HomeMy WebLinkAbout109420 HYDRO CONSTRUCTION CO INC - CONTRACT - RFP - 7220 WATER WW TREATMENT & SITE INFRASTRUCTURE DESI1 City of
1 Fort Collins
1 ! Purchasing
1
1
1
1
1
1
1
1
1
Financial Services
Purchasing Division
215 N. Mason St. 2n0 Floor
PO Sox 580
Fort Collins, CO 80522
970.221.6775
970.221.6707
lcgov.com/purchasing
CONTRACT DOCUMENTS
FORT COLLINS UTILITIES
FOR
CONSTRUCTION WORK ORDERS:
(Contract forms, Conditions of the Contract, General Requirements)
1 Date: May 11, 2011
1 Contractor: Hydro Construction Company, Inc
1 RFP #: 7220 Water/Wastewater Treatment & Site Infrastructure
Design/Construction Contractor
1
1
1
I
1
ARTICLE 7. CONTRACT DOCUMENTS
7.1 The Contract Documents concerning the Work comprise the
entire Agreement between OWNER and CONTRACTOR. Covenants or
representations not contained in this Agreement shall not be binding
on the parties. The Contract Documents consist of the General
Conditions, the Supplementary Conditions, those items listed in
Article 1.10 of the General Conditions, each signed and executed Work
Order, and such other items as are referenced in this Article 7, all
of which are incorporated herein by this reference.
7.2. Forms for
use
by CONTRACTOR in performing the
Work
'
specified in any Work
Order,
and related actions in carrying out
the
terms of this Agreement,
are deemed Contract Documents
and
'
incorporated herein by
00900, these include,
this
but
reference. Included in Sections 00600
are not necessarily limited to,
and
the
following:
7.2.1.
Certificate
of Substantial Completion
7.2.2.
Certificate
of Final Acceptance
7.2.3.
Lien Waiver
Releases
7.2.4.
7.2.5.
Consent of
Application
Surety
for Exemption Certificate
7.2.6.
Application
for Payment
7.3. Drawings, as specified and identified in each Work Order.
The Contract Drawings for a Work Order shall be stamped "Final for
Construction" and dated. Any revisions made shall be clearly
' identified and dated.
7.4. The Contract Documents also include all written amendments
and other documents amending, modifying, or supplementing the Contract
Documents pursuant to paragraphs 3.5 and 3.6 of the General
Conditions, including amendments to any Work Order.
' 7.5. There are no Contract Documents other than those listed or
incorporated by reference in this Article 7. The Contract Documents,
including executed Work Orders issued under this Agreement, may only
be amended, modified or supplemented as provided in paragraphs 3.5 and
3.6 of the General Conditions.
ARTICLE 8. MISCELLANEOUS
8.1. Definitions. Terms used in this Agreement which are
defined in Article 1 of the General Conditions shall have the meanings
indicated in the General Conditions.
8.2. Assignment. No assignment by a party hereto of any rights
under or interests in the Contract Documents will be binding on
' another party hereto without the written consent of the party sought
to be bound; and specifically but not without limitations, moneys that
' AGREEMENT 00520- Page 7
I
' may become due and moneys that are due may not be assigned without
such consent (except to the extent that the effect of this restriction
may be limited by law), and unless specifically stated to the contrary
in any written consent to an assignment no assignment will release or
discharge that assignor from any duty or responsibility under the
Contract Document.
8.3. Binding Effect. OWNER and CONTRACTOR each binds itself,
its partners, officers, employees, successors, agents, assigns and
' legal representatives to the other party hereto, its partners,
officers, employees, successors, agents, assigns, and legal
representatives in respect to all covenants, Agreement and obligations
contained in the Contract Documents.
8.4. Independent Contractor. It is agreed that in the
performance of any services hereunder, CONTRACTOR is an independent
' contractor responsible to OWNER only as to the results to be obtained
in the particular work assignment and to the extent that the work
shall be done in accordance with the terms, plans and specifications
furnished by OWNER. CONTRACTOR shall neither assign any
responsibilities nor delegate any duties arising under the Agreement
without the prior written consent of OWNER.
8.5. Acceptance Not Waiver. OWNER'S approval or acceptance of,
or payment for, any of the Work shall not be construed to operate as a
waiver of any rights under the Agreement or of any cause of action
' arising out of the performance of this Agreement.
8.6. Default. Each and every term and condition hereof shall be
deemed to be a material element of this Agreement. In the event
either party should fail or refuse to perform according to the terms
of this agreement, such party may be declared in default thereof.
8.7. Remedies. In the event a party has been declared in
default, such defaulting party shall be allowed a period of ten (10)
days within which to cure said default. In the event the default
remains uncorrected, the party declaring default may elect to (a)
terminate the Agreement and seek damages; (b) treat the Agreement as
continuing and require specific performance; or (c) avail himself of
any other remedy at law or equity. If the non -defaulting party
commences legal or equitable actions against the defaulting party, the
defaulting party shall be liable to the non -defaulting party for the
non -defaulting party,s reasonable attorney fees and costs incurred
' because of the default.
8.8. Law / Severability. This Agreement shall be governed in
all respects by the laws of the State of Colorado. In the event any
' provision of this Agreement shall be held invalid or unenforceable by
any court of competent jurisdiction, such holding shall not invalidate
or render unenforceable any other provision of this Agreement.
' AGREEMENT 00520- Page 8
-- -
I
I
1
1
8.9 Amendment 54. To the extent that this Agreement may
constitute a "sole source government contract" within the meaning of
Section 2(14.4) of Article XXVIII of the constitution of the State of
Colorado, about which the City makes no representation, Section 15 of
said Article XXVIII, which reads as follows, is hereby incorporated
into this Agreement and made a part hereof:
a. Section 15. Because of a presumption of impropriety
between contributions to any campaign and sole source government
contracts, contract holders shall contractually agree, for the
duration of the contract and for two years thereafter, to cease
making, causing to be made, or inducing by any means, a contribution,
directly or indirectly, on behalf of the contract holder or on behalf
of his or her immediate family member and for the benefit of any
political party or for the benefit of any candidate for any elected
office of the state (of Colorado) or any of its political
subdivisions.
OWNER: CITY OF FORT COLLINS
ByQ-La
BY:
,("6rL JAMES B. O'NEILL II, CPPO,
-0 DIRECTOR OF PURCHASING
1AND RISK MANAGEMENT
Date: 5 - -,) �,, l
Attest:
Approv s to Form:
Ass'st nt City Attorney
AGREEMENT
FNIGP
CONTRACTOR:HYDRO CONSTRUCTION COMPANY,
INC.
Name �ILIYVI `tS ` • IL'tw...L L4
Title:
Date: IG I I 1
(CORPORATE SEAL)
Attest: -
Name: I-14 ey 2'-- 1YCn/fSE✓
License No.
00520- Page 9
I
Exhibit A
> construction cost factors
Exhibit A
> design phase cost
Hourly rates associated with the design phase are as follows:
James Eurich - Project Manager $67.00 per hour
Stan Javemick - Project Manager $60.00 per hour
Tom Noble & John Podeyn - Project Superintendent $58.00 per hour
Subcontractor (when necessary) - $65.00 per hour
Additional expenses - at cost
The proposed team offers extensive experience related to APDS projects and similar treatment
plant projects, which is demonstrated throughout this proposal.
I
SECTION 00525
WORK ORDER & NOTICE OF AWARD
'
TO: Hydro Construction Company, Inc.
WORK ORDER NUMBER:
PURCHASE ORDER NUMBER:
WORK ORDER TITLE:
'
ENGINEER:
OWNER'S REPRESENTATIVE:
NOTICE OF AWARD DATE:
I
I
I
I
r
11
i
I
I
OWNER: CITY OF FORT COLLINS (hereinafter referred to as OWNER)
1. WORK. You are hereby notified that your Bid dated , 2011, for
the above Work Order has been considered. Pursuant to your AGREEMENT with
OWNER dated , you have been awarded a Work Order for this Work
Order Description: shall be inclusive
of all projects associated with the Water, Wastewater Treatment and Site
Infrastructure Design/Construction Contractor as defined in the Master
Agreement dated , 2011. The charges and fees are defined in
Attachment A, hereby attached and incorporated as a part of this
agreement.
2. CONTRACT PRICE, BONDS, AND CERTIFICATES. The Price of your
Work Order is . Pursuant to the AGREEMENT and the
Contract Documents, Performance and Payment Bonds and insurance
are required.
3. CONTRACT TIMES. Pursuant to the AGREEMENT and the Contract
Documents, the number of days or the date for Substantial
Completion of this Work Order is , and, after
Substantial Completion, the number of days or the date for Final
Payment and Acceptance is
4. LIQUIDATED DAMAGES. Pursuant to the AGREEMENT and the
Contract Documents:
A. Substantial Completion: ($ ) for
each calendar day or fraction thereof that expires after
the (_) calendar day period for Substantial
Completion of the Work of this Work Order until the Work is
Substantially Complete.
B. Final Acceptance: After Substantial Completion,
($ ) for each calendar day or
fraction thereof that expires after the ( )
calendar day period for Final Payment and Acceptance of the
I5/98 WORK ORDER & NOTICE OF AWARD
00525• Page I
Work of this Work Order until the Work is ready for Final
Payment and Acceptance.
5. EXECUTION. Three (3) copies of this proposed Work Order & Notice of
Award, and accompanying amendments or supplements to the Contract
Documents (except any applicable Drawings) incorporated herein, are
provided. Four (4) sets of any applicable Drawings will be delivered
separately or otherwise made available to you immediately. You must
comply with the following conditions precedent within fifteen (15) days of
the date of this Work Order & Notice of Award, that is, by , 2011.
A. You must deliver to OWNER Three(3) fully executed counterparts of
this Work Order, including all amendments or supplements to the
Contract Documents incorporated herein. Each Work Order must bear
your signature as provided.
B. You must deliver with the executed Work Order the Contract
Security (Bonds) and insurance, as specified in the Agreement, this
Work Order, the General Conditions (Article 5.1) and the
Supplementary Conditions.
Failure to comply with these conditions within the time specified will
entitle OWNER to consider your Bid abandoned and to annul this Work Order
& Notice of Award. Within ten (10) days after you comply with those
conditions, OWNER will return to you one (1) fully signed counterpart of
this Work Order with any amendments or supplements to the Contract
Documents attached.
CONTRACTOR'S WORK ORDER REPRESENTATION & EXECUTION:
CONTRACTOR agrees to perform the services identified above, and in the
attached Contract Documents consisting of (_) pages, in
accordance with the terms and conditions contained herein and in the
AGREEMENT dated , between the parties. In the event of a conflict
between or ambiguity in the terms of the AGREEMENT and this Work Order
(included the attached Contract Documents), the AGREEMENT shall control.
CONTRACTOR: Hydro Construction Company, Inc.
By: Date:
Name:
5/98 WORK ORDER & NOTICE OF AWARD
Title:
00525- Page 2
11
I
I
A
1
A
' O
T
h
A
A
By: Date: _
JAMES B. O'NEILL II, CPPO, FNIGP
DIRECTOR OF PURCHASING AND RISK MANAGEMENT
(if greater than $60,000)
i
1
1
1
5/98 WORK ORDER & NOTICE OF AWARD
00525- Page 3
SECTION 00530 '
WORK ORDER NOTICE TO PROCEED
WORK ORDER TITLE:
WORK ORDER NUMBER: t
NOTICE TO PROCEED DATE:
TO:Hydro Construction Company Inc
Attn: James Eurich, Project manager
301 East Lincoln Avenue
Fort Collins, CO 80524
This notice is to advise you:
That the Work Order and all amendments and supplements to the Contract
Documents covering the above described Work have been fully executed
by the CONTRACTOR and the OWNER. That the required CONTRACTOR's
Performance and Payment Bonds and insurance have been received by the
OWNER. That the OWNER has approved the said work Order and Contract
Documents.
Therefore, as the CONTRACTOR for the above described Work, you
are hereby authorized and directed to proceed within
( ) calendar days from receipt of this notice as
required by the Work Order and the AGREEMENT.
The dates for Substantial Completion and Final Acceptance shall be
, and I , respectively.
Dated this day of
CITY OF FORT COLLINS
'
OWNER
By:
Name & Title
ACKNOWLEDGMENT OF NOTICE
'
Receipt of the above Work Order Notice to Proceed is hereby
acknowledged this day of
Hydro Construction Company Inc.
CONTRACTOR
By:
Name & Title
5/98 WORK ORDER NOTICE TO PROCEED
00530- Page 1
,
11
SECTION 00600
BONDS AND CERTIFICATES
00610 Performance Bond
00615 Payment Bond
00630 Certificate of Insurance
00635 Certificate of Substantial Completion
00640 Certificate of Final Acceptance
00650 Lien Waiver Release (CONTRACTOR)
00651 Lien Waiver Release (SUBCONTRACTOR)
00660 Consent of Surety
00670 Application for Exemption Certificate
5/98 WORK ORDER NOTICE TO PROCEED
00530- Page 2
I
1
1
1
i
i
1
1
1
1
U1
1
1
1
1
11
1
CONTRACT DOCUMENTS TABLE OF CONTENTS
Section
CONTRACT DOCUMENTS
00500
Construction work Order Agreement Forms
00520
Agreement - Construction Work Order Type
00525
Work Order & Notice of Award
00530
Work Order Notice to Proceed
00600
Bonds and Certificates
00610
Performance Bond
00615
Payment Bond
00630
Certificate of Insurance
00635
Certificate of Substantial Completion
00640
Certificate of Final Acceptance
00650
Lien Waiver Release (CONTRACTOR)
00651
Lien Waiver Release (SUBCONTRACTOR)
00660
Consent of Surety
00670
Application for Exemption Certificate
CONDITIONS
OF THE CONTRACT
00700
General Conditions
Exhibit GC -A
00800
Supplementary Conditions
00900 Addenda, Modifications, and Payment
Pages
00520-1
- 00520-8
00525-1
- 00525-3
00530-1
00530-1
00600
00610-1
- 00610-2
00615-1
- 00615-2
00630-1
00635-1
00640-1
00650-1
- 00650-2
00651-1
- 00651-2
00660-1
00670-1 -
00670-2
00700-1 - 00700-34
GC -Al - GC-A2
00800-1 - 0800-4
00960-1 - 00960-4
SECTION 00610
PERFORMANCE BOND
Bond No
KNOW ALL MEN BY THESE PRESENTS: that Hydro Construction Company Inc., a
Corporation, hereinafter referred to as the "Principal" and
(Firm)
(Address)
hereinafter referred to as "the Surety", are held and firmly bound unto
City of Fort Collins, 300 LaPorte Ave Fort Collins Colorado 80522 a
(Municipal Corporation) hereinafter referred to as the "OWNER", in the
penal sum of in lawful money of the United
States, for the payment of which sum well and truly to be made, we bind
ourselves, successors and assigns, jointly and severally, firmly by these
presents.
THE CONDITIONS OF THIS OBLIGATION are such that whereas the Principal
entered into a certain Agreement with the OWNER, dated the _ day of
2011, a copy of which is hereto attached and made a part hereof, for the
performance of The City of Fort Collins Work Order, titled
Work Order Number, dated the _
day of_, 2011, a copy of which is hereto attached_and made a part
hereof.
NOW, THEREFORE, if the Principal shall well, truly and faithfully perform
its duties, all the undertakings, covenants, terms, conditions and
agreements of said Work Order and Agreement during the original term
thereof, and any extensions thereof which may be granted by the OWNER,
with or without Notice to the Surety and during the life of the guaranty
period, and if the Principal shall satisfy all claims and demands incurred
under such Work Order and Agreement, and shall fully indemnify and save
harmless the OWNER from all cost and damages which it may suffer by reason
of failure to do so, and shall reimburse and repay the OWNER all outlay
and expense which the OWNER may incur in making good any default, then
this obligation shall be void; otherwise to remain in full force and
effect.
PROVIDED, FURTHER, that the said Surety, for value received, hereby
stipulates and agrees that no change, extension of time, alteration or
addition to the terms of the Work Order and Agreement or to the Work to be
performed thereunder or the Specifications accompanying the same shall in
any way affect its obligation on this bond; and it does hereby waive
notice of any such change, extension of time, alteration or addition to
the terms of the Work Order and Agreement or to the Work or to the
Specifications.
PROVIDED, FURTHER, that no final settlement between the OWNER and the
CONTRACTOR shall abridge the right of any beneficiary hereunder, whose
claim may be unsatisfied.
PROVIDED, FURTHER, that the Surety Company must be authorized to transact
business in the State of Colorado and be acceptable to the OWNER.
I
11
I
I
0
I
l
LJ
D
I
0
I
8
I
5198 PERFORMANCE BOND I
00610- Page 1
1
IN WITNESS WHEREOF, this instrument is executed in four (4) counterparts,
' each one of which shall be deemed an original, this day of
IN PRESENCE OF: Principal
(Corporate Seal)
' IN PRESENCE OF:
(Surety Seal)
(Name & Title)
Surety
By:_
(Name) Attorney -in -Fact
(Company)
(Address)
NOTE: Date of Bond must not be prior to date of Work Order.
PERFORMANCE BOND
00610- Page 2
SECTION 00615
PAYMENT BOND
Bond No.
KNOW ALL MEN BY THESE PRESENTS: that _Hydro Construction Company,
Inc., a Corporation, hereinafter referred to as the "Principal"
and
(Firm)
(Address)
hereinafter referred to as "the Surety", are held and firmly bound unto
City of Fort Collins 300 LaPorte Ave Fort Collins Colorado 80522 a
(Municipal Corporation) hereinafter referred to as the "OWNER", in the
penal sum of in lawful money of the United
States, for the payment of which sum well and truly to be made, we bind
ourselves, successors and assigns, jointly and severally, firmly by these
presents.
THE CONDITIONS OF THIS OBLIGATION are such that whereas the Principal
entered into a certain Agreement with the OWNER, dated the _ day of_
2011, a copy of which is hereto attached and made a part hereof, for the
performance of The City of Fort Collins Work Order, titled
Work Order Number dated the th day of , 20_, a copy of
which is hereto attached and made a part hereof.
NOW, THEREFORE, if the Principal shall make payment to all persons, firms,
subcontractors, and corporations furnishing materials for or performing
labor in the prosecution of the Work provided for in such Work Order and
Agreement and any authorized extension or modification thereof, including
all amounts due for materials, lubricants, repairs on machinery, equipment
and tools, consumed, rented or used in connection with the construction of
such Work, and all insurance premiums on said Work, and for all labor,
performed in such Work whether by subcontractor or otherwise, then this
obligation shall be void; otherwise to remain in full force and effect.
PROVIDED, FURTHER, that the said Surety, for value received, hereby
stipulates and agrees that no change, extension of time, alteration or
addition to the terms of the Work Order and Agreement or to the Work to be
performed thereunder or the Specifications accompanying the same shall in
any way affect its obligation on this bond; and it does hereby waive
notice of any such change, extension of time, alteration or addition to
the terms of the Work Order and Agreement or to the Work or to the
Specifications.
PROVIDED, FURTHER, that no final settlement between the OWNER and the
CONTRACTOR shall abridge the right of any beneficiary hereunder, whose
claim may be unsatisfied.
PROVIDED, FURTHER, that the Surety Company must be authorized to transact
business in the State of Colorado and be acceptable to the OWNER.
5/98 PAYMENT BOND
00615- Page
IN WITNESS WHEREOF, this instrument is executed in four (4) counterparts,
each one of which shall be deemed an original, this day of
IN PRESENCE OF: Principal
(Corporate Seal)
IN PRESENCE OF:
(Surety Seal)
(Name & Title)
Surety
By:
Name) Attorney -in -Fact
(Company)
Address)
NOTE: Date of Bond must not be prior to date of Work Order.
5/98 PAYMENT BOND
00615- Page 2
SECTION 00630 '
CERTIFICATE OF INSURANCE
CONTRACTOR shall insert his own standard form for Certificate of
Insurance.
1
t
1_1
5/98 CERTIFICATE OF INSURANCE
00630- Page I ,
I
1
11
I
' rPOTICIr ATC Yn1 nCD
ACORO® CERTIFICATE OF LIABILITY INSURANCE
A Milli
DATE(MMDDIYYYY)
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.
IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to
the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the
certificate holder in lieu of such endorsement(s).
PRODUCER 1-303-534-4567
CONTACT
NAME:
PHONE FAX
A/C No):
IMA of Colorado, Inc.
p�REss:
1550 17th Street
PRODUCER
CUSTOMER ID #-
Suite 600
Denver, CO 80202
INSURER(S)AFFORDING COVERAGE
NAIC #
INSURED
INSURER A: TRAVELERS IND CO
25658
INSURERS: TRAVELERS PROP CAS CO OF AMER
25674
Hydro Construction Company, Inc.
INSURERC: PINNACOL ASSDR
41190
301 East Lincoln Avenue
INSURER D :
Fort Collins, CO 80524
INSURER E :
INSURER F :
rnL/CDAGCC rCOTICICATF MI IMr2FR• 21295314 RFVIi1111%1 NIIMHIFR•
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
INSR
LTR
TYPE OF INSURANCE
ADDL SUBR POLICY NUMBER MMIDDPOLICYNYYY MMIDDEFF Y EXP
LIMA
A
GENERAL LIABILITY
R COMMERCIAL GENERAL LIABILITY
CLAIMS -MADE O OCCUR
R PD Ded:$5,000
DTC08743RO161ND10
09/30/1
09/30/11
EACH OCCURRENCE
$ 1,000,000
DAMAGE T RENTED
PREMISES Ea occurrence)
ccurrence
$ 300,000
MED EXP (Anyone person)
$ 10,000
PERSONAL a ADV INJURY
$ 1,000,000
GENERAL AGGREGATE
$ 2,000,000
GENT AGGREGATE LIMIT APPLIES PER
POLICY R PRO- LOCI
PRODUCTS - COMP/OP AGG
$ 2,000,000
$
B
AUTOMOBILE
LIABILITY
ANY AUTO
ALL OWNED AUTOS
SCHEDULED AUTOS
HIREDAUTOS
NON-OWNEDAUTOS
DT8108743RO16TIL10
09/30/1
09/30/11
COMBINED SINGLE LIMIT
(Ea accident)
$ 1,000,000
R
BODILY INJURY (Per person)
$
BODILY INJURY (Per accident)
$
PROPERTY DAMAGE
(Per accident)
$
R
R
$
$
B
R
UMBRELLA LAB
EXCESS LIAB
R
OCCUR
CLAIMS -MADE
DTSMCUP8743RO16TILIO
09/30/1
09/30/11
EACH OCCURRENCE
$ 1,000,000
AGGREGATE
$ 1,000,000
R
DEDUCTIBLE
RETENTION $ 10,000
$
$
C
WORKERS COMPENSATION
AND EMPLOYERS' LIABILITY
ANY PROPRIETOR/PARTNER/EXECUTIVE FN
OFFICERWEMBER EXCLUDED?
(Mandatory In NH)
If yes, describe under
DESCRIPTION OF OPERATIONS below
NIA
2091550
04/01/1
04/01/12
R WCSI IMIT ER
E.L. EACH ACCIDENT
$ 1,000, 000
E.L. DISEASE - EA EMPLOYEq
$ 1,000,000
E.L. DISEASE -POLICY LIMIT
$ 1, 000, 000
DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (Attach ACORD 101, Additional Remarks Schedule, if more space Is required)
City of Fort Collins is included as Additional Insured on the General Liability Policy if required by written contract
or agreement and with respect to work performed by Insured subject to the policy terns and conditions.
rekiroi I ATinu
RE: 7220 water/Wastewater Treatment E Site Infrastructure
Design/Construction Contractor.
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
City of Fort Collins
THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN
ACCORDANCE WITH THE POLICY PROVISIONS.
700 Wood Street
AUTHORIZED REPRESENTATIVE
Fort Collins, CO 80521-0000
qqq
USA
BD-Ld1
'ACORD 25 (2009109)
21295314
V T9SS--lUU9 AGUH:U GUHPUNAI IUN. All rights reserved.
The ACORD name and logo are registered marks of ACORD
SECTION 00635
' CERTIFICATE OF SUBSTANTIAL COMPLETION
TO: CITY OF FORT COLLINS (OWNER)
WORK ORDER NUMBER:
' DATE OF SUBSTANTIAL COMPLETION:
WORK ORDER TITLE:
PROJECT OR SPECIFIED PART SHALL INCLUDE:
' LOCATION: Fort Collins, Colorado OWNER: City of Fort Collins
CONTRACTOR: Hydro Construction Company, Inc.
CONTRACT DATE: WORK ORDER DATE:
The Work performed under this Work Order, pursuant to the Contract
' Documents, has been inspected by authorized representatives of the OWNER,
CONTRACTOR, and the ENGINEER and the project (or specified part of the
project, as indicated above) is hereby declared to be substantially
completed on the above date. A tentative list of items to be completed or
' corrected is appended hereto. This list may not be exhaustive, and the
failure to include an item on it does not alter the responsibility of the
CONTRACTOR to complete all the Work in accordance with the Contract
Documents.
By:
ENGINEER AUTHORIZED REPRESENTATIVE DATE
The CONTRACTOR accepts the above Certificate of Substantial Completion and
agrees to complete and correct the items on the tentative list within the
' time indicated.
By:
CONTRACTOR AUTHORIZED REPRESENTATIVE DATE
' The OWNER accepts the project or specified area of the project as
substantially complete and will assume full possession of the project or
specified area of the project at 12:01 a.m., on The
' responsibility for heat, utilities, security, and insurance under the
Contract Documents shall be as set forth under "Remarks" below.
' CITY OF FORT COLLINS, COLORADO
By:
OWNER AUTHORIZED REPRESENTATIVE DATE
J
2
SECTION 00640
CERTIFICATE OF FINAL ACCEPTANCE
TO: Hydro Construction Coompany, Inc
Gentlemen:
You are hereby notified that on the day of the
City of Fort Collins, Colorado, has accepted the Work completed by
for the City of Fort Collins Work Order, titled
Work Order Number
A check is attached hereto in the amount of $ as
Final Payment for all Work done, subject to the terms of the Contract
Documents, including the Work Order, which is dated , 20 and the
AGREEMENT, which is dated , 20
In conformance with the Work Order and Contract Documents for this
project, your obligations and guarantees will continue for the specified
time from the following date:
Sincerely,
City of Fort Collins
OWNER
By:
Name & Title
ATTEST:
Name & Title
5/98 CERTIFICATE OF FINAL ACCEPTANCE
000640- Page 1
I
u
[]
1
I
I
SECTION 00650
LIEN WAIVER RELEASE
(CONTRACTOR)
TO: City of Fort Collins, Colorado (OWNER)
FROM: Hydro Construction Company, Inc (CONTRACTOR)
WORK ORDER TITLE:
WORK ORDER NUMBER:
1. The CONTRACTOR acknowledges having received payment, except retainage
from the OWNER for all work, labor, skill and material furnished,
delivered and performed by the CONTRACTOR for the OWNER or for anyone in
the construction, design, improvement, alteration, addition or repair of
the above described project.
2. In consideration of such payment and other good and valuable
consideration, the receipt and adequacy of which are hereby acknowledged,
the CONTRACTOR voluntarily waives all rights, claims and liens, including
but not limited to, mechanic's liens, Miller Act claims (40 U.S.C.A. 270 a
and b), stop notices, equitable liens and labor and material bond rights
which the CONTRACTOR may now or may afterward have, claim or assert for
all and any work, labor, skill or materials furnished, delivered or
performed for the construction, design, improvement, alteration, addition
or repair of the above described project, against the OWNER or its
officers, agents, employees or assigns, against any fund of or in the
possession or control of the OWNER, against the project or against all
land and the buildings on and appurtenances to the land improved by the
project.
3. The CONTRACTOR affirms that all work, labor and materials,
furnished, delivered or performed to or for the construction, design,
improvement, alteration, addition or repair of the project were furnished,
delivered or performed by the CONTRACTOR or its agents, employees, and
servants, or by and through the CONTRACTOR by various Subcontractors or
materialmen or their agents, employees and servants and further affirms
the same have been paid in full and have released in full any and all
existing or possible future mechanic's liens or rights or claims against
the project or any funds in the OWNER'S possession or control concerning
the project or against the OWNER or its officers, agents, employees or
assigns arising out of the project.
4. The CONTRACTOR agrees to defend and hold harmless the OWNER, the
' lender, if any, and the Surety on the project against and from any claim
hereinafter made by the CONTRACTOR's Subcontractors, materialmen,
employees, servants, agents or assigns against the project or against the
' OWNER or its officers, employees, agents or assigns arising out of the
project for all loss, damage and costs, including reasonable attorneys
fees, incurred as a result of such claims.
t S. The parties acknowledge that the description of the project set forth
above constitutes an adequate description of the property and improvements
5/98 LfEN WAIVER RELEASE(CONTRACTOR
00650 Page
•
u
to which this Lien Waiver Release pertains. It is further acknowledged
that this Lien Waiver Release is for the benefit of and may be relied upon
by the OWNER, the lender, if any, and Surety on any labor and material
bonds for the project.
Signed this day of
CONTRACTOR
By:
Name & Title
ATTEST:
Secretary
STATE OF COLORADO)
) ss.
COUNTY OF LARIMER)
Subscribed and sworn to before me this day of
by
Witness my hand and official seal.
My Commission Expires:
5/98 LIEN WAIVER RELEASE(CONTRACTOR
Notary Public
00650 Page 2
SECTION 00500
CONSTRUCTION WORK ORDER AGREEMENT FORMS
00520 Agreement - Construction Work Order Type
00525 Work Order & Notice of Award
00530 Work Order Notice to Proceed
I
SECTION 00650
' LIEN WAIVER RELEASE
(SUBCONTRACTOR)
TO: Hydro Construction Company, Inc (CONTRACTOR)
' FROM: (Subcontractor)
WORK ORDER TITLE:
' WORK ORDER NUMBER:
' 1. The Subcontractor acknowledges having received payment from the
CONTRACTOR for all work, labor, skill and material furnished, delivered
and performed by the Subcontractor for the CONTRACTOR or for anyone in the
construction, design, improvement, alteration, addition or repair of the
above described project.
2. In consideration of such payment and other good and valuable
consideration, the receipt and adequacy of which are hereby acknowledged,
the Subcontractor voluntarily waives all rights, claims and liens,
including but not limited to, mechanic's liens, Miller Act claims (40
U.S.C.A. 270 a and b), stop notices, equitable liens and labor and
' material bond rights which the Subcontractor may now or may afterward
have, claim or assert for all and any work, labor, skill or materials
furnished, delivered or performed for the construction, design,
improvement, alteration, addition or repair of the above described
project, against the CONTRACTOR or its officers, agents, employees or
assigns, against the project or against all land and the buildings on and
appurtenances to the land improved by the project.
3. The Subcontractor affirms that all work, labor and materials,
furnished, delivered or performed to or for the construction, design,
improvement, alteration, addition or repair of the project were furnished,
delivered or performed by the Subcontractor or its agents, employees, and
servants, or by and through the Subcontractor by various sub -
subcontractors or materialmen or their agents, employees and servants, and
further affirms the same have been paid in full and have released in full
' any and all existing or possible future mechanic's liens or rights or
claims against the project or against the CONTRACTOR or its officers,
agents, employees or assigns arising out of the project.
' 4. The Subcontractor agrees to defend and hold harmless the CONTRACTOR,
the lender, if any, and the Surety on the project against and from any
claim hereinafter made by the Subcontractor's sub -subcontractors,
materialmen, employees, servants, agents or assigns against the project or
against the CONTRACTOR or OWNER, lender or Surety or their officers,
employees, agents or assigns arising out of the project for all loss,
damage and costs, including reasonable attorneys fees, incurred as a
result of such claims.
5. The parties acknowledge that the description of the project set
' forth above constitutes an adequate description of the property and
improvements to which this Lien Waiver Release pertains. It is further
' 5/98 LIEN WAIVER RELEASE (SUBCONTRACTOR)
00650 Page 3
acknowledged that this Lien Waiver Release is for the benefit of and may
be relied upon by the CONTRACTOR, OWNER, the lender, if any, and Surety on
any labor and material bonds for the project.
Signed this day of _
SUBCONTRACTOR
By:
Name & Title
ATTEST:
Secretary
STATE OF COLORADO)
)ss.
COUNTY OF LARIMER)
Subscribed and sworn to before me this day of
by
Witness my hand and official seal
My Commission Expires:
Notary Public
5/98 LIEN WAIVER RELEASE (SUBCONTRACTOR)
00650 Page 4
SECTION 00660
CONSENT OF SURETY
TO: City of Fort Collins Colorado
(hereinafter referred to as the "OWNER")
'
CONTRACTOR: Hydro Construction Company Inc
WORK ORDER TITLE:
WORK ORDER NUMBER:
CONTRACT DATE: WORK ORDER DATE:
In accordance with the provisions of the Work Order and Contract between
the OWNER and the CONTRACTOR as indicated above, for the Work Order titled
'
on bond of (Surety)
hereby approves of the Final
Payment to the CONTRACTOR, and agrees that Final Payment to the CONTRACTOR
shall not relieve the Surety Company of any of its obligations to the
'
OWNER, as set forth in the said Surety Company's Bond.
IN WITNESS WHEREOF, the Surety Company has hereunto set its hand this
day of ,
' (Surety Company)
By:
(Name) Attorney -in -Fact
' ATTACH: Power of Attorney and Certificate of Authority of Attorney(s)-in-
Fact.
