Loading...
HomeMy WebLinkAbout126722 WIRELESS ADVANCED COMMUNICATIONS - PURCHASE ORDER - 9124394City of art Collins PURCHASE ORDER PO Number Page 9124394 1of2 r s number must appear all invoices, packing ps and labels. Date: 08/10/2012 Vendor: 126722 Ship To: STREETS DEPARTMENT WIRELESS ADVANCED COMMUNICATIONS CITY OF FORT COLLINS 3901 W SERVICE RD 625 NINTH STREET EVANS Colorado 80620 FORT COLLINS Colorado 80524 Delivery Date: 08/10/2012 Buyer: DOUG CLAPP Note: Line Description Quantity Ordered UOM Unit Price Extended Price 1 AS PER QUOTE 638 1 LOT LS 7,883.75 2 CREDIT MEMO: CM-1016 1 LOT LS -3,300.00 3 CREDIT MEMO: CM-1013 1 LOT LS -4,000.00 Dept: Streets Deliver to: Attn: Scott Bowman 970-221-6762 625 9th Street Fort Collins, CO 80524 Total $583.75 City of Fort Collins Director of Purchasing and Risk Management This order is not valid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO BOX 580, Fort Collins, CO 80522-0580 Phone:970-221-6775 Fax:970-221-6707 Email:purchasing@fcgov.com Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Purchase Order l"emis and Conditions Page 2 of 2 I. COMMERCIAL DETAILS. Tax exemptions. By statute the City of Fart Collins is exempt from stare and local taxes. Our Exemption Number is 11. NONWAIVER. 98-04502. Federal Excise Tax Exemption Certificate of Registry 84-6000587 is registered with the Collector of Failure of the Purchaser Io insist upon strict performance of the terms and conditions hereof, failure or delay to Internal Revenue, Deaver. Colorado (Ref. Colorado Revised Statutes 1973, Chapter 39 26, 114 (a). exercise any rights or remedies provided herein or by law, failure 10 promptly notify the Seller in the event of a breach, the acceptance of or payment for goods hereunder or approval of the design, shall not release the Seller of Goods Rejected. GOODS REJECTED due to failure to meet specifications, either when shipped or due to defects of any of the warranties or obligations of this purchase order and shall not be deemed a waiver of any right of the damage in transit, may be returned to you for credit and are not to be replaced except upon receipt of written Purchaser to insist upon strict performance hereofor any ofits rights or remedies m to any such goods, regardless insurrections from the City o-Fort Collins. of when shipped, received or accepted, as to any prior or subsequent default hereunder, nor shall any outpaced oral modification or rescission of this purchase order by the Purchaser operate as a waiver of any of the terns Inspection. GOODS am subject to the City of Fan Collins inspection on arrival. hereof. Final Acceptance. Receipt of the merchandise, services or equipment in response to this order can result in 12. ASSIGNMENT OF ANTITRUST CLAIMS. authorized payment on the pan of the City of Fort Collins. However, it is to be understood that FINAL Seller and the Purchaser recognize that in actual economic practice, overcharges resulting from antitrust ACCEPTANCE is dependent upon completion of all applicable required inspection procedures. violations are in fact home by the Purchaser. Theretofore, for good cause and as consideration for executing this purchase order, the Seller hereby assigns to the Purchaser any and all claims it may now have or hereafter Freight Terns. Shipments most be F.O.B., City of Fort Collins, 700 Wood St., Fort Collins, CO 80522, unless acquired under federal or state antitrust laws for such overcharges relating to the particular goods or services otherwise specified on this order. If permission is given to prepay freight and charge separately, the original freight purchased or acquired by the Purchaser personal to this purchase order. bill musr accompany invoice. Additional charges for packing will not be accepted. 13. PURCHASERS PERFORMANCE OF SELLERS OBLIGATIONS. Shipment Distance. Where manufacturers have distributing points in various parts of the country, shipment is If the Pnrchnser directs the Seller to correct nonconforming or defective goods by a date to be agreed upon by the expected from the nearest distribution point to destination, and excess freight will be deducted from Invoice when Pnrchnser and the Seller, and the Seller thereafter indicates its inability or unwillingness to comply, the Purchaser shipments are made form greater defiance. may cause the work to be performed by the most expeditious means available to it, and the Seller shall pay all costs associated with such work. Permits. Seller shall procure at sellers sole cost all necessary permits, certificates and licenses required by all applicable laws, regulations, ordinances and rates of the state, municipality, territory or political subdivision where the work is performed, or required by any other duly constituted public authority having jurisdiction over the work of vendor. Seller further agrees to hold the City of Fort Collins harmless from and against all liability and loss incurred by them by reason of an asserted or established violation of any such laws, regulations, ordinances, rates and requirements. Authorization. All parties to this contract agree that the representatives are, in fact, bona fide and possess fall and complete authority to hind said parties. LIMITATION OF TERMS. This Purahrsa Order expressly limits acceptance to the terns and conditions slated herein set font, and any supplementary or additional terms and conditions annexed hereto or incorporated herein by reference. Any additional or different tens and conditions proposed by seller are objected mind hereby rejected. 