HomeMy WebLinkAbout289716 INSIGHT PUBLIC SECTOR INC - PURCHASE ORDER - 9956021Date: 10/8/2009
City of
F„o rt Collins
Page Number: 1
Purchase Order Number: 9956021
......... ltendax 2$gTt 6:. ` . . ;:
Sh€p Ta
INSIIGHT PUBLIC SECTC?R LNG
MIS
:.........;::: .
>p0 BO>t 713096
G1TY OF FrRT CULLINS .::.
tJIH 4-3271 30J
. .2: 5 N MAS0 :1 irl»EJCJ
.:..G0:LUM6US
...
FORT C3LLIN5 GO S(#52A-�t08.>
. .... .
..:::...:::........................................ '.:.:::::...::::..:.......................:...............................:::::::.....:......:.:...::::::.:...::::::::.:...::::........:::::::.::.>:.>::>::>::>::>:::>:<:>:<;«<::>:::.;:.::.;;;:.>:.;:.;:.;:.;:.;:.;:.;:.;:.;:;;.;:.::.
.::......:.............::.::......:::.:::::::::::::::::::::::::::::::::::.::::::.::::.:.:::.:::::::...................
.........................
Delivery Date: 10/6/2 09
. ........... ...... ................
Buver: BONNETTE. ED
Purchase Order number must appear on invoices, packing lists, labels, bills of lading, and all correspondence.
Note: PER QUOTE #13033331 FROM CASSIDY JONES TO ZACH WOOD 10/2/09.
PRICING IS PER STATE OF COLORADO PRICE AGREEMENT 20556YYY11P.
(QTY 10) #M267854 MSELECT WINDOWS SERVER DATACENTER LICENSES
@ $1,561.05/EA = $15,610.50
SHIP TO ATTN: ZACH WOOD; CONTACT #(970) 416-2722.
Line Qty/Units Description Extended Price
1 LOT
1 MSELECT WINDOWS SERVER 15,610.50
DATACENTER 2008 R2 0TY(10)
City of Fort CoPnO Director of Purchasing and Risk Management
This order is slid over $5000 unless signed by James B. O'Neill II, CPPO
City of Fort Collins Purchasing, PO Box 580, Fort Collins, CO 80522-0580
Phone: 970-221-6775 Fax: 970-221-6707 Email: purchasing@fcgov.com
Total $15,610.50
Invoice Address:
City of Fort Collins
Accounting Department
PO Box 580
Fort Collins, CO 80522-0580
Purchase Order Terms and Conditions
I. COMMERCIAL DETAILS.
Tax exemptions. By statute the City of Fort Collins is exempt from state and local taxes. Our Exemption Number is
98-04502. Federal Excise Tax Exemption Certificate of Registry 84-6000587 is registered with the Collector of
Internal Revenue, Denver, Colorado (Ref. Colorado Revised Statutes 1973, Chapter 39-2o, 114 (a).
Goods Rejected. GOODS REJECTED due to failure to meet specifications, either when shipped or due to defects of
damage in transit, may be retumed to you for credit and are not to be replaced except upon receipt of written
instructions from the City of For Collins.
Inspection. GOODS are subject to the City of Fort Collins inspection on mrival.
Final Acceptance. Receipt ofthe merchandise, services or equipment in response to this order can result in authorized
payment on the part of the City of Foil Collins. However, it is to be understood that FINAL ACCEPTANCE is
dependent upon completion of all applicable required inspection procedures.
Freight Terms. Shipments must be F.O.B., City of Fort Collins, 700 Wood St., Foil Collins, CO 80522, unless
otherwise specified on this order. Ifpermission is given to prepay freight and charge separately, the original freight bill
must accompany invoice. Additional charges for packing will not be accepted.
Shipment Distance. Where manufacturers have distributing points in various pails ofthe country, shipment is expected
from the nearest distribution point to destination, and excess freight will be deducted from Invoice when shipments are
trade from greater distance.
Permits. Seller shall procure at sellers sole cost all necessary permits, certificates and licenses required by all applicable
laws, regulations, ordinances and rules ofthe state, municipality, territory or political subdivision where the work is
performed, or required by any other duly constituted public authority having jurisdiction over the work of vendor.