5/98 CONSENT OF SURETY
r --
00660-Page j
u
SECTION 00670
APPLICATION FOR EXEMPTION CERTIFICATE
OR 01?2 (12e0)
COLORADO DEPARTMENT OF REVENUE
DENVER (M)Z32CO 00201 CONTRACTOR APPLICATION
) D2-2H G
FOR
EXEMPTION CERTIFICATE
PursuanttoStatute
Section 39-26.114(1)(a)DW
Uo Nor WRITE IN n0$ SPACE
The exemption certificate for which you are applying crust be used onlyfoi the purpose of put chasing construction and building
materials for the exempt project described below, This exemption does not include or apply to the purchase of rental of equipment,
supplies, and materials which are purchased, retied, or consumed by the contractor and which do not become pail of the structure.
highway, road, street, or other public works owned and used by the exempt organization.
Any unauthorized use of the exemption certificate win result in revocation of your exemption certificate and other penalties provided
by law.
A separate certificate is requited for each contract.
Subcontractors will not be issued Certificates of Exemption by the Department of Revenue. It is
the responsibility of the prince
contractor to issue certificates toeach ofthe subcoraraciors. (See reverse side).
FAILURE TO ACCURATELY COMPLETE ALL BOXES WILL CAUSE THE APPUCA TION TO BE DENIED-
egsaLu ra•t o. Eo azReod by
y
89
0171.750 (999) $0.00
CO N TRA CTO R.I N FO RMATI O N
radio nane/D A
.r, panne, a cuponl. mmr
edurg address ( ny, S a . Ip),
lac er son
- Mail address
9 are p oyer s an ce on um a:
amount or your con act
ex um r.
$
eu.mn. l.Nplon. rumWr:
or. orm u.owun rmrl
Copley of contract or agreement pages (1) Identifying the contracting parties EXEMPTION INFORMATION
and (2) containing slgnaoires of contracting partles must be attached.
erne o axamP organ¢a wn as on con rxr
amp orgauze n s number:
98 -
Address of exemp organize n (City. State. zipy -
Pnmpal contact a exemp Orgdn¢d Orr:
-PFj
Indpa con ac e telephone nu ef:
ca ors ono protec iw igive actual ass 7nan appricaSto am cif" or cowry ties)re protec Is located)
Swd.I.d VMS•r •.r
.nmdon nun da.
Eni +Y ur
li Ntloft
oampn d W
I dedere under penalty of perjury in the second degree that the statements made in this application are true and
complete to the best of my knowledge.
Igne e o owner, per er or corpora o car,Tile
;f corporate officer
5/98 CONSENT OF SURETY 00670-Page I
Special Notice
Contractors
who have completed this application in the past, please note the following changes in procedure:
'
The Departrnent will no longer issue individual Certificates of exemption to subcontractors. Only prime contrac-
tors will receive a Contractor's Exemption Certificate on exempt projects.
Upon receipt of the Certificate, the prime contractor should make a copy for each subcontractor involved in the
project and complete it by filling in the subcontractor's name and address and signing it.
The original Certificate
should always be retained by the prime contractor. Copies of all Certificates that the
prime contractor issued to subcontractors should be kept at the prime contractor's place of business for a
minimum of three years and be available for inspection in the
event of an audit.
Once an 89# has been assigned to
you, please use the next five numbers following it for any applications
submitted for future projects. This should be your permanent number. For instance, if you were assigned 89-
12345.0001, every application submitted thereafter should contain 89-12345 on the application. The succeed-
ing numbers will be issued by the Department of Revenue. DO NOT enter what you believe to be the next in
sequence as this may delay processing of your application.
I
5/98 CONSENT OF SURETY
00670-Page 1
---
GENERAL CONDITIONS
OF THE
CONSTRUCTION CONTRACT
These GENERAL CONDITIONS have been developed by using the
STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION
CONTRACT prepared by the Engineers Joint Contract Documents
Committee, EJCDC No. 1910-8 (1990 Edition), as a base. Changes to
that document are shown by underlining test that has been added and
striking through test that has been deleted.
EJCDC GENERAL CONDITIONS 1910-8 (1990 EDITION) '
WITH CITY OF FORT COLLINS MODIFICATIONS (.REV 9/99)
TABLE OF CONTENTS OF GENERAL CONDITIONS
Article or Paragraph Page Article or Paragraph
Number & Title Number Number & Title
DEFINITIONS
1.1
Addenda .............................................
1
1.2
Agreement.................................I.........1
1.3
Application for Payment .......................
1.4
Asbestos.............................................1
1.5
Bid .....................................................!
1.6
Bidding Documents .............................
(
1.7
Bidding Requirements, .........................
1.8
Bonds .................................................
1.9
Change Order,,...,,,,, ,,,,,,,,,,,,,,,,,I
1.10
Contract Documents(
1.11
Contract Price.....................................1
1.12
Contract Times,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,I
1.13
CONTRACTOR
1.14
dejccrive..............................................
1.15
Drawings.............................................1
1.16
Effective Date of the Agreemen►
1
1.17
...........
ENGINEER.........................................1
1.18
ENGINEER's Consultant,,,,,,,,,,,,,,,,,,,,,,1
1.19
Field Order,,,,,,,,,,,,,,,,,,,,
1.20
General Requirements ..........................2
1.21
Hazardous Waste
2
1.22.a
Laws and Regulations; Laws or
Regulations.......................................2
1.22.b
Legal Holidays,,,,....,,,, .........................
2
1.23
Liens..................................................2
1.24
Milestone ..............................
1.25
Notice of Award
2
1.26
Notice to Proceed,,,,,,,,,,,,,,,,2
1.27
OWNER.............................................2
1.28
Partial Utilization
2
1.29
PCBs..................................................2
1.30
Petroleum...........................................2
1.31
Project................................................2
1.32.a
Radioactive Material
1.32.b
Regular Working Hours„.....................2
1.33
Resident Project Representative,,,..,,,,,
2
1.34
Samples..............................................2
1.35
Shop Drawings ...................................?
1.36
Specifications ......................................
2
1.37
Subcontractor
?
1.38
Substantial Completion .......................2
1.39
Supplementary Conditions...................2
1.40
Supplier.,.,,,,,,
z
1.41
Underground Facilities ....... ..............?-3
1.42
Unit Price Work
1.43
Work.................................................3
1.44
Work Change Directive
j
1.45
Written Amendment
In
Page
Number
2. PRELIMINARY MATTERS3
2.1
Delivery of Bonds .............................j
2.2
Copies of Documents ........................
2.3
Commencement of Contract
Times; Notice to Proceed,,,,,,,,,,,,,,,
3
2.4
Starting the Work ............................j
2.5-2.7
Before Starting Construction;
CONTRACTOR's Responsibility
to Report; Preliminary Scheddes;
Delivery of Certificates of
Insurance...................................3-4
2.8
Preconstruction Conference
4
2.9
Initially Acceptable Schedules ..........
4
3. CONTRACT DOCUMENTS: INTENT,
AMENDING, REUSE..........................................4
3.1-3.2
Intent .............................................
4
3.3
Reference to Standards and Speci-
fications of Technical Societies;
Reporting and Resolving Dis-
crepancies ............... . ...............4-5
3.4
Intent of Certain Terms or
Adjectives .....................................
5
3.5
Amending Contract Documents .........
5
3.6
Supplementing Contract
Documents ...................................
5
3.7
Reuse of Documents
4. AVAILABILITY OF LANDS;
SUBSURFACE
AND PHYSICAL CONDITIONS;
REFERENCE POINTS ,
5
4.1
Availability of Lands.....................5-6
4.2
Subsurface and Physical
Conditions. ...................................
6
4.2.1
Reports and Drawings ......................
4.2.2
Limited Reliance by CONTRAC-
TOR Authorized; Technical
Data............................................
6
4.2.3
Notice of Differing Subsurface
or Physical Conditions
6
4.2.4
ENGINEER's Review
4.2.5
„6
Possible Contract Documents
Change.........................................6
4.2.6
Possible Price and Times
Adjustments...............................0-7
4.3
Physical Conditions --Underground
Facilities ..........................
4.3.1
Shown or Indicated
4.3.2
Not Shown or Indicated
7
4.4
Reference Points„,,,,,,,,,,,,,,,,,,,
7
E1CDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
wl CITY OF FORT COLLINS MODIFICATIONS (REV 9/99)
Article or Paragraph Page Article or Paragraph
Number & Title Number Number & Title
Page
Number
4.5
Asbestos. PCBs, Petroleum,
6.25
Submittal Proceedures; CON -
Hazardous Waste or
TRACTOR's Review Prior
Radioactive Material....................7-8
to Shop Drawing or Sample
Submittal....................................16
5. BONDS AND INSURANCE ,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,
8
6.26
Shop Drawing & Sample Submit-
5.1-5.2
Performance, Payment and Other
tals Review by ENGINEER ......
16-17
Bonds .............................................
8
6.27
Responsibility for Variations
5.3
Licensed Sureties and Insurers;
From Contract Documents
17
Certificates of Insurance....................8
6.28
............
Related Work Performed Prior
5.4
CONTRACTOR's Liability
to ENGINEER's Review and
Insurance..........................................9
Approval of Required
5.5
OWNER's Liability Insurance,,,,,,,,,,,,,,
9
Submittals,,,,,,.............................
17
5.6
Property Insurance,,,,,,,,,,,,,,,,, ,,,,,,,,9-10
6.29
Continuing the Work,.,,,,,,, ........17
5.7
Boiler and Machinery or Addi-
6.30
CONTRACTOR's General
tional Property Insurance.................10
Warranty and Guarantee ..............
17
5.8
Notice of Cancellation Prousion.........
10
6.31-6.33
Indemnification .........................J7-18
5.9
CONTRACTOR's Responsibility
6.34
Survival of Obligations,,,,,,,,,,,,,,,,,,,
18
for Deductible Amounts10
5.10
Other Special Insurance ......................10
7. OTHER WORK ,,.,,.,,......,,.,..,,,,,..,,
18
5.11
Waiver of Rights ..... ......... .........1
1
7.1-7.3
Related Work at Site
18
5.12-5.13
Receipt and Application of
7.4
........................
CoordinatioR...............................„
18
Insurance Proceeds,,,,,,,,,,,,,,,,,,,,,
10-11
5.14
Acceptance of Bonds and Instr-
8. OWNER'S
RESPONSIBILITIES ..........................
18
ance; Option to Replace....................11
8.1
Communications to CON-
5.15
Partial Utilization --Property
TRACTOR.................................18
Insurance........................................11
8.2
Replacement of ENGINEER ............
18
8.3
Furnish Data and Pay Promptly
6. CONTRACTOR'S RESPONSIBILITIES ,,,,,,,,,,,,,,,I
I
When Due,,,,,,,.„..,.,,,,,,,,,,,,,,,,,,,,
18
6.1-6.2
Supervision and Superintendence:,,,,,,,
11
8.4
Lands and Easements; Reports
6.3-6.5
Labor, Materials and Equipment..,
11-12
and Tests ................................
6.6
Progress Schedule..............................J2
8.5
Insurance19
6.7
Substitutes and "Or -Equal" Items;
8.6
Change Orders ...... .........19
CONTRACTOR's Expense;
8.7
Inspections, Tests and
Substitute Construction
Approvals...................................19
Methods or Procedures;
8.8
Stop or Suspend Work;
ENGINEER's Evaluation.............12-13
Terminate CONTRACTOR's
6.8-6.11
Concerning Subcontractors,
Services......................................19
Suppliers and Others;
8.9
Limitations on OWNER'S
Waiver of Rights, ........................
J13-14
Responsibilities- ...........................
19
6.12
Patent Fees and Royalties, .................14
8.10
Asbestos, PCBs, Petroleum,
6.13
Permits.............................................14
Hazardous Waste or
6.14
Laws and Regulations ........................
14
Radioactive Material .....................
19
6.15
Taxes...........................................14-15
8.11
Evidence of Financal
6.16
Use of Premises ................................
15
Arrangements, .............................
19
6.17
Site Cleanliness ................................
15
6.18
Safe Structural Loading ,,,,,,,,,,,,,,,,,,,,„15
9. ENGINEER'S STATUS DURING
6.19
Record Documents .............................15
CONSTRUCTION19
6.20
Safety and Protection ..............15-16
9.1
OWNER's Representative..., .........19
6.21
Safety Representative .........................16
9.2
Visits to Site,,,,,,............................
19
6.22
Hazard Communication Program$,,,,,,
16
9.3
Project Representative ._... ,... *....
,19-21
6.23
Emergencies .....................................
16
9.4
Clarifications and Interpre-
6.24
Shop Drawings and Samples..............16
tations,........................................
21
9.5
Authorized Variations in %rk
21
EICDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
%v/ CITY OF FORT COLLINS MODIFICATIONS (REV 9199)
Article or Paragraph
Number & Title
Page Article or Paragraph
Number Number & Title
9.6
Rejecting De(eGive Work ...................71
9.7-9.9
Shop Drawings, Change Orders
and Payments....................................21
9.10
Determinations for Unit Price$.,.,,,
21-22
9.11-9.12
Decisions on Disputes; ENGI-
NEER as Initial Interpreter..............22
9.13
Limitations on ENGINEER's
Authority and Responsibilitieg.....
2-23
CHANGES IN
THE WORK ........................................
23
10.1
OWNER's Ordered Change................23
10.2
Claim for Adjustment,,,,,,,,,,,,,
23
10.3
Work Not Required by Contract
Documents .....................................
23
10.4
Change Orderg..................................23
10.5
Notification of Surety .........................73
CHANGE OF
CONTRACT PRICE .............................23
11.1-11.3
Contract Price; Claim for
Adjustment; Value of
the Work ...................................
23-24
11.4
Cost of the Work...........................24-25
11.5
Exclusions to Cost of the Work,,,,,,,,,,
25
11.6
CONTRACTOR's Fee ......... :...............
5
11.7
Cost Records .................................
.I 1.8
Cash Allowances...............................26
11.9
Unit Price Work.................................26
CHANGE OF CONTRACT TIMES ............................26
12.1
Claim for Adjustment ........................26
12.2
Time of the Essence „ ......,...26
.... ..........
12.3
Delays Beyond CONTRACTOR's
Control ......................................
26-27
12.4
Delays Beyond OWNER's and
CONTRACTOR's Control27
TESTS AND INSPECTIONS; CORRECTION
REMOVAL OR ACCEPTANCE OF
DEP'1-071 E WORK,.,,_,
27
13.1
Notice of Defects27
13.2
Access to the Work
27
13.3
Tests and Inspections;
CONTRACTOR's Cooperation,,,,,,,,,
27
13.4
OWNER's Responsibilities;
Independent Testing Laboratory.,_,,,
27
13.5
CONTRACTOR's
Responsibilities ...............................27
13.6-13.7
Covering Work Prior to Inspec-
tion, Testing or Approval.................27
M
Page
Number
13.8-13.9 Uncovering Work at ENGI-
NEER's Request .....................27-28
13.10
OWNER May Stop the Work ...........
28
13.11
Correction or Removal of
Dejecrive Work ...........................78
13.12
Correction Period
28
13.13
Acceptance ofDe/acrive Work .........
28
13.14
OWNER May Correct De%Give
Work .....................................
28-29
14. PAYMENTS TO CONTRACTOR AND
COMPLETION.................................................29
14.1
Schedule of Values
29
14.2
Application for Progress
Payment .....................................
29
14.3
CONTRACTOR's Warranty of
Title...........................................29
14.4-14.7
Review of Applications for
Progress Payments,,,,,,,,,,,,,,,,,,
29-30
I4.8-14.9
Substantial Completion..................30
14.10
Partial Utilization ......................30-31
14.11
Final lnspectioq .............................31
14.12
Final Application for Payment ........
31
14.13-14.14
Final Payment and Acceptancq
....... 31
14.15
Waiver of Claims... ....................
31-32
15. SUSPENSION OF WORK AND
TERMINATION................................................32
15.1 OWNER May Suspend Work ..........
32
15.2-15.4 OWNER May Terminate................32
15.5 CONTRACTOR May Stop
Work or Terminate,,,,,,,,,,,,,,,,,
32-33
16. DISPUTE RESOLUTION ................................„ 33
17. MISCELLANEOUS...........................................33
17.1 Giving Notice ................................
33
17.2 Computation of Times....................33
17.3 Notice of Claim,,,,,,
...33
17.4 Cumulative Remedies
33
17.5 Professional Fees and Court
Costs Included ....... *......*.....*
........ J3
17.6 Applicable State Laws„ ..............
33-34
Intentionally left blank.......................................35
EXHIBIT GC -A: (Optional)
Dispute Resolution Agreement,,,,,,,,,,,,,,,,,,,,,
GC -AI
16.1.16.6 Arbitration,,,,,,,,, .....................
QC -AI
16.7 Mediation ,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,GC
-AI
E1CDC GENERAL CONDITIONS 1910.8 (1990 EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9/99)
INDEX TO GENERAL CONDITIONS
City of Fort Collins modifications to the General Conditions of the Construction Contract are not shown in this index
Article or Paragraph
Number
Acceptance of --
Bonds and Insurance........................................5.14
defcclive Work............................)0.4.1, 13.5, 13.13
final payment, ........................................ 9.12. 14.15
insurance....................................................... ..5.14
other Work, by CONTRACTOR ..........................7.3
Substitutes and "Or -Equal" Item$......................6.7.1
Work by OWNER...............................2.5, 6.30, 6.34
Access to the --
Lands, OWNER and CONTRACTOR
responsibilities 4.1
..............................................
site, related Work
Work...........................................13.2, 13.14, 14.9
Acts or Omissions--. Acts and Omissions--
CONTRACTOR...................................6.9.1, 9.13.3
ENGINEER..........................................6.20, 9.13.3
OWNER....................................................0.20. 8.9
Addenda --definition of (also see
definition of Specifications) ....... (1.6, 1.10,6.19), 1.1
Additional Property Insuranceg 5.7
Adjustments --
Contract Price or Contract
Times ...........................1.5, 3.5, 4.1, 4.3.2, 4.5.2,
..............................4.5.3, 9.4, 9.5, 10.2-10.4,
.........................................1 1 12. 14.8, 15.1
progress schedule..............................................6.6
Agreement --
definition of ...................................................... 1.2
"All -Risk" Insurance, policy form...........................5.6.2
Allowances, Cash....................................................I L8
Amending Contract Documents, 3.5
Amendment, Written --
in general,,,,,,,,,,,,,,,, 1.10, 1.45, 3.5, 5.10, 5.12, 6.6.2
...........................6.8.2, 6.19, 10.1, 10.4, 11.2
....................................12.1, 13.12.2, 14.7.2
Appeal, OWNER or CONTRACTOR
intent to9.10, 9. I I, 10.4, 16.2, 16.5
Application for Payment --
definition of,,, 13
ENGINEER's Responsibility 9.9
final payment.................9.13.4, 9.13.5, 14.12-14.15
in general ..........................7.8, 2.9, 5.6.4, 9.10, 15.5
progress payment.......................................14.1.14.7
review of................................................:.14.4-14.7
Arbitration ......
............
................................... 16.1-16.6
Asbestos --
claims pursuant theretq........................... 4.5.2, 4.5.3
CONTRACTOR authorized to stop Work........., 4.5.2
definition of.......................................................1,.4
Article or Paragraph
Number
OWNER responsibilityfor............................4,5.1,
8.10
possible price and times change ........................4.5.2
Authorized Variations in Work,,,,,,,,,,
3.6, 6.25, 6.27, 9.5
Availability of Lands..........................................4.1,
8.4
Award, Notice of--defined.......................................1.25
Before Starting Construction,,,,,.....*,,,,,,,,
,,, ,,,,,,,,,z,5-2.8
Bid --definition of ............... 1.5 (I.1, 1.10, 2.3, 3.3,
........................ 4.2.6.4,
6.13, 1 1.4.3, 1 L9.1)
Bidding Documents --definition
of........... .. ......................................1.6
(6.8.2)
Bidding Requirements --definition
of..........................................1.7
(I.1, 4.2.6.2)
Bonds --
acceptance OF. ...................................................
5.14
additional bonds..................................10.5,
11.4.5.9
Cost of the Work.............................................11.5.4
definition of.......................................................1.8
delivery of...................................................2.1,
5.1
Final Application for Payment .................14.12-14.14
general.......................................1.10,
5.1-5.3, 5.13,
........................................9.13,
10.5, 14.7.6
Performance, Payment and Other...................5.1-5.2
Bonds and Insurance --in general.................................5
Builder's risk "all-risk" policy form ........................5.6.2
Cancellation Provisions, Insurance,,,,,,,,
5.4.11, 5.8, 5.15
Cash Allowances ........................... .........................
1 1.8
Certificate of Substantial Completion
........ 1.38. 6.30.2.3,
..................................................14.8,
14.10
Certificates of Inspection ...................9.13.4.
13.5, 14.12
Certificates of Insuranc@.............2.7,
5.3, 5.4.11, 5.4.13,
.......................5.6.5, 5.8.
5.14, 9.13.4. 14.12
Change in Contract Price --
Cash Allowances...............................................11.8
claim for price
adjustment............4.1, 4.2.6, 4.5, 5.15, 6.8.2, 9.4
................... 9.5, 9.1 1, 10.2,
10.5, 1 1.2, 13.9,
.................. I..... 13.13, 13.14,
14.7, 15.1, 15.5
CONTRACTOR's fee.........................................11.6
Cost of the Work
general ................................................1
1.4-1 1.7
Exclusions to...............................................1
1.5
Cost Records.....................................................11.7
in general.............1.19, 1.44, 9.11,
10.4.2, 10.4.3, 11
Lump Sum Pricing..........................................11.3.2
Notification of Surety.........................................10.5
Scope of...................................................10.3-10.4
Testing and Inspection,
Uncovering the Work ..................................
13.9
E1CDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
wl CITY OF FORT COLLINS MODIFICATIONS (REV 9199)
SECTION 00520
AGREEMENT
CONSTRUCTION WORK ORDER TYPE
' THIS AGREEMENT made and entered into the day and year set forth below,
by and between THE CITY OF FORT COLLINS, COLORADO, a Municipal
Corporation, hereinafter referred to as OWNER, and Hydro Construction
' Company, Inc. hereinafter referred to as CONTRACTOR.
WITNESSETH:
' In consideration of the mutual covenants and obligations herein
expressed, it is agreed by and between the parties hereto as follows:
ARTICLE 1. WORK
1.1 work Order Requirements. CONTRACTOR shall complete all
Work as specified or indicated in the Contract Documents. The Project
for which the Work under the Contract Documents may be the whole or
only a part is generally defined as 7220 Water, Wastewater Treatment
and Site Infrastructure Design and Construction Services Contractor; a
Work Order for a specific portion of the Work, and incorporating the
' Notice of Award for that portion of the Work, may be agreed upon in
writing by the parties from time to time. A blank sample of a Work
Order & Notice of Award is attached hereto as Section 00525,
' consisting of two (2) pages, and incorporated herein by this
reference. Each signed, executed Work Order & Notice of Award is
incorporated into the Contract Documents by this reference.
' 1.2. Work to be Performed. Each Work Order shall include a
description and specification of the work to be performed; the
location and time for initiation and performance of the work; the
amount of and procedures for payment, as specified in Article 5 of
this Agreement; any labor, materials, or support to be supplied by the
City; and any other special circumstances relating to the performance
of work.
1.3. Work Orders Planned. The Project will include Work in
accordance with Water, Waste Water and Stormwater Utility
Infrastructure Design/Construction Contractor Agreement. However,
pursuant to this Agreement and the Contract Documents, OWNER reserves
the right to alter or amend the scope of work of any specific Work
' Order as needed.
1.4. Work Order Authorization. The only work authorized under
this Agreement is that which is performed after CONTRACTOR receives
' Notice to Proceed from OWNER, pursuant to a signed Work Order. The
Notice to Proceed, Section 00530, shall be incorporated into each
executed Work Order. However, in emergency circumstances, as required
' to protect the public health, safety, or welfare, oral work requests
may be issued by OWNER. Oral requests for emergency actions will be
' AGREEMENT 00520-Page t
[1
1
I
1
Unit Price Work 11.9
Article or Paragraph
Number
Value of Work..................................................1
1.3
Change in Contract Times --
Claim for times adjustment ........
4.1, 4.2.6, 4.5, 5.15,
........... 6.8.2, 9.4, 9.5. 9.1
I, 10.2, 10.5. 12.1,
...............13.9, 13.13, 13.14, 14.7, 15.1, 15.5
Contractual time Iimit5.......................
Delays beyond CONTRACTOR's
.....12.2
control........................................................12.3
Delays beyond OWNER's and
CONTRACTOR's control.............................12.4
Notification of surety ............. ..........................
10.5
Scope of change........................................10.3-10A
Change Orders --
Acceptance ofDe%ctive Work
.........13.13
Amending Contract Documents,,,,,,,,,,,,,,,,,,,,,,
3.5
Cash Allowances ...............................................
11.8
Change of Contract Pricg .....................................
II
Change of Contract Time ............................
12
Changes in the Work...........................................10
CONTRACTOR's fee........................................11.6
Cost of the Work
11.4-1 1.7
Cost Records....................................................11.7
definition of
emergencies,,,,,,,,,,,,,,
........0.23
ENGINEER's responsibility,,,,,,,, 9.8, 10.4, 11.2, 12.1
execution of .....
..............................................
10.4
Indemnifiction ...................... 6.12,
6.16, 6.31-6.33
Insurance, Bonds and„.....................5.10,
5.13, 10.5
OWNER may terminate ....... *.......
,,,,,,.[5.2-15.4
OWNER's Responsibility.............................$.6,
10.4
Physical Conditions --
Subsurface and...............................................
3.2
Record Documents,,,,,,,,
6.19
Scope of Change ....................................
10.3-10.4
Substitutes.............................................6.7.3,
6.8.2
Unit Price Work...............................................11.9
value of Work, covered by .................................
11.3
Changes in the Work.................................................lo
Notification of surety.........................................10.5
OWNER's and CONTRACTOR's
responsibilities
10.4
Right to an adjustment.................................10.2
„ .
...............
Scope of change........................................10.3-10.4
Claims --
against CONTRACTOR ....................................
6.16
against ENGINEER ........................................
6.32
against OWNER
6.32
Change of Contract Prick,,,,,,,,,,,,,,
9,4 11.2
Change of Contract Times,,,,,.,,,.,,
9.4 12.1
CONTRACTOR's.............4, 7.1, 9.4,
9.5, 9.11, 10.2,
...........................11.2, 11.9,
12.1, 13.9, 14.8,
............................................15.1,
15.5, 17.3
Vi
CONTRACTOR's Fee........................................11.6
Article or Paragraph
Number
CONTRACTOR's liability ........... 5.4,
6.12, 6.16, 6.31
Cost of the Work,,,,,,,,,,,,,,........... ,,,,,,,,,,,,,.I
1.4, 11.5
Decisions on Disputes...............................9.1
I, 9.12
Dispute Resolution............................................16.1
Dispute Resolution Agreement ....................
16.1-16.6
ENGINEER as initial interpreter,.,,, ............
....„9.11
Lump Sum Pricing .........................................
11.3.2
Notice of ...............................
OWNER's....................9.4, 9.5, 9.1 I,
10.2, 11.2, 11.9
........................12.1, 13.9. 13.13, 13.14, 17.3
OWNER's liability,,,,,,,,,,,,,
5.5
OWNER may refuse to make payment
.................14.7
Professional Fees and Court Costs
Included , ,
request for formal decision
on.......................
9..11
Substitute Items ........................... ..
..........0.7.1.2
Time Extension.................................................12.1
Time requirements....................................9.1
I, 12.1
Unit Price Work.............................................11.9.3
Valueof ...................................
1,1.3
.........
Waiver of --on Final Payment.................14.14,
...............
14.15
Work Change Directive ...........................
10.2
written notice required....
9.1 I, 11.2 12.1
Clarifications and Interpretations,,.,,,,,,,,,
3.6.3, 9.4, 9.11
CleanSite............................................................0..17
Codes of Technical Society, Organization
or Association........................................4.3.3
Commencement of Contract Time$,,,,,,,,,,,,,,,,,,,,,,
2,3
Communications -
general ...........................................6.2,
6.9.2, 8.1
Hazard Communication Programs .....................6,22
Completion --
Final Application for Payment,,,,,,,,._„
14.12
Final Inspection..............................................14.1
1
Final Payment and Acceptancq................
Partial Utilization.,,,,,,,,,,,,,,,,, , ...............
........14.10
Substantial Completion ......................1.38,
14.8-14.9
Waiver of Claims,,,,,,,,, .....
Computation of Times. ........... .............17.2.1-17.2.2
.....14.15
Concerning Subcontractors, Suppliers
and Others..................................................6.8-6.11
Conferences --
initially acceptable schedules,,,,,,,,,,,,,,,,,,,,
2.9
preconstruction.................................................
.. z.8
Conflict, Error, Ambiguity, Discrepancy--
CONTRACTOR to Report,,,,,,,,,,,,,,,,,,,,,,,
2.5. 3.3.2
Construction, before starting by
CONTRACTOR,,,,,.,,
Construction Machinery, Equipment, etc,,,,,,,,,,,,,,,,,
6.4
Continuing the Work
Contract Documents -
Amending
Bonds..............................................................5.1
EJCDC GENERAL CONDITIONS
1910-8 (1990 EDITION)
%V/ CITY OF FORT COLLINS MODIFICATIONS (REV 9/99)
I
Cash Allowances..............................................11.8
Article or Paragraph
Number
Change of Contract Price,,,,,,,,,,,,,,,,,,, .................
I
Change of Contract Times,,, ,, ,,,,,,,,,,,,,,,,,,,,,,,,,
,,,,, 12
Changes in the Work................................10.4-10.5
check and verifj.................................................
2.5
Clarifications and
Interpretations .........................3,2, 3.6, 9.4, 9.11
definition of.....................................................t.10
ENGINEER as initial interpreter of,,,,,,,,,,,,,,,,,,
9.1(
ENGINEER as OWNER'S representative..............9.1
genera13
Insurance,,,,,,,,,,,,,,,,,,
5.3
Intent........................................................3.1-3.4
minor variations in the Work..............................3.6
OWNER's responsibility to furnish data,,,,,,,,,,,,,,
8.3
OWNER's responsibility to make
prompt payment ..........................$.3, 14.4,
14.13
precedence................................................3.1,
3.3.3
Record Documents............................................6.19
Reference to Standards and Specifications
of Technical Societies...................................3.3
Related Work,,,,,,,,,,,,,,,,, ....................................
7.2
Reporting and Resolving Discrepancie$,,,,,...
2.5, 3.3
Reuseof ......................................................
Supplementing ................................
3.6
Termination of ENGINEER's Employment
.......... 8.2
Unit Price Work...............................................J
1.9
variations, .........................................3.6,
6.23, 6.27
Visits to Site, ENGINEER's...............................9.2
Contract Price --
adjustment of...............3.5, 4.1, 9.4, 10.3,
11.2-11.3
Changeof ..........................................................
) I
Decision on Disputes........................................9.11
definition of.....................................................1.11
Contract Times --
adjustment of ..........................3.5, 4.1, 9.4, 10.3, 12
Change of .................. ............ ...................
12.1-12.4
Commencement of.............................................2.3
definition of.....................................................1.12
CONTRACTOR --
Acceptance of Insurance ...................................
5.14
Communications ........ ......... .........6.2,
6.9.2
Continue Work,,,,,,,,,,,,,,,,,
coordination and scheduling............................0.9.2
definition of.....................................................1.13
Limited Reliance on Technical
Data Authorized ,,,,,,,,,,,,,,,„.,......._..,,,,,,,,,,,,4.2.2
May Stop Work or Terminate............................1.5.5
provide site access to others,,,,,,,,,,,,,,,,,,,,,,,
7.2, 13.2
Safety and Protection,,,,,,,,,,,,,,,,,,, 4J.1.2, 6.16, 6.18,
.....................................6.21-6.23,
7.2, 13.2
Shop Drawing and Sample Review
Prior to Submittal6.25
vii
Stop Work requirementg
CONTRACTOR's-
4.5.2 '
Article or Paragraph
Number
Compensation ............................................
11.1-1 1.2
Continuing Obligation .....................................
14.15
De%clive Work ............................... 9.6, 13.10-13.14
Duty to correct defective Work,,,,,,,,,,,,,,,,,,,,,,,,,,
J 3.1 1
Duty to Report --
Changes in the Work caused by
Emergency ...........................................
6.23
Defects in Work of Others .............................
7.3
Differing conditions...................................4.2.3
Discrepancy in Documents,,,,,,,, 2.5, 3.3.2,
6.14.2
Underground Facilities not indicated,,,,,,,,,,
4.3.2
Emergencies .......................................... ...........
6.23
Equipment and Machinery Rental, Cost
of the Work...........................................11.4.5.3
Fee --Cost Plus..........................11.4.5.6, 11.5.1,
11.6
General Warranty and Guaranteq .......................0.30
Hazard Communication Programs ........ .......
...0.22
Indemnification .........................6.12, 6.16,
6.31-6.33
Inspection of the Work ...............................
7.3, 13.4
Labor, Materials and Equipment ....................0.3-6.5
Laws and Regulations, Compliance by .............
6,14.1
Liability Insurance..............................................5.4
Notice of Intent to Appeal ..........................9.10,
10.4
obligation to perform and complete
the Work....................................................6.30
Patent Fees and Royalties, paid for by,,,,,,,,,,,,,,,,
6.12
Performance and Other Bonds.............................
.1
Permits, obtained and paid for by.......................0.13
Progress Schedule ...........................2.6, 2.8, 2.9, 6.6,
........................................6.29, 10.4, 15.2.1
Request for formal decisionon disputes,,,,,,,,,,,,,,
9.11
Responsibilities --
Changes in the Work ..................................
10.1
Concerning Subcontractors, Suppliers
and Others ......................................
