Loading...
HomeMy WebLinkAbout103686 OVERHEAD DOOR CO OF FORT COLLINS - PURCHASE ORDER - 9124615PURCHASE ORDER PO Number Page 9124615 1 of 18 This number must appear on all invoices, packing slips and labels. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax: 970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Date: 09/07/2012 Vendor : 103686 Ship To: OPERATIONS SERVICES OVERHEAD DOOR CO OF FORT COLLINS CITY OF FORT COLLINS 900B SMITHFIELD DR 300 Laporte Avenue FORT COLLINS Colorado 80524 Building B FORT COLLINS Colorado 80521 Delivery Date: 08/23/2012 Buyer: DOUG CLAPP Note: Line Description Quantity Ordered UOM Unit Price Extended Price 1 Transfort Bus Wash 1 LOT LS 15,176.00 Install 2 roll-up doors per proposal #1-1376 dated 8/20/12 including operators and accessories. FEDERAL TRANSIT ADMINISTRATION TABLE OF CONTENTS Federally Required and Other Model Contract Clauses 1.NO GOVERNMENT OBLIGATION TO THIRD PARTIES 1 2.PROGRAM FRAUD AND FALSE OR FRAUDULENT STATEMENTS AND RELATED ACTS 1 3.ACCESS TO RECORDS AND REPORTS 1 4.FEDERAL CHANGES 2 1.TERMINATION 3 2.CIVIL RIGHTS REQUIREMENTS 4 3.DISADVANTAGED BUSINESS ENTERPRISE (DBE) 5 4.INCORPORATION OF FEDERAL TRANSIT ADMINISTRATION (FTA) TERMS 6 5.CARGO PREFERENCE REQUIREMENTS 6 6.DAVIS-BACON AND COPELAND ANTI-KICKBACK ACTS 7 7.CONTRACT WORK HOURS AND SAFETY STANDARDS ACT 13 8.ENERGY CONSERVATION REQUIREMENTS 14 9.RECYCLED PRODUCTS 14 10.ADA Access 15 1. NO GOVERNMENT OBLIGATION TO THIRD PARTIES No Obligation by the Federal Government. (1) The Purchaser and Contractor acknowledge and agree that, notwithstanding any concurrence by the Federal Government in or approval of the solicitation or award of the underlying contract, absent the express written consent by the Federal Government, the Federal Government is not a party to this contract and shall not be subject to any obligations or liabilities to the Purchaser, Contractor, or any other party (whether or not a party to that contract) pertaining to any matter resulting from the underlying contract. (2) The Contractor agrees to include the above clause in each subcontract financed in whole or in part with PURCHASE ORDER PO Number Page 9124615 2 of 18 This number must appear on all invoices, packing slips and labels. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax: 970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Line Description Quantity Ordered UOM Unit Price Extended Price Federal assistance provided by FTA. It is further agreed that the clause shall not be modified, except to identify the subcontractor who will be subject to its provisions. 2. PROGRAM FRAUD AND FALSE OR FRAUDULENT STATEMENTS AND RELATED ACTS Program Fraud and False or Fraudulent Statements or Related Acts. (1) The Contractor acknowledges that the provisions of the Program Fraud Civil Remedies Act of 1986, as amended, 31 U.S.C. § 3801 et seq . and U.S. DOT regulations, "Program Fraud Civil Remedies," 49 C.F.R. Part 31, apply to its actions pertaining to this Project. Upon execution of the underlying contract, the Contractor certifies or affirms the truthfulness and accuracy of any statement it has made, it makes, it may make, or causes to be made, pertaining to the underlying contract or the FTA assisted project for which this contract work is being performed. In addition to other penalties that may be applicable, the Contractor further acknowledges that if it makes, or causes to be made, a false, fictitious, or fraudulent claim, statement, submission, or certification, the Federal Government reserves the right to impose the penalties of the Program Fraud Civil Remedies Act of 1986 on the Contractor to the extent the Federal Government deems appropriate. (2) The Contractor also acknowledges that if it makes, or causes to be made, a false, fictitious, or fraudulent claim, statement, submission, or certification to the Federal Government under a contract connected with a project that is financed in whole or in part with Federal assistance originally awarded by FTA under the authority of 49 U.S.C. § 5307, the Government reserves the right to impose the penalties of 18 U.S.C. § 1001 and 49 U.S.C. § 5307(n)(1) on the Contractor, to the extent the Federal Government deems appropriate. (3) The Contractor agrees to include the above two clauses in each subcontract financed in whole or in part with Federal assistance provided by FTA. It is further agreed that the clauses shall not be modified, except to identify the subcontractor who will be subject to the provisions. 3. ACCESS TO RECORDS AND REPORTS Access to Records - The following access to records requirements apply to this Contract: A. Where the Purchaser is not a State but a local government and is the FTA Recipient or a subgrantee of the FTA Recipient in accordance with 49 C.F.R. 18.36(i), the Contractor agrees to provide the Purchaser, the FTA Administrator, the Comptroller General of the United States or any of their authorized representatives access to any books, documents, papers and records of the Contractor which are directly pertinent to this contract for the purposes of making audits, examinations, excerpts and transcriptions. Contractor also agrees, pursuant to 49 C.F.R. 633.17 to provide the FTA Administrator or his authorized representatives including any PMO Contractor access to Contractor's records and construction sites pertaining to a major capital project, defined at 49 U.S.C. 5302(a)1, which is receiving federal financial assistance through the programs described at 49 U.S.C. 5307, 5309 or 5311. B. The Contractor agrees to permit any of the foregoing parties to reproduce by any means whatsoever or to copy excerpts and transcriptions as reasonably needed. C. The Contractor agrees to maintain all books, records, accounts and reports required under this contract for a period of not less than three years after the date of termination or expiration of this contract, except in the event of litigation or settlement of claims arising from the performance of this contract, in which case Contractor agrees to maintain same until the Purchaser, the FTA Administrator, the Comptroller General, or any of their duly authorized representatives, have disposed of all such litigation, appeals, claims or exceptions related thereto. Reference 49 CFR 18.39(i)(11). D. FTA does not require the inclusion of these requirements in subcontracts. Requirements for Access to Records and Reports by Types of Contract PURCHASE ORDER PO Number Page 9124615 3 of 18 This number must appear on all invoices, packing slips and labels. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax: 970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Line Description Quantity Ordered UOM Unit Price Extended Price SAT ($100,000) imposed on state pass thru to Contractor b. Contracts above None Yes, if non- None unless None None unless non- $100,000/Capital unless 1 competitive non- unless competitive award Projects non- award or if competitive non- competitive funded thru 2 award competitive award 5307/5309/5311 award II Non State Grantees a.Contracts below Those SAT ($100,000) Yes 3 imposed on Yes Yes Yes Yes Non-state Grantee b.Contracts above pass thru to $100,000/Capital Yes 3 Contractor Yes Yes Yes Yes Projects Sources of Authority: 1 49 USC 5325 (a) 2 49 CFR 633.17 3 18 CFR 18.36 (i) 4. FEDERAL CHANGES Federal Changes - Contractor shall at all times comply with all applicable FTA regulations, policies, procedures and directives, including without limitation those listed directly or by reference in the Master Agreement between Purchaser and FTA, as they may be amended or promulgated from time to time during the term of this contract. Contractor's failure to so comply shall constitute a material breach of this contract. 1. TERMINATION a. Termination for Convenience (General Provision) The City may terminate this contract, in whole or in part, at any time by written notice to the Contractor when it is in the Government's best interest. The Contractor shall be paid its costs, including contract close-out costs, and profit on work performed up to the time of termination. The Contractor shall promptly submit its termination claim to the City to be paid the Contractor. If the Contractor has any property in its possession belonging to the City, the Contractor will account for the same, and dispose of it in the manner the City directs. b. Termination for Default [Breach or Cause] (General Provision) If the Contractor does not deliver supplies in accordance with the contract delivery schedule, or, if the contract is for services, the Contractor fails to perform in the manner called for in the contract, or if the Contractor fails to comply with any other provisions of the contract, the City may terminate this contract for default. Termination shall be effected by serving a notice of termination on the contractor setting forth the manner in which the Contractor is in default. The contractor will only be paid the contract price for supplies delivered and accepted, or services performed in accordance with the manner of performance set forth in the contract. If it is later determined by the City that the Contractor had an excusable reason for not performing, such as a strike, fire, or flood, events which are not the fault of or are beyond the control of the Contractor, the City, after setting up a new delivery of performance schedule, may allow the Contractor to continue work, or treat the termination as a termination for convenience. c. Opportunity to Cure (General Provision) The City in its sole discretion may, in the case of a termination for breach or default, allow the Contractor [an appropriately short period of time] in which to cure the defect. In such case, the notice of termination will state the time period in which cure is permitted and other appropriate conditions If Contractor fails to remedy to the City' s satisfaction the breach or default of any of the terms, covenants, or PURCHASE ORDER PO Number Page 9124615 4 of 18 This number must appear on all invoices, packing slips and labels. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax: 970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Line Description Quantity Ordered UOM Unit Price Extended Price further obligation to Contractor. Any such termination for default shall not in any way operate to preclude the City from also pursuing all available remedies against Contractor and its sureties for said breach or default. d. Termination for Default (Construction) If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract or any extension or fails to complete the work within this time, or if the Contractor fails to comply with any other provisions of this contract, the City may terminate this contract for default. The City shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. In this event, the Recipient may take over the work and compete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the Recipient resulting from the Contractor's refusal or failure to complete the work within specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the Recipient in completing the work. The Contractor's right to proceed shall not be terminated nor the Contractor charged with damages under this clause if- 1. The delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include: acts of God, acts of the Recipient, acts of another Contractor in the performance of a contract with the Recipient, epidemics, quarantine restrictions, strikes, freight embargoes; and 2. The contractor, within [10] days from the beginning of any delay, notifies the City in writing of the causes of delay. If in the judgment of the City, the delay is excusable, the time for completing the work shall be extended. The judgment of the City shall be final and conclusive on the parties, but subject to appeal under the Disputes clauses. If, after termination of the Contractor's right to proceed, it is determined that the Contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if the termination had been issued for the convenience of the Recipient. 2. CIVIL RIGHTS REQUIREMENTS Civil Rights - The following requirements apply to the underlying contract: (1) Nondiscrimination - In accordance with Title VI of the Civil Rights Act, as amended, 42 U.S.C. § 2000d, section 303 of the Age Discrimination Act of 1975, as amended, 42 U.S.C. § 6102, section 202 of the Americans with Disabilities Act of 1990, 42 U.S.C. § 12132, and Federal transit law at 49 U.S.C. § 5332, the Contractor agrees that it will not discriminate against any employee or applicant for employment because of race, color, creed, national origin, sex, age, or disability. In addition, the Contractor agrees to comply with applicable Federal implementing regulations and other implementing requirements FTA may issue. (2) Equal Employment Opportunity - The following equal employment opportunity requirements apply to the underlying contract: (a) Race, Color, Creed, National Origin, Sex - In accordance with Title VII of the Civil Rights Act, as amended, 42 U.S.C. § 2000e, and Federal transit laws at 49 U.S.C. § 5332, the Contractor agrees to comply with all applicable equal employment opportunity requirements of U.S. Department of Labor (U.S. DOL) regulations, "Office of Federal Contract Compliance Programs, Equal Employment Opportunity, Department of Labor," 41 C.F.R. Parts 60 et seq ., (which implement Executive Order No. 11246, "Equal Employment Opportunity," as amended by Executive Order No. 11375, "Amending Executive Order 11246 Relating to Equal Employment Opportunity," 42 U.S.C. § 2000e note), and with any applicable Federal statutes, executive orders, regulations, PURCHASE ORDER PO Number Page 9124615 5 of 18 This number must appear on all invoices, packing slips and labels. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax: 970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Line Description Quantity Ordered UOM Unit Price Extended Price requirements FTA may issue. (b) Age - In accordance with section 4 of the Age Discrimination in Employment Act of 1967, as amended, 29 U.S.C. § § 623 and Federal transit law at 49 U.S.C. § 5332, the Contractor agrees to refrain from discrimination against present and prospective employees for reason of age. In addition, the Contractor agrees to comply with any implementing requirements FTA may issue. (c) Disabilities - In accordance with section 102 of the Americans with Disabilities Act, as amended, 42 U.S.C. § 12112, the Contractor agrees that it will comply with the requirements of U.S. Equal Employment Opportunity Commission, "Regulations to Implement the Equal Employment Provisions of the Americans with Disabilities Act," 29 C.F.R. Part 1630, pertaining to employment of persons with disabilities. In addition, the Contractor agrees to comply with any implementing requirements FTA may issue. (3) The Contractor also agrees to include these requirements in each subcontract financed in whole or in part with Federal assistance provided by FTA, modified only if necessary to identify the affected parties. 3. DISADVANTAGED BUSINESS ENTERPRISE (DBE) a. This contract is subject to the requirements of Title 49, Code of Federal Regulations, Part 26, Participation by Disadvantaged Business Enterprises in Department of Transportation Financial Assistance Programs. The national goal for participation of Disadvantaged Business Enterprises (DBE) is 10%. The agency' s overall goal for DBE participation is __ %. A separate contract goal [of __ % DBE participation has] [has not] been established for this procurement. b. The contractor shall not discriminate on the basis of race, color, national origin, or sex in the performance of this contract. The contractor shall carry out applicable requirements of 49 CFR Part 26 in the award and administration of this DOT-assisted contract. Failure by the contractor to carry out these requirements is a material breach of this contract, which may result in the termination of this contract or such other remedy as City of Fort Collins deems appropriate. Each subcontract the contractor signs with a subcontractor must include the assurance in this paragraph ( see 49 CFR 26.13(b)). c. { If a separate contract goal has been established, use the following} Bidders/offerors are required to document sufficient DBE participation to meet these goals or, alternatively, document adequate good faith efforts to do so, as provided for in 49 CFR 26.53. Award of this contract is conditioned on submission of the following [concurrent with and accompanying sealed bid] [concurrent with and accompanying an initial proposal] [prior to award] : 1. The names and addresses of DBE firms that will participate in this contract; 2. A description of the work each DBE will perform; 3. The dollar amount of the participation of each DBE firm participating; 4. Written documentation of the bidder/offeror' s commitment to use a DBE subcontractor whose participation it submits to meet the contract goal; 5. Written confirmation from the DBE that it is participating in the contract as provided in the prime contractor' s commitment; and 6. If the contract goal is not met, evidence of good faith efforts to do so. [Bidders][Offerors] must present the information required above [as a matter of responsiveness] [with initial proposals] [prior to contract award] ( see 49 CFR 26.53(3)). { If no separate contract goal has been established, use the following} The successful bidder/offeror will be required to report its DBE participation obtained through race-neutral means throughout the period of performance. PURCHASE ORDER PO Number Page 9124615 6 of 18 This number must appear on all invoices, packing slips and labels. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax: 970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Line Description Quantity Ordered UOM Unit Price Extended Price contractor' s receipt of the partial retainage payment related to the subcontractor' s work.] e. The contractor must promptly notify City of Fort Collins whenever a DBE subcontractor performing work related to this contract is terminated or fails to complete its work, and must make good faith efforts to engage another DBE subcontractor to perform at least the same amount of work. The contractor may not terminate any DBE subcontractor and perform that work through its own forces or those of an affiliate without prior written consent of City of Fort Collins. 