Seller further agrees to hold the City effort Collins harmless front and against all liability and loss incurred by them by
reason of an asserted or established violation of any such laws, regulations, ordinances, rules and requirements.
Authorization. All parties to this contract agree that the representatives are, in fact, bona fide and possess full and
complete authority to bind said parties.
LIMITATION OF TERMS. This Purchase Order expressly limits acceptance to the teens and conditions sorted herein
set forth and any supplementary or additional terms and conditions annexed hereto or incorporated herein by reference.
Any additional or different terms and conditions proposed by seller are objected to and hereby rejected.
2. DELIVERY.
PLEASE ADVISE PURCHASING AGENT immediately if you cannot make complete shipment to a rive on your
promised delivery date as noted. Time is ofthe essence. Delivery and performance must be effected within the time
stated on the purchase order and the documents attached hereto. No acts of the Purchasers including, without
limitation, acceptance of partial late deliveries, shall operate as a waiver of this provision. In the event of any delay, the
Purchaser shall have, in addition to other legal and equitable remedies, the option of placing this order elsewhere and
holding the Seller liable for damages. However, the Seller shall not be liable for damages as a result of delays due W'
causes not reasonably foreseeable which are beyond its reasonable control and without its fault ofnegligence, sulactSl
of God, acts of civil or military authorities, governmental priorities, fires, strikes, food, epidemics, wars or riots
provided that notice of the conditions causing such delay is given to the Purchaser within five (5) days of the time
when the Seller first received knowledge thereof. In the event of any such delay, the date of delivery shall be extended
for the period equal to the time actually lost by reason ofthe delay.
3. WARRANTY.
The Seller warrants that all goods, articles, materials and work covered by this order will conform with applicable
drawings, specifications, samples and/or other descriptions given, will be fit for the purposes intended, and performed
with the highest degree of care and competence in accordance with accepted standards for work of a similar nature.
The Seller agrees to hold the purchaser harmless from any loss, damage or expense which the Purchaser ntty suffer or
incur on account ofthe Sellers breach of waranty. The Seller shall replace, repair m make good, without cost to the
purchaser, any defects or faults arising within one(]) year or within such longer period of time as maybe prescribed by
law or by the tents of any applicable warranty provided by the Seller after the date of acceptance of the goods
furnished hereunder (acceptance not to be um easonably delayed), resulting fi om imperfect or defective work done or
materials fumished by the Seller. Acceptance or use of goods by the Purchaser shall not constitute a waiver of any
claim under this waranty. Except as otherwise provided in this purchase order, the Sellers liability hereunder still[
extend to all damages proximately caused by the breach of any of the foregoing warranties or guarantees, but such
liability shall in no event include loss of profits or loss of use. NO IMPLIED WARRANTY OR
MERCHANTABILITY OR OF FITNESS FOR PURPOSE SHALL APPLY.
4. CHANGES IN LEGAL TERMS.
The Purchaser may make changes to legal terns by written change order.
5. CHANGES IN COMMERCIAL TERMS.
The Purchaser may make any changes to the terms, other than legal terms, including additions to m deletions fronrthe
quantities originally ordered in the specifications or drawings, by verbal or written change order. I f any such change
affects the amount due or the time of performance hereunder, an equitable adjustment shall be made.
6. TERMINATIONS.
The Purchaser may at anytime by written change order, terminate this agreement as to any m all portions of the goods
then not shipped, subject to any equitable adjustment between the parties as to any work or materials then in progress
provided that the Purchaser shall not be liable for any claims for anticipated profits on the uncompleted portion ofthe
goods and/or work, for incidental or consequential damages, and that no such adjustment be made in favor ofthe Seller
with respect to any goods which are the Sellers standard stock. No such termination shall relieve the Purchaser or the
Seller of any of their obligations as to any goods delivered hereunder.
7. CLAIMS FOR ADJUSTMENT.
Any claim for adjustment must be asserted within thirty (30) days front the date the change or termination is ordered.