6.8-6.1 1
Continuing the Work ..........................0.29,
10.4
CONTRACTOR'S expense...........................6.7.1
CONTRACTOR'S General Warranty
and Guarantee.......................................6.30
CONTRACTOR's review prior to Shop
Drawing or Sample submittal.................6.25
Coordination of Work................................6.9.2
Emergencies...............................................6.23
ENGINEER's evaluation, Substitutes
or "Or -Equal" Items..............................0.7.3
For Acts and Omissions
of Others.............................6.9.1-6.9.2, 9.13
for deductible amounts, insurance...................5.9
general........................................6, 7.2,
7.3, 8.9
Hazardous Communication Programg...........
.22
Indemnification
6.31-6.33
EJCDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9199)
J
1
I
11
1
I
Labor, Materials and Equipment..............6.3-6.5
Laws and Regulations..................................6.14
Liability Insurance .........................................5.4
Article or Paragraph
Number
Notice of variation from Contract
Documents ...........................................
6.27
Patent Fees and Royalties. ............................
h. 12
Permits............................. ..................6
13
Progress Schedule.........................................6.6
Record Documents ......................................
6.19
related Work performed prior to
ENGINEER'S approval of required
submittals.............................................5.28
safe structural loading.................................6.18
Safety and Protection,,,,,,,,,,,,,,,,,,,,
6.20, 7.2, 13.2
Safety Representative...................................6.21
Scheduling the Work .........
6.9.2
Shop Drawings and Samples
.. , ....6.24
Shop Drawings and Samples Review
by ENGINEER,,,,.,
6.26
Site Cleanliness..........................................6.17
Submittal Procedures6.25
Substitute Construction Methods
and Procedures6.7.2
Substitutes and "Or -Equal" Item5................0.7.1
Superintendence...........................................6.2
Supervision...................................................0.1
„ Survival of Obligations.,,,....., ....................
6.34
Taxes......................:..................................
6.15
Tests and Inspections..................................13.5
ToReport......................................................
.......... ......... .........
2.5
Use of Premises 6 ......................16-6.18, 6.30.2.4
Review Prior to Shop Drawing or
Sample Submittal ........................................
6.25
Right to adjustment for changes in the Work ..... 10.2
right to claint,,,,,...... 4, 7.1, 9.4, 9.5, 9.1 I, 10.2,11.2,
.......... 1 1.9, 12.1, 11% 14.8, 15.1,
15.5, 17.3
Safety and Protection,,,,,,,,,,,,,,,,, 6.20-6.22, 7.2, 13.2
Safety Representative .......................................
6.21
Shop Drawings and Samples Submittal5,.,,.6.24-6.28
Special Consultants........................................11.4.4
Substitute Construction Methods and Procedure5,6.7
Substitutes and "Or -Equal" Items,
Expense ..........................................
6.7.1, 6.7.2
Subcontractors, Suppliers and Others ..........
6.8-6.11
Supervision and Superintendence .........
6.1, 6.2, 6.21
Taxes, Payment by...........................................6.15
Use of Premises
6.16-6.18
Warranties and guarantees, .........................
0.5,6.30
Warranty of Title ...... ......... .................,
14.3
Written Notice Required --
CONTRACTOR stop Work or terminate,
,,,,,..15.5
Reports of Differing Subsurface
and Physical Conditions,,,,,,,,,,,,,,,,
4.2.3
Substantial Completion................................14.8
Vad
CONTRACTORS--other7
Contractual Liability Insurance . ............................. 5; 4.10
Contractual Time Limits .........................................12.2
Article or Paragraph
Number
Coordination—
CONTRACTOR's responsibility .........................6.9.2
Copies of Documents................................................
2.2
Correction Period .......... ......... ..................13
12
Correction, Removal or Acceptance
ofDejective, Work--
in general...................................10.4.1,
13.10-13.14
Acceptance of Defective Work ..........................13.13
Correction or Removal of
Defective Work.................................6.30,
13.11
Correction Period............................................13.12
OWNER May Correct Defective Work..............J3.14
OWNER May Stop Work ........ .................13.10
Cost--
ofTestsand Inspection$.....................................13.4
Records11.7
Cost of the Work --
Bonds and insurance, additional...................j
1.4.5.9
Cash Discounts. ..............................................
J14.2
CONTRACTOR's Fee ..........
11.6
Employee Expenses......................................11.4.5.1
Exclusions to.....................................................11.5
General 11.4-1 1.5
Home office and overhead expenses ....................11.5
Losses and damages.....................................11.4.5.6
Materials and equipment ......... I ...............
11.4.2
Minor expenses............................................
11.4.5.8
Payroll costs on changes,,,,,,,,,,,,,,,,,
1 1.4.1
performed by Subcontractors ............................
f 1.4.3
Records 11.7
Rentals of construction equipment
and machinery.......................................11.4.5.3
Royalty payments, permits and
license fees, ...........................................
11.4.5.5
Site office and temporary facilities,,,,,,,,,,,,,,,,
J 1.4.5.2
Special Consultants, CONTRACTOR's............
11.4.4
Supplemental.................................................1
1.4.5
Taxes related to the Work.............................(1.4.5.4
Tests and Inspection.........................................13.4
Trade Discounts
1 1.4.2
Utilities, fuel and sanitary facilities,,,,,,,,,,,,,
11.4.5.7
Work after regular hours.................................11.4.1
Covering Work...............................................13.6-13.7
Cumulative Remedies17.4-17.5
Cutting, fitting and patching....................................7.2
Data, to be furnished by OWNER,. .........
. .........0 3
Day --definition of,,,,,,,,,,
17.2.2
Decisions on Disputes,,,,,,,,,,,,,,,,,,,„ ..............9.11,
9.12
defective --definition of...........................................1.14
defective Work--
Acceptanceof......................................10.4.1,
13.13
E1CDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9199)
Correction or Removal of
Correction Period
...............
in general ........................
.................10.4.1, 13.11
............................ J3.12
...............13, 14.7, 14.11
Article or Paragraph
Number
Observation by ENGINEER................................9.2
OWNER May Stop Work.................................13.10
Prompt Notice of Defects...................................13.1
Rejecting...........................................................9.6
Uncovering the Work .......................................
13.8
Definitions................................................................
I
Delays......................................4.1, 6.29, 12.3-12.4
Delivery of Bonds.....................................................2.1
Delivery of certificates of insurance ............................7.7
Determinations for Unit Prices ................................
9.10
Differing Subsurface or Physical Conditions --
Noticeof........................................................4.2.3
ENGINEER's Review4.2.4
Possible Contract Documents Change,,,,,,,,,,,,,,
4.2.5
Possible Price and Times Adjustment*..............4.2.6
Discrepancies -Reporting
and Resolving...............................2.5, 3.3.2,
6.14.2
Dispute Resolution—
Agreement, ...............................................16.1-16.6
Arbitration................................................J
6.1-16.5
general 16
Mediation........................................................16.6
Dispute Resolution Agreement..........................t6.1-16.6
Disputes, Decisions by ENGINEER,,,,,,,,,,,,,,,,,, ...................
Documents --
Copiesof...........................................................7.2
Record 6.19
Reuseof. ...........................................................
3.7
Drawings --definition of...........................................1.15
Easements.............................................................4.1
Effective date of Agreement -- definition of.............j.16
Emergencies...........................................................0..23
ENGINEER --
as initial interpreter on disputes,,,,,,,,,,,,,,,, ................
definition of.....................................................1.17
Limitations on authority and responsibilitie6
..... 9.13
Replacement of..................................................8.2
Resident Project Representative ...........................9.3
ENGINEER's Consultant -- definition of .................1.18
ENGINEER's--
authority and responsibility, limitations oil
........ 9.13
Authorized Variations in the Work.....................9.5
Change Orders, responsibility for ....... 9.7.
10, 11, 12
Clarifications and Interpretations ..............}.6.3,
9.4
Decisions on Disputes ..............................
9.11-9.12
defective Work, notice of..................................13.1
Evaluation of Substitute Item; ..........................6.7.3
Liability...................................................0.32,
9.12
Notice Work is Acceptable..............................14.13
Observations ...........................................
.30.2, 9.2
ix
OWNER's Representative....................................9.1
Payments to the CONTRACTOR,
Responsibility for.....................................9.9,
14
Recommendation of Payment ....................14.4,
14.13
Article or Paragraph
Number
Responsibilities --Limitations oq.................9.11-9.13
Review of Reports on Differing Subsurface
and Physical Conditions, .............................
4.2.4
Shop Drawings and Samples, review
responsibility ..............................................
5.26
Status During Construction --
authorized variations in the Work..................9.5
Clarifications and Interpretation8 ..................PA
Decisions on Disputes ......... ..........
9.11-9.12
Determinations on Unit Price......................9.10
ENGINEER as Initial Interpreter ..........
9.11-9.12
ENGINEER's Responsibilities,,,
...9.1-9.12
Limitations on ENGINEER's Authority
and Responsibilitie;..............................9.13
OWNER's Representative..............................9.1
Project Representative...................................9.3
Rejecting Defective Work ..... ......................9.6
Shop Drawings, Change Orders
and Payments....................................9.7-9.9
Visits to Site.................................................9.2
Unit Price determinations.................................9.10
Visits to Site ............. ......... .........
........9.2
Written consent required,,,,,,,,,,,,,,
7.2, 9.1
Equipment, Labor, Materials and ........................0.3-6.5
Equipment rental, Cost of the Work...................11.4.5.3
Equivalent Materials and Equipment .........................0.7
error or omission$..................................................0.33
Evidence of Financial Arrangements .......................$.1
I
Explorations of physical conditions ........................4.2.1
Fee, CONTRACTOR's--Costs Plus ...........................
I 1.6
Field Order --
definition of.....................................................J.19
issued by ENGINEER................................3.6.1,
9.5
Final Application for Payment...............................14.12
Final Inspection...................................................14.11
Final Payment --
and Acceptance .....................................
14.13-14.14
Prior to, for cash allovances...... ...................11.8
General Provisions17.3-17.4
General Requirements --
definition of.....................................................1.20
principal references tq..............z.6, 6.4,
6.6.6.7, 6.24
Giving Notice.........................................................17.1
Guarantee of Work --by CONTRACTOR..,,,,,,
6.30, 14.12
Hazard Communication Programs ..........................
6.22
Hazardous Waste --
definition of.....................................................1.21
general.............................................................4.5
OWNER's responsibility for..............................8.10
EJCDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9/99)
I
I
I
11
I
I
I
[1
Indemnification., ......................6.12, 6,16, 6.31-6.33
.......
Initially Acceptable Schedules...................................2.9
Inspection --
Certificates of..............................9.13.4, 13.5, 14.12
Final ... ......... ...................14.11
Article or Paragraph
Number
Special, required by ENGINEER .........................9.6
Tests and Approval,,,,,,,,,,,,,,,, ,,,,,,,,$.7, 13.3-13.4
Insurance --
Acceptance of, by OWNER...............................5.14
Additional, required by changes
in the Work............................................11.4.5.9
Before starting the Work ....................................
2.7
Bonds and --in general..........................................5
Cancellation Provisions .....................................
5.8
Certificates of ........ .......7.7, 5, 5.3, 5.4.11,
5.4.13,
........................5.6.5, 5.8, 5.14, 9.13.4,
14.12
completed operationss....................................5.4.13
CONTRACTOR's Liability ..................................5.4
CONTRACTOR's objection to coverage,,,,,,,,,,,,,
5.14
Contractual Liability......................................5.4.10
deductible amounts, CONTRACTOR's
responsibility ................................................5.9
Final Application for Payment, .........................14.12
Licensed Insurers...............................................5.3
Notice requirements, material change$ ........
5.8, 10.5
Option to Replace.............................................5.14
other special insurances ....................................5.10
OWNER as fiduciary for insured; ........,_„5.12-5.13
OWNER'S Liability ............................................5.5
OWNER'S Responsibility.....................................8.5
Partial Utilization, Property Insurance...............5.15
Property.....................................................5.6-5.10
Receipt and Application of Insurance
Proceeds, .............................................
5.12-5.13
Special Insurance .............................................
5.10
Waiver of Rights..............................................5.1
1
Intent of Contract Documents ,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,),I-3.4
Interpretations and Clarification8 .....................3.6.3,
9.4
Investigations of physical conditions ..........................4.2
Labor, Materials and Equipment..........................6.3-6.5
Lands --
and Easements...................................................$.4
Availability of.............................................4.1,
8.4
Reports and Tests...............................................8.4
Laws and Regulations --Laws or Regulations--
Bonds.........................................................
Changes in the Work........................................10.4
Contract Documents
),I
CONTRACTOR's Responsibilities .....................6.14
Correction Period,dejedivc Work,,,,,,, ..............
13.12
Cost of the Work, taxes................................11.4.5.4
definition of.....................................................1.22
general6.14
Indemnification ........................................
6.31-6.33
s
Insurance,,.,..., 5.3
.................................................
Precedence................................................3.1, 3.3.3
Referenceto....................................................3.3.1
Safety and Protection,..... .6.20, 13.2
Subcontractors, Suppliers and Other$ ........... 6.8-6.1 1
Article or Paragraph
Number
Tests and Inspections ,,,,,,,,,,,,,*.......... ,,,,,,,-,,,13.5
Use of Premises,,,,,,,,,,,,,, ..................0.16
Visitsto Site.......................................................9.2
Liability Insurance--
CONTRACTOR's ...............................................
5.4
OWNER's...........................................................5.5
Licensed Sureties and Insurer$.................................5.3
Liens --
Application for Progress Payment .......................(4.2
CONTRACTOR's Warranty of Title....................14.3
Final Application for Payment ..........................l4.12
definition of,,,,,,,,,,,,,,,,,,,,,,,,,,, ..........................
.1.23
Waiver of Claims,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,
j4.15
Limitations on ENGINEER'S authority and
responsibilities.................................................
9.13
Limited Reliance by CONTRACTOR
Authorized.......................................................4.2.2
Maintenance and Operating Manuals --
Final Application for Payment ..........................t4.12
Manuals (of others) --
Precedence ....................................................3.3.3.1
Reference to in Contract Documents..................).3.1
Materials and equipment --
furnished by CONTRACTOR...............................6.3
not incorporated in Work...................................14.2
Materials or equipment --equivalent ...........................0.7
Mediation (Optional)..............................................J6.7
Milestones --definition of........................................1.24
Miscellaneous --
Computation of Times, .......................................
17.2
Cumulative Remedies ........................................
17.4
Giving Notice....................................................17.1
Notice of Claim.................................................17.3
Professional Fees and Court Costs Included .........
17.5
Multi -prime contracts .................................................
7
Not Shown or Indicated.........................................4.3.2
Notice of --
Acceptability of Project,,,,,,,,,,,,,,,,,,,,,,,,,"
"14.13
Award, definition of,,,
1.25
Claim............................................................17.3
Defects,13.1
Differing Subsurface or Physical Conditions ......
4.2.3
Giving............................................................J.7.1
Tests and Inspection$,,,,,,,,,,,,,,
13.3
Variation, Shop Drawing and Sample,,,,,,,,,,,,
,,,,0.27
Notice to Proceed --
definition of ..................................................
(,26
givingof............................................................2.3
E1CDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
xv( CITY OF FORT COLLINS MODIFICATIONS (REV 9!99)
I
Notification to Surety..............................................j0.5
Observations, by ENGINEER...........................k.30,
9.2
Occupancy of the Work,,,,,,,,,,,,,,,,,,,
5.15, 6.30.2.4, 14.10
Omissions or acts by CONTRACTOR ,............... 6.9, 9.13
Open Peril policy form, Insurancq ..........................5..6.2
Option to Replace,,,,,,,,,,,,,,,,,,,,,,,, ............................
5.14
Article or Paragraph
Number
"Or Equal" Items......................................................6.7
Other work 7
Overtime Work --prohibition of„...............................6.3
OWNER --
Acceptance oftlefecrive Work,,,,,,,,,,,,,,,,,,,,,,,,,,
13.13
appoint an ENGINEER......................................8.2
as fiduciary...............................................5.12-5.13
Availability of Lands, responsibility ....................4.1
definitionof.....................................................1.27
data, furnish......................................................8.3
May Correct Dejecrive Work...........................1.3.14
May refuse to make payment„...........................J4.7
May Stop the Work.,,,,,,....
May Suspend Work,
Terminate............................$.8, 13.10,
15.1-15.4
Payment, make prompt.....................8.3, 14.4,
14.13
performance of other work ..................................
7.1
permits and licenses, requiremenk$....................0.13
purchased insurance requirementg ...............5.6-5.10
O WN E R's--
Acceptance of the Work...............................6.30.2.5
Change Orders, obligation to execut4..........
8.6, 10.4
Communications
8.1
Coordination of the Work
7.4
Disputes, request for decisioq ............................9.
1 I
Inspections, tests and approvalg..................8.7,
13.4
Liability Insurance..............................................5.5
Notice of Defects ...... ........................................13.1
Representative --During Construction,
ENGINEER's Status......................................9.1
Responsibilities --
Asbestos, PCBs, Petroleum, Hazardous
Waste or Radioactive Material8.10
ChangeOrders..............................................8.6
Changes in the Work...................................10.1
communications............................................8.1
CONTRACTOR's responsibilities ..................8.9
evidence of financial arrangement�..............?.I
1
inspections, tests and approval$.....................8.7
insurance......................................................8.5
lands and easements.....................................8.4
prompt payment by . .......................................
8.3
replacement of ENGINEER ...........................8.2
reports and tests............................................8.4
stop or suspend Work..................8.8, 13.10,
15.1
terminate CONTRACTOR's
services..........................................8.8,
15.2
separate representative at sit4 ............................
9.3
xi
testing, independent.........................................13.4
use or occupancy
of the Work ..........................5.15, 6.30.2.4, 14.10
written consent or approval
required.........................................9.1, 6.3, 11.4
E1CDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
%r/ CITY OF FORT COLLINS MODIFICATIONS (REV 9/99)
I
Article or Paragraph
Number
written notice required ........................7.1,
9.4, 9.11,
....................................1 1.2,
1 1.9, 14.7, 15.4
PCBs —
definition ol......................................................1.29
general..............................................................4.5
OWNER's responsibility for...............................8.10
Partial Utilization --
definition of.....................................................1.28
general6.30.2.4, 14.10
Property Insurance............................................5.15
Patent Fees and Royalties ......................................
6.12
Payment Bonds...................................................5.1-5.2
Payments, Recommendation of..............14.4-14.7,
14.13
Payments to CONTRACTOR and Completion
--
Application for ProgressPayments ......................J4.2
CONTRACTOR's Warranty of Title...................14.3
Final Application for Payment .........................14.12
Final Inspection ...............................................14.1
1
Final Payment and Acceptancq ................14.13-14.14
general.........................................................$.3,
14
Partial Utilization............................................14.10
Retainage..........................................................14.2
Review of Applications for
Progress Payments ................. ...............
14.4-14.7
prompt payment..................................................8.3
Schedule of Values14.1
Substantial Completion...............................14.8-14.9
Waiver of Claims
14.15
when payments due ................................
14.4, 14.13
withholding payment........................................14.7
Performance Bond;............................................5.1-5.2
Permits .................................
Petroleum --
definition of......................................................J.30
general..............................................................4.5
OWNER's responsibility for...............................8.10
Physical Conditions --
Drawings of, in or relating IQ ........................
4.2.1.2
ENGINEER's review
4.2.4
existing structures............................................4.2.2
general 4.2.1.2 ...............................
Notice of Differing Subsurface or,,,,,,,,,,,,,,,
4.2.3
Possible Contract Documents Changq...............4.2.5
Possible Price and Times Adjustment ..............4.2.6
Reports and Drawings......................................4.2.1
Subsurface and ..................................
4.2
Subsurface Conditionss..................................4.2.1.1
Technical Data, Limited Reliance by
CONTRACTOR Authorized .......................4.2.2
Underground Facilities--
general.........................................................4.3
Not Shown or Indicated,,,,,,...*....................4.3.2
Protection of........................................4.3,
6.20
Xii
Article or Paragraph
Number
Shown or Indicated,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,
Technical Data...............................................4.2.2
Preconstruction ConfereneG.......................................2.8
Preliminary Matters.....................................................2
Preliminary Schedules .............................................
2.6
Premises, Use of .............................................. ..............................................
Price, Change of Contract ,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,I
Price, Contract --definition of ...................................
I.I 1
Progress Payment, Applications for ..........................J4.2
Progress Payment--retainagq...................................
14.2
Progress schedule, CONTRACTOR's,...........
2.6, 2.8, 2.9,
................................. 6.6, 6.29,
10.4. 15.2.1
Project --definition of...............................................1.31
Project Representative —
ENGINEER'S Status During Construction,,,,,,,,,,,,
9.3
Project Representative, Resident --definition of......... 1.33
prompt payment by OWNER.....................................8.3
Property Insurance--
Additional.........................................................5.7
genera15.6-5.10
Partial Utilization,,,,,,,,,,,,,,,,, ........5.15,
14.10.2
receipt and application of proceed4............
5.12-5.13
Protection, Safety and..............................6.20-6.21,
13.2
Punchlist..........................................................14.11
Radioactive Material--
defintion of.....................................................1.32
genera14.5
OWNER's responsibility for..............................$.10
Recommendation of Payment ....... ........14.4, 14.5, 14.13
Record Documents........................................6.19,
14.12
Records, procedures for maintaining ..........................7.8
Reference Points.......................................................4.4
Reference to Standards and Specifications
of Technical Societies.........................................3.3
Regulations, Laws and(or)......................................6.14
Rejecting Defective Work..........................................9.6
Related Work --
atSite........................................................7.1-7.3
Performed prior to Shop Drawings
and Samples submittals review....................6.28
Remedies, cumulative .....................................17.4,
17.5
Removal or Correction ofDefeclive Work................J3.11
rental agreements, OWNER approval required
,.... 11.4.3.3
replacement of ENGINEER, by OWNER,,,,,,,,,,,,,,,,,,,,
8.2
Reporting and Resolving
Discrepancies................................2.5,
3.3.2, 6.14.2
Reports --
and Drawings.................................................4.2.1
and Tests, OWNER's responsibility .....................8A
Resident and Project Representative --
definition of.....................................................1.33
provisionfor............................................................9.3
E1CDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
%v/ CITY OF FORT COLLINS MODIFICATIONS (REV 9199)
Article or Paragraph
Number
Resident Superintendent, CONTRACTOR'$,,,,,,,,,,,,,,, 6.2
Responsibilities—
CONTRACTOR's-in general..................................6
ENGINEER's-in general........................................9
Limitations on.............................................9.13
OWNER'S -in general .............................................
Retainage............................................................1.4.2
Reuse of Documents..................................................3.7
Review by CONTRACTOR: Shop Drawings
and Samples Prior to Submittal ..........................6.25
Review of Applications for
Progress Payments.....................................14.4-I4.7
Right to an adjustment...........................................10.2
Rights of Way..........................................................4.1
Royalties, Patent Fees and,,,,,,,,,,,,,,,,,,,
I..................6.12
Safe Structural Loading .... .........
................6.18
Safety --
and Protection................................4.3.2,
6.16. 6.18.
.......... ........ 6.20-6.21,
7.2, 13.2
general .....................................................0.20-6.23
Representative, CONTRACTOR's......................
6.21
Samples --
definition of......................................................1.34
general .....................................................6.24-6.28
Review by CONTRACTOR ...............................
6.25
Review by ENGINEER..............................6.26,
6.27
related Work.....................................................0.28
submittal of. ...................................................
0.24.2
submittal procedures.........................................6.25
Schedule of progress.............................2.6,
2.8-2.9, 6.6,
....... ......... ............6.29.
10.4, 15.2.1
Schedule of Shop Drawing and Sample
Submittals..............................2.6,
2.8-2.9, 6.24-6.28
Schedule of Values..............................2.6,
2.8-2.9, 14.1
Schedules --
Adherence to..................................................J5.2.1
Adjusting...........................................................6.6
Change of Contract Time$.................................10.4
Initially Acceptable.......................................
2.8, 2.9
Preliminary........................................................2.6
Scope of Changes.......................................10.3-10.4
Subsurface Conditions,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,
Shop Drawings --
and Samples, general ................................
6.24-6.28
Change Orders & Applications for
Payments, and.........................................9.7-9.9
definition of......................................................1.35
ENGINEER's approval of.....................:...........3.6.2
ENGINEER's responsibility
for review .....................................
9.7, 6.24.6.28
related Work.....................................................6.28
review procedures................................2.8,
6.24-6.28
Article or Paragraph
Number
submittal required...............................................6.24.1
Submittal Procedures ..............................
„6.25
use to approve substitution$..............................6.7.3
Shown or Indicated...............................................4.3.1
Site Access......................................................7.2,
13.2
Site Cleanliness......................................................6.17
Site, Visits to --
by ENGINEER ..........................................
9.2, 13.2
by others ..............................
13.
"special causes of loss" policy form,
insurance........................................................5.6.2
definition of.....................................................J.36
Specifications--
defination of....................................................J.36
of Technical Societies, reference
tp...................).3.1
precedence .............................
3.3.3
Standards and Specifications
of Technical Societies .. ...............................
3.3
Starting Construction, Before,,,,,2.5-2.8
Starting the Work ................................................
2A
Stop or Suspend Work --
by CONTRACTOR...........................................15.5
by OWNER.....................................8.8,
13.10, 15.1
Storage of materials and equipment .....................4.I,
7.2
Structural Loading, Safety .......................................
6.18
Subcontractor—
Concerning................................................
0.8-6.1 1
definition of.....................................................1.37
delays.............................................................12.3
waiver of rights................................................6.11
Subcontractors --in general.................................6.8-6.11
Subcontracts --required provisions.........
5.11, 6.11, 11.4.3
Submittals --
Applications for Payment,,,,,,,
,,,,,, ,,,,,,,,,,,14.2
Maintenance and Operation Manual$
...............14.12
Procedures.......................................................6.25
Progress Schedules......................................2.6,
2.9
Samples...................................................6.24-6.28
Schedule of Values.....................................2.6,
14.1
Schedule of Shop Drawings and Samples
Submissions......................................2.6,
2.8-2.9
Shop Drawings ........................................
6.24-6.28
Substantial Completion —
certification of............................6.30.2.3,
14.8-14.9
definition of.....................................................J.38
Substitute Construction Methods or Procedure$,,,,,...6.7.2
Substitutes and "Or Equal" Item$...............................6.7
CONTRACTOR's Expense.............................6.7.1.3
ENGINEER's Evaluation .................................
6.7.3
"Or-Equal"...................................................6.7.1.1
Substitute Construction Methods
EJCDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
w/ CITY OF FORT COLUNS MODIFICATIONS (REV 9/99)
Article or Paragraph
Number
or Procedures.............................................6.7.2
Substitute Items............................................6.7.1.2
Subsurface and Physical Conditions --
Drawings of, in or relathg to ........................4.2.1.2
ENGINEER's Review .......................................
4 2.4
general ........................................ ....................
..4.2
Limited Reliance by CONTRACTOR
A uth o ri zed .................................................
4.2.2
Notice of Differing Subsurface or
Physical Conditions.........................................4,2.3
Physical Conditions.......................................4.2.1.2
Possible Contract Documents Change,,,,,,,,,,,,,,,
4.2.5
Possible Price and Times Adjustments,,,,,,,,,,,,,,,
4.2.6
Reports and Drawingss.....................................4.2.1
Subsurface and,,,......
,,.,. „ .........................................
4.2
Subsurface Conditions at the Site,,,,,,,,,,,,,,,,
4.2.1.1
Technical Data.................................................4.2.2
Supervision—
CONTRACTOR's responsibility ...........................6.1
OWNER shall not supervise .............................
8.9
ENGINEER shall not supervise,,,,,,,,,,,,,,,,
9.2, 9.13.2
Superintendence .......................................................0.2
Superintendent, CONTRACTOR's resident
...............6.2
Supplemental costs...............................................1
1.4.5
Supplementary Conditions --
definition of.....................................................1.39
principal references to.................J.10,
1.18, 2.2, 2.7,
........................4.2, 4.3, 5.1, 5.3,
5.4, 5.6-5.9,
................5.1I,6.8,6.13,7.4,8.11,9.3,9.10
Supplementing Contract Documents .........................3.6
Supplier --
definition of.....................................................J.40
principal references to ........... 3.7, 6.5, 6.8-6.11.
6.20,
..........................................6.24, 9.13, 14.12
Waiver of Rights...............................................6.11
Surety --
consent to final payment,,,,,,,,,,,,,,,..........
14.12, 14.14
ENGINEER has no duty to................................9.13
Notification of..................................10.1,
10.5, 15.2
qualification of.............................................5.1-5.3
Survival of Obligations, ..........................................
6.34
Suspend Work, OWNER May .......................J3.10,
15.1
Suspension of Work and Termination-- ......................j
5
CONTRACTOR May Stop Work
or Terminate...............................................15.5
OWNER May Suspend Work..............................15.1
OWNER May Terminate..,,,,, ......................
15.2-15.4
Taxes --Payment by CONTRACTOR ........................
6.15
Technical Data --
Limited Reliance by CONTRACTOR .................4.2.2
Possible Price and Times Adjustments..............4.2.6
Reports of Differing Subsurface and
Physical Conditions....................................4.2.3
xiv
Temporary construction facilities 4.1
Article or Paragraph
Number
Termination--
by CONTRACTOR...........................................15.5
by OWNER,,,,,,,,,,,,,, 8.8, 15.1.15.4
..........................
of ENGINEER's employment...............................$.2
Suspension of Work-in general .............................J5
Terms and Adjective$,,,,,,,,,,,,,,,,,,,
3A
Tests and Inspections --
Access to the Work, by others............................13.2
CONTRACTOR's responsibilities .......................13.5
cost of 13.4
covering Work priortq..............................13.6-13.7
Laws and Regulations(or)................................
13.5
Notice of Defects...............................................13.1
OWNER May Stop Work,,,,,,,,,,,,,13.10
OWNER's independent testing . .......................j3.4
special, required by ENGINEER ..........................9.6
timely notice required. ......................................
13.4
Uncovering the Work, at ENGINEER's
request. ................................................
13.8-13.9
Times --
Adjusting...........................................................6.6
Change of Contract............ .................................
12
Computation of ................17.2
.................................
Contract Times --definition of ...........................j.12
day.........................................................17.2.2
Milestones ..........................................................12
Requirements--
appeals.................................................9.10,
16
clarifications,
claims and disputes ,,,,,,,,,,,,,„.„9.1
I, 11.2, 12
Commencement of Contract Times,,,,,,,,,,,,,,,,
2.3
Preconstruction Conference ...........................?.8
schedules.........................................2.6, 2.9, 6.6
Starting the Work.........................................2.4
Title, Warranty Of. ...................................................
14.3
Uncovering Work.............................................13.8-13.9
Underground Facilities, Physical Conditions--
definition of,,,,,,,,,,,,,,,,,,,,,,,,,
Not Shown or Indicated...................................4.3.2
protection of,,,,,,,,,,,,,,,,,,............. ...............4.3,
6.20
Shown or Indicated .............................. ...........
4.3.1
Unit Price Work--
claims.........................................................11.9.3
definition of,,,,,,,,,,,,,,,,,,,,,,,,,,,,, .......................
1.42
general11.9, 14.1, 14.5
Unit Prices--
general11.3.1
Determination for.
9.10
Use of Premises 6.16, 6.18,
6.30.2.4
Utility owners.. ...........*...............0.13, 6.20, 7.1.7.3,
13.2
Utilization, Partial..................1.28, 5.15, 6,30.2.4,
14.10
Value of the Work ........ ..........................................
11.3
Values, Schedule Of..............................2.6, 2.8-2.9, 14.1
E1CDC GENER,4L CONDITIONS 1910-8 (1990 EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9/99)
Variations in Work --Minor
Authorized ....................................... 6.25, 6.27, 9.5
Article or Paragraph
Number
Visits to Site --by ENGINEER....................................9.2
Waiver of Claims --on Final Payment ......................14.15
Waiver of Rights by insured parties..................5.1
I, 6.1 1
Warranty and Guarantee, General --by
CONTRACTOR................................................6.30
Warranty of Title, CONTRACTOR's........................14.3
Work --
Access to..........................................................13.2
by others,.
7
Changesin the.....................................................10
Continuing the ..................................................
0.29
CONTRACTOR May Stop Work
or Terminate...............................................15.5
Coordination of..................................................7.4
Cost of the.................................................1
1.4-1 1.5
definition o(......................................................1.43
neglected by CONTRACTOR ..........................
13.14
other Work,,,,,,,,,,,,,,,,,,,,,,,
7
OWNER May Stop Work .................................
13.10
OWNER May Suspend Work...................13.10,
15.1
Related, Work at Site,,,,,,,,,,,,;,,,,,,,,,,,,,,,,,,,,,,,7.1-7.3
Starting the........................................................2.4
Stopping by CONTRACTOR .............................
15.5
Stopping by OWNER.................................15.1-15.4
Variation and deviation authorized,
minor ........... 3.6
Work Change Directive --
claims pursuant to.............................................10.2
definition o(......................................................1.44
principal references to......................�1.5.3,
10.1-10.2
Written Amendment --
definition o%......................................................1.45
principal references to..............1.10, 3.5, 5.10,15.12,
........................6.6.2, 6.8.2,
6.19, 10.1, 10.4,
.............................11. 2, 12.1,
13.12.2, 14. 7. 2
Written Clarifications and
Interpretations...................................3.6.3,
9.4, 9.11
Written Notice Required --
by CONTRACTOR............................7.1,
9.10-9.1 I,
...........................................
10.4, 11.2, 12.1
by OWNER,,,,,,,,,,,,,,,,,,,, 9.10-9.1 I,
10.4, 1 1.2, 13.14
sc
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
E1CDC GENERAL CONDITIONS 1910.8 (1990 EDITION)
wl CITY OF FORT COLLINS MODIFICATIONS (REV 9/99) I
I
' confirmed by issuance of a written work Order within two (2) working
days; however, nothing in this paragraph may be construed to alter or
eliminate CONTRACTOR'S responsibilities pursuant to paragraph 6.23 of
the General Conditions.