4. INCORPORATION OF FEDERAL TRANSIT ADMINISTRATION (FTA) TERMS Incorporation of Federal Transit Administration (FTA) Terms - The preceding provisions include, in part, certain Standard Terms and Conditions required by DOT, whether or not expressly set forth in the preceding contract provisions. All contractual provisions required by DOT, as set forth in FTA Circular 4220.1E, are hereby incorporated by reference. Anything to the contrary herein notwithstanding, all FTA mandated terms shall be deemed to control in the event of a conflict with other provisions contained in this Agreement. The Contractor shall not perform any act, fail to perform any act, or refuse to comply with any (name of grantee) requests which would cause (name of grantee) to be in violation of the FTA terms and conditions. 5. CARGO PREFERENCE REQUIREMENTS Cargo Preference - Use of United States-Flag Vessels - The contractor agrees: a. to use privately owned United States-Flag commercial vessels to ship at least 50 percent of the gross tonnage (computed separately for dry bulk carriers, dry cargo liners, and tankers) involved, whenever shipping any equipment, material, or commodities pursuant to the underlying contract to the extent such vessels are available at fair and reasonable rates for United States-Flag commercial vessels; b. to furnish within 20 working days following the date of loading for shipments originating within the United States or within 30 working days following the date of leading for shipments originating outside the United States, a legible copy of a rated, "on-board" commercial ocean bill-of -lading in English for each shipment of cargo described in the preceding paragraph to the Division of National Cargo, Office of Market Development, Maritime Administration, Washington, DC 20590 and to the FTA recipient ( through the contractor in the case of a subcontractor's bill-of-lading.) c. to include these requirements in all subcontracts issued pursuant to this contract when the subcontract may involve the transport of equipment, material, or commodities by ocean vessel. 6. DAVIS-BACON AND COPELAND ANTI-KICKBACK ACTS Background and Application The Davis-Bacon and Copeland Acts are codified at 40 USC 3141, et seq. and 18 USC 874. The Acts apply to grantee construction contracts and subcontracts that " at least partly are financed by a loan or grant from the Federal Government." 40 USC 3145(a), 29 CFR 5.2(h), 49 CFR 18.36(i)(5). The Acts apply to any construction contract over $2,000. 40 USC 3142(a), 29 CFR 5.5(a). ' Construction,' for purposes of the Acts, includes " actual construction, alteration and/or repair, including painting and decorating." 29 CFR 5.5(a). The requirements of both Acts are incorporated into a single clause ( see 29 CFR 3.11) enumerated at 29 CFR 5.5(a) and reproduced below. The clause language is drawn directly from 29 CFR 5.5(a) and any deviation from the model clause below should be coordinated with counsel to ensure the Acts' requirements are satisfied. Clause Language Davis-Bacon and Copeland Anti-Kickback Acts (1) Minimum wages - (i) All laborers and mechanics employed or working upon the site of the work (or under the United States PURCHASE ORDER PO Number Page 9124615 7 of 18 This number must appear on all invoices, packing slips and labels. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax: 970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Line Description Quantity Ordered UOM Unit Price Extended Price which may be alleged to exist between the contractor and such laborers and mechanics. Contributions made or costs reasonably anticipated for bona fide fringe benefits under section 1(b)(2) of the Davis-Bacon Act on behalf of laborers or mechanics are considered wages paid to such laborers or mechanics, subject to the provisions of paragraph (1)(iv) of this section; also, regular contributions made or costs incurred for more than a weekly period (but not less often than quarterly) under plans, funds, or programs which cover the particular weekly period, are deemed to be constructively made or incurred during such weekly period. Such laborers and mechanics shall be paid the appropriate wage rate and fringe benefits on the wage determination for the classification of work actually performed, without regard to skill, except as provided in 29 CFR Part 5.5(a)(4). Laborers or mechanics performing work in more than one classification may be compensated at the rate specified for each classification for the time actually worked therein: Provided, That the employer's payroll records accurately set forth the time spent in each classification in which work is performed. The wage determination (including any additional classifications and wage rates conformed under paragraph (1)(ii) of this section) and the Davis-Bacon poster (WH-1321) shall be posted at all times by the contractor and its subcontractors at the site of the work in a prominent and accessible place where it can be easily seen by the workers. (ii) (A) The contracting officer shall require that any class of laborers or mechanics, including helpers, which is not listed in the wage determination and which is to be employed under the contract shall be classified in conformance with the wage determination. The contracting officer shall approve an additional classification and wage rate and fringe benefits therefore only when the following criteria have been met: (1) Except with respect to helpers as defined as 29 CFR 5.2(n)(4), the work to be performed by the classification requested is not performed by a classification in the wage determination; and (2) The classification is utilized in the area by the construction industry; and (3) The proposed wage rate, including any bona fide fringe benefits, bears a reasonable relationship to the wage rates contained in the wage determination; and (4) With respect to helpers as defined in 29 CFR 5.2(n)(4), such a classification prevails in the area in which the work is performed. (B) If the contractor and the laborers and mechanics to be employed in the classification (if known), or their representatives, and the contracting officer agree on the classification and wage rate (including the amount designated for fringe benefits where appropriate), a report of the action taken shall be sent by the contracting officer to the Administrator of the Wage and Hour Division, Employment Standards Administration, U.S. Department of Labor, Washington, DC 20210. The Administrator, or an authorized representative, will approve, modify, or disapprove every additional classification action within 30 days of receipt and so advise the contracting officer or will notify the contracting officer within the 30-day period that additional time is necessary. (C) In the event the contractor, the laborers or mechanics to be employed in the classification or their representatives, and the contracting officer do not agree on the proposed classification and wage rate (including the amount designated for fringe benefits, where appropriate), the contracting officer shall refer the questions, including the views of all interested parties and the recommendation of the contracting officer, to the Administrator for determination. The Administrator, or an authorized representative, will issue a determination within 30 days of receipt and so advise the contracting officer or will notify the contracting officer within the 30- day period that additional time is necessary. (D) The wage rate (including fringe benefits where appropriate) determined pursuant to paragraphs (a)(1)(ii) (B) or (C) of this section, shall be paid to all workers performing work in the classification under this contract from the PURCHASE ORDER PO Number Page 9124615 8 of 18 This number must appear on all invoices, packing slips and labels. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax: 970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Line Description Quantity Ordered UOM Unit Price Extended Price request of the contractor, that the applicable standards of the Davis-Bacon Act have been met. The Secretary of Labor may require the contractor to set aside in a separate account assets for the meeting of obligations under the plan or program. (v) (A) The contracting officer shall require that any class of laborers or mechanics which is not listed in the wage determination and which is to be employed under the contract shall be classified in conformance with the wage determination. The contracting officer shall approve an additional classification and wage rate and fringe benefits therefore only when the following criteria have been met: (1) The work to be performed by the classification requested is not performed by a classification in the wage determination; and (2) The classification is utilized in the area by the construction industry; and (3) The proposed wage rate, including any bona fide fringe benefits, bears a reasonable relationship to the wage rates contained in the wage determination. (B) If the contractor and the laborers and mechanics to be employed in the classification (if known), or their representatives, and the contracting officer agree on the classification and wage rate (including the amount designated for fringe benefits where appropriate), a report of the action taken shall be sent by the contracting officer to the Administrator of the Wage and Hour Division, Employment Standards Administration, Washington, DC 20210. The Administrator, or an authorized representative, will approve, modify, or disapprove every additional classification action within 30 days