all liability and claims of any nature resulting from the performance ofsuch work. This release shall apply even in the event of fault of negligence of the party released and shall extend to the directors, officers and employees of such party. The Sellers contractor] obligations, including warranty, shall not be deemed to be reduced, in any way, because such work is performed or caused to be performed by the Purchaser. 14. PATENTS. Whenever the Seller is required to use any design, device, material or process covered by letter, patent, trademark or copyright, the Seller shall indemnify and save harmless the Purchaser from any and all claims for infringement by reason of the use of such patented design, device, material or process in connection with the contract, and shall indenmi fy the Purchaser for my cost, expense or damage which it may be obliged to pay by reason of such infringement at any time during the prosecution or after the completion of the work. In case said equipment, or any part thereof or the intended use of the goods, is in such suit held to constitute infringement and the use of said equipment or pan is enjoined, die Seller shall, at its awn expense and at its option, either procure for the Purchaser the right to continue using said equipment or parts, replace the same with substantially equal but noninfringing equipment, or modify it so it becomes noninfringing. 15. INSOLVENCY. If the Seller shall became insolvent or bankrupt, make an assignment for the benefit of creditors, appoint a receiver or trustee for any of the Sellers property or business, this order may forthwith be canceled by the Purchaser without liability. 16. GOVERNING LAW. The definitions of terms used or the interpretation of the agreement and the rights of all parties hereunder shall be construed under and governed by the laws of the State of Colorado, USA. The following Additional Conditions apply only in cases where the Seller is to perform work hereunder, including the services of Sellers Representative(s), on the premises of others. 17. SELLERS RESPONSIBILITY. The Seller shall carry on said work at Sellers own risk until the same is fully completed and accepted, and shall, in case of any accident, destruction or injury to the work and/or materials before Seller's final completion and acceptance, complete the work at Sellers own expense and to the satisfaction of the Purchaser. When materials and equipment are fumished by others for installation or erection by the. Seller, the Seller shall receive, unload, store and handle same at the site and become responsible therefor as though such materials and/or equipment were being furnished by the Seller under the order. I & INSURANCE. The Seller shall, at his own expense, provide for the payment of workers compensation, including occupational disease benefit, to its employees employed on or in connection with the work covered by this purchase order, and/or to their dependents in accordance with the laws of the state in which the work is to be done. The Seller shall also tarty comprehensive general liability including, but not limited to, contracmal and automobile public liability insurance with bodily injury and death limit of at least S300,000 for any one person, $500,000 for any one accident and property damage limit per accident of S400,000. The Seller shall likewise require his contractors, if any, to provide for such compensation and insurance. Before any of the Sellers or his contractors employees shall do any work upon the premises of others, the Seller shall furnish the Purchaser with a certificate that such compensation and insurance have been provided. Such certificates shall specify the date when such compensation and insurance have been provided. Such certificates shall specify the date when such compensation and insurance expires. The Seller agrees that such compensation and insurance shall be maintained until after the entire work is completed and accepted. 19. PROTECTION AGAINST ACCIDENTS AND DAMAGES. The Seller hereby assumes the entire responsibility and liability for my and all damage, lass or injury of any kind or nature whatsoever to persons or property caused by or resulting from the execution of the work provided for in this purchase order or in connection herewith. The Seller will indemnify and hold harmless the Purchaser and any or all of the Purchasers officers, agent and employees from and against any and all claims, losses, damages, charges or expenses, whether direct or indirect, and whether to persons or property to which the Purchaser may be put or subject by reason of any act, action, neglect, omission or default on the part of the Seller, any of his contractors, or any of the Sellers or contractors officers, agent or employees. In case my suit or other proceedings shall be brought against the Purchaser, or its officers, agents or employees at any time on account or by reason of any act, action, neglect, omission or default of the Seller of any of his contractors or my of its or their officers, agent or employees as aforesaid, the Seller hereby agrees to assume the defense thereof and to defend the same at the Sellers own expense, to pay my and all costs, charges, attorneys fees and other expenses, any and all judgments that may be incurred by or obtained against the Purchaser or any of its or their officers, agent or employees in such suits or other proceedings, and in case judgment or other lien be placed upon or obtained against the property of the Purchaser, or said parties in or as a result of such suit or other proceedings, the Seller will at once cause the same to be dissolved and discharged by giving band or otherwise. The Seller and his contractors shall take all safety precautions, famish and install all guards necessary for the prevention of accidents, comply with all laws and regulations with regard to safety including, but without limitation, the Occupational Safety and Health Act of 1970 and all odes and regulations issued pursuant thereto. Revised 0312010