' 1.5. Changes in the work. OWNER may, at any time during the
term of a particular Work Order and without invalidating the
Agreement, make changes within the general scope of the particular
work assigned and CONTRACTOR agrees to perform such changed work,
' pursuant to the provisions of the Contract Documents. OWNER reserves
the right to independently contract for any services, rather than
issuing work to CONTRACTOR pursuant to this Agreement. Nothing within
this Agreement shall obligate OWNER to have any particular service
performed by CONTRACTOR.
1.6. Bonds & Certificates. Pursuant to the Contract Documents
and Article 5 of the General Conditions, each Work Order & Notice of
Award shall specify the requirements for Performance and Payment
Bonds. CONTRACTOR shall provide insurance required pursuant to the
Contract Documents prior to OWNER'S execution of any Work Order, and,
as may be required at the sole option of OWNER, prior to the Work
Order Notice to Proceed.
' ARTICLE 2. ENGINEER
2.1. ENGINEER. Each portion of the Project to be performed by
' CONTRACTOR through the issuance of a work Order will be designed by a
person, firm, or corporation designated by OWNER and identified in the
Work Order, who is hereinafter called ENGINEER and who will assume all
duties and responsibilities and will have the rights and authority
' assigned to ENGINEER in the Contract Documents in connection with
completion of the Work in accordance with the Contract Documents.
' 2.2. OWNER'S Representative. Notwithstanding the provisions of
paragraph 2.1 above, the OWNER will designate, prior to the
commencement of work on each specific Work Order, the OWNER'S
Representative, who shall make, within the scope of his or her
authority, all necessary and proper decisions with reference to the
work requested. All requests concerning this Agreement shall be
directed to OWNER'S Representative.
ARTICLE 3. CONTRACT TIMES
'
3.1. Substantial Completion and Final Payment & Acceptance. Each
Work Order shall define the Contract Times, including
the number of
days or dates for the
Work of that
Work Order to be Substantially
Complete, as provided in
the General
Conditions, and completed and
'
ready for Final Payment
and Acceptance
in accordance with the General
Conditions.
' 3.2. Liquidated Damages. OWNER and CONTRACTOR recognize that
time is of the essence of each Work Order authorized under this
AGREEMENT 00520- Page 2
I
f
(This page left blank intentionally)
E1CDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
%v/ CITY OF FORT COLLINS MODIFICATIONS (REV 9199)
1
GENERAL CONDITIONS
ARTICLE I —DEFINITIONS
Wherever used in these General Conditions or in the other
Contract Documents the following terns have the
meanings indicated which are applicable to both the
singular and plural thereof:
I.I. Addenda —Written or graphic instruments issued
prior to the opening of Bids which clarify, correct or
change die Bidding Requirements or the Contract
Documents.
1.2. Agreement —The written contract between OWNER
and CONTRACTOR covering the Work to be performed;
other Contract Documents are attached to the Agreement
and made a part thereof as provided therein.
1.3. .-Application Jar Pgvnrent—The form accepted by
ENGINEER which is to be used by CONTRACTOR in
requesting progress or final payments and which is to be
accompanied by such supporting documentation as is
required by the Contract Documents.
1.4. Ashestae—Any material that contains more than one
percent asbestos and is friable or is releasing asbestos fibers
into the air above current action levels established by the
United States Occupational Safety and Health
Administration.
1.5. Bid —The offer or proposal of the bidder submitted
on the prescribed form setting forth the prices for the Work
to be performed.
1.6. Bidding Docnnrents—The advertisement or
invitation to Bid, instructions to bidders, the Bid form, and
the proposed Contract Documents (including all Addenda
issued prior to receipt of Bids).
1.7. Bidding Requirements -The advertisement or
invitation to Bid, instructions to bidders, and the Bid form.
I.S. Bonds —Performance and Payment bonds and other
instruments of security.
1.9. Change Order —A document recommended by
ENGINEER, which is signed by CONTRACTOR and
OWNER and authorizes an addition, deletion or revision in
the Work, or an adjustment in the Contract Price or the
Contract Times, issued on or after the Effective Date of the
Agreement.
1.10. Contract Docia rents --The Agreement, Addenda
(which pertain to the Contract Documents),
CONTRACTOR's Bid (including documentation
accompanying the Bid and any post Bid documentation
submitted prior to the Notice of Award) when attached as
an exhibit to the Agreement, the Notice to Proceed, the
Bonds, these General Conditions, the Supplementary
Conditions, the Specifications and the Drawings as the
EICDC GENERAL CONDITIONS 1910-8 (1990 Edition)
%v/ CITY OF FORT COLLINS MODIFICATIONS (REV 412000)
same are more specifically identified in the Agreement,
together with all Written Amendments, Change Orders,
Work Change Directives, Field Orders and ENGINEER's
written interpretations and clarifications issued pursuant to
paragraphs 3.5, 3.6.1 and 3.6.3 on or after the Effective
Date of the Agreement. Shop Drawing submittals
approved pursuant to paragraphs 6.26 and 6.27 and the
reports and drawings referred to in paragraphs 4.2.1 and
4.2.2 are not Contract Documents.
1.11. Contract Price —The moneys payable by
OWNER to CONTRACTOR for completion of the Work
in accordance with the Contract Documents as stated in
the Agreement (subject to the provisions of
paragraph 1 1.9.1 in the case of Unit Price Work).
1.12. Conti -act Times —The numbers of days or the
dates stated in the Agreement: (i) to achieve Substantial
Completion, and (ii) to complete the Work so that it is
ready for final payment as evidenced by ENGINEER's
written recommendation of final payment in accordance
with paragraph 14.13.
1.13. CONTRACTOR —The person, firm or corporation
with whom OWNER has entered into the Agreement.
1.14. defective —An adjective which when modifying
the word Work refers to Work that is unsatisfactory, faulty
or deficient in that it does not conform to the Contract
Documents, or does not meet the requirements of any
inspection, reference standard, test or approval referred to
in the Contract Documents, or has been damaged prior to
ENGINEER's recommendation of final payment (unless
responsibility for the protection thereof has been assumed
by OWNER at Substantial Completion in accordance with
paragraph 14.8 or 14.10).
1.15. Drawings —The drawings which show the scope,
extent and character of the Work to be furnished and
performed by CONTRACTOR and which have been
prepared or approved by ENGINEER and are referred to
in the Contract Documents. Shop drawings are not
Drawings as so defined.
1.16. Effective Dale of the Agreement —The date
indicated in the Agreement on which it becomes effective,
but if no such date is indicated it means the date on which
the Agreement is signed and delivered by the last of the
two parties to sign and deliver.
1,17. ENGINEER —The person, firm or corporation
named as such in the Agreement.
1.18. ENGINEERS Consulani—A person, firm or
corporation having a contract with ENGINEER to furnish
services as ENGINEER's independent professional
associate or consultant with respect to the Project and who
is identified as such in the Supplementary Conditions.
1.19. rield Order --A written order issued by
ENGINEER which orders minor changes in the Work in
accordance with paragraph 9.5 but which does not involve
a change in the Contract Price or the Contract Times.
1.20. General Requirements —Sections of Division I of
the Specifications.
1.21. Hazardous 1Vasre—The term Hazardous Waste shall
have the meaning provided in Section 1004 of the Solid
Waste Disposal Act (42 USC Section 6903) as amended
from time to time.
1.22.a. laws and Regulations; Laws or Regulations -Any
and all applicable laws, rules, regulations, ordinances,
codes and orders of any and all governmental bodies,
agencies, authorities and courts having jurisdiction.
1.22.b. legal Holidays —shall be those holidays observed
by the City of Fort Collins
1.23. Lienv—Liens, charges, security interests or
encumbrances upon real property or personal property.
1.24. Alilesione—A principal event specified in the
Contract Documents relating to an intermediate completion
date or time prior to Substantial Completion of all the
Work.
1.25. Notice tfAward—A written notice by OWNER to
the apparent successful bidder stating that upon compliance
by the apparent successful bidder with the conditions
precedent enumerated therein, within the time specified,
OWNER will sign and deliver the Agreement.
1.26. Notice to Proceed —A written notice given by
OWNER to CONTRACTOR (with a copy to ENGINEER)
fixing the date on which the Contract Times will
commence to run and on which CONTRACTOR shall start
to perform CONTRACTOR'S obligations under the
Contract Documents.
1.27. 0111NCR—The public body or authority,
corporation, association, firm or person with whom
CONTRACTOR has entered into the Agreement and for
whom the Work is to be provided.
1.28. Partial Utilization —Use by OWNER of a
substantially completed part of the Work for the purpose
for which it is intended (or a related purpose) prior to
Substantial Completion of all the Work.
1.29. PCBs —Polychlorinated biphenyls.
1.30. Petrorleuor—Petroleum, including crude oil or any
fraction thereof which is liquid at standard conditions of
temperature and pressure (60 degrees Fahrenheit and
14.7 pounds per square inch absolute), such as oil,
petroleum, fuel oil, oil sludge, oil refuse, gasoline, kerosene
and oil mixed with other non -Hazardous Wastes and crude
of Is.
1.31. Project —The total construction of which the Work
to be provided under the Contract Documents may be the
whole, or a part as indicated elsewhere in the Contract
Documents.
1.32.a. Radioactive V61crial—Source, special nuclear, or
byproduct material as defined by the Atomic Energy Act of
1 2
I
EJCDC GENERAL CONDITIONS 1910.8 (1990 Edition)
w/ CITY OF FORT COLONS MODIFICATIONS (REV 4/2000)
1954 (42 USC Section 2011 et seq.) as amended from
time to time.
1.32.b. Regular Working Hours —Regular working hours
are defined as 7:00am to 6:00om unless otherwise
specified in the General Requirements.
1.33. Resident 11rrjea Representative —The authorized
representative of ENGINEER who may be assigned to the
site or any part thereof.
1.34. Samples —Physical examples of materials,
equipment, or workmanship that are representative of
some portion of the Work and which establish the
standards by which such portion of the Work will be
judged.
1.35. Shop Drawings —All drawings, diagrams,
illustrations, schedules and other data or information
which are specifically prepared or assembled by or for
CONTRACTOR and submitted by CONTRACTOR to
illustrate some portion of the Work.
1.36. Specifications —Those portions of the Contract
Documents consisting of written technical descriptions of
materials, equipment, construction systems, standards and
workmanship as applied to the Work and certain
administrative details applicable thereto.
1.37. Subcontractor —An individual, firm or corporation
having a direct contract with CONTRACTOR or with any
other Subcontractor for the performance of a part of the
Work at the site.
1.38. Substantial Completion —The Work (or a
specified part thereol) has progressed to the point where,
in the opinion of ENGINEER as evidenced by
ENGINEER's definitive certificate of Substantial
Completion, it is sufficiently complete, in accordance with
the Contract Documents, so that the Work (or specified
part) can be utilized for the purposes for which it is
intended; or if no such certificate is issued, when the
Work is complete and ready for final payment as
evidenced by ENGINEER's written recommendation of
final payment in accordance with paragraph 14.13. The
terms "substantially complete" and "substantially
completed" as applied to all or part of the Work refer to
Substantial Completion thereof.
1.39. Supplementary Conditions -The part of the
Contract Documents which amends or supplements these
General Conditions.
1:40. 5'ttpplier•—A manufacturer, fabricator, supplier,
distributor, materialman or vendor having a direct contract
with CONTRACTOR or with any Subcontractor to
famish materials or equipment to be incorporated in the
Work by CONTRACTOR or any Subcontractor.
1.41. Underground Facilities —All pipelines, conduits,
ducts, cables, wires, manholes, vaults, tanks, tunnels or
other such facilities or attachments, and any encasements
containing such facilities which have been installed
underground to furnish any of the following services or
U-
materials: electricity, gases, steam, liquid petroleum
products, telephone or other communications, cable
television, sewage and drainage removal, traffic or other
control systems or water.
1.42. Unit Price Work —Work to be paid for on the basis
of unit prices.
1.43. Work —The entire completed construction or the
various separately identifiable parts thereof required to be
furnished under the Contract Documents. Work includes
and is the result of performing or furnishing labor and.
furnishing and incorporating materials and equipment into
the construction, and performing or furnishing services and
furnishing documents, all as required by the Contract
Documents.
1.44. Work Change Directive —A written directive to
CONTRACTOR, issued on or after the Effective Date of
the Agreement and signed by OWNER and recommended
by ENGINEER, ordering an addition, deletion or revision
in the Work, or responding to differing or unforeseen
physical conditions under which the Work is to be
performed as provided in paragraph 4.2 or 4.3 or to
emergencies under paragraph 6.23. A Work Change
Directive will not change the Contract Price or the Contract
Times, but is evidence that the parties expect that the
change directed or documented by a Work Change
Directive will be incorporated in a subsequently issued
Change Order following negotiations by the parties as to its
effect, if any, on the Contract Price or Contract Times as
provided in paragraph 10.2.
1.45. Written Antendnteni—A written amendment of the
Contract Documents, signed by OWNER and
CONTRACTOR on or after the Effective Date of the
Agreement and normally dealing with the nonengineering
or nontechnical rather than strictly construction -related
aspects of the Contract Documents.
ARTICLE 2—PRELIMINARY MATTERS
Delivery of Bonds.
2.1. When CONTRACTOR delivers the executed
Agreements to OWNER, CONTRACTOR shall also
deliver to OWNER such Bonds as CONTRACTOR may
be required to famish in accordance with paragraph 5.1.
Copies of Documents:
2.2. OWNER shall furnish to CONTRACTOR up to ten
copies (unless otherwise specified in the Supplementary
Conditions) of the Contract Documents as are reasonably
necessary for the execution of the Work. Additional copies
will be furnished, upon request, at the cost of reproduction.
Contntencetnent of Contract Tintes; Notice to Proceed.
2.3. The Contract Times will commence to run on the
thirtieth day after the Effective Date of the Agreement, or,
EJCDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
if a Notice to Proceed is given, on the day indicated in the
Notice to Proceed. A Notice to Proceed may be given at
any time within thirty days after the Effective Date of the
Agreement. 1- ne eyent will the Gent_et Times
„emmenee to o:a ,,.,....:..,. R laWr : aR t e xiiieth day - .do rafteF the day
•.. n
Ote
,. F.1... A..-.,,.....,..• th@ Ih th is 1•
eaF
Starting the Work:
2.4. CONTRACTOR shall start to perform the Work
on the date when the Contract Times commence to run,
but no Work shall be done at the site prior to the date on
which the Contract Times commence to run.
Before Starting Construction:
2.5. Before undertaking each part of the Work,
CONTRACTOR shall carefully study and compare the
Contract Documents and check and verify pertinent
figures shown thereon and all applicable field
measurements. CONTRACTOR shall promptly report in
writing to ENGINEER any conflict, error, ambiguity or
discrepancy which CONTRACTOR may discover and
shall obtain a written interpretation or clarification from
ENGINEER before proceeding with any Work affected
thereby; however, CONTRACTOR shall not be liable to
OWNER or ENGINEER for failure to report any conflict,
error, ambiguity or discrepancy in the Contract
Documents, unless CONTRACTOR knew or reasonably
should have known thereof.
2.6. Within ten days after the Effective Date of the
Agreement (unless otherwise specified in the General
Requirements), CONTRACTOR shall submit to
ENGINEER for review:
2.6.1. a preliminary progress schedule indicating
the times (numbers of days or dates) for starting and
completing the various stages of the Work, including
any Milestones specified in the Contract Documents;
2.6.2. a preliminary schedule of Shop Drawing and
Sample submittals which will list each required
submittal and the times for submitting, reviewing and
processing such submittal;
2.6.2.1. In no case will a schedule be
acceptable which allows less than 21 calendar
days for each review by Engineer.
2.6.3. A preliminary schedule of values for all of
the Work which will include quantities and prices of
items aggregating the Contract Price and will
subdivide the Work into component parts in sufficient
detail to serve as the basis for progress payments
during construction. Such prices will include an
appropriate amount of overhead and profit applicable
to each item of Work.
2.7. Before any Work at the site is started,
CONTRACTOR and QALN9 shall each deliver to the
edter OWNER with copies to eaph Additional :_ imed
: n .Le Suppie.. entaFy Genditia ,. ENGINEER,
I
1
I
I
I
certificates of insurance (and other evidence of insurance
r-easenabty--requesE requested by OWNER) which
CONTRACTOR and OWNER :espeet;:ury are is required
to purchase and maintain in accordance with
paragraphs 5A, 5.6 and 5. .
Preconstruction Conference:
2.8. Within twenty days after the Contract Times start to
run, but before any Work at the site is started, a conference
attended by CONTRACTOR. ENGINEER and others as
appropriate will be held to establish a working
understanding among the parties as to the Work and to
discuss the schedules referred to in paragraph 2.6,
procedures for handling Shop Drawings and other
submittals processing Applications for Payment and
maintaining required records.
Initially Acceptable Schedules:
2.9. Unless otherwise provided in the Contract
Documents, '......t Wi days bef Fe _UbFRi5Si8_ Of the �._.
before any work at the site begins,
a conference attended by CONTRACTOR, ENGINEER
and others as apprepFiete designated by OWNER, will be
held to review for acceptability to ENGINEER as provided
below the schedules submitted in accordance with
paragraph 2.6. and Division I - General Requirements.
CONTRACTOR shall have an additional ten days to make
corrections and adjustments and to complete and resubmit
the schedules. No progress payment shall be made to
CONTRACTOR until the schedules are submitted to and
acceptable to ENGINEER as provided below. The
progress schedule will be acceptable to ENGINEER as
providing an orderly progression of the Work to
completion within any specified Milestones and the
Contract Times, but such acceptance will neither impose on
ENGINEER responsibility for the sequencing, scheduling
or progress of the Work nor interfere with or relieve
CONTRACTOR from CONTRACTOR's full
responsibility therefor. CONTRACTOR's schedule of
Shop Drawing and Sample submissions will be acceptable
to ENGINEER as providing a workable arrangement for
reviewing and processing the required submittals
CONTRACTOR's schedule of values will be acceptable to
ENGINEER as to form and substance.
ARTICLE 3—CONTRACT DOCUMENTS: INTENT,
AMENDING, REUSE
Intent:
3.1. The Contract Documents comprise the entire
agreement between OWNER and CONTRACTOR
concerning the Work. The Contract Documents are
complementary; what is called for by one is as binding as if
called for by all. The Contract Documents will be
construed in accordance with the law of the place of the
Project
3.2. It is the intent of the Contract Documents to
FJCDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4(2000)
describe a functionally complete Project (or part thereof)
to be constructed in accordance with the Contract
Documents. Any Work, materials or equipment that may
reasonably be inferred from the Contract Documents or
from prevailing custom or trade usage as being required to
produce the intended result will be furnished and
performed whether or not specifically called for. When
words or phrases which have a well-known technical or
construction industry or trade meaning are used to
describe Work, materials or equipment, such words or
phrases shall be interpreted in accordance with that
meaning. Clarifications and interpretations of the Contract
Documents shall be issued by ENGINEER as provided in
paragraph 9.4.
3.3. Reference to Standards and Specifhcations of
Technical Societies, Reporting and Resolving
Discrepancies.
3.3.1. Reference to standards, specifications,
manuals or codes of any technical society, organization
or association, or to the Laws or Regulations of any
governmental authority, whether such reference be
specific or by implication, shall mean the latest
standard, specification, manual, code or Laws or
Regulations in effect at the time of opening of Bids (or,
on the Effective Date of the Agreement if there were
no Bids), except as may be otherwise specifically
stated in the Contract Documents.
3.3.2. If, during the performance of the Work,
CONTRACTOR discovers any conflict, error,
ambiguity or discrepancy within the Contract
Documents or between the Contract Documents and
any provision of any such Law or Regulation
applicable to the performance of the Work or of any
such standard, specification, manual or code or of any
instruction of any Supplier referred to in paragraph 6.5,
CONTRACTOR shall report it to ENGINEER in
writing at once, and, CONTRACTOR shall not
proceed with the Work affected thereby (except in an
emergency as authorized by paragraph 6.23) until an
amendment or supplement to the Contract Documents
has been issued by one of the methods indicated in
paragraph 3.5 or 3.6; provided, however, that
CONTRACTOR shall not be liable to OWNER or
ENGINEER for failure to report any such conflict,
error, ambiguity or discrepancy unless
CONTRACTOR knew or reasonably should have
known thereof.
3.3.3. Except as otherwise specifically stated in the
Contract Documents or as may be provided by
amendment or supplement thereto issued by one of the
methods indicated in paragraph 3.5 or 3.6, the
provisions of the Contract Documents shall take
precedence in resolving any conflict, error, ambiguity
or discrepancy between the provisions of the Contract
Documents and:
3.3.3.1. the provisions of any such standard,
specification, manual, code or instruction (whether
or not specifically incorporated by reference in the
Contract Documents); or
11
3.3.3.2. the provisions of any such Laws or
Regulations applicable to the performance of the
Work (unless such an interpretation of the
provisions of the Contract Documents would result
in violation of such Law or Regulation).
No provision of any such standard, specification, manual,
code or instruction shall be effective to change the duties
and responsibilities of OWNER, CONTRACTOR or
ENGINEER, or any of their subcontractors, consultants,
agents or employees from those set forth in the Contract
Documents, nor shall it be effective to assign to OWNER.
ENGINEER or any of ENGINEER's Consultants, agents or
employees any duty or authority to supervise or direct the
furnishing or performance of the Work or any duty or
authority to undertake responsibility inconsistent with the
provisions of paragraph 9.13 or any other provision of the
Contract Documents.
3.4. Whenever in the Contract Documents the terms "as
ordered", "as directed", "as required", "as allowed", "as
approved" or terms of like effect or import are used, or the
adjectives "reasonable", "suitable", "acceptable", "proper"
or "satisfactory" or adjectives of like effect or import are
used to describe a requirement, direction, review or
judgment of ENGINEER as to the Work, it is intended that
such requirement, direction, review or judgment will be
solely to evaluate, in general, the completed Work for
compliance with the requirements of and information in the
Contract Documents and conformance with the design
concept of the completed Project as a functioning whole as
shown or indicated in the Contract Documents (unless there
is a specific statement indicating otherwise). The use of
any such term or adjective shall not be effective to assign to
ENGINEER any duty or authority to supervise or direct the
furnishing or performance of the Work or any duty or
authority to undertake responsibility contrary to the
provisions of paragraph 9.13 or any other provision of the
Contract Documents.
Amending and Supplementing Contract Documents.
3.5. The Contract Documents may be amended to
provide for additions, deletions and revisions in the Work
or to modify the terms and conditions thereof in one or
more of the following ways:
3.5.1. a formal Written Amendment,
3.5.2. a Change Order (pursuant to paragraph 10.4),
or
EICDC GENERAL CONDITIONS 1910-8 (1990 Edition)
wt CITY OF FORT COLLINS MODIFICATIONS (REV V2000)
3.5.3. a Work Change Directive (pursuant to
paragraph 10.1).
3.6. In addition, the requirements of the Contract
Documents may be supplemented, and minor variations
and deviations in the Work may be authorized, in one or
more of the following ways:
3.6.1. A Field Order (pursuant to paragraph 9.5),
3.6.2. ENGINEER's approval of Shop Drawing or
Sample (pursuant to paragraphs 6.26 and 6.27), or
3.6.3. ENGINEER's written interpretation or
clarification (pursuant to paragraph 9.4).
Reuse of Documents.
3.7. CONTRACTOR, and any Subcontractor or
Supplier or other person or organization performing or
furnishing any of the Work under a direct or indirect
contract with OWNER (i) shall not have or acquire any
title to or ownership rights in any of the Drawings,
Specifications or other documents (or copies of any
thereof) prepared by or bearing the seal of ENGINEER or
ENGINEER's Consultant, and (ii) shall not reuse any of
such Drawings, Specifications, other documents or copies
on extensions of the Project or any other project without
written consent of OWNER and ENGINEER and specific
written verification or adaptation by ENGINEER.
ARTICLE 4—AVAILABILITY OF LANDS;
SUBSURFACE AND PHYSICAL CONDITIONS;
REFERENCE POINTS
Availability of Lands.-
4.1. OWNER shall furnish, as indicated in the Contract
Documents, the lands upon which the Work is to be
performed, rights -of -way and easements for access
thereto, and such other lands which are designated for the
use of CONTRACTOR. "-A- -....,.,.....1110'00fitteR FOEIHOSh
8F eF filing a meehanie's lien against stieh lands in
OWNER shall identify any encumbrances or restrictions
not of general application but specifically related to use of
lands so furnished with which CONTRACTOR will have
to comply in performing the Work. Easements for
permanent structures or permanent changes in existing
facilities will be obtained and paid for by OWNER, unless
otherwise provided in the Contract Documents. If
CONTRACTOR and OWNER are unable to agree on
entitlement to or the amount or extent of any adjustments
in the Contract Price or the Contract Times as a result of
any delay in OWNER's furnishing these lands, rights -of -
way or easements, CONTRACTOR may make a claim
therefor as provided in Articles II and 12.
I
I
I
I
I
CONTRACTOR shall provide for all additional lands and
access thereto that may be required for temporary
construction facilities or storage of materials and
equipment.
4.Z Subsurface and Physical Conditions:
4.2.1. Reports and Drawings: Reference is made to
the Supplementary Conditions for identification of:
4.2.1.1. Subsurface Conditions: Those reports of
explorations and tests of subsurface conditions at or
contiguous to the site that have been utilized by
ENGINEER in preparing the Contract Documents;
and
4.2.1.2. Phvsical Conditions: Those drawings of
physical conditions in or relating to existing surface
or subsurface structures at or contiguous to the site
(except Underground Facilities) that have been
utilized by ENGINEER in preparing the Contract
Documents.
4.2.2. Limited Reliance by CON71t4C'POR Authorized;
'Technical Dula: CONTRACTOR may rely upon the
general accuracy of the "technical data" contained in such
reports and drawings, but such reports and drawings are not
Contract Documents. Such "technical data" is identified in
the Supplementary Conditions. Except for such reliance on
such "technical data", CONTRACTOR may not rely upon
or make any claim against OWNER, ENGINEER or any of
ENGINEER's Consultants with respect to:
4.2.2.1. the completeness of such reports and
drawings for CONTRACTOR's purposes.
including, but not limited to, any aspects of the
means, methods, techniques. sequences and
procedures of construction to be employed by
CONTRACTOR and safety precautions and
programs incident thereto, or
4.2.2.2. other data, interpretations, opinions
and information contained in such reports or shown
or indicated in such drawings, or
4.2.2.3. any CONTRACTOR interpretation of
or conclusion drawn from any "technical data" or
any such data, interpretations, opinions or
information.
4.2.3. Notice of Differing Subsurface rn• Physical
CondiNons•: If CONTRACTOR believes that any
subsurface or physical condition at or contiguous to the site
that is uncovered or revealed either:
4.2.3.1. is of such a nature as to establish that
any "technical data" on which CONTRACTOR is
entitled to rely as provided in paragraphs 4.2.1 and
4.2.2 is materially inaccurate, or
4.2.3.2. is of such a nature as to require a
change in the Contract Documents, or
4.2.3.3. differs materially from that shown or
EJCDC GENERAL CONDITIONS 1910-8 (1990 Edition)
vv/ CITY OF FORT COLLINS MODIFICATIONS (REV 412000)
indicated in the Contract Documents, or
4.2.3.4. is of an unusual nature, and differs
materially from conditions ordinarily encountered
and generally recognized as inherent in work of
the character provided for in , the Contract
Documents; then
CONTRACTOR shall, pfgmpily immediately after
becoming aware thereof and before further disturbing
conditions affected thereby or performing any Work in
connection therewith (except in an emergency as
permitted by paragraph 6.23), notify OWNER and
ENGINEER in writing about such condition.
CONTRACTOR shall not further disturb such conditions
or perform any Work in connection therewith (except as
aforesaid) until receipt of written order to do so.
4.2.4. ENGINEER's Review: ENGINEER will
promptly review the pertinent conditions, determine the
necessity of OWNER's obtaining additional exploration or
tests with respect thereto and advise OWNER in writing
(with a copy to CONTRACTOR) of ENGINEER's
findings and conclusions.
4.2.5. Possible Conti -act Documents Change: If
ENGINEER concludes that a change in the Contract
Documents is required as a result of a condition that meets
one or more of the categories in paragraph 4.2.3, a Work
Change Directive or a Change Order will be issued as
provided in Article 10 to reflect and document the
consequences of such change.
4.2.6. Possible Price and Times Adjustments: An
equitable adjustment in the Contract Price or in the
Contract Times, or both, will be allowed to the extent that
the existence of such uncovered or revealed condition
causes an increase or decrease in CONTRACTOR's cost
of, or time required for performance of, the Work; subject,
however, to the following:
4.2.6.1. such condition must meet any one or
more of the categories described in
paragraphs4.2.3.1 through4.2.3.4, inclusive;
4.2.6.2. a change in the Contract Documents
pursuant to paragraph 4.2.5 will not be an
automatic authorization of nor a condition
precedent to entitlement to any such adjustment;
4.2.6.3. with respect to Work that is paid for
on a Unit Price Basis, any adjustment in Contract
Price will be subject to the provisions of
paragraphs 9.10 and 11.9;and
4.2.6.4. CONTRACTOR shall not be entitled
to any adjustment in the Contract Price or Times
if,,
4.2.6.4.1. CONTRACTOR knew of
the existence of such conditions at the
time CONTRACTOR made a final
commitment to OWNER in respect of
Contract Price and Contract Times by the
[I
submission of a bid or becoming bound
under a negotiated
give written notice to that owner and to OWNER and
contract; or
ENGINEER. ENGINEER will promptly review the
Underground Facility and determine the extent, if
4.2.6.4.2. the existence of such
any, to which a change is required in the Contract
condition could reasonably have been
Documents to reflect and document the consequences
discovered or revealed as a result of any
of the existence of the Underground Facility. If
examination, investigation, exploration,
ENGINEER concludes that a change in the Contract
test or study of the site and contiguous
Documents is required, a Work Change Directive or a
areas required by the Bidding
Change Order will be issued as provided in Article 10
Requirements or Contract Documents to be
to reflect and document such consequences. During
conducted by or for CONTRACTOR prior
such time, CONTRACTOR shall be responsible for
to CONTRACTOR's making such final
the safety and protection of such Underground
commitment; or
Facility as provided in paragraph 6.20.
CONTRACTOR shall may be allowed an increase in
,
4.2.6.4.3. CONTRACTOR failed to
the Contract Price or an extension of the Contract
give the written notice within the time and
Times, or both, to the extent that they are attributable
as required by paragraph 4.2.3.
to the existence of any Underground Facility that was
not shown or indicated in the Contract Documents
If OWNER and CONTRACTOR are unable to agree on
and that CONTRACTOR did not know of and could
entitlement to or as to the amount or length of any such
not reasonably have been expected to be aware of or
equitable adjustment in the Contract Price or Contract
to have anticipated. If OWNER and CONTRACTOR
Times, a claim may be made therefor as provided in
are unable to agree on entitlement to or the amount or
Articles I I and 12. However, OWNER, ENGINEER and
length of any such adjustment in Contract Price or
ENGINEER's Consultants shall not be liable to
Contract Times, CONTRACTOR may make a claim
CONTRACTOR for any claims, costs, losses or damages
therefor as provided in Articles I I and 12. However,
sustained by CONTRACTOR on or in connection with any
OWNER, ENGINEER and ENGINEER's
other project or anticipated project.
Consultants shall not be liable to CONTRACTOR for
any claims, costs, losses or damages incurred or
4.3. Physical Conditions —Underground Facilities:
sustained by CONTRACTOR on or in connection
with any other project or anticipated project.
4.3.1. Shown or Indicated: The information and data
shown or indicated in the Contract Documents with
Reference Points:
,
respect to existing Underground Facilities at or
contiguous to the site is based on information and data
4.4. OWNER shall provide engineering surveys to
furnished to OWNER or ENGINEER by the owners of
establish reference points for construction which in
such Underground Facilities or by others. Unless it is
ENGINEER's judgment are necessary to enable
otherwise expressly provided in the Supplementary
CONTRACTOR to proceed with the Work.
Conditions:
CONTRACTOR shall be responsible for laying out the
Work, shall protect and preserve the established reference
4.3.1.1. OWNER and ENGINEER shall not be
points and shall make no changes or relocations without
responsible for the accuracy or completeness of any
the prior written approval of OWNER. CONTRACTOR
Q
such information or data; and
shall report to ENGINEER whenever any reference point
is lost or destroyed or requires relocation because of
4.3.1.2. The cost of all of the following will be
necessary changes in grades or locations, and shall be
included in the Contract Price and CONTRACTOR
responsible for the accurate replacement or relocation of
shall have full responsibility for: (i) reviewing and
such reference points by professionally qualified
checking all such information and data, (ii) locating
personnel.
all Underground Facilities shown or indicated in the
Contract Documents,(iii) coordination of the Work
4.5. Asbestos, PCBs, Petroleum, Hazardous Waste or
with the. owners of such Underground Facilities
Radioactive Material..
during construction, and (iv) the safety and
protection of all such Underground Facilities as
4.5.1. OWNER shall be responsible for any
provided in paragraph 6.20 and repairing any
Asbestos, PCBs, Petroleum, Hazardous Waste or
damage thereto resulting from the Work.
Radioactive Material uncovered or revealed at the site
which was not shown or indicated in Drawings or
4.3.2. Not Shown or Indicated: If an Underground
Specifications or identified in the Contract
Facility is uncovered or revealed at or contiguous to
Documents to be within the scope of the Work and
the site which was not shown or indicated in the
which may present a substantial danger to persons or
Contract Documents, CONTRACTOR shall, pFE)FRP65'
property exposed thereto in connection with the Work
immediately after becoming aware thereof and before
at the site. OWNER shall not be responsible for any
further disturbing conditions affected thereby or
such materials brought to the site by
performing any Work in connection therewith (except
CONTRACTOR, Subcontractors, Suppliers or
In an emergency as required by paragraph 6.23),
anyone else for whom CONTRACTOR is
identify the owner of such Underground Facility and
responsible.