of receipt and so advise the contracting officer or will notify the contracting officer within the 30-day period that additional time is necessary. (C) In the event the contractor, the laborers or mechanics to be employed in the classification or their representatives, and the contracting officer do not agree on the proposed classification and wage rate (including the amount designated for fringe benefits, where appropriate), the contracting officer shall refer the questions, including the views of all interested parties and the recommendation of the contracting officer, to the Administrator for determination. The Administrator, or an authorized representative, will issue a determination with 30 days of receipt and so advise the contracting officer or will notify the contracting officer within the 30-day period that additional time is necessary. (D) The wage rate (including fringe benefits where appropriate) determined pursuant to paragraphs (a)(1)(v) (B) or (C) of this section, shall be paid to all workers performing work in the classification under this contract from the first day on which work is performed in the classification. (2) Withholding - The City of Fort Collins shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld from the contractor under this contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to Davis-Bacon prevailing wage requirements, which is held by the same prime contractor, so much of the accrued payments or advances as may be considered necessary to pay laborers and mechanics, including apprentices, trainees, and helpers, employed by the contractor or any subcontractor the full amount of wages required by the contract. In the event of failure to pay any laborer or mechanic, including any apprentice, trainee, or helper, employed or working on the site of the work (or under the United States Housing Act of 1937 or under the Housing Act of 1949 in the construction or development of the project), all or part of the wages required by the contract, the City of Fort Collins may, after written notice to the contractor, sponsor, applicant, or owner, take such action as may be necessary to cause the suspension of any further payment, advance, or guarantee of funds until such violations have ceased. PURCHASE ORDER PO Number Page 9124615 9 of 18 This number must appear on all invoices, packing slips and labels. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax: 970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Line Description Quantity Ordered UOM Unit Price Extended Price the Davis-Bacon Act), daily and weekly number of hours worked, deductions made and actual wages paid. Whenever the Secretary of Labor has found under 29 CFR 5.5(a)(1)(iv) that the wages of any laborer or mechanic include the amount of any costs reasonably anticipated in providing benefits under a plan or program described in section 1(b)(2)(B) of the Davis-Bacon Act, the contractor shall maintain records which show that the commitment to provide such benefits is enforceable, that the plan or program is financially responsible, and that the plan or program has been communicated in writing to the laborers or mechanics affected, and records which show the costs anticipated or the actual cost incurred in providing such benefits. Contractors employing apprentices or trainees under approved programs shall maintain written evidence of the registration of apprenticeship programs and certification of trainee programs, the registration of the apprentices and trainees, and the ratios and wage rates prescribed in the applicable programs. (ii) (A) The contractor shall submit weekly for each week in which any contract work is performed a copy of all payrolls to the City of Fort Collins for transmission to the Federal Transit Administration. The payrolls submitted shall set out accurately and completely all of the information required to be maintained under section 5.5(a)(3)(i) of Regulations, 29 CFR part 5. This information may be submitted in any form desired. Optional Form WH-347 is available for this purpose and may be purchased from the Superintendent of Documents (Federal Stock Number 029-005-00014-1), U.S. Government Printing Office, Washington, DC 20402. The prime contractor is responsible for the submission of copies of payrolls by all subcontractors. (B) Each payroll submitted shall be accompanied by a "Statement of Compliance," signed by the contractor or subcontractor or his or her agent who pays or supervises the payment of the persons employed under the contract and shall certify the following: (1) That the payroll for the payroll period contains the information required to be maintained under section 5.5(a)(3)(i) of Regulations, 29 CFR part 5 and that such information is correct and complete; (2) That each laborer or mechanic (including each helper, apprentice, and trainee) employed on the contract during the payroll period has been paid the full weekly wages earned, without rebate, either directly or indirectly, and that no deductions have been made either directly or indirectly from the full wages earned, other than permissible deductions as set forth in Regulations, 29 CFR part 3; (3) That each laborer or mechanic has been paid not less than the applicable wage rates and fringe benefits or cash equivalents for the classification of work performed, as specified in the applicable wage determination incorporated into the contract. (C) The weekly submission of a properly executed certification set forth on the reverse side of Optional Form WH-347 shall satisfy the requirement for submission of the "Statement of Compliance" required by paragraph (a)(3)(ii)(B) of this section. (D) The falsification of any of the above certifications may subject the contractor or subcontractor to civil or criminal prosecution under section 1001 of title 18 and section 231 of title 31 of the United States Code. (iii) The contractor or subcontractor shall make the records required under paragraph (a)(3)(i) of this section available for inspection, copying, or transcription by authorized representatives of the Federal Transit Administration or the Department of Labor, and shall permit such representatives to interview employees during working hours on the job. If the contractor or subcontractor fails to submit the required records or to make them available, the Federal agency may, after written notice to the contractor, sponsor, applicant, or owner, take such action as may be necessary to cause the suspension of any further payment, advance, or guarantee of funds. Furthermore, failure to submit the required records upon request or to make such records available may be grounds for debarment action pursuant to 29 CFR 5.12. PURCHASE ORDER PO Number Page 9124615 10 of 18 This number must appear on all invoices, packing slips and labels. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax: 970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Line Description Quantity Ordered UOM Unit Price Extended Price Apprenticeship and Training or a State Apprenticeship Agency (where appropriate) to be eligible for probationary employment as an apprentice. The allowable ratio of apprentices to journeymen on the job site in any craft classification shall not be greater than the ratio permitted to the contractor as to the entire work force under the registered program. Any worker listed on a payroll at an apprentice wage rate, who is not registered or otherwise employed as stated above, shall be paid not less than the applicable wage rate on the wage determination for the classification of work actually performed. In addition, any apprentice performing work on the job site in excess of the ratio permitted under the registered program shall be paid not less than the applicable wage rate on the wage determination for the work actually performed. Where a contractor is performing construction on a project in a locality other than that in which its program is registered, the ratios and wage rates (expressed in percentages of the journeyman's hourly rate) specified in the contractor's or subcontractor's registered program shall be observed. Every apprentice must be paid at not less than the rate specified in the registered program for the apprentice's level of progress, expressed as a percentage of the journeymen hourly rate specified in the applicable wage determination. Apprentices shall be paid fringe benefits in accordance with the provisions of the apprenticeship program. If the apprenticeship program does not specify fringe benefits, apprentices must be paid the full amount of fringe benefits listed on the wage determination for the applicable classification. If the Administrator of the Wage and Hour Division of the U.S. Department of Labor determines that a different practice prevails for the applicable apprentice classification, fringes shall be paid in accordance with that determination. In the event the Bureau of Apprenticeship and Training, or a State Apprenticeship Agency recognized by the Bureau, withdraws approval of an apprenticeship program, the contractor will no longer be permitted to utilize apprentices at less than the applicable predetermined rate for the work performed until an acceptable program is approved. (ii) Trainees - Except as provided in 29 CFR 5.16, trainees will not be permitted to work at less than