8. COMPLIANCE WITH LAW.
The Seller warrants that all goods sold hereunder shall have been produced, sold, delivered and fumished in strict
compliance with all applicable laws and regulations to which the goods ate subject. The Seller shall execute and deliver
such documents as may be required to effect or evidence compliance. All laws and regulations required to be
incorporated in agreements of this character are hereby incorporated herein by this reference. The Seller agrees to
indemnify and hold the Purchaser harmless fiom all costs and damages Suffered by the Purchaser as a result of the
Sellers failure to comply with such law.
If and only to the extent this [Agreement] constitutes a "sole source government contract" within the meaning of
Article XXVIII ofthe Colorado Constitution ("Article XXVIII"), then the provisions of Section 15 ofArticle XXVIII
are hereby incorporated into this [Agreement]. In such a case, if the [ContractorJ or any other person who is a
"contract holder" as defined in Section 2(4.5) ofArticle XXVIII intentionally violates Section 15 or Section 17(2) of
Article XXVIII, then the [Contractor] agrees it shall be ineligible to hold any sole source government contract, or
public employment with the state of Colomdo or any of its political subdivisions, for three years.
9. ASSIGNMENT.
Neither party shall assign, transfer, or convey this order, or any monies due or to become due hereunder without the
prior written consent ofthe other party.
10, TITLE,
The Seller warrants full, clear and unrestricted title to the Purchaser total] equipment, materials, and items fumished in
performance of this agreement, free and clear of any and all liens, restrictions, reservations, security interest
encumbrances and claims of others.
IL NONWAIVER.
Failure of the Purchaser to insist upon strict performance of the terns and conditions hereof, failure or delay to
exercise any rights or remedies provided herein or by law. failure to promptly notify the Seller in the event of a breach,
the acceptance of or payment for goods hereunder or approval ofthe design, shall not release the Seller of any ofthe
warranties or obligations of this purchase order and shall not be deemed a waiver of any right ofthe purchaser to insist
upon strict perfomtance hereof or any of its rights or remedies as to any such goods, regardless of when shipped,
received or accepted, as to any prior or subsequent default hereunder, not shall any purported oral modification or
rescission of this purchase order by the Purchaser operate as a waiver of any ofthe terms hereof.
12. ASSIGNMENT OF ANTITRUST CLAIMS.
Seller and the Purchaser recognize that in actual economic practice, overcharges resulting fi om antitrust violations are
in fact bome by the Purchaser. Theretofore, for good cause and as consideration fr executing this purchase order, the
Seller hereby assigns to the Purchaser any and all claims it may now have m hereafter acquired under federal or state
antitrust laws fur such overcharges relating to the particular goods or services purchased or acquired by the Purchaser
pursuant to this purchase order.
13. PURCHASERS PERFORMANCE OF SELLERS OBLIGATIONS.
If the Purchaser directs the Seller to correct nonconforming m defective goods by a date to be agreed upon by the
Purchaser and the Seller, and the Seller thereafter indicates its inability qi ugwillingnes�[o comply: the Purchaser may
cause the work to be perforned4W',tjielnost expeditiods mnseaavnilable tolit, and ihe-$eller shall pay all costs
associated with such work. - I '
The Seller shall release the Purchaser and its contractors of any tier fiom all liability and claims of any nature resulting
from the perfintnance of such work.
This release shall apply even in the event of fault of negligence of the party released and shall extend to the directors,
officers and employees of such party.
The Seller's contractual obligations, including warranty, shall not be deemed to be reduced, in any way, because such
work is performed or caused to be performed by the Purchaser.
14. PATENTS.
Whenever the Seller is required to use any design, device, material or process covered by letter, patent, trademark or
copyright, the Seller shall indemnify and save harmless the Purchaser fionn any and all claims for htfingenent by reason
ofthe use of such patented design, device, material or process in connection with the contract, and shall indemnify the
Purchaser for any cost. expense or damage which it maybe obliged to pay by reason of such infringement at anytime
r . during the prosecation or after the completions f the work. In case said equipment, or any tiwi thereof or the intended
useroivihe goods, is in.sucQjiiiTefd•to const�dte infiingement;andyl�euse ofsaid equiprrretitocpart is enjoined, the
Seller steal, m its own expense and at its option, either procure (or the Purchascr'ihe nghi to continue using said
equipment or parts, replace the same with substantially equal but non-infi-inging equipment, or modify it so it becomes
non -infringing.