EJCDC GENERAL. CONDITIONS 191" (1990 Edition)
7
w! CITY OF FORT COLLINS MODIFICATIONS (REV 412000)
I
1
MUM-
EJCDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
ARTICLES —BONDS AND INSURANCE
Performance, Prg,nrent and Other Bonds:
5.1. CONTRACTOR shall furnish Performance and
Payment Bonds, each in an amount at least equal to the
Contract Price as security for the faithful performance and
payment of all CONTRACTOR's obligations under the
Contract Documents. These Bonds shall remain in effect
at least until one year after the date when final payment
becomes due, except as provided otherwise by Laws or
Regulations or by the Contract Documents.
CONTRACTOR shall also famish such other Bonds as
are required by the Supplementary Conditions. All Bonds
shall be in the form prescribed by the Contract Documents
except as provided otherwise by Laws or Regulations and
shall be executed by such sureties as are named in the
current list of "Companies Holding Certificates of
Authority as Acceptable Sureties on Federal Bonds and as
Acceptable Reinsuring Companies" as published in
Circular 570 (amended) by the Audit Staff, Bureau of
Government Financial Operations, U.S. Treasury
Department. All Bonds signed by an agent must be
accompanied by a certified copy of such agent's authority
to act.
5.2. If the surety on any on famished by
CONTRACTOR is declared a bankrupt or becomes
insolvent or its right to do business is terminated in any
state where any part of the Project is located or it ceases to
meet the requirements of paragraph 5.1, CONTRACTOR
shall within ten days thereafter substitute another Bond
and surety, both of which must be acceptable to OWNER.
5.3. Licensed Sureties and Insurers, Certificates of
Insurance:
5.3.1. All Bonds and insurance required by the
Contract Documents to be purchased and maintained
by OWNER or CONTRACTOR shall be obtained
from surety or insurance companies that are duly
licensed or authorized in the jurisdiction in which the
Project is located to issue Bonds or insurance policies
for the limits and coverages so required. Such surety
and insurance companies shall also meet such
additional requirements and qualifications as may be
provided in the Supplementary Conditions.
5.3.2. CONTRACTOR shall deliver to OWNER,
with copies to each additional insured identified in the
Supplementary Conditions, certificates of insurance
(and other evidence of insurance requested by
OWNER or any other additional insured) which
CONTRACTOR is required to purchase and maintain
in accordance with paragraph 5.4. OWNER shell
CONTRACTOR's Liability Insurance:
5.4. CONTRACTOR shall purchase and maintain such
liability and other insurance as is appropriate for the Work
being performed and furnished and as will provide
protection from claims set forth below which may arise out
of or result from CONTRACTOR's performance and
famishing of the Work and CONTRACTOR's other
obligations under the Contract Documents, whether it is to
be performed or furnished by CONTRACTOR, any
Subcontractor or Supplier, or by anyone directly or
indirectly employed by any of them to perform or furnish
any of the Work, or by anyone for whose acts any of them
may be liable:
5.4.1. claims under workers' compensation, disability
benefits and other similar employee benefit acts;
5.4.2. claims for damages because of bodily injury,
occupational sickness or disease, or death of
CONTRACTOR's employees;
5.4.3. claims for damages because of bodily injury,
sickness or disease. or death of any person other than
CONTRACTOR's employees;
5.4.5. claims for damages, other than to the Work
itself, because of injury to or destruction of tangible
property wherever located, including loss of use
resulting therefrom; and
5.4.6. claims for damages because of bodily injury or
death of any person or property damage arising out of
the ownership, maintenance or use of any motor
vehicle.
The policies of insurance so required by this paragraph 5A
to be purchased and maintained shall:
5.4.7. with respect to insurance required by
paragraphs 5.4.3 through 5.4.6 inclusive and 5.4.9,
include as additional insureds (subject to any
customary exclusion in respect of professional
liability), OWNER, ENGINEER, ENGINEER's
Consultants and any other persons or entities identified
in the Supplementary Conditions, all of whom shall be
listed as additional insureds, and include coverage for
the respective officers and employees of all such
additional insureds;
5.4.8. include the specific coverages and be written
for not less than the limits of liability provided in the
Supplementary Conditions or required by Laws or
Regulations, whichever is greater;
5.4.9. include completed operations insurance;
E)CDC GENERAL CONDITIONS 1910-5 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 412000)
5.4.10. include contractual liability insurance
covering CONTRACTOR's indemnity obligations
under paragraphs 6.12, 6.16 and 6.31 through 6,33;
5.4.11. contain a provision or endorsement that the
coverage afforded will not be cancelled, materially
changed or renewal refused until at least thirty days'
prior written notice has been given to OWNER and
CONTRACTOR and to each other additional insured
identified in the Supplementary Conditions to whom
a certificate of insurance has been issued (and the
certificates of insurance furnished by the
CONTRACTOR pursuant to paragraph 5.3.2 will so
provide);
5.4.12. remain in effect at least until final payment
and at all times thereafter when CONTRACTOR may
be correcting, removing or replacing defective Work
in accordance with paragraph 13.12; and
5.4.13. with respect to completed operations
insurance, and any insurance coverage written on a
claims -made basis, remain in effect for at least two
years after final payment (and CONTRACTOR shall
furnish OWNER and each other additional insured
identified in the Supplementary Conditions to whom
a certificate of insurance has been issued evidence
satisfactory to OWNER and any such additional
insured of continuation of such insurance at final
payment and one year thereafter).
OWNER's Liability Insurance:
5.5. In addition to insurance required to be provided
by CONTRACTOR under paragraph 5.4, OWNER, at
OWNER's option, may purchase and maintain at
OWNER's expense OWNER's own liability insurance as
will protect OWNER against claims which may arise from
operations under the Contract Documents.
Property Insurance:
5.6.2. LP I3 •Ide09
Risk"all sit
c
shall..t de
ti
r
Fi Rd WAFT.
leas
and shallagainst
fel(ewing —perils fire, lightning,
at
ettet,ded
Agreement and that OWNER will suffer financial loss if the Work is not
completed within the times specified in each Work Order pursuant to
paragraph 3.1. above, plus any extensions thereof allowed in
accordance with Article 12 of the General Conditions. They also
recognize the delays, expenses and difficulties involved in proving in
a legal proceeding the actual loss suffered by OWNER if the Work is
not completed on time. Accordingly, instead of requiring any such
proof, OWNER and CONTRACTOR agree that as liquidated damages for delay
(but not as penalty) CONTRACTOR shall pay OWNER the amount set forth
in each Work Order.
3.3. Contract Period.
This
Agreement shall
commence
upon the
date of execution as shown by
the
date this Agreement is
signed by
'
OWNER, and shall continue in
full
force and effect
through
May 31,
2012. In addition, at the option
of the City, the
agreement may be
'
extended for additional one
additional one year periods.
year
Written
periods not to
notice of
exceed
renewal
four (4)
shall be
provided to the Contractor and
mailed no later than
ninety
(90) days
prior to contract end.
1]
3.4. Early Termination by OWNER / Notices. Notwithstanding the
time periods contained herein or in any Work Order, OWNER may
terminate this Agreement or any Work Order at any time without cause
by providing written notice of termination to CONTRACTOR. Such notice
shall be mailed at least fifteen (15) days prior to the termination
date contained in said notice unless otherwise agreed in writing by
the parties. All notices provided under this Agreement shall be
effective when mailed, postage prepaid and sent to the following
address:
OWNER:
City of Fort Collins
Attn: Purchasing Dept.
PO Box 580
Fort Collins, CO 80522
With Copy to:
City of Fort Collins
Purchasing Division
Attn: Opal F. Dick,
CPPO, Senior Buyer
CONTRACTOR:
Hydro Construction
Company, Inc.
Attn: James Eurich
PO Box 580 301 East Lincoln Ave
Fort Collins, CO 80522 Loveland, CO 80524
In the event of early termination by OWNER, CONTRACTOR shall be
paid for services rendered to the termination date, subject only to
the satisfactory performance of CONTRACTOR'S obligations under this
Agreement. Such payment shall be CONTRACTOR'S sole right and remedy
for such termination.
' ARTICLE 4. CONTRACT PRICE
4.1. Unless otherwise provided in a Work Order, OWNER shall pay
' CONTRACTOR for performance of the Work in accordance with the Contract
Documents in current funds, as specified in each Work Order, as
AGREEMENT 00520- Page 3
I
L
1
1
I
1
C
1
1
1
I
I
1
eeveffige,
Walff dafflege, and .I as may be
-.:
NUN -
ow
WMP
5.9. OWNER shall not be responsible for purchasing
and maintaining any property insurance to protect the
interests of CONTRACTOR, Subcontractors or others in
the—'A'94. !a the estest r ,1 d •t.t 1.
at aF8
caPplemen"Eenditiens The ris{F-ssmeh less and any
to EICDC GENERAL CONDITIONS 1910-8(1990 Edition)
wi CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
-
�1!i!A:
1
Receipt and Application of Insurance Proceeds.
5.12. Any insured loss under the policies of insurance
required by paragraphs 5.6 and 5.7 will be adjusted with
OWNER and made payable to OWNER as fiduciary for the
insureds, as their interests may appear, subject to the
requirements of any applicable mortgage clause and of
paragraph 5.13. OWNER shall deposit in a separate
account any money so received, and shall distribute it in
accordance with such agreement as the parties in interest
may reach. If no other special agreement is reached the
damaged Work shall be repaired or replaced, the moneys so
received applied on account thereof and the Work and the
cost thereof covered by an appropriate Change Order or
Written Amendment.
5.13. OWNER as fiduciary shall have power to adjust
and settle any loss with the insurers unless one of the
parties in interest shall object in writing within fifteen days
after the occurrence of loss to OWNER's exercise of this
power. If such objection be made, OWNER as fiduciary
shall make settlement with the insurers in accordance with
such agreement as the parties in interest may reach. If no
such agreement among the parties in interest is reached,
OWNER as fiduciary shall adjust and settle the loss with
the insurers and of - - 6 -
'�9
Acceptance of Bonds and Insurance; Option to Replace:
5.14. If eith•- ^ ^"• IntlIA E; ..- ( QNT-D (-Tr�D
OWNER has any objection to the coverage afforded by or
other provisions of the Bends er insurance required to be
purchased and maintained by the athff pats}
CONTRACTOR in accordance with Article 5 on the basis
of non-conformance with the Contract Documents, the
8bie6liNgPfft5'..n a ..,,..�..,_....FIZOWNERwill
notify CONTRACTOR^in writing within ten fifteen days
after reeeipt delivery of the certificates (eF -fir e•:idene
FeqUested) to OWNER as required by paragraph 2.7.
Partial Utilization —Property Insurance:
5.15. If OWNER finds it necessary to occupy or use a
portion or portions of the Work prior to Substantial
FJCDC GENERAL CONDITIONS 1910-8 (1990 Edition)
wl CITY OF FORT COLLINS MODIFICATIONS (REV 412000)
Completion of all the Work, such use or occupancy may
be accomplished in accordance with paragraph 14.10;
provided that no such use or occupancy shall commence
before the insurers providing the property insurance have
acknowledged notice thereof and in writing effected any
changes in coverage necessitated thereby. The insurers
providing the property insurance shall consent by
endorsement on the policy or policies, but the property
insurance shall not be cancelled or permitted to lapse on
account of any such partial use or occupancy.
ARTICLE 6—CONTRACTOR'S
RESPONSIBILITIES
Supervision and Superintendence:
6.1. CONTRACTOR shhall supervise, inspect and
direct the Work competently and efficiently, devoting
such attention thereto and applying such skills and
expertise as may be necessary to perform the Work in
accordance with the Contract Documents.
CONTRACTOR shall be solely responsible for the means,
methods, techniques, sequences and procedures of
construction, but CONTRACTOR shall not be responsible
for the negligence of others in the design or specification
of a specific means, method, technique, sequence or
procedure of construction which is shown or indicated in
and expressly required by the Contract Documents.
CONTRACTOR shall be responsible to see that the
completed Work complies accurately with the Contract
Documents.
6.2. CONTRACTOR shall keep on the Work at all
times during its progress a competent resident
superintendent, who shall not be replaced without written
notice to OWNER and ENGINEER except under
extraordinary circumstances. The superintendent will be
CONTRACTOR's representative at the site and shall have
authority to act on behalf of CONTRACTOR. All
communications to the superintendent shall be as binding
as if given to CONTRACTOR.
Labor, Materials and Equipment:
6.3. CONTRACTOR shall provide competent,
suitably qualified personnel to survey, lay out and
construct the Work as required by the Contract
Documents. CONTRACTOR shall at all times maintain
good discipline and order at the site. Except as otherwise
required for the safety or protection of persons or the
Work or property at the site or adjacent thereto, and
except as otherwise indicated in the Contract Documents,
all Work at the site shall be performed during regular
working hours and CONTRACTOR will not permit
overtime work or the performance of Work on Saturday,
Sunday or any legal holiday without OWNER's written
consent given after prior written notice to ENGINEER.
CONTRACTOR shall submit requests to the ENGINEER
no less than 48 hours in advance of any Work to be
performed on Saturday, Sunday. Holidays or outside the
Regular Working Hours.
I
6.4. Unless otherwise specified in the General
Requirements, CONTRACTOR shall furnish and assume
full responsibility for all materials, equipment, labor,
transportation, construction equipment and machinery,
tools, appliances, fuel, power, light, heat, telephone, water,
sanitary facilities, temporary facilities and all other
facilities and incidentals necessary for the furnishing,
performance, testing, start-up and completion of the Work.
6.4.1. Purchasing Restrictions: CONTRACTOR
must comply with the Citv's Purchasing restrictions A
copv of the resolutions are available for review in the
'
offices of the Purchasing and Risk Management
Division or the City Clerk's office.
6.4.2. Cement Restrictions: City of Fort Collins
Resolution 91-121 requires that suppliers and Producers
of cement or products containing cement to certify that
1
the cement was not made in cement kilns that bum
hazardous waste as a fuel.
6.5. All materials and equipment shall be of good
quality and new, except as otherwise provided in the
Contract Documents. All warranties and guarantees
specifically called for by the Specifications shall expressly
run to the benefit of OWNER, if required by ENGINEER,
CONTRACTOR shall furnish satisfactory evidence
(including reports of required tests) as to the kind and
quality of materials and equipment. All materials and
equipment shall be applied, installed, connected, erected,
used, cleaned and conditioned in accordance with
'
instructions of the applicable Supplier, except as otherwise
provided in the Contract Documents.
i
Progress Schedule:
6.6. CONTRACTOR shall adhere to the progress
schedule established in accordance with paragraph 2.9 as it
may be adjusted from time to time as provided below:
'
6.6.1. CONTRACTOR shall submit to ENGINEER
for acceptance (to the extent indicated in
paragraph 2.9) proposed adjustments in the progress
schedule that will not change the Contract Times (or
Milestones). Such adjustments will conform generally
to the progress schedule then in effect and additionally
will comply with any provisions of the General
Requirements applicable thereto.
'
6.6.2. Proposed adjustments in
the progress schedule
that will change the. Contract Times (or Milestones)
shall be submitted in accordance with the requirements
of paragraph 12.1. Such adjustments may only be
'
made by a Change Order or Written Amendment in
accordance with Article 12.
6.7. Substitutes and "Or -Equal" /tents: '
6.7.1. Whenever
an item of material or equipment is
specified or described in the Contract Documents by
using the name of a proprietary item or the name of a
particular Supplier, the specification or description is
intended to establish the type, function and quality
required. Unless the specification or description
EJCDC GENERAL CONDITIONS
1910.8 (1990 Edition)
12
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 412000)
contains or is followed by words reading that no like,
equivalent or "or -equal" item or no substitution is
permitted, other items of material or equipment or
material or equipment of other Suppliers may be
accepted by ENGINEER under the following
circumstances:
6.7.1.1. "Or -Equal": If in ENGINEER's sole
discretion an item of material or equipment
proposed by CONTRACTOR is functionally
equal to that named and sufficiently similar so that
no change in related Work will be required, it may
be considered by ENGINEER as an "or -equal"
item, in which case review and approval of the
proposed item may, in ENGINEER's sole
discretion, be accomplished without compliance
with some or all of the requirements for
acceptance of proposed substitute items.
6.7.1.2. Substitute Items: If in ENGINEER's sole
discretion an item of material or equipment
proposed by CONTRACTOR does not qualify as
an "or -equal" item under subparagraph 6.7.1.1, it
will be considered a proposed substitute item.
CONTRACTOR shall submit sufficient
information as provided below to allow
ENGINEER to determine that the item of material
or equipment proposed is essentially equivalent to
that named and an acceptable substitute therefor.
The procedure for review by the ENGINEER will
include the following as supplemented in the
General Requirements and as ENGINEER may
decide is appropriate under the circumstances.
Requests for review of proposed substitute items
of material or equipment will not be accepted by
ENGINEER from anyone other than
CONTRACTOR. If CONTRACTOR wishes to
furnish or use a substitute item of material or
equipment, CONTRACTOR shall first make
written application to ENGINEER for acceptance
thereof, certifying that the proposed substitute will
perform adequately the functions and achieve the
results called for by the general design, be similar
in substance to that specified and be suited to the
same use as that specified. The application will
state the extent, if any, to which the evaluation
and acceptance of the proposed substitute will
prejudice CONTRACTOR's achievement of
Substantial Completion on time, whether or not
acceptance of the substitute for use in the Work
will require a change in any of the Contract
Documents (or in the provisions of any other
direct contract with OWNER for work on the
Project) to adapt the design to the proposed
substitute and whether or not incorporation or use
of the substitute in connection with the Work is
subject to payment of any license fee or royalty.
All variations of the proposed substitute from that
specified will be identified in the application and
available maintenance, repair and replacement
service will be indicated. The application will
also contain an itemized estimate of all costs or
credits that will result directly or indirectly from
acceptance of such substitute, including costs of
redesign and claims of other contractors affected
by the resulting change, all of which will be
considered by ENGINEER in the
CONTRACTOR shall perform not less than 20
die Work its forces (that is,
evaluating
percent of with own
proposed substitute. ENGINEER may require
without subcontracting). The 20 percent requirement
CONTRACTOR to furnish additional data about
shall be understood to refer to the Work the value of
the proposed substitute.
which totals not less than 20 percent of the Contract
Price.
'
6.7.1.3. CONTRAC7.OR's l•:rpense: All data to be
provided by CONTRACTOR in support of any
6.8.2. Bidding
proposed "or -equal" or substitute item will be at
Documents require the identity of certain
CONTRACTOR's expense.
Subcontractors, Suppliers or other persons or
organizations (including those who are to furnish the
6.7.2. Substitute Construclion Methods ar
principal items of materials or equipment) to be
Prrx:edures: If a specific means, method, technique,
submitted to OWNER in
sequence or procedure of construction is shown or
date prior to the Effective Date of the Agreement for
indicated in and expressly required by the Contract
acceptance by OWNER and ENGINEER;and—i#
,
Documents, CONTRACTOR may furnish or utilize a
C-QlSlTDAr:PPR has ...ihmiapd ,, list theFe9f
substitute means, method, technique, sequence or
^^-d^^^^ the c Genditie..
Nvith ppl^...enta..
procedure of construction acceptable to ENGINEER.
OWNER's or ENGINEER's acceptance (either in
CONTRACTOR shall submit sufficient information to
writing or by failing to make written objection thereto
allow ENGINEER, in ENGINEER's sole discretion, to
by the date indicated for acceptance or objection in
determine that the substitute proposed is equivalent to
the bidding documents or the Contract Documents) of
that expressly called for by the Contract Documents.
identified
The procedure for review by ENGINEER will be
eFganization se may -be FPAIRkpd An th
similar to that provided in subparagraph 6.7.1.2.
hnq4q Af
FPBsenable abjeetieft
...I.:..I.C shall ....1....it
6.7.3. lingineer:s Tvuluution: ENGINEER will be
-9111T%kGTOR an
iteeeptable substitute, 1.'.. ^,.^'-..^• Price Will
allowed a reasonable time within which to evaluate
each proposal or submittal made pursuant to
paragraphs 6.7.1.2 and 6.7.2. ENGINEER will be the
An L^ 641.10d ,.F \tl.:w.... Amendment sigAed, will
sole judge of acceptability. No "or -equal" or
constitute a condition of the Contract requiring the
substitute will be ordered, installed or utilized without
use of the named subcontractors, suppliers or other
ENGINEER'S prior written acceptance which will be
persons or organization on the Work unless prior
,
evidenced by either a Change Order or an approved
written approval is obtained from OWNER and
Shop Drawing. OWNER may require
ENGINEER. No acceptance by OWNER or
CONTRACTOR to fumish at CONTRACTOR's
ENGINEER of any such Subcontractor. Supplier or
expense a special performance guarantee or other
other person or organization shall constitute a waiver
surety with respect to any "or -equal" or substitute.
of any right of OWNER or ENGINEER to reject
ENGINEER will record time required by
defective Work.
ENGINEER and ENGINEER's Consultants in
evaluating substitutes proposed or submitted by
6_9.
CONTRACTOR pursuant to paragraphs 6.7.1.2 and
'
6.7.2 and in making changes at the Contract
6.9.1. CONTRACTOR shall be fully responsible to
Documents (or in the provisions of any other direct
OWNER and ENGINEER for all acts and omissions
contract with OWNER for work on the Project)
of the Subcontractors, Suppliers and other persons
occasioned thereby. Whether or not ENGINEER
and organizations performing or fumishing any of the
accepts a substitute item so proposed or submitted by
Work under a direct or indirect contract with
CONTRACTOR, CONTRACTOR shall reimburse
CONTRACTOR just as CONTRACTOR is
OWNER for the charges of ENGINEER and
responsible for CONTRACTOR's own acts and
ENGINEER's Consultants for evaluating each such
omissions. Nothing in the Contract Documents shall
proposed substitute item.
create for the benefit of any such Subcontractor,
,
Supplier or other person or organization any
6_8. Concerning Subcontractors, Suppliers and
contractual relationship between OWNER or
Others:
ENGINEER and any such Subcontractor, Supplier or
other person or organization, nor shall it create any
'
6.8.1. CONTRACTOR shall not employ any
obligation on the part of OWNER or ENGINEER to
Subcontractor, Supplier or other person or organization
pay or to see to the payment of any moneys due any
(including those acceptable to OWNER and
such Subcontractor, Supplier or other person or
ENGINEER as indicated in paragraph 6.8.2), whether
organization except as may otherwise be required by
'
initially or as a substitute, against whom OWNER or
Laws and Regulations. OWNER or ENGINEER may
ENGINEER may have reasonable objection.
furnish to anv Subcontractor. supplier or other person
CONTRACTOR shall not be required to employ any
or organization evidence of amounts paid to
Subcontractor, Supplier or other person or organization
CONTRACTOR in accordance with
to furnish or perform any of the Work against whom
CONTRACTOR'S "Applications for Payment".
CONTRACTOR has reasonable objection.
EICDC GENERAL CONDITIONS 1910-8 (1990 Edition) 13
%v! CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
I
I
I
I
I
I
LI
6.9.2. CONTRACTOR shall be solely responsible
for scheduling and coordinating the Work of
Subcontractors, Suppliers and other persons and
organizations performing or furnishing any of the
Work under a direct or indirect contract with
CONTRACTOR. CONTRACTOR shall require all
Subcontractors, Suppliers and such other persons and
organizations performing or furnishing any of the
Work to communicate with the ENGINEER through
CONTRACTOR.
6.10. The divisions and sections of the Specifications and
the identifications of any Drawings shall not control
CONTRACTOR in dividing the Work among
Subcontractors or Suppliers or delineating the Work to be
performed by any specific trade.
6.11. All Work performed for CONTRACTOR by a
Subcontractor or Supplier will be pursuant to an
appropriate agreement between CONTRACTOR and the
Subcontractor or Supplier which specifically binds the
Subcontractor or Supplier to the applicable terms and
conditions of the Contract Documents for the benefit of
OWNER and ENGINEER. "" ..-._. _... _.__! ....._...._..
Patent Fees and Royalties:
6.12. CONTRACTOR shall pay all license fees and
royalties and assume all costs incident to the use in the
performance of the Work or the incorporation in the Work
of any invention, design, process, product or device which
is the subject of patent rights or copyrights held by others.
If a particular invention, desibm, process, product or device
is specified in the Contract Documents for use in the
performance of the Work and if to the actual knowledge of
OWNER or ENGINEER its use is subject to patent rights
or copyrights calling for the payment of any license fee or
royalty to others, the existence of such rights shall be
disclosed by OWNER in the Contract Documents. To the
fullest extent permitted by Laws and Regulations,
CONTRACTOR shall indemnify and hold harmless
OWNER, ENGINEER, ENGINEER's Consultants and the
officers, directors, employees, agents and other consultants
of each and any of them from and against all claims, costs,
losses and damages arising out of or resulting from any
infringement of patent rights or copyrights incident to the
use in the performance of the Work or resulting from the
incorporation in the Work of any invention, design,
process, product or device not specified in the Contract
Documents.
E1CDCGENERAL CONDITIONS 1910-80990 Edition)
14 wt CITY OF FORT COLLINS MODIFICATIONS (REV Q2000)
Permits:
6.13. Unless otherwise provided in the Supplementary
Conditions, CONTRACTOR shall obtain and pay for all
construction permits and licenses. OWNER shall assist
CONTRACTOR, when necessary, in obtaining such
permits and licenses. CONTRACTOR shall pay all
governmental charges and inspection fees necessary for
the prosecution of the Work, which are applicable at the
time of opening of Bids, or, if there are no Bids, on the
Effective Date of the Agreement. CONTRACTOR shall
pay all charges of utility owners for connections to the
Work, and OWNER shall pay all charges of such utility
owners for capital costs related thereto such as plant
investment fees.
6.14. Laws and Regulations.
6.14.1. CONTRACTOR shall give all notices and
comply with all Laws and Regulations applicable to
furnishing and performance of the Work. Except
where otherwise expressly required by applicable
Laws and Regulations, neither OWNER nor
ENGINEER shall be responsible for monitoring
CONTRACTOR's compliance with any Laws or
Regulations.
6.14.2. If CONTRACTOR perfomts any Work
knowing or having reason to know that it is contrary
to Laws or Regulations, CONTRACTOR shall bear
all claims, costs, losses and damages caused by,
arising out of or resulting therefrom; however, it shall
not be CONTRACTOR's primary responsibility to
make certain that the Specifications and Drawings are
in accordance with Laws and Regulations, but this
shall not relieve CONTRACTOR of
CONTRACTOR's obligations under paragraph 3.3.2.
Tares:
6.15. CONTRACTOR shall pay all sales, consumer,
use and other similar taxes required to be paid by
CONTRACTOR in accordance with the Laws and
Regulations of the place of the Project which are
applicable during the performance of the Work.
6.15.1. OWNER is exempt from Colorado State and
local sales and use taxes on materials to be
Permanently incorporated into the project Said taxes
shall not be included in the Contract Price
Address:
Colorado Department of Revenue
State Capital Annex
1375 Sherman Street
Denver, Colorado, 80261
Sales and Use Taxes for the State of Colorado
Regional Transportation District (RTD) and certain
Colorado counties are collected by the State of
Colorado and are included in the Certification of
Exemption.
All applicable Sales and Use Taxes (including State
collected taxes), on any items other than construction
and building materials Physically incorporated into the
protect are to be Paid by CONTRACTOR and are to
be included in appropriate bid items
Use of Premises:
6.16. CONTRACTOR shall confine construction
equipment, the storage of materials and equipment and the
operations of workers to the site and land and areas
identified in and permitted by the Contract Documents and
other land and areas permitted by Laws and Regulations,
rights -of -way, permits and easements, and shall not
unreasonably encumber the premises with construction
equipment or • other materials or equipment.
CONTRACTOR shall assume full responsibility for any
damage to any such land or area, or to the owner or
occupant thereof or of any adjacent land or areas, resulting
from the performance of the Work. Should any claim be
made by any such owner or occupant because of the
performance of the Work, CONTRACTOR shall promptly
settle with such other party by negotiation or otherwise
resolve the claim by arbitration or other dispute resolution
proceeding or at law. CONTRACTOR shall, to the fullest
extent permitted by Laws and Regulations, indemnify and
hold harmless OWNER, ENGINEER, ENGINEER's
Consultant and anyone directly or indirectly employed by
any of them from and against all claims, costs, losses and
damages arising out of or resulting from any claim or
action, legal or equitable, brought by any such owner or
occupant against OWNER, ENGINEER or any other party
indemnified hereunder to the extent caused by or based
upon CONTRACTOR's performance of the Work.
6.17. During the progress of the Wont, CONTRACTOR
shall keep the premises free from accumulations of waste
materials, rubbish and other debris resulting from the
Work. At the completion of the Work CONTRACTOR
shall remove all waste materials, rubbish and debris from
and about the premises as well as all tools, appliances,
construction equipment and machinery and surplus
materials. CONTRACTOR shall leave the site clean and
ready for occupancy by OWNER at Substantial
Completion of the Work. CONTRACTOR shall restore to
original condition all property not designated for alteration
by the Contract Documents.
6.18. CONTRACTOR shall not load nor permit any part
of any structure to be loaded in any manner that will
endanger the structure, nor shall CONTRACTOR subject
any part of the Work or adjacent property to stresses or
pressures that will endanger it.
Record Documents:
EJCDC GENERAL CONDITIONS 1910-8 (1990 Edition)
iv/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
6.19. CONTRACTOR shall maintain in a safe place at
the site one record copy of all Drawings, Specifications,
Addenda, Written Amendments, Change Orders, Work
Change Directives, Field Orders and written
interpretations and clarifications (issued pursuant to
paragraph 9.4) in good order and annotated to show all
changes made during construction. These record
documents together with all approved Samples and a
counterpart of all approved Shop Drawings will be
available to ENGINEER for reference. Upon completion
of the Work, and prior to release of final payment, these
record documents, Samples and Shop Drawings will be
delivered to ENGINEER for OWNER.
Safety and Protection:
6.20. CONTRACTOR shall be responsible for
initiating, maintaining and supervising all safety
precautions and programs in connection with the Work.
CONTRACTOR shall take all necessary precautions for
the safety of, and shall provide the necessary protection to
prevent damage, injury or loss to:
6.20.1. all persons on the Work site or who may be
affected by the Work;
6.20.2. all the Work and materials and equipment to
be incorporated therein, whether in storage on or off
the site; and
6.20.3. other property at the site or adjacent thereto,
including trees, shrubs, lawns, walks, pavements,
roadways, structures, utilities and Underground
Facilities not designated for removal, relocation or
replacement in the course of construction.
CONTRACTOR shall comply with all applicable Laws
and Regulations of any public body having jurisdiction for
safety of persons or property or to protect them from
damage, injury or loss; and shall erect and maintain all
necessary safeguards for such safety and protection.
CONTRACTOR shall notify owners of adjacent property
and of Underground Facilities and utility owners when
prosecution of the Work may affect them, and shall
cooperate with them in the protection, removal, relocation
and replacement of their property. All damage, injury or
loss to any property referred to in paragraphs 6.20.2 or
6.20.3 caused, directly or indirectly, in whole or in part, by
CONTRACTOR, any Subcontractor, Supplier or any
other person or organization directly or indirectly
employed by any of them to perform or furnish any of the
Work or anyone for whose acts any of them may be liable,
shall be remedied by CONTRACTOR (except damage or
loss attributable to the fault of Drawings or Specifications
or to the acts or omissions of OWNER or ENGINEER or
ENGINEER's Consultant or anyone employed by any of
them or anyone for whose acts any of them may be liable,
and not attributable, directly or indirectly, in whole or in
part, to the fault or negligence of CONTRACTOR or any
Subcontractor, Supplier or other person or organization
directly or indirectly employed by any of them).
CONTRACTOR's duties and responsibilities for the safety
and protection of the Work shall continue until such time
as all the Work is completed and ENGINEER has issued a
15
I
1
0
notice to OWNER and CONTRACTOR in, accordance
with paragraph 14.13 that the Work is acceptable (except as
otherwise expressly provided in connection with
Substantial Completion).
6.21. Safety Representative:
CONTRACTOR shall designate a qualified and
experienced safety representative at the site whose duties
and responsibilities shall be the prevention of accidents and
the maintaining and supervising of safety precautions and
programs. '
Hazard Contnrunication Programs:
6.22. CONTRACTOR shall be responsible for
coordinating any exchange of material safety data sheets or
other hazard communication information required to be
made available to or exchanged between or among
employers at the .site in accordance with Laws or
Regulations.
' Entergencies:
i
I
n
I
I
6.23. In emergencies affecting the safety or protection of
persons or the Work or property at the site or adjacent
thereto, CONTRACTOR, without special instruction or
authorization from OWNER or ENGINEER, is obligated to
act to prevent threatened damage, injuryi or loss.
CONTRACTOR shall give ENGINEER prompt written
notice if CONTRACTOR believes that any Isignificant
changes in the Work or variations from the Contract
Documents have been caused thereby. If ENGINEER
determines that a change in the Contract Documents is
required because of the action taken by CONTRACTOR in
response to such an emergency, a Work Change Directive
or Change Order will be issued to document the
consequences of such action. I
6.24. Shop Drawings and Samples:
1 16
I
6.24.1. CONTRACTOR shall submit Shop; Drawings
to ENGINEER for review and approval in accordance
with the accepted schedule of Shop Drawings and
Sample submittals (see paragraph 2.9). All submittals
will be identified as ENGINEER may require and in
the number of copies specified in the General
Requirements. The data shown on the Shop Drawings
will be complete with respect to quantities,
dimensions, specified performance and design criteria,
materials and similar data to show ENGINEER the
materials and equipment CONTRACTOR proposes to
provide and to enable ENGINEER to review the
information for the limited purposes required by
paragraph 6.26.