the predetermined rate for the work performed unless they are employed pursuant to and individually registered in a program which has received prior approval, evidenced by formal certification by the U.S. Department of Labor, Employment and Training Administration. The ratio of trainees to journeymen on the job site shall not be greater than permitted under the plan approved by the Employment and Training Administration. Every trainee must be paid at not less than the rate specified in the approved program for the trainee's level of progress, expressed as a percentage of the journeyman hourly rate specified in the applicable wage determination. Trainees shall be paid fringe benefits in accordance with the provisions of the trainee program. If the trainee program does not mention fringe benefits, trainees shall be paid the full amount of fringe benefits listed on the wage determination unless the Administrator of the Wage and Hour Division determines that there is an apprenticeship program associated with the corresponding journeyman wage rate on the wage determination which provides for less than full fringe benefits for apprentices. Any employee listed on the payroll at a trainee rate who is not registered and participating in a training plan approved by the Employment and Training Administration shall be paid not less than the applicable wage rate on the wage determination for the classification of work actually performed. In addition, any trainee performing work on the job site in excess of the ratio permitted under the registered program shall be paid not less than the applicable wage rate on the wage determination for the work actually performed. In the event the Employment and Training Administration withdraws approval of a training program, the contractor will no longer be permitted to utilize trainees at less than the applicable predetermined rate for the work performed until an acceptable program is approved. (iii) Equal employment opportunity - The utilization of apprentices, trainees and journeymen under this part shall be in conformity with the equal employment opportunity requirements of Executive Order 11246, as amended, PURCHASE ORDER PO Number Page 9124615 11 of 18 This number must appear on all invoices, packing slips and labels. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax: 970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Line Description Quantity Ordered UOM Unit Price Extended Price subcontractor with all the contract clauses in 29 CFR 5.5. (7) Contract termination: debarment - A breach of the contract clauses in 29 CFR 5.5 may be grounds for termination of the contract, and for debarment as a contractor and a subcontractor as provided in 29 CFR 5.12. (8) Compliance with Davis-Bacon and Related Act requirements - All rulings and interpretations of the Davis- Bacon and Related Acts contained in 29 CFR parts 1, 3, and 5 are herein incorporated by reference in this contract. (9) Disputes concerning labor standards - Disputes arising out of the labor standards provisions of this contract shall not be subject to the general disputes clause of this contract. Such disputes shall be resolved in accordance with the procedures of the Department of Labor set forth in 29 CFR parts 5, 6, and 7. Disputes within the meaning of this clause include disputes between the contractor (or any of its subcontractors) and the contracting agency, the U.S. Department of Labor, or the employees or their representatives. (10) Certification of eligibility - (i) By entering into this contract, the contractor certifies that neither it (nor he or she) nor any person or firm who has an interest in the contractor's firm is a person or firm ineligible to be awarded Government contracts by virtue of section 3(a) of the Davis-Bacon Act or 29 CFR 5.12(a)(1). (ii) No part of this contract shall be subcontracted to any person or firm ineligible for award of a Government contract by virtue of section 3(a) of the Davis-Bacon Act or 29 CFR 5.12(a)(1). (iii) The penalty for making false statements is prescribed in the U.S. Criminal Code, 18 U.S.C. 1001. 7. CONTRACT WORK HOURS AND SAFETY STANDARDS ACT Background and Application The Contract Work Hours and Safety Standards Act is codified at 40 USC 3701, et seq. The Act applies to grantee contracts and subcontracts " financed at least in part by loans or grants from … the [Federal] Government." 40 USC 3701(b)(1)(B)(iii) and (b)(2), 29 CFR 5.2(h), 49 CFR 18.36(i)(6). Although the original Act required its application in any construction contract over $2,000 or non-construction contract to which the Act applied over $2,500 (and language to that effect is still found in 49 CFR 18.36(i)(6)), the Act no longer applies to any " contract in an amount that is not greater than $100,000." 40 USC 3701(b)(3) (A)(iii). The Act applies to construction contracts and, in very limited circumstances, non-construction projects that employ " laborers or mechanics on a public work." These non-construction applications do not generally apply to transit procurements because transit procurements (to include rail cars and buses) are deemed " commercial items." 40 USC 3707, 41 USC 403 (12). A grantee that contemplates entering into a contract to procure a developmental or unique item should consult counsel to determine if the Act applies to that procurement and that additional language required by 29 CFR 5.5(c) must be added to the basic clause below. The clause language is drawn directly from 29 CFR 5.5(b) and any deviation from the model clause below should be coordinated with counsel to ensure the Act' s requirements are satisfied. Clause Language Contract Work Hours and Safety Standards (1) Overtime requirements - No contractor or subcontractor contracting for any part of the contract work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in such workweek. (2) Violation; liability for unpaid wages; liquidated damages - In the event of any violation of the clause set forth in paragraph (1) of this section the contractor and any subcontractor responsible therefore- shall be liable for the PURCHASE ORDER PO Number Page 9124615 12 of 18 This number must appear on all invoices, packing slips and labels. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax: 970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Line Description Quantity Ordered UOM Unit Price Extended Price (3) Withholding for unpaid wages and liquidated damages - The ( write in the name of the grantee ) shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2) of this section. (4) Subcontracts - The contractor or subcontractor shall insert in any subcontracts the clauses set forth in paragraphs (1) through (4) of this section and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor shall be responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in paragraphs (1) through (4) of this section. 8. ENERGY CONSERVATION REQUIREMENTS Energy Conservation - The contractor agrees to comply with mandatory standards and policies relating to energy efficiency which are contained in the state energy conservation plan issued in compliance with the Energy Policy and Conservation Act. 9. RECYCLED PRODUCTS Recovered Materials - The contractor agrees to comply with all the requirements of Section 6002 of the Resource Conservation and Recovery Act (RCRA), as amended (42 U.S.C. 6962), including but not limited to the regulatory provisions of 40 CFR Part 247, and Executive Order 12873, as they apply to the procurement of the items designated in Subpart B of 40 CFR Part 247. 10. ADA Access Accessibility. Facilities to be used in public transportation service must comply with 42 U.S.C. Sections 12101 et seq . and DOT regulations, " Transportation Services for Individuals with Disabilities (ADA)," 49 CFR Part 37; and Joint ATBCB/DOT regulations, " Americans with Disabilities (ADA) Accessibility Specifications for Transportation Vehicles," 36 CFR Part 1192 and 49 CFR Part 38. Notably, DOT incorporated by reference the ATBCB' s " Americans with Disabilities Act Accessibility Guidelines" (ADAAG), revised July 2004, which include accessibility guidelines for buildings and facilities, and are incorporated into Appendix A to 49 CFR Part 37. DOT also added specific provisions to Appendix A modifying the ADAAG, with the result that buildings and facilities must comply with both the ADAAG and amendments thereto in Appendix A to 49 CFR Part 37. General Decision Number: CO120008 08/31/2012 CO8 Superseded General Decision Number: CO20100008 State: Colorado Construction Type: Building County: Larimer County in Colorado. BUILDING CONSTRUCTION PROJECTS (does not include residential construction consisting of single family homes and apartments up to and including 4 stories) Modification Number Publication Date 0 01/06/2012 1 01/13/2012 PURCHASE ORDER PO Number Page 9124615 13 of 18 This number must appear on all invoices, packing slips and labels. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax: 970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Line Description Quantity Ordered UOM Unit Price Extended Price 2 01/27/2012 3 02/24/2012 4 04/06/2012 5 05/18/2012 6 06/01/2012 7 07/27/2012 8 08/03/2012 9 08/17/2012 10 08/31/2012 ASBE0028-001 07/01/2010 Rates Fringes Asbestos Workers/Insulator (Includes application of all insulating materials, protective coverings, coatings and finishings to all types of mechanical systems)....................