15. INSOLVENCY.
If the Seller shall become insolvent or bankrupt, make an assignment for the benefit of creditors, appoint a receiver m-
trustee for any ofthe Sellers property or business, this order may forthwith be canceled by the Purchaser without
liability.
Its. GOVERNING LAW.
The definitions of tennis used or the interpretation ofthe agreement and the rights of all parties hereunder shall be
consumed under and governed by the laws ofthe State of Colorado, USA.
The following Additional Conditions apply only in cases where the Seller is to perform work hereunder, including the
services of Sellers Representative(s), on the premises of others.
17. SELLERS RESPONSIBILITY,
The Seller shall canyon said work at Seller's own risk until the same is fully completed and accepted, and shall, in case
of any accident, destruction or injury to the work and/or materials before Seller's final completion and acceptance,
complete the work at Seller's own expense and to the satisfaction ofthe Purchaser. When materials and equipment me
furnished by others for installation or erection by the Seller, the Seller shall receive, unload, store and handle same at
the site and become responsible therefor as though such materials and/or equipment were being famished by the Seller
under the order.
18. INSURANCE.
'rhe Seller shall, at his own expense, provide for the payment of workers compensation, including occupational disease
benefits, to its employees employed on or in connection with the work covered by this purchase order, and/or to their
dependents in accordance with the laws of the state in which the work is to be done. The Seller shall also carry
comprehensive general liability including, but not limited to, contractual and automobile public liability insurance with
bodily injury and death limits of at least $300,000 for any one person, $500.000 far any one accident and property
damage limit per accident of $400.000. The Seller shall likewise require his contractors, if any, to In for such
compensation and insurance. Before any of the Sellers or his contractors employees shall do any work upon the
premises of others. the Seller shall furnish the Purchaser with a certificate that such compensation and insurance have
been provided. Such certificates shall specify the date when such compensation and insurance have been provided.
Such certificates shall specify the date when such compensation and insurance expires. The Seller agrees that such
compensation and insurance shall be maintained until after the entire work is completed and accepted.
19. PROTECTION AGAINST ACCIDENTS AND DAMAGES.
The Seller hereby assumes the entire responsibility and liability for any and all damage, loss or injury of any kind or
nauue whatsoever to persons or property caused by or resulting from the execution ofthe work provided for in this
purchase order or in connection herewith. The Seller will indemnify and hold harmless the Purchaser and any or all of
the Pmchasers officers. agents and employees from and against any and all claims, losses, damages, charges or
expenses, whether direct or indirect, and whether to persons or property to which the Purchaser maybe put or subject
by reason of any act, action, neglect, omission or default on the part of the Seller, any ofhis contractors, or any of the
Sellers or contractors officers, agents or employees. Incise any suit or other proceedings shall be brought against the
Purchaser, or its officers, agents or employees at any time on account or by reason of any act, action, neglect, omission
or default ofthe Seller of any of his connectors or any of its or their officers, agents or employees as aforesaid, the
Seller hereby agrees to assume the defense thereof and to defend the sane at the Sellers own expense, to pay any and
Lill costs, charges, attorneys fees and other expenses, any and alijudgments that may be incurred by or obtained against
the Purchaser or any of its or their officers, agents or employees in such suits or other proceedings, and in case
judgment or other lien be placed upon or obtained against the property of the Purchaser, or said parties in oral a result
of such suits or other proceedings, the Seller will at once cause the same to be dissolved and discha ged bygiving bond
m otherwise. The Seller and his contractors steal take all safety precautions, furnish and install all guards necessary for
the prevention of accidents, comply with all Imes and regulations with regard to safety including, but without
limitation, the Occupational Safety and I lealth Act of 1970 and all rules and regulations issued pursuant thereto.
Revised 04/2009