6.24.2. CONTRACTOR shall also submit Samples to
ENGINEER for review and approval in accordance
with said accepted schedule of Shop Drawings and
Sample submittals. Each Sample will be identified
clearly as to material, Supplier, pertinent data such as
catalog numbers and the use for which intended and
otherwise as ENGINEER may require to enable
ENGINEER to review the submittal for the limited
E1CDC GENERAL CONDITIONS 1910-80990 Edition)
w! CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
purposes required by paragraph 6.26. The numbers
of each Sample to be submitted will be as specified in
the Specifications.
6.25. Submittal Procedures:
6.25.1. Before submitting each Shop Drawing or
Sample. CONTRACTOR shall have determined and
verified:
6.25.1.1. all field measurements, quantities,
dimensions, specified performance criteria,
installation requirements, materials, catalog
numbers and similar information with respect
thereto,
6.25.1.2. all materials with respect to intended
use, fabrication, shipping, handling, storage,
assembly and installation pertaining to the
performance of the Work, and
6.25.1.3. all information relative to
CONTRACTOR's sole responsibilities in respect
of means, methods, techniques, sequences and
procedures of construction and safety precautions
and programs incident thereto.
CONTRACTOR shall also have reviewed and
coordinated each Shop Drawing or Sample with other
Shop Drawings and Samples and with the
requirements of the Work and the Contract
Documents.
6.25.2. Each submittal will bear a stamp or specific
written indication that CONTRACTOR has satisfied
CONTRACTOR's obligations under the Contract
Documents with respect to CONTRACTOR's review
and approval of that submittal.
6.25.3. At the time of each submission,
CONTRACTOR shall give ENGINEER specific
written notice of such variations, if any, that the Shop
Drawing or Sample submitted may have from the
requirements of the Contract Documents, such notice
to be in a written communication separate from the
submittal; and, in addition, shall cause a specific
notation to be made on each Shop Drawing and
Sample submitted to ENGINEER for review and
approval of each such variation.
6.26. ENGINEER will review and approve Shop
Drawings and Samples in accordance with the schedule of
Shop Drawings and Sample submittals accepted by
ENGINEER as required by paragraph 2.9. ENGINEER's
review and approval will be only to determine if the items
covered by the submittals will, after installation or
incorporation in the Work. conform to the information
given in the Contract Documents and be compatible with
the design concept of the completed Project as a
functioning whole as indicated by the Contract
Documents. ENGINEER's review and approval will not
extend to means. methods, techniques, sequences or
procedures of construction (except where a particular
means, method, technique, sequence or procedure of
I
construction is specifically and expressly called for by the
Contract Documents) or to safety precautions or programs
incident thereto. The review and approval of a separate
item as such will not indicate approval of the assembly in
which the item functions. CONTRACTOR shall make
corrections required by ENGINEER, and shall return the
required number of corrected copies of Shop Drawings and
submit as required new Samples for review and approval.
CONTRACTOR shall direct specific attention in writing to
revisions other than the corrections called for by
ENGINEER on previous submittals.
6.27. ENGINEER's review and approval of Shop
Dmwings or Samples shall not relieve CONTRACTOR
from responsibility for any variation from the requirements
of the Contract Documents unless CONTRACTOR has in
writing called ENGINEER's attention to each such
variation at the time of submission as required by
paragraph 6.25.3 and ENGINEER has given written
approval of each such variation by a specific written
notation thereof incorporated in or accompanying the Shop
Drawing or Sample approval; nor will any approval by
ENGINEER relieve CONTRACTOR from responsibility
for complying with the requirements of paragraph 6.25. I.
6.28. Where a Shop Drawing or Sample is required by
the Contract Documents or the schedule of Shop Drawing
and Sample submissions accepted by ENGINEER as
required by paragraph 2.9. any related Work performed
prior to ENGINEER's review and approval of the pertinent
submittal will be at the sole expense and responsibility of
CONTRACTOR.
Continuing the Work:
6.29. CONTRACTOR shall carry on the Work and
adhere to die progress schedule during all disputes or
disagreements with OWNER. No Work shall be delayed or
postponed pending resolution of any disputes or
disagreements, except as permitted by paragraph 15.5 or as
OWNER and CONTRACTOR may otherwise agree in
writing.
6.30. CONTRACTOR's General Warranty and
Guarantee:
6.30.1. CONTRACTOR warrants and guarantees to
OWNER, ENGINEER and ENGINEER's Consultants
that all Work will be in accordance with the Contract
Documents and will not be defec9ive.
CONTRACTOR's warranty and guarantee hereunder
excludes defects or damage caused by:
6.30.1.1. abuse, modification or improper
maintenance or operation by persons other than
CONTRACTOR, Subcontractors or Suppliers; or
6.30.1.2. normal wear and tear under normal
usage.
6.30.2. CONTRACTOR's obligation to perform and
complete the Work in accordance with the Contract
Documents shall be absolute. None of the following
will constitute an acceptance of Work that is not in
EICDC GENERAL CONDITIONS 19108 (1990 Edition)
cot CITY OF FORT COLLINS MODIFICATIONS (REV 412000)
accordance with the Contract Documents or a release
of CONTRACTOR's obligation to perform the Work
in accordance with the Contract Documents:
6.30.2.1. observations by ENGINEER;
6.30.2.2. recommendation of any progress or
final payment by ENGINEER;
6.30.2.3. the issuance of a certificate of
Substantial Completion or any payment by
OWNER to CONTRACTOR under the Contract
Documents;
6.30.2.4. use or occupancy of the Work or any
part thereof by OWNER;
6.30.2.5. any acceptance by OWNER or any
failure to do so;
6.30.2.6. any review and approval of a Shop
Drawing or Sample submittal or the issuance of a
notice of acceptability by ENGINEER pursuant
to paragraph 14.13;
6.30.2.7. any inspection, test or approval by
others; or
6.30.2.8. any correction of defective Work by
OWNER.
Indemnification:
6.31. To the fullest extent permitted by Laws and
Regulations, CONTRACTOR shall indemnify and hold
harmless ' OWNER, ENGINEER, ENGINEER's
Consultants and the officers, directors, employees, agents
and other consultants of each and any of them from and
against all claims, costs, losses and damages (including,
but not limited to, all fees and charges of engineers,
architects, attorneys and other professionals and all court
or arbitration or other dispute resolution costs) caused by,
arising out of or resulting from the performance of the
Work, provided that any such claim, cost, loss or damage:
(i) is attributable to bodily injury, sickness, disease or
death, or to injury to or destruction of tangible property
(other than the Work itself), including the loss of use
resulting therefrom, and (ii) is caused in whole or in part
by any negligent act or omission of CONTRACTOR, any
Subcontractor, any Supplier, any person or organization
directly or indirectly employed by any of them to perform
or furnish any of the Work or anyone for whose acts any
of them may be liable, regardless of whether or not caused
in part by any negligence or omission of a person or entity
indemnified hereunder or whether liability is imposed
upon such indemnified party by Laws and Regulations
regardless of the negligence of any such person or entity.
6.32. In any and all claims against OWNER or
ENGINEER or any of their respective consultants, agents,
officers, directors or employees by any employee (or the
survivor or personal representative of such employee) of
CONTRACTOR, any Subcontractor, any Supplier, any
person or organization directly or indirectly employed by
17
11
11
I
i
11
I
1
I
I
I
I
I
11
1
I
1
any of them to perform or furnish any of the Work or
anyone for whose acts any of them may be! liable, the
indemnification obligation under paragraph 6.3I shall not
be limited in any way by any limitation on the amount or
type of damages, compensation or benefits payable by or
for CONTRACTOR or any such Subcontractor, Supplier or
other person or organization under workers' compensation
acts, disability benefit acts or other employee benefit acts.
6.33. The indemnification obligations of
CONTRACTOR under paragraph 6.31 shall not extend to
the liability of ENGINEER and ENGINEER's Consultants,
officers, directors, employees or agents caused by the
professional negligence, errors or omissions of any of them.
Survival of Obligations:
6.34. All representations, indemnifications, warranties
and guarantees made in, required by or given in accordance
with the Contract Documents, as well as all continuing
obligations indicated in the Contract Documents, will
survive final payment, completion and acceptance of the
Work and termination or completion of the Agreement.
ARTICLE 7—OTHER WORK
Related Work at Site:
7.1. OWNER may perform other work related to the
Project at the site by OWNER's own forces, or let other
direct contracts therefor which shall contain General
Conditions similar to these, or have other work performed
by utility owners. If the fact that such other work is to be
performed was not noted in the Contract Documents, then:
(i) written notice thereof will be given to CONTRACTOR
prior to starting any such other work and
(ii) CONTRACTOR may make a claim therefor as
provided in Articles I I and 12 if CONTRACTOR believes
that such performance will involve additional expense to
CONTRACTOR or requires additional time and:the parties
are unable to agree as to the amount or extent thereof.
7.2. CONTRACTOR shall afford each other contractor
who is a party to such a direct contract and each utility
owner (and OWNER, if OWNER is performing the
additional work with OWNER's employees) proper and
safe access to the site and a reasonable opportunity for the
introduction and storage of materials and equipment and
the execution of such other work and shall properly connect
and coordinate the Work with theirs. Unless I otherwise
provided in the Contract Documents, CONTRACTOR
shall do all cutting, fitting and patching of the Work that
may be required to make its several parts come together
properly and integrate with such other work.
CONTRACTOR shall not endanger any work of others by
cutting, excavating or otherwise altering their work and
will only cut or alter their work with the written consent of
ENGINEER and the others whose work will be affected.
The duties and responsibilities of CONTRACTOR' under
this paragraph are for the benefit of such utility owners and
other contractors to the extent that there are comparable
' 18
I
EJCDC GENERAL CONDITIONS 1910.8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
provisions for the benefit of CONTRACTOR in said
direct contracts between OWNER and such utility owners
and other contractors.
7.3. If the proper execution or results of any part of
CONTRACTOR's Work depends upon work performed
by others under this Article 7, CONTRACTOR shall
inspect such other work and promptly report to
ENGINEER in writing any delays, defects or deficiencies
in such other work that render it unavailable or unsuitable
for the proper execution and results of CONTRACTOR's
Work. CONTRACTOR's failure so to report will
constitute an acceptance of such other work as fit and
proper for integration with CONTRACTOR's Work
except for latent or nonapparent defects and deficiencies
in such other work.
Coordination:
7.4. If OWNER contracts with others for the
performance of other work on the Project at the site, the
following will be set forth in Supplementary Conditions:
7.4.1. the person, firm or corporation who will have
authority and responsibility for coordination of the
activities among the various prime contractors will be
identified;
7.4.2. the specific matters to be covered by such
authority and responsibility will be itemized; and
7.4.3. the extent of such authority and
responsibilities will be provided.
Unless otherwise provided in the Supplementary
Conditions, OWNER shall have sole authority and
responsibility in respect of such coordination.
ARTICLE 8—OWNER'S RESPONSIBILITIES
8.1. Except as otherwise provided in these General
Conditions, OWNER shall issue all communications to
CONTRACTOR through ENGINEER.
8.2. In case of termination of the employment of
ENGINEER, OWNER shall appoint an engineer agaipM
whose status under the Contract Documents shall be that
of the former ENGINEER.
8.3. OWNER shall furnish the data required of
OWNER under the Contract Documents promptly and
shall make payments to CONTRACTOR promptly when
they are due as provided in paragraphs 14.4 and 14.13.
8.4. OWNER's duties in respect of providing lands
and easements and providing engineering surveys to
establish reference points are set forth in paragraphs 4.1
and 4.4. Paragraph4.2 refers to OWNER's identifying
and making available to CONTRACTOR copies of
reports of explorations and tests of subsurface conditions
at the site and drawings of physical conditions in existing
structures at or contiguous to the site that have been utilized
by ENGINEER in preparing the Contract Documents.
wid Fneintaining i'
8.6. OWNER is obligated to execute Change Orders as
indicated in paragraph 10.4.
8.7. OWNER's responsibility in respect of certain
inspections, tests and approvals is set forth in
paragraph 13.4.
8.8. In connection with OWNER's right to stop Work or
suspend Work, see paragraphs 13.10 and 15.1,
Paragraph 15.2 deals with OWNER's right to terminate
services of CONTRACTOR under certain circumstances.
8.9. The OWNER shall not supervise, direct or have
control or authority over, nor be responsible for,
CONTRACTOR's means, methods, techniques, sequences
or procedures of construction or the safety precautions and
programs incident thereto, or for any failure of
CONTRACTOR to comply with Laws and Regulations
applicable to the furnishing or performance of the Work.
OWNER will not be responsible for CONTRACTOR's
failure to perform or furnish the Work in accordance with
the Contract Documents.
•_ . .. .. .. 1�Yi1fAl11MI��1!i�iL�iiY;'FI*I�i41
ARTICLE 9—ENGINEER'S STATUS DURING
CONSTRUCTION
OWNER's Representative:
9.1. ENGINEER will be OWNER's representative
during the construction period. The duties and
responsibilities and the limitations of authoritv of
ENGINEER as OWNER's representative during
construction are set forth in the Contract Documents and
shall not be extended without written consent of OWNER
and ENGINEER.
I <sits to Site:
9.2. ENGINEER will make visits to the site at intervals
appropriate to the various stages of construction as
ENGINEER deems necessary in order to observe as an
experienced and qualified design professional the progress
EJCDC GENERAL CONDITIONS 1910.8 (1990 Edition).
w,' CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
that has been made and the quality of the various aspects
of CONTRACTOR's executed Work. Based on
information obtained during such visits and observations,
ENGINEER will endeavor for the benefit of OWNER to
determine, in general, if the Work is proceeding in
accordance with the Contract Documents. ENGINEER
will not be required to make exhaustive or continuous on -
site inspections to check the quality or quantity of the
Work. ENGINEER's efforts will be directed toward
providing for OWNER a greater degree of confidence that
the completed Work will conform generally to the
Contract Documents. On the basis of such visits and on -
site observations, ENGINEER will keep OWNER
informed of the progress of the Work and will endeavor to
guard OWNER against defective Work. ENGINEER's
visits and on -site observations are subject to all the
limitations on ENGINEER' authority and responsibility
set forth in paragraph 9.13, and particularly, but without
limitation, during or as a result of ENGINEER's on -site
visits or observations of CONTRACTOR's Work
ENGINEER will not supervise, direct, control or have
authority over or be responsible for CONTRACTOR's
means, methods, techniques, sequences or procedures of
construction, or the safety precautions and programs
incident thereto, or for any failure of CONTRACTOR to
comply with Laws and Regulations applicable to the
furnishing or performance of the Work.
Project Representative:
9.3. If OWNER and ENGINEER agree, ENGINEER
will furnish a Resident Project Representative to assist
ENGINEER in providing more continuous observation of
the Work. The responsibilities and authority and
limitations thereon of any such Resident Project
Representative and assistants will be as provided in
paragraphs 9.3 and 9.13
Conditions of these General Conditions. If OWNER
designates another representative or agent to represent
OWNER at the site who is not ENGINEER's Consultant,
agent or employee, the responsibilities and authority and
limitations thereon of such her person will be as
provided in '�� c
�--rr._.••_••••••� ., Paragraph 9.3
9.3.2. Duties and Responsibilities. Representative
will:
9.3.2.1. Schedules - Review the progress
19
' Contract Price equal to the Cost of the Work plus a Fixed Fee in
accordance with Exhibit "A" or Fixed Cost by specific line items. The
' Cost of the Work shall be as defined or excluded in Article 11,
paragraphs 11.4 and 11.5, of the General Conditions, subject to the
following:
' 4.1.1. Unless otherwise provided in a Work Order, payroll
costs in the Cost of the Work shall be as defined in Article 11.4.1 of
the General Conditions and shall not exceed thirty nine (39%) percent
' of the salaries and wages.
' 4.1.2. Unless otherwise provided in a Work Order, the
Contract Price, exclusive of the cost or credit of any Change Orders
or of Owner -procured equipment or Owner -provided work listed in each
Work Order, is guaranteed by the CONTRACTOR not to exceed a Guaranteed
' Maximum Price specified in each Work Order, for all work covered by
and included in the Work Order. The Allowable Cost of the Work shall
be defined as the difference in the Fixed Fee and the Guaranteed
Maximum Price. Costs which would cause the CONTRACTOR to exceed the
Allowable Cost of the Work and/or Guaranteed Maximum Price shall be
paid by the CONTRACTOR without reimbursement by the OWNER.
' 4.1.3. Unless otherwise provided in a Work Order, the
CONTRACTOR'S Fixed Fee that may be authorized in the Work Order shall
include all Field Office and General Office overhead, mark-up on all
materials, equipment and subcontract costs, small tools allowance,
equipment fuels, and equipment rentals as defined in Article 11.4.5.3
and the CONTRACTOR'S profit for the Allowable Cost of the Work.
' Payment for additional Field Office and General Office overhead and
the CONTRACTOR'S profit shall not be included in any Change Order
unless the total Contract Price, including all Change Orders, exceeds
the Guaranteed Maximum Price. For any Change Order which increases
the total Contract Price above the Guaranteed Maximum Price, the
CONTRACTOR'S fee applied to the net increase shall, unless otherwise
provided in the Work Order, include Field Office overhead and profit
which shall be defined as 5.5(5.5%) percent of the actual Cost of the
Work, General Office overhead and profit which shall be defined as 5.0
(5.0%) percent of the actual Cost of the Work.
' 4.2. Shared Savings Clause. Should a new way of constructing
any portion of the Project be discovered that involves a substantial
savings, Shared Savings may be applied. The shared savings proposal
must involve modifying the means, methods and/or the materials used
without impacting the quality of the project. After receiving
approval from the Design Engineer, the construction team shall submit
their proposal to the review Committee. This committee will be
' comprised of the Senior Utilities Engineer, the Utility Senior Buyer,
and the contractor's General Manager. If the change is approved, a
Change Order will be processed documenting the change(s) to the
Contract. Seventy-five (75) percent of the savings shall belong to
the City while twenty-five (25) percent of the savings shall belong to
' AGREEMENT 00520- Page 4
'
schedule and other schedules prepared by the
CONTRACTOR and consult with the
ENGINEER concerningacceptability. •,
9.3.2.2. Conferences and Meeting I - Attend
'
meeting with the CONTRACTOR' such as
preconstruction conferences, growess meetings
and other job conferences and prepare and
circulate copies of minutes of meetings!
i
9.3.2.3. Liaison
9.3.2.3.1. Serve as ENGINEER'S liaison
with CONTRACTOR. working_ principally
through CONTRACTOR'S superintendent to
assist the CONTRACTOR in understanding
the Contract Documents.
'
9.3.2.3.2. Assist in obtaining from OWNER
additional details or information, when
required, for proper execution of the Work.
1
I
' 20
9.3.2.3.3. Advise the ENGINEER and
CONTRACTOR of the commencement of
any Work requiring a Shop Drawing or
sample submission if the submission has not
been approved by the ENGINEER.
9.3.2.4.Review of Work. Reiection of Defective
Work. Inspections and Tests -
9.3.2.4.1. Conduct on -site observations of
the Work in progress to assist the ENGINEER
in determining that the Work is proceeding in
accordance with the Contract Documents.
9.3.2.4.3. Accompany visiting inspectors
representing public or other agencies having
iurisdiction over the Project, record dhe results
of these inspections and report to the
ENGINEER.
9.3.2.5. Interpretation of Contract
Documents. Report to ENGINEER when
clarifications and interpretations of the Contract
Documents are needed and transmit to
CONTRACTOR clarification and interpretation
of the Contract Documents as issued by the
ENGINEER
9.3.2.6. Modifications. Consider and
evaluate CONTRACTOR'S suggestions for
FJCDC GENERAL CONDITIONS 1910.8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
modification in Drawings or Specifications and
report these recommendations to ENGINEER.
Accurately transmit to CONTRACTOR
decisions issued by the ENGINEER.
9.3.2.7. Records.
9.3.2.7.3. Record names,
addresses and telephone numbers of all
CONTRACTORS, subcontractors and
manor suppliers of equipment and materials.
9.3.2.8. Reports.
9.3.2.8.1. Furnish ENGINEER Deriodic
reports, as required, of the progress of the
Work and of the CONTRACTOR'S
compliance with the progress schedule and
schedule of shoo Drawing and samole
submittals
9.3.2.8.2. Consult with ENGINEER in
advance of scheduling maior tests.
inspections or start of important phases of the
Work.
9.3.2.8.3. Draft proposed Change Orders
and Work Directive Changes, obtaining
backup material from the CONTRACTOR
and recommend to ENGINEER Change
Orders. Work Directive Changes and field
orders.
9.3.2.8.4. Report immediately to
ENGINEER and OWNER the occurrence of
any accident.
9.3.2.9. Payment Requests. Review applications
for payment with CONTRACTOR for compliance
with the established procedure for their
submission and forward with recommendation to
ENGINEER. noting oarticularly the relationshin of
the payment requested to the schedule of values
work completed and materials and equipment
delivered at the site but not incorporated in the
Work.
9.3.2.10. Completion.
9.3.2.10.1. Before ENGINEER issues a
Certificate of Substantial Completion submit
to CONTRACTOR a list of observed items
requiring correction or completion.
9.3.2.10.2. Conduct final inspection in the
company of the ENGINEER. OWNER and
CONTRACTOR and prepare a final list of
items to be corrected or completed.
9.3.2.10.3. Observe that all items on the
final list have been corrected or completed and
make recommendations to ENGINEER
concerning acceptance.
9.3.3. Limitation of Authority The Representative shall
not:
9.3.3.1. Authorize any deviations from the
Contract Documents or accept any substitute
materials or equipment, unless authorized by the
ENGINEER.
9.3.3.2. Exceed limitations of ENGINEER'S
authority as set forth in the Contract Documents
9.3.3.3. Undertake anv of the responsibilities
of the CONTRACTOR. Subcontractors or
CONTRACTOR'S superintendent.
9.3.3.4. Advise on, or issue directions relative
to, or assume control over any aspect of the
means, methods, techniques sequences or
Procedures for construction unless such is
specifically called for in the Contract Documents
9.3.3.5. Advise on or issue directions
regarding or assume control over safety
precautions and programs in connections with the
Work.
9.3.3.6. Accept Shoo Drawings or sample
submittals from anyone other than the
CONTRACTOR.
9.3.3.7. Authorize OWNER to occupy the
Work in whole or in part.
9.3.3.8. Participate in specialized field or
laboratory tests or inspections conducted by others
except as specifically authorized by the
ENGINEER.
Clarifications and Interpretations:
9.4. ENGINEER will issue with reasonable promptness
such written clarifications or interpretations of the
EICDC GENERAL. CONDITIONS 1910.8 (1990 Edition)
a'! CITY OF FORT COLLINS MODIFICATIONS (REV 412000)
requirements of the Contract Documents (in the form of '
Drawings or otherwise) as ENGINEER may determine
necessary, which shall be consistent with the intent of and
reasonably inferable from the Contract Documents. Such '
written clarifications and interpretations will be binding on
OWNER and CONTRACTOR. If OWNER or
CONTRACTOR believes that a written clarification or
interpretation justifies an adjustment in the Contract Price
or the Contract Times and the parties are unable to agree
to the amount or extent thereof, if any, OWNER or
CONTRACTOR may make a written claim therefor as
provided in Article I I or Article 12.
Authorized Variations in Work:
'
9.5. ENGINEER may authorize minor variations in
the Work from the requirements of the Contract
Documents which do not involve an adjustment in the
Contract Price or the Contract Times and are compatible
,
with the design concept of the completed Project as a
functioning whole as indicated by the Contract
Documents. These may be accomplished by a Field Order
and will be binding on OWNER and also on
'
CONTRACTOR who shall perform the Work involved
promptly. If OWNER or CONTRACTOR believes that a
Field Order justifies an adjustment in the Contract Price or
the Contract Times and the parties are unable to agree as
to the amount or extent thereof, OWNER or
,
CONTRACTOR may make a written claim therefor as
provided in Article I I or 12.
Rejecting Defective Work:
'
9.6. ENGINEER will have authority to disapprove or
reject Work which ENGINEER believes to be defective,
or that ENGINEER believes will not produce a completed
'
Project that conforms to the Contract Documents or that
will prejudice the integrity of the design concept of the
completed Project as a functioning whole as indicated by
the Contract Documents. ENGINEER will also have
authority to require special inspection or testing of the
,
Work as provided in paragraph 13.9, whether or not the
Work is fabricated, installed or completed.
Shop Drawings, Change Orders and Payments:
'
9.7. In connection with ENGMEER's authority as to
Shop Drawings and Samples, see paragraphs 6.24 through
6.28 inclusive.
'
9.8. In connection with ENGINEER's authority as to
Change Orders, see Articles 10, 11, and 12.
9.9. In connection with ENGINEER's authority as to
'
Applications for Payment, see Article 14.
Deterndnations for Unit Prices:
9.10. ENGINEER determine
'
will the actual quantities
and classifications of Unit Price Work performed by
CONTRACTOR. ENGINEER will review with
CONTRACTOR the ENGINEER's preliminary
determinations on such matters before rendering a written
decision thereon (by recommendation of an Application
21
'
'
for Payment or otherwise). ENGINEER's written decision
decision, unless otherwise agreed in writing by OWNER
thereon will be final and binding upon OWNER and
and CONTRACTOR.
CONTRACTOR, unless, within ten days aftenthe date of
any such decision, either OWNER or CONTRACTOR
9.12. When functioning as interpreter and judge under
delivers to the other and to ENGINEER written notice of
paragraphs9.10 and 9.1 I, ENGINEER will not show
'
intention to appeal from ENGINEER's decision and: (i) an
partiality to OWNER or CONTRACTOR and will not be
appeal from ENGINEER's decision is taken within the time
liable in connection with any interpretation or decision
limits and in accordance with the procedures set forth in
rendered in good faith in such capacity. The rendering of
Exhibit GC -A, "Dispute Resolution Agreement", entered
into between OWNER and CONTRACTOR pursuant to
a decision by ENGINEER pursuant to paragraphs 9.10 or
9.11 with respect to any such claim, dispute or other
Article 16, or (ii) if no such Dispute Resolution, Agreement
matter (except any which have been waived by the making
has been entered into, a formal proceeding is instituted by
or acceptance of final payment as provided in
the appealing party in a forum of competent jurisdiction to
paragraph 14.15) will be a condition precedent to any
exercise such rights or remedies as the appealing party may
exercise by OWNER or CONTRACTOR of such rights or
'
have with respect to ENGINEER's decision, unless
remedies as either may otherwise have under the Contract
otherwise agreed in writing by OWNER and
Documents or by Laws or Regulations in respect of any
CONTRACTOR. Such appeal will not be subject to the
such claim, dispute or other matter puFsuant to Aftiele 16.
procedures of paragraph 9.11.
'
9.13. Limitations on ENGINEER's Authority and
Decisions on Disputes:
Responsibilities:
9.11: ENGINEER will be the initial interpreter of the
9.13.1. Neither ENGINEER's authority or
'
requirements of the Contract Documents and judge of the
responsibility under this Article 9 or under any other
acceptability of the Work thereunder. Claims, disputes and
provision of the Contract Documents nor any decision
other matters relating to the acceptability of the Work or
made by ENGINEER in good faith either to exercise
the interpretation of the requirements of the Contract
or not exercise such authority or responsibility or the
Documents pertaining to the performance and furnishing of
undertaking, exercise or performance of any authority
'
the Work and claims under Articles I I and 12 in respect of
or responsibility by ENGINEER shall create, impose
changes in the Contract Price or Contract Times will be
or give rise to any duty owed by ENGINEER to
referred initially to ENGINEER in writing with a request
CONTRACTOR, any Subcontractor, any Supplier,
for a formal decision in accordance with this paragraph.
any other person or organization, or to any surety for
'
Written notice of each such claim, dispute or other matter
or employee or agent of any of them.
will be delivered by the claimant to ENGINEER and the
other party to the Agreement promptly (but in no event
9.13.2. ENGINEER will not supervise, direct,
later than thirty days) after the start of the occurrence or
control or have authority over or be responsible for
'
event giving rise thereto, and written supporting data will
CONTRACTOR's means, methods, techniques,
be submitted to ENGINEER and the other party within
sequences or procedures of construction, or the safety
sixty days after the start of such occurrence or event unless
precautions and programs incident thereto, or for any
ENGINEER allows an additional period of time for the
failure of CONTRACTOR to comply with Laws and
submission of additional or more accurate data in support
Regulations applicable to the furnishing or
'
of such claim, dispute or other matter. The opposing party
performance of the Work. ENGINEER will not be
shall submit any response to ENGINEER and the claimant
responsible for CONTRACTOR's failure to perform
within thirty days after receipt of the claimant's last
or furnish the Work in accordance with the Contract
submittal (unless ENGINEER allows additional time).
Documents.
'
ENGINEER will render a formal decision in writing within
thirty days after receipt of the opposing parry's submittal, if
9.13.3. ENGINEER will not be responsible for the
any, in accordance with this paragraph. ENGINEER's
acts or omissions of CONTRACTOR or of any
written decision on such claim, dispute or other matter will
Subcontractor, any Supplier, or of any other person or
be final and binding upon OWNER and CONTRACTOR
organization performing or furnishing any of the
unless: (i) an appeal from ENGINEER's decision is taken
Work.
within the time limits and in accordance with the
procedures set forth in EXHIBIT GC -A,' "Dispute
9.13.4. ENGINEER's review of the final Application
Resolution Agreement", entered into between OWNER and
for Payment and accompanying documentation and
'
CONTRACTOR pursuant to Article 16, or (h) if no such
all maintenance and operating instructions, schedules,
Dispute Resolution Agreement has been entered into, a
guarantees, Bonds and certificates of inspection, tests
written notice of intention to appeal from ENGINEER's
and approvals and other documentation required to be
written decision is delivered by OWNER or
delivered by paragraph 14.12 will only be to
CONTRACTOR to the other and to ENGINEER within
determine generally that their content complies with
thirty days after the date of such decision and a formal
the requirements of, and in the case of certificates of
proceeding is instituted by the appealing party in a forum of
inspections, tests and approvals that the results
competent jurisdiction to exercise such rights or remedies
certified indicate compliance with, the Contract
as the appealing party may have with respect to such claim,
Documents.
dispute or other matter in accordance with applicable Laws
and Regulations within sixty days of the date of such
9.13.5. The limitations upon authority and
22 E1CDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
1
u 17
responsibility set forth in this paragraph 9.13 shall also
apply to ENGINEER's Consultants, Resident Project
Representative and assistants.
ARTICLE 10—CHANGES IN THE WORK
10.1. Without invalidating the Agreement and without
notice to any surety, OWNER may, at any time or from
time to time, order additions. deletions or revisions in the
Work. Such additions, deletions or revisions will be
authorized by a Written Amendment, a Change Order, or a
Work Change Directive. Upon receipt .of any such
document, CONTRACTOR shall promptly proceed with
the Work involved which will be performed under the
applicable conditions of the Contract Documents (except as
otherwise specifically provided).
10.2. If OWNER and CONTRACTOR are unable to
agree as to the extent, if any, of an adjustment in the
Contract Price or an adjustment of the Contract Times that
should be allowed as a result of a Work Change Directive,
a claim may be made therefor as provided in Article I I or
Article 12.
10.3. CONTRACTOR shall not be entitled to an increase
in the Contract Price or an extension of the Contract Times
with respect to any Work performed that is not required by
the Contract Documents as amended, modified and
supplemented as provided in paragraphs 3.5 and 3.6, except
in the case of an emergency as provided in paragraph 6.23
or in the case of uncovering Work as provided in
paragraph 13.9.
10.4. OWNER and CONTRACTOR shall execute
appropriate Change Orders recommended by ENGINEER
(or Written Amendments) covering:
10.4.1. changes in the Work which are (i) ordered
by OWNER pursuant to paragraph 10.1, (ii) required
because of acceptance of defective Work under
paragraph 13.13 or correcting defective Work under
paragraph 13.14, or (iii) agreed to by the parties;
10.4.2. changes in the Contract Price or Contract
Times which are agreed to by the parties; and
10.4.3. changes in the Contract Price or Contract
Times which embody the substance of any written
decision rendered by ENGINEER pursuant to
paragraph 9.11;
provided that, in lieu of executing any such Change Order,
an appeal may be taken from any such decision in
accordance with the provisions of the Contract Documents
and applicable Laws and Regulations, but during any such
appeal, CONTRACTOR shall carry on the Work and
adhere to the progress schedule as provided in
paragraph 6.29.
10.5. If notice of any change affecting the general scope
of the Work or the provisions of the Contract Documents
EJCDC GENERAL. CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV V2000)
(including, but not limited to, Contract Price or Contract
Times) is required by the provisions of any Bond to be
given to a surety, the giving of any such notice will be
CONTRACTOR's responsibility, and the amount of each
applicable Bond will be adjusted accordingly.
ARTICLE I I —CHANGE OF CONTRACT PRICE
11.1. The Contract Price constitutes the total
compensation (subject to authorized adjustments) payable
to CONTRACTOR for performing the Work. All duties,
responsibilities and obligations assigned to or undertaken
by CONTRACTOR shall be at CONTRACTOR's expense
without change in the Contract Price.