$ 30.23 11.53 ---------------------------------------------------------------- CARP1001-001 05/01/2009 Rates Fringes CARPENTER (Including Formbuilding and Metal Stud Work)........$ 26.60 8.89 ---------------------------------------------------------------- CARP1607-002 06/01/2012 Rates Fringes MILLWRIGHT.......................$ 28.95 11.10 ---------------------------------------------------------------- ELEC0068-009 06/01/2011 Rates Fringes ELECTRICIAN (Including Low Voltage Wiring and Installation of Communications Systems, Security Systems, Telephones, and Temperature Controls).......$ 31.60 12.57 ---------------------------------------------------------------- ELEV0025-002 01/01/2012 PURCHASE ORDER PO Number Page 9124615 14 of 18 This number must appear on all invoices, packing slips and labels. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax: 970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Line Description Quantity Ordered UOM Unit Price Extended Price Rates Fringes Elevator Constructor.............$ 39.34 23.535 FOOTNOTE: a. Employer contributes 8% of basic hourly rate for over 5 years' service and 6% basic hourly rate for 6 months' to 5 years' service as Vacation Pay Credit. PAID HOLIDAYS: New Year's Day; Memorial Day; Independence Day; Labor Day; Veterans Day; Thanksgiving Day; Friday after Thanksgiving Day; and Christmas Day. ---------------------------------------------------------------- IRON0024-001 07/01/2011 Rates Fringes IRONWORKER, STRUCTURAL...........$ 23.80 10.91 ---------------------------------------------------------------- PAIN0930-001 07/01/2012 Rates Fringes GLAZIER..........................$ 27.77 7.42 ---------------------------------------------------------------- PLAS0577-001 08/01/2011 Rates Fringes Cement Mason/Concrete Finisher...$ 23.00 10.75 ---------------------------------------------------------------- PLUM0003-001 07/01/2012 Rates Fringes PLUMBER (Excluding HVAC work).......$ 33.18 11.44 ---------------------------------------------------------------- * PLUM0208-001 07/12/2012 Rates Fringes PIPEFITTER (Including HVAC pipe).......$ 30.10 11.52 ---------------------------------------------------------------- SHEE0009-001 01/01/2011 Rates Fringes PURCHASE ORDER PO Number Page 9124615 15 of 18 This number must appear on all invoices, packing slips and labels. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax: 970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Line Description Quantity Ordered UOM Unit Price Extended Price Sheet metal worker (Includes HVAC duct and installation of HVAC systems)....................$ 31.66 10.98 ---------------------------------------------------------------- SUCO2001-015 12/20/2001 Rates Fringes LABORER Common......................$ 9.56 2.36 ---------------------------------------------------------------- WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental. ================================================================ Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)). ---------------------------------------------------------------- The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is union or non-union. Union Identifiers An identifier enclosed in dotted lines beginning with characters other than "SU" denotes that the union classification and rate have found to be prevailing for that classification. Example: PLUM0198-005 07/01/2011. The first four letters , PLUM, indicate the international union and the four-digit number, 0198, that follows indicates the local union number or district council number where applicable , i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. The date, 07/01/2011, following these characters is the effective date of the most current negotiated rate/collective bargaining agreement which would be PURCHASE ORDER PO Number Page 9124615 16 of 18 This number must appear on all invoices, packing slips and labels. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax: 970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Line Description Quantity Ordered UOM Unit Price Extended Price July 1, 2011 in the above example. Union prevailing wage rates will be updated to reflect any changes in the collective bargaining agreements governing the rate. Non-Union Identifiers Classifications listed under an "SU" identifier were derived from survey data by computing average rates and are not union rates; however, the data used in computing these rates may include both union and non-union data. Example: SULA2004-007 5/13/2010. SU indicates the rates are not union rates, LA indicates the State of Louisiana; 2004 is the year of the survey; and 007 is an internal number used in producing the wage determination. A 1993 or later date, 5/13/2010, indicates the classifications and rates under that identifier were issued as a General Wage Determination on that date. Survey wage rates will remain in effect and will not change until a new survey is conducted. ---------------------------------------------------------------- WAGE DETERMINATION APPEALS PROCESS 1.) Has there been an initial decision in the matter? This can be: * an existing published wage determination * a survey underlying a wage determination * a Wage and Hour Division letter setting forth a position on a wage determination matter * a conformance (additional classification and rate) ruling On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.) and 3.) should be followed. With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to: Branch of Construction Wage Determinations PURCHASE ORDER PO Number Page 9124615 17 of 18 This number must appear on all invoices, packing slips and labels. City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax: 970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Line Description Quantity Ordered UOM Unit Price Extended Price Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W. Washington, DC 20210 2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to: Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W. Washington, DC 20210 The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue. 3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to: Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W. Washington, DC 20210 4.) All decisions by the Administrative Review Board are final. ================================================================ END OF GENERAL DECISION Total $15,176.00 Purchase Order Terms and Conditions 1. COMMERCIAL DETAILS. Tax exemptions. By statute the City of Fort Collins is exempt from state and local taxes. Our Exemption Number is 98-04502. Federal Excise Tax Exemption Certificate of Registry 84-6000587 is registered with the Collector of Internal Revenue, Denver, Colorado (Ref. Colorado Revised Statutes 1973, Chapter 39-26, 114 (a). Goods Rejected. GOODS REJECTED due to failure to meet specifications, either when shipped or due to defects of damage in transit, may be returned to you for credit and are not to be replaced except upon receipt of written instructions from the City of Fort Collins. Inspection. GOODS are subject to the City of Fort Collins inspection on arrival. Final Acceptance. Receipt of the merchandise, services or equipment in response to this order can result in authorized payment on the part of the City of Fort Collins. However, it is to be understood that FINAL ACCEPTANCE is dependent upon completion of all applicable required inspection procedures. Freight Terms. Shipments must be F.O.B., City of Fort Collins, 700 Wood St., Fort Collins, CO 80522, unless otherwise specified on this order. If permission is given to prepay freight and charge separately, the original freight bill must accompany invoice. Additional charges for packing will not be accepted. Shipment Distance. Where manufacturers have distributing points in various parts of the country, shipment is expected from the nearest distribution point to destination, and excess freight will be deducted from Invoice when shipments are made from greater distance. Permits. Seller shall procure at sellers sole cost all necessary permits, certificates and licenses required by all applicable laws, regulations, ordinances and rules of the state, municipality, territory or political subdivision where the work is performed, or required by any other duly constituted public authority having jurisdiction over the work of vendor. Seller further agrees to hold the City of Fort Collins harmless from and against all liability and loss incurred by them by reason of an asserted or established violation of any such laws, regulations, ordinances, rules and requirements. Authorization. All parties to this contract agree that the representatives are, in fact, bona fide and possess full and complete authority to bind said parties. LIMITATION OF TERMS. This Purchase Order expressly limits acceptance to the terms and conditions stated herein set forth and any supplementary or additional terms and conditions annexed hereto or incorporated herein by reference. Any additional or different terms and conditions proposed by seller are objected to and hereby rejected. 