2. DELIVERY, PLEASE ADVISE PURCHASING AGENT immediately if you cannot make complete shipment to arrive on your promised delivery date as noted. Tinte is of the essence. Delivery and performance must be effected within the time stated on the purchase order and the documents attached hereto. No acts of the Purchasers including, without limitation, acceptance of partial late deliveries, shall operate m a waiver of this provision. In the event of any delay, the Purchaser shall have, in addition to other legal and equitable remedies, the option of placing this order elsewhere and holding the Seller liable for damages. However, the Seller shall not be liable for damages as a result of delays due to causes not reasonably foreseeable which are beyond its reasonable control and without its fault of negligence, such acts of God, acts of civil or military authorities, governmental priorities, fires, strikes, flood, epidemics, wars or riots provided that notice of the conditions causing such delay is given to the Purchaser within five (5) days of the time when the Seller first received knowledge thereof. In the event of any such delay, the date of delivery shall be extended for the period equal to the time actually lost by reason of the delay. 3. WARRANTY. The Seller watrans that all goods, articles, materials and work covered by this order will conform with applicable drawings, specifications, samples an&or other descriptions given, will be fit for the purposes intended, and performed with the highest degree of care and competence in accordance with accepted standards for work of a similar nature. The Seller agrees to hold the purchaser harmless from any loss, damage or expense which the Purchaser may suffer or incur on account of the Sellers breach of warranty. The Seller shall replace, repair or make good, without cost to the purchaser, any defects or faults arising within one (1) year or within such longer period of time m may be prescribed by law or by the tents of any applicable warranty provided by the Seller after the date of acceptance of the goods furnished hereunder (acceptance not to be unreasonably delayed), resulting from imperfect or defective work done or materials furnished by the Seller. Acceptance or use of goods by the Purchaser shall not constitute a waiver of any claim under this warranty. Except as otherwise provided in this purchase order, the Sellers liability hereunder shall extend to all damages proximately coursed by the breach ofany of the foregoing warranties, or guarantees, but such liability shall in no event include loss of profits or loss of use. NO IMPLIED WARRANTY OR MERCHANTABILITY OR OF FITNESS FOR PURPOSE SHALL APPLY. 4. CHANGES IN LEGAL TERMS. The Purchaser may make changes to legal tens by written change order. 5. CHANGES IN COMMERCIAL TERMS. The Purchaser may make any changes to the terms, other than legal terms, including additions to or deletions from the quantities originally ordered in the specifications or drawings, by verbal or written change order. If any such change affects the amount due or the time of perfunance hereunder, an equitable adjustment shall be made. 6. TERMINATIONS. The Purchaser may at any time by written change order, terminate this agreement m to any or all portions of the goods then not shipped, subject to any equitable adjustment between the panics as to any work or materials then in progress provided that the Purchaser shall not be liable for any claims for anticipated profits on the uncompleted portion of the goods and/or work, for incidental or consequential damages, and that no such adjustment be made in favor of the Seller with respect to any goods which are the Sellers standard stock. No such termination shall relieve the Purchaser or the Seller of any of their obligations as to any goods delivered hereunder. 7. CLAIMS FOR ADJUSTMENT. Any claim for adjustment must be asserted within thirty (30) days from the date the change or termination is ordered. 8. COMPLIANCE WITH LAW. The Seller w'a.m that all goods sold hereunder shall have been produced, sold, delivered and famished in strict compliance with all applicable laws and regulations to which the goods are subject. The Seller shall execute and deliver such documents as may be required to effect or evidence compliance. All laws and regulations required to be incorporated in agreements of this character are hereby incorporated herein by this reference. The Seller agrees to indemnify and hold the Purchuer harmless from all costs and damages suffered by the Purchaser as a result of the Sellers failure to comply with such law. 9. ASSIGNMENT. Neither party shall assign, transfer, or convey this order, or any monies due or to become due hereunder without the prior written consent of the other party. 10. TITLE. The Seller warrants full, clear and unrestricted title to the Purchaser for all equipment, materials, and items famished in performance of this agreement, free and clear of any and all liens, restrictions, reservations, security interest encumbrances and claims of others. The Seller shall release the Purchaser mud its contractors of any tier from all liability and claims of any nature resulting from the pctfonnance of such work. This release shall apply even in the event of fault of negligence of the party released and shall extend to the directors, officers and employees of arch party. The Seller's contractual obligations, including warranty, shall not be deemed to be reduced, in any way, because such work is penonned or caused to be performed by the Purchaser. 