11.2. The Contract Price may only be changed by a
Change Order or by a Written Amendment. Any claim
for an adjustment in the Contract Price shall be based on
written notice delivered by the party making the claim to
the other party and to ENGINEER promptly (but in no
event later than thirty days) after the start of the
occurrence or event giving rise to the claim and stating the
general nature of the claim. Notice of the amount of the
claim with supporting data shall be delivered within sixty
days after the start of such occurrence or event (unless
ENGINEER allows additional time for claimant to submit
additional or more accurate data in support of the claim)
and shall be accompanied by claimant's written statement
that the adjustment claimed covers all known amounts to
which the claimant is entitled as a result of said
occurrence or event. All claims for adjustment in the
Contract Price shall be determined by ENGINEER in
accordance with paragraph 9.1 I if OWNER and
CONTRACTOR cannot otherwise agree on the amount
involved. No claim for an adjustment in the Contract
Price will be valid if not submitted in accordance with this
paragraph 11.2.
11.3. The value of any Work covered by a Change
Order or of any claim for an adjustment in the Contract
Price will be determined as follows:
11.3.1. where the Work involved is covered by unit
prices contained in the Contract Documents, by
application of such unit prices to the quantities of the
items involved (subject to the provisions of
23
paragraphs 11.9.1 through 11.9.3, inclusive);
11.3.2. where the Work involved is not covered by
unit prices contained in the Contract Documents, by a
mutually agreed payment basis, including lump sum
(which may include an allowance for overhead and
profit not necessarily in accordance with
paragraph 11.6.2);
'
11.3.3. where the Work involved is not covered by unit
prices contained in the Contract Documents and
agreement to a lump sum is not reached under
paragraph 11.3.2, on die basis of the Cost of the Work
(determined as provided in paragraphs 11.4 and 11.5)
plus a CONTRACTOR's fee for overhead and profit
(determined as provided in paragraph 11.6).
Cost of the Work:
11.4. The term Cost of the Work means the sum of all
costs necessarily incurred and paid by CONTRACTOR in
the proper performance of the Work. Except as otherwise
'
may be agreed to in writing by OWNER, such costs shall
be in amounts no higher than those prevailing in the
locality of the Project, shall include only the following
items and shall not include any of the costs itemized in
'
paragraph 11.5:
1 1.4.1. Payroll costs for employees in ; the direct
employ of CONTRACTOR in the performance of the
Work under schedules of job classifications agreed
upon by OWNER and CONTRACTOR. Such
employees shall include without limitation
superintendents, foremen and other personnel
employed full-time at the site. Payroll costs for
'
employees not employed full-time on the Work shall
be apportioned on the basis of their time spent on the
Work. Payroll costs shall inekide, butitet be limited to,
salaries and wages plus the cost of fringe benefits
which shall include social security contributions,
unemployment, excise and payroll taxes, workers'
compensation, health &Rd- e4Feme t benefits-benesesr
applicable thereto.
'
The expenses of performing Work after regular
working hours, on Saturday, Sunday or legal holidays,
shall be included in the above to the extent authorized
by OWNER.
11.4.2. Cost of all materials and equipment furnished
and incorporated in the Work, including costs of
transportation and storage thereof, and Suppliers' field
services required in connection therewith.. All cash
discounts shall accrue to CONTRACTOR unless
OWNER deposits funds with CONTRACTOR with
which to make payments, in which case the cash
discounts shall accrue to OWNER. All trade
discounts, rebates and refunds and returns from sale of
surplus materials and equipment shall accrue to
OWNER, and CONTRACTOR shall make provisions
so that they may be obtained.
11.4.3. Payments made by CONTRACTOR to the
Subcontractors for Work performed or furnished by
Subcontractors. If required by OWNER,
'
EJCDC GENERAL CONDITIONS
74 1910-8(1990 Edition)
cot CITY OF FORT COLLINS MODIFICATIONS (REV 4)2000)
CONTRACTOR shall obtain competitive bids from
Subcontractors acceptable to OWNER and
CONTRACTOR and shall deliver such bids to
OWNER who will then determine, with the advice of
ENGINEER, which bids, if any, will be accepted. If
any subcontract provides that the Subcontractor is to
be paid on the basis of Cost of the Work plus a fee,
the Subcontractor's Cost of the Work and fee shall be
determined in the same manner as CONTRACTOR's
Cost of the Work and fee as provided in
paragraphs 1 IA, 11.5, 11.6 and 11.7. All
subcontracts shall be subject to the other provisions of
the Contract Documents insofar as applicable.
11.4.4. Costs of special consultants (including but
not limited to engineers, architects, testing
laboratories, surveyors, attorneys and accountants)
employed for services specifically related to the
Work.
11.4.5. Supplemental costs including the following
11.4.5.1. The proportion of necessary
transportation, travel and subsistence expenses of
CONTRACTOR's employees incurred in
discharge of duties connected with the Work.
11.4.5.2. Cost, including transportation and
maintenance, of all materials, supplies,
equipment, machinery, appliances, office and
temporary facilities at the site and hand tools not
owned by the workers, which are consumed in the
performance of the Work, and cost less market
value of such items used but not consumed which
remain the property of CONTRACTOR.
11.4.5.3. Rentals of all construction
equipment and machinery and the parts thereof
whether rented from CONTRACTOR or others in
accordance with rental agreements approved by
OWNER with the advice of ENGINEER, and the
costs of transportation, loading, unloading,
installation, dismantling and removal thereof —all
in accordance with terms of said rental
agreements. The rental of any such equipment,
machinery or parts shall cease when the use
thereof is no longer necessary for the Work.
11.4.5.4. Sales, consumer, use or similar taxes
related to the Work, and for which
CONTRACTOR is liable, imposed by Laws and
Regulations.
11.4.5,5. Deposits lost for causes other than
negligence of CONTRACTOR, any
Subcontractor or anyone directly or indirectly
employed by any of them or for whose acts any
of them may be liable, and royalty payments and
fees for permits and licenses.
11.4.5.6. Losses and damages (and related
expenses) caused by damage to the Work, not
compensated by insurance or otherwise, sustained
by CONTRACTOR in connection with the
performance and furnishing of the Work (except
losses and damages within the deductible amounts
of property insurance established by OWNER in
accordance with paragraph 5.9), provided they
have resulted from causes other than the
negligence of CONTRACTOR, any
Subcontractor, or anyone directly or indirectly
employed by any of [Item or for whose acts any of
them may be liable. Such losses shall include
settlements made with the written consent and
approval of OWNER. No such losses, damages
and expenses shall be included in the Cost of the
Work for the purpose of determining
CONTRACTOR's fee. If, however, any such loss
or damage requires reconstruction and
CONTRACTOR is placed in charge thereof.
CONTRACTOR shall be paid for services a fee
proportionate to that stated in paragraph 11.6.2.
11.4.5.7. The cost of utilities, fuel and sanitary
facilities at the site.
11.4.5.8. Minor expenses such as telegrams,
long distance telephone calls, telephone service at
the site, expressage and similar petty cash items in
connection with the Work.
11.4.5.9. Cost of premiums for additional Bonds
and insurance required because of changes in the
Work.
11.5. The term Cost of the Work shall not include any of
the following:
11.5.1. Payroll costs and other compensation of
CONTRACTOR's officers, executives, principals (of
partnership and sole proprietorships), general managers,
engineers, architects, estimators, attorneys, auditors,
accountants, purchasing and contracting agents,
expediters, timekeepers, clerks and other personnel
employed by CONTRACTOR whether at the site or in
CONTRACTOR's principal or a branch office for
general administration of the Work and not specifically
included in the agreed upon schedule of job
classifications referred to in paragraph 11.4.1 or
specifically covered by paragraph 11.4.4—all of which
are to be considered administrative costs covered by the
CONTRACTOR's fee.
11.5.2. Expenses of CONTRACTOR' principal and
branch offices other than CONTRACTOR's office at
the site.
11.5.3. Any part of CONTRACTOR's capital
expenses, including interest on CONTRACTOR'S
capital employed for the Work and charges against
CONTRACTOR for delinquent payments.
11.5.4. Cost of premiums for all Bonds and for all
insurance whether or not CONTRACTOR is required
by the Contract Documents to purchase and maintain
the same (except for the cost of premiums covered by
subparagraph 11.4.5.9 above).
EJCDC GENERA!- CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 412000)
11.5.5. Costs due to the negligence of
CONTRACTOR, any Subcontractor, or anyone
directly or indirectly employed by any of them or for
whose acts any of them may be liable, including but
not limited to, the correction of defective Work,
disposal of materials or equipment wrongly supplied
and making good any damage to property.
11.5.6. Other overhead or general expense costs of
any kind and the costs of any item not specifically and
expressly included in paragraph 11.4.
11.6. The CONTRACTOR's fee allowed to
CONTRACTOR for overhead and profit shall be
determined as follows;
1 1.6.1. a mutually acceptable fixed fee; or
11.6.2. if a fixed fee is not agreed upon, then a fee
based on the following percentages of the various
portions of the Cost of the Work;
11-6.2.1. for costs incurred under
paragraphs 11.4.1 and 11.4.2. the
CONTRACTOR's fee shall be fifteen percent;
11.6.2.2. for costs incurred under
paragraph 11.4.3, the CONTRACTOR's fee shall
be five percent;
11.6.2.3. where one or more tiers of
subcontracts are on the basis of Cost of the Work
plus a fee and no fixed fee is agreed upon, the
intent of paragraphs 11.4.1, 11.4.2, 11.4.3 and
11.6.2 is that the Subcontractor who actually
performs or furnishes the Work, at whatever tier,
will be paid a fee of fifteen percent of the costs
incurred by such Subcontractor under paragraphs
11.4.1 and 11.4.2 and that any higher tier
Subcontractor and CONTRACTOR will each be
paid a fe
; to be negotiated
in good faith with the OWNER but not to exceed
five percent of the amount Paid to the next lower
tier Subcontractor.
11.6Z.4. no fee shall be payable on the basis
of costs itemized under paragraphs 11.4.4, 11.4.5
and 11.5;
11.6.2.5. the amount of credit to be allowed
by CONTRACTOR to OWNER for any change
which results in a net decrease in cost will be the
amount of the actual net decrease in cost plus a
deduction in CONTRACTOR's fee by an amount
equal to five percent of such net decrease; and
11.6.2.6. when both additions and credits are
involved in any one change, the adjustment in
CONTRACTORS fee shall be computed on the
basis of the net change in accordance with
paragraphs 11.6.2.1 through 11.6.2.5, inclusive.
11.7. Whenever the cost of any Work is to be
25
[1
11
determined pursuant to paragraphs 11.4 and 11.5,
CONTRACTOR will establish and maintain records
thereof in accordance with generally accepted accounting
practices and submit in forth acceptable to ENGINEER an
itemized cost breakdown together with supporting data.
Cash Allowances:
11.8. It is understood that CONTRACTOR has included
in the Contract Price all allowances so named in the
Contract Documents and shall cause the Work so covered
to be furnished and performed for such sums as may be
acceptable to OWNER and ENGINEER. CONTRACTOR
agrees that:
11.8.1. the allowances include the cost to
CONTRACTOR (less any applicable trade discounts)
of materials and equipment required by the allowances
to be delivered at the site, and all applicable taxes; and
11.8.2. CONTRACTOR's costs for unloading and
handling on the site, labor, installation costs, overhead,
profit and other expenses contemplated for the
allowances have been included in the Contract Price
and not in the allowances and no demand for
additional payment on account of any of the foregoing
will be valid.
Prior to final payment, an appropriate Change Oder will be
issued as recommended by ENGINEER to reflect actual
amounts due CONTRACTOR on account of Work covered
by allowances, and the Contract Price shall be
correspondingly adjusted.
11.9. Unit Price Work:
1 1.9.1. Where the Contract Documents provide that all
or part of the Work is to be Unit Price Work, initially
the Contract Price will be deemed to include for all
Unit Price Work an amount equal to the sum of the
established unit prices for each separately identified
item of Unit Price Work times the estimated quantity
of each item as indicated in the Agreement. The
estimated quantities of items of Unit Price Work are
not guaranteed and are solely for the purpose of
comparison of Bids and determining an initial Contract
Price. Determinations of the actual quantities and
classifications of Unit Price Work performed by
CONTRACTOR will be made by ENGINEER in
accordance with paragraph 9.10.
11.9.2. Each unit price will be deemed to include an
amount considered by CONTRACTOR to be adequate
to cover CONTRACTOR's overhead and profit for
each separately identified item.
11.9.3.OWNER or CONTRACTOR may make a
claim for an adjustment in the Contract Price in
accordance with Article 1 I if:
11.9.3.1. the quantity of any item of Unit Price
Work performed by CONTRACTOR differs
materially and significantly from the estimated
quantity of such item indicated in the Agreement;
' 26 EJCDC GENERAL. CONDITIONS 1910-8(1990 Edition)
a'/ CITY OF FORT COLLINS MODIFICATIONS (REV 4,2000)
and
11.9.3.2. there is no corresponding adjustment
with respect to any other item of Work; and
11.9.3.3. if CONTRACTOR believes that
CONTRACTOR is entitled to an increase in
Contract Price as a result of having incurred
additional expense or OWNER believes that
OWNER is entitled to a decrease in Contract Price
and the parties are unable to agree as to the
amount of any such increase or decrease.
11.9.3.4. CONTRACTOR acknowlecles that
the OWNER has the right to add or delete items in
the Bid or change quantities at OWNER'S sole
discretion without affecting the Contract Price of
any remaining item so long as the deletion or
addition does not exceed twentv-five percent of
the original total Contract Price
ARTICLE 12—CHANGE OF CONTRACT TIMES
12.1. The Contract Times (or Milestones) may only be
changed by a Change Order or a Written Amendment.
Any claim for an adjustment of the Contract Times (or
Milestones) shall be based on written notice delivered by
the party making the claim to the other parry and to
ENGINEER promptly (but in no event later than thirty
days) after the occurrence of the event giving rise to the
claim and stating the general nature of the claim. Notice
of the extent of the claim with supporting data shall be
delivered within sixty days after such occurrence (unless
ENGINEER allows additional time to ascertain more
accurate data in support of the claim) and shall be
accompanied by the claimant's written statement that the
adjustment claimed is the entire adjustment to which the
claimant has reason to believe it is entitled as a result of
the occurrence of said event. All claims for adjustment in
the Contract Times (or Milestones) shall be determined by
ENGINEER in accordance with paragraph 9.1 1 if
OWNER and CONTRACTOR cannot otherwise agree.
No claim for an adjustment in the Contract Times (or
Milestones) will be valid if not submitted in accordance
with the requirements of this paragraph 12.1.
12.2. All time limits stated in the Contract Documents
are of the essence of the Agreement.
12.3. Where CONTRACTOR is prevented from
completing any part of the Work within the Contract
Times (or Milestones) due to delay beyond the control of
CONTRACTOR, the Contract Times (or Milestones) will
be extended in an amount equal to time lost due to such
delay if a claim is made therefor as provided in
paragraph 12.1. Delays beyond the control of
CONTRACTOR shall include, but not be limited to, acts
or neglect by OWNER, acts or neglect of utility owners or
other contractors performing other work as contemplated
by Article 7, fires, floods, epidemics, abnormal weather
conditions or acts of God. Delays attributable to and
within the control of a Subcontractor or Supplier shall be
deemed to be delays within the control of CONTRACTOR.
12.4. Where CONTRACTOR is prevented from
completing any part of the Work within the Contract Times
(or Milestones) due to delay beyond the control of both
OWNER and CONTRACTOR, an extension of the
Contract Times (or Milestones) in an amount equal to the
time lost due to such delay shall be CONTRACTOR's sole
and exclusive remedy for such delay. In no event shall
OWNER be liable to CONTRACTOR, any Subcontractor,
any Supplier, any other person or organization, or to any
surety for or employee or agent of any of them, for
damages arising out of or resulting from (i) delays caused
by or within the control of the CONTRACTOR, or
(ii) delays beyond the control of both parties including, but
not limited to, fires, floods, epidemics, abnormal weather
conditions, acts of God or acts or neglect by utility owners
or other contractors performing other work as contemplated
by Article 7.
ARTICLE 13—TESTS AND INSPECTIONS;
CORRECTION, REMOVAL OR ACCEPTANCE OF
DEFECTIVE WORK
13.1. Notice of Defects:
Prompt notice of all defective Work of which OWNER or
ENGINEER have actual knowledge will be given to
CONTRACTOR. All defective Work may be rejected,
corrected or accepted as provided in this Article 13.
Access to Work:
13.2. OWNER, ENGINEER, ENGINEER's Consultants,
other representatives and personnel of OWNER,
independent testing laboratories and governmental agencies
with jurisdictional interests will have access to the Work et
reasetaehfe Fifties for their observation, inspecting and
testing. CONTRACTOR shall provide them proper and
safe conditions for such access and advise them of
CONTRACTOR's site safety procedures and programs so
that they may comply therewith as applicable.
Tests and Inspections:
13.3. CONTRACTOR shall give ENGINEER timely
notice of readiness of the Work for all required inspections,
tests or approvals, and shall cooperate with inspection and
testing personnel to facilitate required inspections or tests.
13.4. OWNER shall employ and pay for the services of
an independent testing laboratory to perform all
inspections, tests, or approvals required by the Contract
Documents except:
13.4.1. for inspections, tests or approvals covered
by paragraph 13.5 below;
13.4.2. that costs incurred in connection with tests
or inspections conducted pursuant to paragraph 13.9
EICDC GENERAL CONDITIONS 1910.8 (1990 Edition)
a'/ CITY OF FORT COLLINS MODIFICATIONS (REV 412000)
below shall be paid as provided in said
paragraph 13.9; and
13.4.3. as otherwise specifically provided in the
Contract Documents.
13.5. If Laws or Regulations of any public body having
jurisdiction require any Work (or part thereof) specifically
to be inspected, tested or approved by an employee or
other representative of such public body, CONTRACTOR
shall assume full responsibility for arranging and
obtaining such inspections, tests or approvals, pay all costs
in connection therewith, and furnish ENGINEER the
required certificates of inspection, or approval.
CONTRACTOR shall also be responsible for arranging
and obtaining and shall pay all costs in connection with
any inspections, tests or approvals required for OWNER's
and ENGINEER's acceptance of materials or equipment to
be incorporated in the Work, or of materials, mix designs,
or equipment submitted for approval prior to
CONTRACTOR's purchase thereof for incorporation in
the Work.
13.6. If any Work (or the work of others) that is to be
inspected, tested or approved is covered by
CONTRACTOR without written concurrence of
ENGINEER, it must, if requested by ENGINEER, be
uncovered for observation.
13.7. Uncovering Work as provided in paragraph 13.6
shall be at CONTRACTOR's expense unless
CONTRACTOR has given ENGINEER timely notice of
CONTRACTOR's intention to cover the same and
ENGINEER has not acted with reasonable promptness in
response to such notice.
Uncovering Work:
13.8. If any Work is covered contrary to the written
request of ENGINEER, it must, if requested by
ENGINEER, be uncovered for ENGINEER's observation
and replaced at CONTRACTOR's expense.
13.9. If ENGINEER considers it necessary or advisable
that covered Work be observed by ENGINEER or
inspected or tested by others, CONTRACTOR, at
ENGINEER's request. shall uncover, expose or otherwise
make available for observation, inspection or testing as
ENGINEER may require, that portion of the Work in
question, furnishing all necessary labor, material and
equipment. If it is found that such Work is defective,
CONTRACTOR shall pay all claims, costs, losses and
damages caused by, arising out of or resulting from such
uncovering, exposure, observation, inspection and testing
and of satisfactory replacement or reconstruction.
(including but not limited to all costs of repair or
replacement of work of others); and OWNER shall be
entitled to an appropriate decrease in the Contract Price,
and, if the parties are unable to agree as to the amount
thereof, may make a claim therefor as provided in
Article 11. If, however, such Work is not found to be
defective, CONTRACTOR shall be allowed an increase in
the Contract Price or an extension of the Contract Times
(or Milestones), or both, directly attributable to such
27
uncovering, exposure, observation, inspection, testing,
replacement and reconstruction; and, if the parties are
unable to agree as to the amount or extent thereof,
CONTRACTOR may make a claim therefor as provided in
Articles I I and 12.
OWNER Map .Stop the Work:
13.10. If the Work is defective, or CONTRACTOR fails
to supply sufficient skilled workers or suitable materials or
equipment, or fails to furnish or perform the Work in such a
way that the completed Work will conform to the Contract
Documents, OWNER may order CONTRACTOR to stop
the Work, or any portion thereof, until the cause for such
order has been eliminated; however, this right of OWNER
to stop the Work shall not give rise to any duty on the part
of OWNER to exercise this right for the benefit of
CONTRACTOR or any surety or other party.
Correction or Removal of Defective Work:
13.11. If required by ENGINEER, CONTRACTOR shall
promptly, as directed, either correct all defective Work,
whether or not fabricated, installed or completed, or, if the
Work has been rejected by ENGINEER, remove it from the
site and replace it with Work that is not defective.
CONTRACTOR shall pay all claims, costs,'losses and
damages caused by or resulting from such correction or
removal (including but not limited to all costs of repair or
replacement of work of others).
13.12. Correction Period.
28
13.12.1. If within one yea f two year after the date of
Substantial Completion or such longer period of time as
may be prescribed by Laws or Regulations or by the
terms of any applicable special guarantee required by
the Contract Documents or by any specific provision of
the Contract Documents, any Work is found to be
defective, CONTRACTOR shall promptly, without cost
to OWNER and in accordance with OWNER's written
instructions: (i) correct such defective Work, or, if it has
been rejected by OWNER, remove it from the site and
replace it with Work that is not defective, and (ii)
satisfactorily correct or remove and replace any damage
to other Work or the work of others resulting therefrom.
If CONTRACTOR does not promptly comply with the
terms of such instructions, or in an emergency where
delay would cause serious risk of loss or damage,
OWNER may have the defective Wort: corrected or the
rejected Work removed and replaced, and all claims,
costs, losses and damages caused by or resulting from
such removal and replacement (including but not
limited to all costs of repair or replacement of work of
others) will be paid by CONTRACTOR. '
13.12.2.In special circumstances where a particular
item of equipment is placed in continuous service
before Substantial Completion of all the Work, the
correction period for that item may start to run from an
earlier date if so provided in the Specifications or by
Written Amendment.
13.12.3. Where defective Work (and damage to other
FJCOC GENERAL CONDITIONS 1910-3 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 412000)
Work resulting therefrom) has been corrected,
removed or replaced under this paragraph 13.12, the
correction period hereunder with respect to such Work
will be extended for an additional period of ere 5-eav
two year after such correction or removal and
replacement has been satisfactorily completed.
Acceptance of Defective Work:
13.13. If, instead of requiring correction or removal and
replacement of defective Work, OWNER (and, prior to
ENGINEER's recommendation of final payment, also
ENGINEER) prefers to accept it, OWNER may do so.
CONTRACTOR shall pay all claims, costs, losses and
damages attributable to OWNER's evaluation of and
determination to accept such defective Work (such costs to
be approved by ENGINEER as to reasonableness). If any
such acceptance occurs prior to ENGINEER's
recommendation of final payment, a Change Order will be
issued incorporating the necessary revisions in the
Contract Documents with respect to the Work; and
OWNER shall be entitled to an appropriate decrease in the
Contract Price, and, if the parties are unable to agree as to
the amount thereof, OWNER may make a claim therefor
as provided in Article 11. If the acceptance occurs after
such recommendation, an appropriate amount will be paid
by CONTRACTOR to OWNER.
OWNER May Correct Defective Work:
13.14. If CONTRACTOR fails within a reasonable time
after written notice from ENGINEER to correct defective
Work or to remove and replace rejected Work as required
by ENGINEER in accordance with paragraph 13.1 I, or if
CONTRACTOR fails to perform the Work in accordance
with the Contract Documents, or if CONTRACTOR fails
to comply with any other provision of the Contract
Documents, OWNER may, after seven days' written
notice to CONTRACTOR, correct and remedy any such
deficiency. In exercising the rights and remedies under
this paragraph OWNER shall proceed expeditiously. In
connection with such corrective and remedial action,
OWNER may exclude CONTRACTOR from all or part of
the site, take possession of all or part of the Work, and
suspend CONTRACTOR's services related thereto, take
possession of CONTRACTOR's tools, appliances,
construction equipment and machinery at the site and
incorporate in the Work all materials and equipment
stored at the site or for which OWNER has paid
CONTRACTOR but which are stored elsewhere.
CONTRACTOR shall allow OWNER, OWNER's
representatives, agents and employees, OWNER's other
contractors and ENGINEER and ENGfNEER's
Consultants access to the site to enable OWNER to
exercise the rights and remedies under this paragraph. All
claims, costs, losses and damages incurred or sustained by
OWNER in exercising such rights and remedies will be
charged against CONTRACTOR and a Change Order will
be issued incorporating the necessary revisions in the
Contract Documents with respect to the Work; and
OWNER shall be entitled to an appropriate decrease in the
Contract Price, and, if the parties are unable to agree as to
the amount thereof, OWNER may make a claim therefor
as provided in Article 11. Such claims, costs, losses and
1 --
damages will include but not be limited to all costs of
repair or replacement of work of others destroyed or
damaged by correction, removal or replacement of
CONTRACTOR's defective Work. CONTRACTOR shall
not be allowed an extension of the Contract Times (or
Milestones) because of any delay in performance of the
Work attributable to the exercise by OWNER of OWNER's
rights and remedies hereunder.
ARTICLE 14—PAYMENTS TO CONTRACTOR AND
COMPLETION
Schedule of Values:
14.1. The schedule of values established as provided in
paragraph 2.9 will serve as the basis for progress payments
and will be incorporated into a form of Application for
Payment acceptable to ENGINEER. Progress payments on
account of Unit Price Work will be based on the number of
units completed.
Application for Progress Payntent:
14.2. At least twenty days before the date established for
each progress payment (but not more often than once a
month), CONTRACTOR shall submit to ENGINEER for
review an Application for Payment filled out and signed by
CONTRACTOR covering the Work completed as of the
date of the Application and accompanied by such
supporting documentation as is required by the Contract
Documents. If payment is requested on the basis of
materials and equipment not incorporated in the Work but
delivered and suitably stored at the site or at another
location agreed to in writing, the Application for Payment
shall also be accompanied by a bill of sale, invoice or other
documentation warranting that OWNER has received the
materials and equipment free and clear of all Liens and
evidence that the materials and equipment are covered by
appropriate property insurance and other arrangements to
protect OWNER's interest therein, all of which will be
satisfactory to OWNER. The amount of retainage with
respect to progress payments will be as stipulated in the
Agreement. Any funds that are withheld by the OWNER
shall not be subject to substitution by the CONTRACTOR
with securities or anv arrangements involvine an escrow or
custodianship. By executing the application for payment
form the CONTRACTOR expressly waives his ri t to the
benefits of Colorado Revised Statutes. Section 24-91-101,
et sea.
CONTRACTOR's Warranty of Title:
14.3. CONTRACTOR warrants and guarantees that title
to all Work, materials and equipment covered by any
Application for Payment, whether incorporated in the
Project or not, will pass to OWNER no later than the time
of payment free and clear of all Liens.
Review of Applications for Progress Ptiynient:
14.4. ENGINEER will, within ten days after receipt of
each Application for Payment, either indicate in writing a
EJCDC GENERAL CONDITIONS 1910-8 (1990 Edition)
%W CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
recommendation of payment and present the Application
to OWNER, or return the Application to CONTRACTOR
indicating in writing ENGINEER's reasons for refusing to
recommend payment. In the latter case, CONTRACTOR
may make the necessary corrections and resubmit the
Application. Ten days after presentation of the
Application for Payment to OWNER with ENGINEER's
recommendation, the amount recommended will (subject
to the provisions of the last sentence of paragraph 14.7)
become due and when due will be paid by OWNER to
CONTRACTOR.
14.5. ENGINEER's recommendation of any payment
requested in an Application for Payment will constitute a
representation by ENGINEER to OWNER, based on
ENGINEER's on -site observations of the executed Work
as an experienced and qualified design professional and on
ENGINEER's review of the Application for Payment and
the accompanying data and schedules, that to the best of
ENGINEER's knowledge, information and belief:
14.5.1. the Work has progressed to the point
indicated,
14.5.2. the quality of the Work is generally in
accordance with the Contract Documents (subject to
an evaluation of the Work as a functioning whole
prior to or upon Substantial Completion, to the results
of any subsequent tests called for in the Contract
Documents, to a final determination of quantities and
classifications for Unit Price Work under
paragraph 9.10, and to any other qualifications stated
in the recommendation), and
14.5.3. the conditions precedent to
CONTRACTOR's being entitled to such payment
appear to have been fulfilled insofar as it is
ENGINEER's responsibility to observe the Work.
However, by recommending any such payment
ENGINEER will not thereby be deemed to have
represented that: (i) exhaustive or continuous on -site
inspections have been made to check the quality or the
quantity of die Work beyond the responsibilities
specifically assigned to ENGINEER in the Contract
Documents or (ii) that there may not be other matters or
issues between the parties that might entitle
CONTRACTOR to be paid additionally by OWNER or
entitle OWNER to withhold payment to CONTRACTOR.
14.6. ENGINEER's recommendation of any payment,
including final payment, shall not mean that ENGINEER
is responsible for CONTRACTOR's means, methods,
techniques, sequences or procedures of construction, or
the safety precautions and programs incident thereto, or
for an), failure of CONTRACTOR to comply with Laws
and Regulations applicable to the furnishing or
performance of Work, or for any failure of
CONTRACTOR to perform or furnish Work in
accordance with the Contract Documents.
14.7. ENGINEER may refuse to recommend the whole
or any part of any payment if, in ENGINEER's opinion, it
would be incorrect to make the representations to
29
the Contractor. Shared Savings shall not apply to any cost or credit
of any Change Orders.
ARTICLE 5. PAYMENT PROCEDURES
CONTRACTOR shall submit Applications for Payment in accordance
with Article 14 of the General Conditions. Applications for Payment
will be processed by ENGINEER as provided in the General Conditions.
5.1. Progress Payments. OWNER shall make progress payments on
account of the Contract Price for each executed Work Order on the
basis of CONTRACTOR'S Application for Payment as recommended by
ENGINEER, once each month during construction as provided below. All
progress payments will be on the basis of the progress of the Work
measured by the schedule of values established in paragraph 2.6 of the
General Conditions and in the case of Unit Price Work based on the
number of units completed, and in accordance with the General
Requirements concerning Unit Price Work.
5.1.1. Retainage. Prior to Substantial Completion of a
Work Order, progress payments will be in the amount equal to the
percentage indicated below, but, in each case, less the aggregate of
payments previously made and less such amounts as ENGINEER shall
determine, or OWNER may withhold, in accordance with paragraph 14.7 of
the General Conditions. Ninety (90%) percent of the value of Work
completed until the Work has been fifty (50%) percent completed as
determined by ENGINEER, when the retainage equals five (5%) of the
Contract Price, and if the character and progress of the Work have
been satisfactory to OWNER and ENGINEER, OWNER on recommendation of
ENGINEER, may determine that as long as the character and progress of
the Work remain satisfactory to them, there will be no additional
retainage on account of Work completed in which case the remaining
progress payments prior to Substantial Completion will be in an amount
equal to one hundred(100 percent of the Work completed. Ninety(90%)
percent of materials and equipment not incorporated in the Work (but
delivered, suitably stored and accompanied by documentation
satisfactory to OWNER as provided in paragraph 14.2 of the General
Conditions) may be included in the application for payment.
' 5.1.2. Upon Substantial completion of a Work Order,
payment will be made in an amount sufficient to increase total
payments to CONTRACTOR to ninety- five (95%) percent of the Contract
Price, less such amounts as ENGINEER shall determine or OWNER may
' withhold in accordance with paragraph 14.7 of the General Conditions
or as provided by law.
5.2. Final Payment. Upon Final Completion and Acceptance of the
Work in a Work Order in accordance with paragraph 14.13 of the General
Conditions, OWNER shall pay the remainder of the Contract Price as
recommended by ENGINEER as provided in said paragraph 14.13.
' AGREEMENT 00520- Page 5
t
I
LI
[1
OWNER referred to in paragraph 14.5. ENGINEER may
also refuse to recommend any such payment, or, because of
subsequently discovered evidence or the results of
subsequent inspections or tests, nullify any such payment
previously recommended, to such extent as may be
necessary in ENGINEER's opinion to protect OWNER
from loss because:
14.7.1. the Work is dejecrive, or completed Work has
been damaged requiring correction or replacement.
14.7.2. the Contract Price has been reduced by
Written Amendment or Change Order,
14.7.3. OWNER has been required to correct
dejec/ive Work or complete Work in accordance with
paragraph 13.14, or
14.7.4. ENGINEER has actual knowledge of the
occurrence of any of the events enumerated in
paragraphs 15.2.1 through 15.2.4 inclusive. '
OWNER may refuse to make payment of the full amount
recommended by ENGINEER because:
14.7.5. claims have been made against OWNER on
account of CONTRACTOR's performance or furnishing
of the Work,
14.7.6. Liens have been filed in connection with the
Work, except where CONTRACTOR has delivered a
specific Bond satisfactory to OWNER to secure the
satisfaction and discharge of such Liens,
14.7.7. there are other items entitling OWNER to a set-
off against the amount recommended, or
14.7.8. OWNER has actual knowledge of the
occurrence of any of the events enumerated in
paragraphs 14.7.1 through 14.7.3 or paragraphs 15.2.1
through 15.2.4 inclusive;
but OWNER must give CONTRACTOR immediate
written notice (with a copy to ENGINEER) stating the
reasons for such action and promptly pay CONTRACTOR
the amount so withheld, or any adjustment thereto agreed
to by OWNER and CONTRACTOR, when
CONTRACTOR corrects to OWNER's satisfaction the
reasons for such action.
Substantial Completion:
14.8. When CONTRACTOR considers the entire Work
ready for its intended use CONTRACTOR shall notify
OWNER and ENGINEER in writing that the entire Work
is substantially complete (except for items specifically
listed by CONTRACTOR as incomplete) and request that
ENGINEER issue a certificate of Substantial Completion.