2. DELIVERY. PLEASE ADVISE PURCHASING AGENT immediately if you cannot make complete shipment to arrive on your promised delivery date as noted. Time is of the essence. Delivery and performance must be effected within the time stated on the purchase order and the documents attached hereto. No acts of the Purchasers including, without limitation, acceptance of partial late deliveries, shall operate as a waiver of this provision. In the event of any delay, the Purchaser shall have, in addition to other legal and equitable remedies, the option of placing this order elsewhere and holding the Seller liable for damages. However, the Seller shall not be liable for damages as a result of delays due to causes not reasonably foreseeable which are beyond its reasonable control and without its fault of negligence, such acts of God, acts of civil or military authorities, governmental priorities, fires, strikes, flood, epidemics, wars or riots provided that notice of the conditions causing such delay is given to the Purchaser within five (5) days of the time when the Seller first received knowledge thereof. In the event of any such delay, the date of delivery shall be extended for the period equal to the time actually lost by reason of the delay. 3. WARRANTY. The Seller warrants that all goods, articles, materials and work covered by this order will conform with applicable drawings, specifications, samples and/or other descriptions given, will be fit for the purposes intended, and performed with the highest degree of care and competence in accordance with accepted standards for work of a similar nature. The Seller agrees to hold the purchaser harmless from any loss, damage or expense which the Purchaser may suffer or incur on account of the Sellers breach of warranty. The Seller shall replace, repair or make good, without cost to the purchaser, any defects or faults arising within one (1) year or within such longer period of time as may be prescribed by law or by the terms of any applicable warranty provided by the Seller after the date of acceptance of the goods furnished hereunder (acceptance not to be unreasonably delayed), resulting from imperfect or defective work done or materials furnished by the Seller. Acceptance or use of goods by the Purchaser shall not constitute a waiver of any claim under this warranty. Except as otherwise provided in this purchase order, the Sellers liability hereunder shall extend to all damages proximately caused by the breach of any of the foregoing warranties or guarantees, but such liability shall in no event include loss of profits or loss of use. NO IMPLIED WARRANTY OR MERCHANTABILITY OR OF FITNESS FOR PURPOSE SHALL APPLY. 4. CHANGES IN LEGAL TERMS. The Purchaser may make changes to legal terms by written change order. 5. CHANGES IN COMMERCIAL TERMS. The Purchaser may make any changes to the terms, other than legal terms, including additions to or deletions from the quantities originally ordered in the specifications or drawings, by verbal or written change order. If any such August, 2012 Independent Cost Estimate: Replacement of two garage doors at Transfort Facility Replacement of the garage doors should be between $ 6,000.00 and $ 8,000.00 each based past purchase orders for replacement of doors and controllers that occurred at Transfort between 2001 and 2003. Price Analysis The replacement doors and controllers in the wash bay were bid by the following two companies: Dollars reflect total price for two doors, two controllers and accessories: Overhead Door Company of Fort Collins – $ 15,176.00 Front Range Raynor – $ 15,564.00 The bids received are in-line with the ICE for replacement of doors and controllers including the need for the controller to have a NEMA 4 enclosure due to the wet environment they will be located in. change affects the amount due or the time of performance hereunder, an equitable adjustment shall be made. 6. TERMINATIONS. The Purchaser may at any time by written change order, terminate this agreement as to any or all portions of the goods then not shipped, subject to any equitable adjustment between the parties as to any work or materials then in progress provided that the Purchaser shall not be liable for any claims for anticipated profits on the uncompleted portion of the goods and/or work, for incidental or consequential damages, and that no such adjustment be made in favor of the Seller with respect to any goods which are the Sellers standard stock. No such termination shall relieve the Purchaser or the Seller of any of their obligations as to any goods delivered hereunder. 7. CLAIMS FOR ADJUSTMENT. Any claim for adjustment must be asserted within thirty (30) days from the date the change or termination is ordered. 8. COMPLIANCE WITH LAW. The Seller warrants that all goods sold hereunder shall have been produced, sold, delivered and furnished in strict compliance with all applicable laws and regulations to which the goods are subject. The Seller shall execute and deliver such documents as may be required to effect or evidence compliance. All laws and regulations required to be incorporated in agreements of this character are hereby incorporated herein by this reference. The Seller agrees to indemnify and hold the Purchaser harmless from all costs and damages suffered by the Purchaser as a result of the Sellers failure to comply with such law. 9. ASSIGNMENT. Neither party shall assign, transfer, or convey this order, or any monies due or to become due hereunder without the prior written consent of the other party. 10. TITLE. The Seller warrants full, clear and unrestricted title to the Purchaser for all equipment, materials, and items furnished in performance of this agreement, free and clear of any and all liens, restrictions, reservations, security interest encumbrances and claims of others. Page 18 of 18 11. NONWAIVER. Failure of the Purchaser to insist upon strict performance of the terms and conditions hereof, failure or delay to exercise any rights or remedies provided herein or by law, failure to promptly notify the Seller in the event of a breach, the acceptance of or payment for goods hereunder or approval of the design, shall not release the Seller of any of the warranties or obligations of this purchase order and shall not be deemed a waiver of any right of the purchaser to insist upon strict performance hereof or any of its rights or remedies as to any such goods, regardless of when shipped, received or accepted, as to any prior or subsequent default hereunder, nor shall any purported oral modification or rescission of this purchase order by the Purchaser operate as a waiver of any of the terms hereof. 12. ASSIGNMENT OF ANTITRUST CLAIMS. Seller and the Purchaser recognize that in actual economic practice, overcharges resulting from antitrust violations are in fact borne by the Purchaser. Theretofore, for good cause and as consideration for executing this purchase order, the Seller hereby assigns to the Purchaser any and all claims it may now have or hereafter acquired under federal or state antitrust laws for such overcharges relating to the particular goods or services purchased or acquired by the Purchaser pursuant to this purchase order. 13. PURCHASERS PERFORMANCE OF SELLERS OBLIGATIONS. If the Purchaser directs the Seller to correct nonconforming or defective goods by a date to be agreed upon by the Purchaser and the Seller, and the Seller thereafter indicates its inability or unwillingness to comply, the Purchaser may cause the work to be performed by the most expeditious means available to it, and the Seller shall pay all costs associated with such work. The Seller shall release the Purchaser and its contractors of any tier from all liability and claims of any nature resulting from the performance of such work. This release shall apply even in the event of fault of negligence of the party released and shall extend to the directors, officers and employees of such party. The Seller's contractual obligations, including warranty, shall not be deemed to be reduced, in any way, because such work is performed or caused to be performed by the Purchaser. 14. PATENTS. Whenever the Seller is required to use any design, device, material or process covered by letter, patent, trademark or copyright, the Seller shall indemnify and save harmless the Purchaser from any and all claims for infringement by reason of the use of such patented design, device, material or process in connection with the contract, and shall indemnify the Purchaser for any cost, expense or damage which it may be obliged to pay by reason of such infringement at any time during the prosecution or after the completion of the work. In case said equipment, or any part thereof or the intended use of the goods, is in such suit held to constitute infringement and the use of said equipment or part is enjoined, the Seller shall, at its own expense and at its option, either procure for the Purchaser the right to continue using said equipment or parts, replace the same with substantially equal but noninfringing equipment, or modify it so it becomes noninfringing. 15. INSOLVENCY. If the Seller shall become insolvent or bankrupt, make an assignment for the benefit of creditors, appoint a receiver or trustee for any of the Sellers property or business, this order may forthwith be canceled by the Purchaser without liability. 