14. PATENT S. Whenever the Seller is required to use any design, device, material or process covered by letter, patent, trademark or copyright, the Seller shall indenmify and save honless the Purchaser from any and all claims for infringement by reason of the use of soul, pmemed design, device, material or process in connection with the contract, and shall indenmify the Pnrchnser [',,,any cost, expense or damage which it may be obliged to pay by reason of such infringement no may time during the prosecution or after the completion of the work. In case said equipment, or any part thereof or the intended use of the goods, is in such suit held to constitute infringement and the use of said equipment or pan is enjoined, the Seller shall, at its own expense and at its option, either procure for the Purchaser the right to eontione using said equipment or parts, replace the same with substantially equal but noninfringing equipment, or modify it so it becomes noninfringing. 15. INSOLVENCY. If the Seller shall become insolvent or bankrupt, make an assignment for the benefit of creditors, appoint a receiver or trustee for any of the Sellers property or business, this order may forthwith be canceled by the Purchaser without liability. 16. GOVERNING LAW. The definitions ofternu used or the interprcmtion afthe agreement and the rights ofall parries hereunder sha11 be construed under and governed by the laws ofthe State of Colorado, USA. The following Additional Conditions apply only in cases where the Seller is to perform work hereunder, including the services of Sellers Representative(s), on the premises ofothers. 17, SELLERS RESPONSIBILITY. The Seller shall tarty on said work at Sellers own risk until the same is fully completed and accepted, and shall, in case of any accident, destruction or injury to the work and/or materials before Sellers final completion and acceptance, complete the work at Seller's awn expense and to the satisfaction of the Purchaser. When materials and equipment are famished by others for installation or erection by the Seller, the Seller shall receive, unload, stare and handle same at the site anti become responsible therefor m though such materials and/or equipment were being famished by the Seller under the order. 18. INSURANCE. The Seller shall, at his own expense, provide lot the payment of workers compensation, including occupational disease benefits, to its employees employed on or in connection with the work covered by this purchase order, and/or to their dependents in accordance with the laws of the state in which the work is to be done. The Seller shaft also carry comprehensive general liability including, but not limited to, contractual and automobile public liability insurance with bodily injury and death limits of at least S300,000 for any one person, S500,000 for any one accident and property damage limit per accident of S400,000. The Seller shall likewise require his contractors, if any, to provide f'or such compensation and insurance. Before any of the Sellers or his contractors employees shift du any work upon the premises of others, the Seller shall famish the Purchaser with a certificate that such commpereation and insurance have been provided Such certificates shall specify the date when such compensation unit insurance have been provided. Such certificates shall specify the date when such compensation and insurance expires. The Seiler agrees that such compensation and insurance shall be maintained until after the entire work is completed and accepted. 19. PROTECTION AGAINST ACCIDENTS AND DAMAGES. The Seller hereby assumes the entire responsibility and liability for any and all damage, lass or injury ofany kind or nature whatsoever to persons or property caused by or resulting from the execution of the work provided for in this purchase order or in connection herewith. The Seller will indemnify and hold harmless the Purchaser and any or all of the Purchasers officers, agents and employees from and against any and all claims, losses, damages, charges or expenses, whether direct or indirect, and whether to persons or property to which the Purchaser may be put or subject by mason of any act, action, neglect, omission or default on the pan of the Seller, any of his contmcmrs, or any of the Sellers or contractors officers, agents or employees. In case any suit ar other proceedings shall be brought against the Purchaser. or its officers, agents or employees at any time on account or by reason of any act, action, neglect, omission or default of the Seller of any of his contractors or any of its or their officers, agents or employees as aforesaid, the Seller hereby agrees to assume the defense thereof and to defend the same at the Sellers own expense, to pay any and all costs, charges, attorneys fees and other expenses, any and all judgments that may be incurred by or obtained against the Purchaser or any of its or their officers, agents or employees in such suits or other proceedings, and in case judgment or other lien be placed upon or obtained against the property of the Purchaser, or said parties in or as a result of such suits or other proceedings, the Seller , i11 at once cause the same to be dissolved and discharged by giving bond or otherwise. The Seller and his contractor shall take all safety precautions, famish and install all guards necessary for the prevention of accidents, comply with all laws and regulations with regard to safety including, but without limitation, the Occupational Safety and Health Act of 1970 and all rules and regulations issued pursuant thereto. Revised 03/2010