Within a reasonable time thereafter, OWNER,
CONTRACTOR and ENGINEER shall make an inspection
of the Work to determine the status of completion. If
ENGINEER does not consider the Work substantially
complete, ENGINEER will notify CONTRACTOR in
writing giving the reasons therefor. If ENGINEER
' 30 EICDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
considers the Work substantially complete, ENGINEER
will prepare and deliver to OWNER a tentative certificate
of Substantial Completion which shall fix the date of
Substantial Completion. There shall be attached to the
certificate a tentative list of items to be completed or
corrected before final payment. OWNER shall have seven
days after receipt of the tentative certificate during which
to make written objection to ENGINEER as to any
provisions of the certificate or attached list. If, after
considering such objections, ENGINEER concludes that
the Work is not substantially complete, ENGINEER will
within fourteen days after submission of the tentative
certificate to OWNER notify CONTRACTOR in writing,
stating the reasons therefor. If, after consideration of
OWNER's objections, ENGINEER considers the Work
substantially complete, ENGINEER will within said
fourteen days execute and deliver to OWNER and
CONTRACTOR a definitive certificate of Substantial
Completion (with a revised tentative list of items to be
completed or corrected) reflecting such changes from the
tentative certificate as ENGINEER believes justified after
consideration of any objections from OWNER. At the
time of delivery of the tentative certificate of Substantial
Completion ENGINEER will deliver to OWNER and
CONTRACTOR a written recommendation as to division
of responsibilities pending final payment between
OWNER and CONTRACTOR with respect to security,
operation, safety, maintenance, heat, utilities, insurance
and warranties and guarantees. Unless OWNER and
CONTRACTOR agree otherwise in writing and so inform
ENGINEER in writing prior to ENGINEER's issuing the
definitive certificate of Substantial Completion,
ENGINEER's aforesaid recommendation will be binding
on OWNER and CONTRACTOR until final payment.
14.9. OWNER shall have the right to exclude
CONTRACTOR from the Work after the date of
Substantial Completion, but OWNER shall allow
CONTRACTOR reasonable access to complete or correct
items on the tentative list -
Partial Utilization:
14.10. Use by OWNER at OWNER's option of any
substantially completed part of the Work, which: (i) has
specifically been identified in the Contract Documents, or
(ii) OWNER, ENGINEER and CONTRACTOR agree
constitutes a separately functioning and usable part of the
Work that can be used by OWNER for its intended
purpose without significant interference with
CONTRACTOR's performance of the remainder of the
Work, may be accomplished prior to Substantial
Completion of all the Work subject to the.following:
14.10.I.OWNER at any time may, request
CONTRACTOR in writing to permit OWNER to use
any such part of the Work which OWNER believes to
be ready for its intended use and substantially
complete. If CONTRACTOR agrees that such part of
the Work is substantially complete, CONTRACTOR
will certify to OWNER and ENGINEER that such
part of the Work is substantially complete and request
ENGINEER to issue a certificate of Substantial
Completion for that part of the Work.
CONTRACTOR at any time may notify OWNER and
ENGINEER in writing that CONTRACTOR considers
any such part of the Work ready for its intended use
and substantially complete and request ENGINEER to
issue a certificate of Substantial Completion for that
part of the Work. Within a reasonable time after either
such request, OWNER, CONTRACTOR and
ENGINEER shall make an inspection of that part of
the Work to determine its status of completion. If
ENGINEER does not consider that part of the Work to
be substantially complete, ENGINEER will notify
OWNER and CONTRACTOR in writing giving the
reasons therefor. If ENGINEER considers that part of
the Work to be substantially complete, the provisions
of paragraphs 14.8 and 14.9 will apply with respect to
certification of Substantial Completion of that part of
the Work and the division of responsibility in respect
thereofand access thereto.
14.10.2. No occupancy or separate operation of part
of the Work will be accomplished prior to compliance
with the requirements of paragraph 5.15 in respect of
property insurance.
Final Inspection:
14.11. Upon written notice from CONTRACTOR that the
entire Work or an agreed portion thereof is complete.
ENGINEER will make a final inspection with OWNER
and CONTRACTOR and will notify CONTRACTOR in
writing of all particulars in which this inspection reveals
that the Work is incomplete or defective. CONTRACTOR
shall immediately take such measures as are necessary to
complete such work or remedy such deficiencies.
Final Application for Payntent:
14.12. After CONTRACTOR has completed all such
corrections to the satisfaction of ENGINEER and delivered
in accordance with the Contract Documents all
maintenance and operating instructions, schedules,
guarantees, Bonds, certificates or other evidence of
insurance required by paragraph 5.4. certificates of
inspection, marked -up record documents (as provided in
paragraph 6.19) and other documents, CONTRACTOR
may make application for final payment following the
procedure for progress payments. The final Application for
Payment shall be accompanied (except as previously
delivered) by: (i) all documentation called for in the
Contract Documents, including but not limited to the
evidence of insurance required by subparagraph 5.4.13,
(ii) consent of the surety, if any, to final payment, and
(iii) complete and legally effective releases or waivers
(satisfactory to OWNER) of all Liens arising out of or filed
in connection with the Work. In lieu of such releases or
waivers of Liens and as approved by OWNER,
CONTRACTOR may furnish receipts or releases in full
and affidavit of CONTRACTOR that: (i) the releases and
receipts include all labor, services, material and equipment
for which a Lien could be filed, and (ii) all payrolls,
material and equipment bills, and other indebtedness
connected with the Work for which OWNER or OWNER's
property might in any way be responsible have been paid or
otherwise satisfied. If any Subcontractor or Supplier fails
EJCDC GENERAL CONDITIONS 1910-8 (1990 Edition)
wl CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
to furnish such a release or receipt in full.
CONTRACTOR may furnish a Bond or other collateral
satisfactory to OWNER to indemnify OWNER against
any Lien. Releases or waivers of liens and the consent of
the surety to finalize payment are to be submitted on
forms conforming to the format of the OWNER'S standard
forms bound in the Project manual.
Final Payment and Acceptance:
14.13. If, on the basis of ENGINEER's observation of
the Work during construction and final inspection, and
ENGINEER's review of the final Application for Payment
and accompanying documentation as required by the
Contract Documents, ENGINEER is satisfied that the
Work has been completed and CONTRACTOR's other
obligations under the Contract Documents have been
fulfilled, ENGINEER will, within ten days after receipt of
the final Application for Payment, indicate in writing
ENGINEER's recommendation of payment and present
the Application to OWNER for payment. At the same
time ENGINEER will also give written notice to OWNER
and CONTRACTOR that the Work is acceptable subject
to the provisions of paragraph 14.15. Otherwise,
ENGINEER will return the Application to
CONTRACTOR, indicating in writing the reasons for
refusing to recommend final payment, in which case
CONTRACTOR shall make the necessary corrections and
resubmit the Application. Thirty days after presentation to
OWNER of the Application and accompanying
documentation, in appropriate form and substance and
with ENGINEER's recommendation and notice of
acceptability, the amount recommended by ENGINEER
will become due and will be paid by OWNER to
CONTRACTOR subject to oaragmnh 17.6.2 of these
General Conditions.
14.14. If, through no fault of CONTRACTOR, final
completion of the Work is significantly delayed and if
ENGINEER so confirms, OWNER shall, upon receipt of
CONTRACTOR's final Application for Payment and
recommendation of ENGINEER, and without terminating
the Agreement, make payment of the balance due for that
portion of the Work fully completed and accepted. If the
remaining balance to be held by OWNER for Work not
fully completed or corrected is less than the retainage
stipulated in the Agreement, and if Bonds have been
furnished as required in paragraph 5.1, the written consent
of the surety to the payment of the balance due for that
portion of the Work fully completed and accepted shall be
submitted by CONTRACTOR to ENGINEER with the
Application for such payment. Such payment shall be
made under the terms and conditions governing final
payment, except that it shall not constitute a waiver of
claims.
Waiver of Claints:
14.15. The making and acceptance of final payment will
constitute:
14.15.1.a waiver of all claims by OWNER against
CONTRACTOR, except claims arising from
unsettled Liens, from defective Work appearing after
31
final inspection pursuant to paragraph 14.11, from
failure to comply with the Contract Documents or the
terms of any special guarantees specified therein, or
from CONTRACTOR's continuing obligations under
the Contract Documents; and
14.15.2. A waiver of all claims by CONTRACTOR
against OWNER other than those previously made in
writing and still unsettled.
ARTICLE I5—SUSPENSION OF WORK AND
TERMINATION
OWNER May Suspend Work:
15.1. At any time and without cause, OWNER may
suspend the Work or any portion thereof for a period of not
more than ninety days by notice in writing to
CONTRACTOR and ENGINEER which will fix the date
on which Work will be resumed. CONTRACTOR shall
resume the Work on the date so fixed. CONTRACTOR
shall be allowed an adjustment in the Contract Price or an
extension of the Contract Times, or both, directly
attributable to any such suspension if CONTRACTOR
makes an approved claim therefor as provided in
Articles I I and 12.
OWNER May Terndnare:
15.2. Upon the occurrence of any one or more of the
following events:
15.2.1. if CONTRACTOR persistently fails to perform
the Work in accordance with the Contract Documents
(including, but not limited to, failure to supply sufficient
skilled workers or suitable materials or equipment or
Failure to adhere to the progress schedule established
under paragraph 2.9 as adjusted from time to time
pursuant to paragraph 6.6);
15.2.2. if CONTRACTOR disregards Laws or
Regulations of any public body having jurisdiction;
15.2.3. if CONTRACTOR disregards the authority of
ENGINEER; or
15.2.4. if CONTRACTOR otherwise violates in any
substantial way any provisions of the Contract
Documents;
OWNER may, after giving CONTRACTOR (and the
surety, if any) seven days' written notice and to the extent
permitted by Laws and Regulations, terminate the services
of CONTRACTOR, exclude CONTRACTOR from the site
and take possession of the Work and of all
CONTRACTOR's tools, appliances, construction
equipment and machinery at the site and use the same to
the full extent they could be used by CONTRACTOR
(without liability to CONTRACTOR for trespass or
conversion), incorporate in the Work all materials and
equipment stored at the site or for which OWNER has paid
32
FJCDC GENERAL CONDITIONS 1910-8(1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4;2000)
CONTRACTOR but which are stored elsewhere, and
finish the Work as OWNER may deem expedient. In such
case CONTRACTOR shall not be entitled to receive any
further payment until the Work is finished. If the unpaid
balance of the Contract Price exceeds all claims, costs,
losses and damages sustained by OWNER arising out of
or resulting from completing the Work such excess will be
paid to CONTRACTOR. If such claims, costs, losses and
damages exceed such unpaid balance, CONTRACTOR
shall pay the difference to OWNER. Such claims, costs,
losses and damages incurred by OWNER will be reviewed
by ENGINEER as to their reasonableness and when so
approved by ENGINEER incorporated in a Change Order,
provided that when exercising any rights or remedies
under this paragraph OWNER shall not be required to
obtain the lowest price for the Work performed.
15.3. Where CONTRACTOR's services have been so
terminated by OWNER, the termination will not affect
any rights or remedies of OWNER against
CONTRACTOR then existing or which may thereafter
accrue. Any retention or payment of moneys due
CONTRACTOR by OWNER will not release
CONTRACTOR from liability.
15.4. Upon seven days' written notice to
CONTRACTOR and ENGINEER, OWNER may,
without cause and without prejudice to any other right or
remedy of OWNER, elect to terminate the Agreement. In
such case, CONTRACTOR shall be paid (without
duplication of any items):
15.4.1. for completed and acceptable Work executed
in accordance with the Contract Documents prior to
the effective date of termination, including fair and
reasonable sums for overhead and profit on such
Work;
15.4.2. for expenses sustained prior to the effective
date of termination in performing services and
furnishing labor, materials or equipment as required
by the Contract Documents in connection with
uncompleted Work, plus fair and reasonable sums for
overhead and profit on such expenses;
15.4.3. for all claims, costs, losses and damages
incurred in settlement of terminated contracts with
Subcontractors, Suppliers and others; and
15.4.4. for reasonable expenses directly attributable
to termination.
CONTRACTOR shall not be paid on account of loss of
anticipated profits or revenue or other economic loss
arising out of or resulting from such termination.
CONTRACTOR May Stop Work or Terndnare:
15.5. If, through no act or fault of CONTRACTOR, the
Work is suspended for a period of more than ninety days
by OWNER or under an order of court or other public
authority, or ENGINEER fails to act on any Application
for Payment within thirty days after it is submitted or
OWNER fails for thirty days to pay CONTRACTOR any
sum finally determined to be due, then CONTRACTOR
may, upon seven days' written notice to OWNER and
ENGINEER, and provided OWNER or ENGINEER do not
remedy such suspension or failure within that time,
terminate the Agreement and recover from OWNER
payment on the same terms as provided in paragraph 15.4.
In lieu of terminating the Agreement and without prejudice
to any other right or remedy, if ENGINEER has failed to
act on an Application for Payment within thirty days after it
is submitted, or OWNER has failed for thirty days to pay
CONTRACTOR any sum finally determined to be due,
CONTRACTOR may upon seven days' written notice to
OWNER and ENGINEER stop the Work until payment of
all such amounts due CONTRACTOR, including interest
thereon. The provisions of this paragraph 15.5 are not
intended to preclude CONTRACTOR from making claim
under Articles I I and 12 for an increase in Contract Price
or Contract Times or otherwise for expenses or damage
directly attributable to CONTRACTOR's stopping Work as
permitted by this paragraph.
ARTICLE 16—DISPUTE RESOLUTION
If and to the extent that OWNER and CONTRACTOR
have agreed on the method and procedure for resolving
disputes between them that may arise under this
Agreement, such dispute resolution method and procedure,
if any, shall be as set forth in Exhibit GC -A, "Dispute
Resolution Agreement", to be attached hereto and made a
part hereof. If no such agreement on the method and
procedure for resolving such disputes has been reached,
and subject to the provisions of paragraphs 9.10, 9.11 and
9.12, OWNER and CONTRACTOR may exercise such
rights or remedies as either may otherwise have under the
Contract Documents or by Laws or Regulations in respect
of any dispute.
ARTICLE 17—MISCELLANEOUS
Giving Notice:
17.1. Whenever any provision of the Contract
Documents requires the giving of written notice, it will be
deemed to have been validly given if delivered in person to
the individual or to a member of the firm, or to an officer of
the corporation for whom it is intended, or if delivered at or
sent by registered or certified mail, postage prepaid, to the
last business address known to the giver of the notice.
17.2. Computation ofTinre:
17.2.1. When any period of time is referred to in the
Contract Documents by days, it will be computed to
exclude the first and include the last day of such
period. If the last day of any such period falls on a
Saturday or Sunday or on a day made a legal holiday
by the law of the applicable jurisdiction, such day will
be omitted from the computation.
E1CDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 412000)
17.2.2. A calendar day of twenty-four hours measured
from midnight to the next midnight will constitute a
day.
Notice of Claim:
17.3. Should OWNER or CONTRACTOR suffer injury
or damage to person or property because of any error,
omission or act of the other parry or of any of the other
party's employees or agents or others for whose acts the
other parry is legally liable, claim will be made in writing
to the other party within a reasonable time of the first
observance of such injury or damage. The provisions of
this paragraph 17.3 shall not be construed as a substitute
for or a waiver of the provisions of any applicable statute
of limitations or repose.Cunmlative Remedies:
17.4. The duties and obligations imposed by these
General Conditions and the rights and remedies available
hereunder to the parties hereto, and, in particular but
without limitation, the warranties, guarantees and
obligations imposed upon CONTRACTOR by
paragraphs 6.12, 6.16, 6.30, 6.31, 6.32, 13.1, 13.12, 13.14,
14.3 and 15.2 and all of the rights and remedies available
to OWNER and ENGINEER thereunder, are in addition
to, and are not to be construed in any way as a limitation
of, any rights and remedies available to any or all of them
which are otherwise imposed or available by Laws or
Regulations by special warranty or guarantee or by other
provisions of the Contract Documents, and the provisions
of this paragraph will be as effective as if repeated
specifically in the Contract Documents in connection with
each particular duty, obligation, right and remedy to which
the)' apply.
Professional Fees and Court Costs Included:
17.5. Whenever reference is made to "claims, costs,
losses and damages", it shall include in each case, but not
be limited to, all fees and charges of engineers, architects,
attorneys and other professionals and all court or
arbitration or other dispute resolution costs.
17.6. The laws of the State of Colorado aooly to this
Agreement. Reference to two pertinent Colorado statutes
are as follows:
17.6.2. If a claim is filed. OWNER is required by
law (CRS 38-26-107) to withhold from all payments to
CONTRACTOR sufficient funds to insure the
pavment of all claims for labor, materials, team hire,
sustenance. provisions, provender, or other supplies
used or consumed by CONTRACTOR or his
33
11
IJ
I
1
34 EICDC GENERAL CONDITIONS 1910-8(1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 412000)
(This page left blank intentionally.)
EJCDC GENERAL CONDITIONS 1910-8 (1990 Edi(ion) 35
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 412000)
1
1
1
1
1
1
1
I
1
I
1
1
1
1
1
i
11
36 EJCDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLMS MODIFICATIONS (REV 412000)
F
SECTION 00800
SUPPLEMENTARY CONDITIONS
Conditions of the Contract
These Supplementary Conditions amend or supplement the General Conditions
of the Construction Contract (EJCDC General Conditions 1910-8, 1990
edition, with City of Fort Collins Modifications, Rev. 9/94) and other
provisions of the Contract Documents as indicated below.
SC-1 DEFINITIONS
SC-1.38. Add the following language to the conclusion of paragraph 1.38 of
the General Conditions:
1.38. Substantial Completion. .... Substantial Completion is further
defined as that degree of completion of the operating facilities or
systems of the Project defined in the Work Order sufficient to provide the
OWNER the full time, uninterrupted, continuous, beneficial operation of
the modifications, and all inspections required have been completed and
identified conditions corrected.
SC-1.43.A. Add the following new paragraph immediately after paragraph
1.43 of the General Conditions:
1.43.A. Work Order --A written document executed by OWNER and CONTRACTOR
that provides for the construction of a portion of the Work, pursuant to
the Agreement and all as required by the Contract Documents, and that
becomes a Contract Document when executed.
SC-2 PRELIMINARY MATTERS
SC-2.8. Delete paragraph 2.8 of the General Conditions entirely and replace it with the following paragraph:
2.8. Preconstruction Conference. Within ten days after the
Contract Times for a Work Order start to run, but before any Work at the
site is started, a conference attended by CONTRACTOR, ENGINEER and others
as appropriate will be held to establish a working relationship among the
parties as to the Work and to discuss the schedules referred to in
paragraph 2.6, procedures for handling Shop Drawings and other submittals,
processing Applications for Payment, and maintaining required records.
SC-2.10. Add the following new paragraph immediately after paragraph 2.9
of the General Conditions:
2.10. Work Order Required for All Work. References to the Agreement in
this Article 2 and in the General and Supplementary Conditions and
Contract Documents notwithstanding, no Work shall be initiated or
performed until CONTRACTOR has received a signed and executed Work Order,
5/98 AGREEMENT 00800 Page I
i
incorporating the Notice to Proceed, from OWNER; and no provision of this
Article 2 or of the General and Supplementary Conditions and Contract
Documents shall permit or require any action of CONTRACTOR in the absence
of a signed and executed Work Order. All provisions of this Article 2 and
of the General and Supplementary Conditions and Contract Documents
i referencing the Agreement or other parts of the Contract Documents, or
permitting or requiring any action of CONTRACTOR, shall be read as
referencing and, as appropriate, requiring a signed and executed Work
Order.
1
SC-4 AVAILABILITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS;
iREFERENCE POINTS
SC-4.2.1.2. Add the following new paragraph immediately following
iparagraph 4.2.1.2 of the General Conditions:
4.2.1.2.1. No drawing of physical conditions in or relating to existing
surface or subsurface structures (except Underground Facilities referred
' to in paragraph 4.3) which are at or contiguous to the site have been
utilized by the Engineer in preparation of the Contract Documents, except
the following:
' 1.
' SC-5 BONDS AND INSURANCE
SC-5.4.7. Include the following parties or entities as additional
i insureds, as provided in paragraph 5.4.7 of the General Conditions:
5.4.7.1. City of Fort Collins, Colorado, 4316 LaPorte Avenue, Fort
Collins, Colorado 80522
i5.4.7.2.
SC-5.4.8.1. Add the following new paragraph immediately following
iparagraph 5.4.8 of the General Conditions:
5.4.8.1. Limits of Liability. The limits of liability for the insurance
i required by the paragraph numbers of the General Conditions listed below
are as follows:
For Paragraphs 5.02.A.1 and 5.02.A.2: Coverage A - Statutory Limits;
Coverage B - $100,000 / $100,000 / $500,000.
i For Paragraphs 5.02.A.3 and 5.02.A.5: The Commercial General Liability
policy will have limits of $1,000,000 combined single limits (CSL). This
Policy will include coverage for Explosion, Collapse, and Underground
coverage unless waived by the Owner.
i For Paragraph 5.02.A.6: The Comprehensive Automobile Liability Insurance
policy will have limits of $1,000,000 combined single limits (CSL).
For Paragraph 5.02.3.3: This policy will include completed operations
coverage / product liability coverage with limits of $1,000,000 combined
single limits (CSL). This policy shall also include an Umbrella Excess
i5/98 AGREEMENT 00800 Page 2
i
Liability as follows: General liability and automobile liability insurance
in an amount not less than $1,000,000 per occurrence in excess of the
above stated primary limits.
SC-6 CONTRACTOR'S RESPONSIBILITIES
SC-6.14.3. Add the following new paragraph immediately after paragraph
6.14.2 of the General Conditions:
6.14.3. The following Laws or Regulations are included in the Contract
Documents as mandated by statute or for the convenience of the CONTRACTOR.
Other Laws and Regulations apply which are not included herein, and are
within the CONTRACTOR's duty and responsibility for compliance thereto:
6.14.3.1. Notice to owners of Underground Facilities is required prior to
excavations in the vicinity of such facilities.
6.14.3.2. Unless otherwise decided by reason of the amount of the Contract
Price involved, or other good reason, before or at the time that the
contract is awarded to a corporation outside the State of Colorado, such
corporation must carry out the proper procedure to become authorized to do
business in the State of Colorado, designate a place of business therein,
and appoint an agent for service of process.
Such corporation must furnish the OWNER with a certificate from the
Secretary of State of Colorado has been issued by its office and there
shall also be procured from the Colorado Secretary of State of photostatic
or certified copy of the designated of place of business and appointment
of agent for service of process, or a letter from the Colorado Secretary
of State that such designation of place of business and agent for service
of process have been made.
6.14.3.3. The CONTRACTOR must conform to the rules and regulations of the
Industrial Commission of Colorado. Particular reference is made to rules
and regulations governing excavation Work adopted by the Industrial
Commission of Colorado.
SC-11 CHANGE OF CONTRACT PRICE
SC-11.6.2.7. Add the following new paragraph to paragraph 11.6.2 of the
General Conditions:
11.6.2.7. Cost of the Work. Allowances for profit, overhead and mark-up
prescribed by Article 4 of the Agreement shall be used in lieu of any
CONTRACTORS fee, overhead, profit or mark-up allowances as prescribed in
paragraphs 11.6.2.1, 11.6.2.2, and 11.6.2.3.
SC-12 CHANGE OF CONTRACT TIMES
SC-12.3. Add the following language to the end of paragraph 12.3 of the
General Conditions:
12.3. .... Lost days due to abnormal weather conditions will be allocated
as required.
5/98 AGREEMENT 00800 Page 3
I
1
L
1
ARTICLE 6. CONTRACTOR'S
In order to induce OWNER to enter into this Agreement, CONTRACTOR
makes the following representations, which CONTRACTOR shall perform
for each proposed Work Order prior to OWNER'S execution of said Work
Order:
6.1. CONTRACTOR has familiarized himself with the nature and
extent of the Contract Documents, Work, site, locality, and with all
local conditions and Laws and Regulations that in any manner may
affect cost, progress, performance or furnishing of the Work.
6.2. CONTRACTOR has studied carefully all reports of
explorations and tests of subsurface conditions and drawings of
physical conditions which are identified in the Supplementary
Conditions as provided in paragraph 4.2 of the General Conditions.
6.3. CONTRACTOR has obtained and carefully studied (or assumes
responsibility for obtaining and carefully studying) all such
examinations, investigations, explorations, tests, reports, and
studies (in addition to or to supplement those referred to in
paragraph 6.2 above) which pertain to the subsurface or physical
condition at or contiguous to the site or otherwise may affect the
cost, progress, performance or furnishing of the Work as CONTRACTOR
considers necessary for the performance or furnishing of the Work at
the Contract Price, within the Contract Times and in accordance with
the other terms and conditions of the Contract Documents, including
specifically the provisions of paragraph 4.2 of the General
Conditions; and no additional examinations, investigations,
explorations, tests, reports, studies or similar information or data
are or will be required by CONTRACTOR for such purposes.
6.4. CONTRACTOR has reviewed and checked all information and
data shown or indicated on the Contract Documents
with respect to
existing Underground Facilities at or
contiguous
to the site and
assumes responsibility for the accurate
location of
said Underground
Facilities. No additional examinations, investigations, explorations,
tests, reports, studies or similar information or data in respect
said Underground Facilities are or will
be required
of
by CONTRACTOR in
order to perform and furnish the Work at the Contract Price, within
the Contract Times and in accordance
with the
other terms and
conditions of the Contract Documents,
including
specifically the
provision of Article 4.3. of the General
Conditions.
6.5. CONTRACTOR has correlated the
results of all
such
observations, examinations, investigations,
tests, reports and
data
with the terms and conditions of the Contract
Documents.
'
6.6. CONTRACTOR has given ENGINEER
written notice of
all
conflicts, errors or discrepancies that he
has discovered in
the
Contract Documents and the written resolution
thereof by ENGINEER
is
'
acceptable to CONTRACTOR.
' AGREEMENT 00520- Page 6
SC-14 PAYMENTS TO CONTRACTOR AND COMPLETION
SC-14.1. Add the following language to the end of paragraph 14.1 of the
General Conditions:
14.1. Schedule of Values. .... Progress payments on the fixed fee shall be
in proportion to the cumulative actual Cost of the Work as a percentage of
the Allowable Cost of the Work. An amount not to exceed fifteen (15%)
percent of the fixed fee shall be advanced to the Contractor for
mobilization in the first progress payment.
5/98 AGREEMENT
00800 Page ¢
SECTION 00900
ADDENDA, MODIFICATIONS AND PAYMENT
00950 Change Order
00960 Application for Payment
5/98 AGREEMENT 00800 Page Q
CITY OF FORT COLLINS
CHANGE ORDER
++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++
CONTRACTOR: Hydro Construction
PROJECT TITLE: Water/Wastewater Treatment & Site Infrastructure
Design/Construction Contractor
ADDRESS: PROJECT NUMBER: 7220
PURCHASE ORDER NO.: CHANGE ORDER NUMBER:
++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++
DESCRIPTION:
1. Reason for change:
2. Description of Change:
3. Change in Contract Cost:
4. Change in Contract Time:
++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++
ORIGINAL CONTRACT COSTS
TOTAL APPROVED CHANGE ORDER(S)
TOTAL PENDING CHANGE ORDER(S)
TOTAL THIS CHANGE ORDER
TOTAL °s OF ORIGINAL CONTRACT, THIS CO:
TOTAL % OF ORIGINAL CONTRACT, ALL CO'S:
ADJUSTED CONTRACT COST
(Assuming all change orders approved)
++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++
ACCEPTED BY: DATE:
Contractor's Representative
ACCEPTED BY:
DATE:
Project Manager
REVIEWED BY: DATE:
Title:
APPROVED BY: DATE:
Title:
APPROVED BY: DATE:
Title (Purchasing Agent if > $60,000)
CC: City Clerk Architect/Engineer
Finance Purchasing
Project Manager Contractor
1 5/98 AGREEMENT 00960 Page
i
1
SECTION 00960
PAYMENT APPLICATION i
1
i
1
1
1
1
1
i
1
1
1
1
1
1
5/98 AGREEMENT 00960 Page 2 i
1
i
1
1
1
1
1
1
1
1
1
1
1
1
i
1
1
1
Item 'mace
Nwwf Nunba Desci lim
On Held
Hevian
errfm
Received
Tlis
Pons]
Inslelled
Ths
Pe"m
On Held
Ths
ecalm
$000
woo
$000
$000
WOO
$000
w.00
w.0O
$0.0O
w.0O
$0.00
$0.00
woo
$000
$000
w.0O
$000
$000
w0O
$000
w.0O
$000
$000
so DO
$0.00
w00
$000
woo
0.0O
woo
$000
$000
$000
TOTALS
$000
$000
$000
$00O
5/98 AGREEMENT
00960 Page 3
DINNER: CIMo1Fwt CdI= PROJECT:
APPLICATION NUMBER
APPLICATION DATE'
PERIOD BEG'NN NO:
ENGINEER: CONTRACTOR:
PERt00 ENDING.
PROJECT NUMBER
CHANGE ORDERS
Application is made IN Payment as shown below in connection with Contract
NUMBER LATE AMOUNT
The Nesenl status of the awounl IN this Cdnlrwl is as follows-
1
2
Odgnal Contract Amounl*
3
Nei Change by Change Order;
Current contract Amou d
$000
Total Completed and Shed to Dale:
Less Previous Appscations,'.
Amount Due Ibis Applmwtion - Before Releirhage'.
$000
Less Retamage,
Net Change by Change Order $0.00
AMOUNT DUE THIS APPLICATION
$000
CERTIFICATION:
The undersigned CONTRACTOR certifies that of obhgafiwss of CONTRACTOR marred in connection with
the Work have been satisfied as rec"red in Paragraph 14.3. of the General Conditions of the Contract
The above Amount Due Thm App4cs4on is requested by the CONTRACTOR •
Dale. By
Payment of the above Amount Due This Applimlon is recommended by the ENGINEER
Date: BY
Paymonl of the above Amour /are This Application has been reviewed by he OWNERS Project Manager.
DaIe. By
Payment of trha above Amount Due This Apptirs4onis approved by the OWNER.
Gate: B
5/98 AGREEMENT 00960 Page 4
Item
rdumoer Dawtolion Owmtity Urils
LIM Poide Amoral
ork Completed
This MoM
ply. Amount
Work Completed
Previous Periods
q Amount
Wok Completed
To Dale
q prneinl
Sbred
Malenals
This
Total
To Dale B 9 demed nl
000
000
$O00
$O00
f000
$O00
f00O
$00000
E000
000
$000f0000
$000 00
$000
$000
00
$000
$000
$O00
00O
$000$000
woo
$0OO
0000
0
$000$000$000$000000
$000$000WOO
$00
$000
soon
$00O
�
$000
f000
100O
$000
$000
f000
0,00
$O0O
so0
$000
5000
$000
OOOD
$000
000
f000
f000
f000
$0.00
f000
$O,00
$0.00
$000
f000
�oo
fD00
$00
$000
f000
f000
$000
f000
f000
f000
00
000
f000
f000
$000$000$000
$00
$000
00
000
$oon
$000
$0000
f000
f000
s000
$000
f000
$000
$000
00
Oro
tOaa
00
$00O
sO.00
000
f000
f000
f000
$000
$000
00
$0.00
0.W
$00
$00000
$0
f000
�0°
f000
$000
so.00
f000
00
0000
$000000
f000
$000f00
00
$000$0.00
0.0
00
0.00
00
00
woo
0.0
$000
$000$000$0.0O
00
TOTALS
00
0.0
$00
$00
0.00
5/98 AGREEMENT
00960 Page 5
CK6ME ORDERS
APPLICATION
FOR PAYMENT
PAGE 30FT-
84
Work Completed
Wcrk Competed
Work Completed Stared
Item
TNs Marts
Prenotis Pttiods
To Date Motonats
Total
Numger Oosaipion Quantity Units
Unit Price Amounl
ON
Ths
Evened Percent
An)0uplt
Oly. Amount
ON. Amount Pemiod
To Date Wed
$000
$000
$0.00
$000
$000
$0.00
$000
$0.00
to.00
$0.00
$0.00
$000
$000
W00
$0.00
$0.00
$000
$0.00
$000
$0.00
$0.00
$000
$0.00
$0,00
$0.00
$000
$000
$000
$0.00
$0.00
$000
$000
$0.00
$0.00
$000
$000
$000
$0.00
$0.00
$0.00
$000
$000
$0,00
$0.00
$0.00
$0.00
so OD
$0.00
X00
$0.00
$000
$000
$000
$000
$000
$000
$000
$0.00
$000
S0.00
$000
$000
to00
$000
$000
$000
$000
$0.00
$0.00
$000
$000
$000
$0.00
$0.00
$0.00
$000
$000
$0.00
$000
$0.00
$000
$000
$0.00
$0.00
$0.00
$000
Ilow
$0.00
$0.00
$0.00
$000
$000
$0.00
$000
$000
$0,00
$000
$000
$000
$0.00
$000
$000
$0.00
$0.00
S000
$000
$000
$0.00
$0.00
$000
$000
$000
$0.00
.$0.00
$0.00
$000
$000
$0.00
$000
$0.00
$000
$000
$0,00
1000
$0.00
$000
$000
$0.00
1000
$0.00
$000
$000
$000
$000
$0cc
$0.00
$000
$000
f0.00
$0.00
$0.00
$000
$0.00
$0.00
$0.00
$000
$000
$0.00
$0.00
$:0.00
$000
$000
$0.00
$000
$0.00
$000
$000
$0.00
$000
$0.00
$000
$000
$0.00
10.00
$0.00
TOTALS CHANGE ORDERS
$000
$000
$0.00
$0.00
$000
PROJECT TOTALS
$000
$000
$0.co
$000
50.00
5/98 AGREEMENT 00960 Page 6