16. GOVERNING LAW. The definitions of terms used or the interpretation of the agreement and the rights of all parties hereunder shall be construed under and governed by the laws of the State of Colorado, USA. The following Additional Conditions apply only in cases where the Seller is to perform work hereunder, including the services of Sellers Representative(s), on the premises of others. 17. SELLERS RESPONSIBILITY. The Seller shall carry on said work at Seller's own risk until the same is fully completed and accepted, and shall, in case of any accident, destruction or injury to the work and/or materials before Seller's final completion and acceptance, complete the work at Seller's own expense and to the satisfaction of the Purchaser. When materials and equipment are furnished by others for installation or erection by the Seller, the Seller shall receive, unload, store and handle same at the site and become responsible therefor as though such materials and/or equipment were being furnished by the Seller under the order. 18. INSURANCE. The Seller shall, at his own expense, provide for the payment of workers compensation, including occupational disease benefits, to its employees employed on or in connection with the work covered by this purchase order, and/or to their dependents in accordance with the laws of the state in which the work is to be done. The Seller shall also carry comprehensive general liability including, but not limited to, contractual and automobile public liability insurance with bodily injury and death limits of at least $300,000 for any one person, $500,000 for any one accident and property damage limit per accident of $400,000. The Seller shall likewise require his contractors, if any, to provide for such compensation and insurance. Before any of the Sellers or his contractors employees shall do any work upon the premises of others, the Seller shall furnish the Purchaser with a certificate that such compensation and insurance have been provided. Such certificates shall specify the date when such compensation and insurance have been provided. Such certificates shall specify the date when such compensation and insurance expires. The Seller agrees that such compensation and insurance shall be maintained until after the entire work is completed and accepted. 19. PROTECTION AGAINST ACCIDENTS AND DAMAGES. The Seller hereby assumes the entire responsibility and liability for any and all damage, loss or injury of any kind or nature whatsoever to persons or property caused by or resulting from the execution of the work provided for in this purchase order or in connection herewith. The Seller will indemnify and hold harmless the Purchaser and any or all of the Purchasers officers, agents and employees from and against any and all claims, losses, damages, charges or expenses, whether direct or indirect, and whether to persons or property to which the Purchaser may be put or subject by reason of any act, action, neglect, omission or default on the part of the Seller, any of his contractors, or any of the Sellers or contractors officers, agents or employees. In case any suit or other proceedings shall be brought against the Purchaser, or its officers, agents or employees at any time on account or by reason of any act, action, neglect, omission or default of the Seller of any of his contractors or any of its or their officers, agents or employees as aforesaid, the Seller hereby agrees to assume the defense thereof and to defend the same at the Sellers own expense, to pay any and all costs, charges, attorneys fees and other expenses, any and all judgments that may be incurred by or obtained against the Purchaser or any of its or their officers, agents or employees in such suits or other proceedings, and in case judgment or other lien be placed upon or obtained against the property of the Purchaser, or said parties in or as a result of such suits or other proceedings, the Seller will at once cause the same to be dissolved and discharged by giving bond or otherwise. The Seller and his contractors shall take all safety precautions, furnish and install all guards necessary for the prevention of accidents, comply with all laws and regulations with regard to safety including, but without limitation, the Occupational Safety and Health Act of 1970 and all rules and regulations issued pursuant thereto. Revised 03/2010 unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1) of this section. and 29 CFR part 30. (5) Compliance with Copeland Act requirements - The contractor shall comply with the requirements of 29 CFR part 3, which are incorporated by reference in this contract. (6) Subcontracts - The contractor or subcontractor shall insert in any subcontracts the clauses contained in 29 CFR 5.5(a)(1) through (10) and such other clauses as the Federal Transit Administration may by appropriate instructions require, and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor shall be responsible for the compliance by any subcontractor or lower tier (4) Apprentices and trainees - (i) Apprentices - Apprentices will be permitted to work at less than the predetermined rate for the work they performed when they are employed pursuant to and individually registered in a bona fide apprenticeship program registered with the U.S. Department of Labor, Employment and Training Administration, Bureau of Apprenticeship and Training, or with a State Apprenticeship Agency recognized by the Bureau, or if a person is employed in his or her first 90 days of probationary employment as an apprentice in such an apprenticeship program, who is not individually registered in the program, but who has been certified by the Bureau of (3) Payrolls and basic records - (i) Payrolls and basic records relating thereto shall be maintained by the contractor during the course of the work and preserved for a period of three years thereafter for all laborers and mechanics working at the site of the work (or under the United States Housing Act of 1937, or under the Housing Act of 1949, in the construction or development of the project). Such records shall contain the name, address, and social security number of each such worker, his or her correct classification, hourly rates of wages paid (including rates of contributions or costs anticipated for bona fide fringe benefits or cash equivalents thereof of the types described in section 1(b)(2)(B) of first day on which work is performed in the classification. (iii) Whenever the minimum wage rate prescribed in the contract for a class of laborers or mechanics includes a fringe benefit which is not expressed as an hourly rate, the contractor shall either pay the benefit as stated in the wage determination or shall pay another bona fide fringe benefit or an hourly cash equivalent thereof. (iv) If the contractor does not make payments to a trustee or other third person, the contractor may consider as part of the wages of any laborer or mechanic the amount of any costs reasonably anticipated in providing bona fide fringe benefits under a plan or program, Provided, That the Secretary of Labor has found, upon the written Housing Act of 1937 or under the Housing Act of 1949 in the construction or development of the project), will be paid unconditionally and not less often than once a week, and without subsequent deduction or rebate on any account (except such payroll deductions as are permitted by regulations issued by the Secretary of Labor under the Copeland Act (29 CFR part 3)), the full amount of wages and bona fide fringe benefits (or cash equivalents thereof) due at time of payment computed at rates not less than those contained in the wage determination of the Secretary of Labor which is attached hereto and made a part hereof, regardless of any contractual relationship d. The contractor is required to pay its subcontractors performing work related to this contract for satisfactory performance of that work no later than 30 days after the contractor' s receipt of payment for that work from the City of Fort Collins . In addition, [the contractor may not hold retainage from its subcontractors.] [is required to return any retainage payments to those subcontractors within 30 days after the subcontractor's work related to this contract is satisfactorily completed.] [is required to return any retainage payments to those subcontractors within 30 days after incremental acceptance of the subcontractor' s work by the City of Fort Collins and and Federal policies that may in the future affect construction activities undertaken in the course of the Project. The Contractor agrees to take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, creed, national origin, sex, or age. Such action shall include, but not be limited to, the following: employment, upgrading, demotion or transfer, recruitment or recruitment advertising, layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. In addition, the Contractor agrees to comply with any implementing conditions of this Contract within [ten (10) days] after receipt by Contractor of written notice from the City setting forth the nature of said breach or default, the City shall have the right to terminate the Contract without any Contract Operational Turnkey Construction Architectural Acquisition Professional Characteristics Service Engineering of Rolling Stock Services I State Grantees a. Contracts below None Those None None None None