Loading...
HomeMy WebLinkAbout426767 HOFF CONSTRUCTION - PURCHASE ORDER - 9953230 (3)Date: 9/15/2009 Fort of Page Number: 1 Purchase Order Number: 9953230 Delivery Date: 5/27/2009 Buyer: STEPHEN, JOHN Purchase Order number must appear on invoices, packing lists, labels, bills of lading, and all correspondence. Note: Line Qty/Units Description Extended Price 3 1 LOT 256.96- Change order 2 City of Fort CqKinY Director of Purchasing and Risk Management This order is dctValid over $5000 unless signed by James B. O'Neill II, CPPO City of Fort Collins Purchasing, PO Box 580, Fort Collins, CO 80522-0580 Phone: 970-221-6775 Fax: 970-221-6707 Email: purchasing@fcgov.com Total $256.96- Invoice Address: City of Fort Collins Accounting Department PO Box 580 Fort Collins, CO 80522-0580 Purchase Order Terms and Conditions I. COMMERCIAL DETAILS. Tax exemptions. By statute the City of Fort Collins is exempt from state and local taxes. Our Exemption Number is 98-04502. Federal Excise Tax Exemption Certificate of Registry 84-6000587 is registered with the Collector of Internal Revenue, Denver, Colorado (Ref. Colorado Revised Statutes IW3, Chapter 30-26. 114 (a) Goods Rejected. GOODS REJECTED due to failure to meet specifications. either when shipped or due to defects of damage in transit, may be returned to you for credit and are not to be replaced except upon receipt of written instructions from the City of Fort Collins, Inspection. GOODS we subject to the City of Fort Collins inspection or arrival. Final Acceptance. Receipt ofthe merchandise, services or equipment in response to this order can result in authorized payment on the pat of the City of Fort Collins. However, it is to be understood that FINAL ACCEPTANCE is dependent upon completion of all applicable required inspection procedures. Freight Terms. Shipments must be F.O.B., City of Fort Collins, 700 Wood St., Fort Collins. CO 80522, unless otherwise specified on this order. If permission is given to prepay freight and charge separately, the original fixight bill must accompany invoice. Additional charges for packing will not be accepted. Shipment Distance. Where manufacturers have distributing points in various pans ofthe country, shipment is expected fromthe nearest distribution point to destination, and excess freight will be deducted front Invoice when shipments are made from greater distance. Permits. Seller shall procure at sellers sole cost all necessary permits, certificates mid licenses required by all applicable laws, regulations, ordinances and rules of the state, municipality, territory or political subdivision where the work is performed or required by any other duly constituted public authority having jurisdiction over the work of vendor. Seller further agrees to hold the City of Fort Collins harmless fi•om and against all liability and loss incun'ed by than by reason of an asserted or established violation of any such laws. regulations, ordinances. rules and requirements. Authorization. All parties to this contract agree that the representatives arc, in fact, Iona tide and possess full :ad complete authority to bind said parties. LIMITATION OF TERMS. This Purchase Order expressly limits acceptance to the terms and conditions stated herein set forth and any supplementary or additional terms and conditions annexed hereto or incorporated herein by reference. Any additional or different terms and conditions proposed by seller are objected to and hereby rejected. 2. DELIVERY. PLEASE ADVISE PURCHASING AGENT immediately if you cannot make complete shipment to arrive on your promised delivery date as noted. Time is ofthe essence. Delivery and performance must be effected within the time stated on the purchase order and the documents attached hereto. No acts of the Purchasers including, without limitation, acceptance ofpartial late deliveries, shall operate as a waiver ofthis provision. In the event ofany delay, the Purchaser shall have, in addition to other legal and equitable remedies, the option of placing this order elsewhere and holding the Seller liable for damages. However, the Seller stall not be liable for damages m a result of delays due to causes not reasonably foreseeable which arc beyond its reasonable control and without its fault ofnegligence, such acts of God, acts of civil or military authorities, governmental priorities, fires, strikes, flood. epidemics, wars or riots provided that notice of the conditions causing such delay is given to the Purchaser within five (5) days ofthe time when the Seller first received knowledge thereof. In the event ofany such delay, the date of delivery shall be extended for the period equal to the time actually lost by reason of the delay. 3. WARRANTY The Seller warrants that all goods, articles, materials and work covered by this order will conform with applicable drawings, specifications, samples and/or other descriptions given, will be tit for the I uposes intended, and paron ned with the highest degree of care and competence in accordance with accepted standards for work of n similar nature. The Seller agrees to hold the purchaser harmless from any loss, damage or expense which the Purchaser may suffer or incur on account ofthe Sellers breach ofwarranty. The Seller shall replace, repair or nuke good, without cost to the purchaser, any defects or faults arising within one (1) year or within such longer period of time as may be prescribed by law or by the tents of any applicable warranty provided by the Seller after the date of acceptance of the goods furnished hereunder (acceptance not to be unreasonably delayed), resulting from imperfect or defective work done or materials furnished by the Seller. Acceptance or use of goods by the Purchaser shall not constitute a waiver ofany claim under this waranty. Except as otherwise provided in this purchase order, the Sellers liability hereunder shall extend to all damages proximately caused by the breach ofany of the foregoing warranties or guarantees, but such liability shall in no event include loss of profits or loss of use. NO IMPLIED WARRANTY OR MERCHANTABILITY OR OF FITNESS FOR PURPOSE SHALL APPLY. 4. CHANGES IN LEGAL TERMS. The Purchaser may make changes to legal terms by written change order. 5. CHANGES IN COMMERCIAL TERMS. The Purchaser may make any changes to the terms. other than legal terms, including additions to or deletions from the quantities originally ordered in the specifications or drawings, by verbal or written change order. I f any such change affects the amount due or the time of performance hereunder, an equitable adjustment shall be trade. 6. TERMINATIONS. The Purchaser may at any time by written change order, terminate this agreement as to any or all portions ofthe goods then not shipped, subject to any equitable adjustment between the parties as to any work or materials then in progress provided that the Purchaser shall not be liable for any claims for anticipated profits on the uncompleted portion of the goods and/or work, for incidental or consequential damages, and that no such adjusonent be trade in favor ofthe Seller with respect to any goods which are the Sellers standard stock. No such termination shall relieve the Purchaser or the Seller of any of their obligations as to any goods delivered hereunder. 7. CLAIMS FOR ADJUSTMENT Any claim for adjustment must be asserted within thirty (30) days fi o the date the change or termination is ordered 8. COMPLIANCE WITH LAW. The Seller warrants that all goods sold hereunder shall have been produced, sold, delivered and furnished in strict compliance with all applicable laws and regulations to which the goods are subject. The Seller shall execute and deliver such documents as may be required to effect or evidence compliance. All laws and regulations required to be incorporated in agreements of this character are hereby incorporated herein by this reference. The Seller agrees to indemnify and hold the Purchaser harmless from all costs and damages suffered by the Purchaser as a result of the Sellers failure to comply with such law. If and only to the extent this [Agreement] constitutes a "sole source government contract" within the meaning of Article XXVIII ofthe Colorado Constitution ("Article XXVIII"), then the provisions of Section 15 ofArticle XXVIII are hereby incorporated into this [Agreement]. In such a case, if the [Contractor] or any other person who is a "contract holder" as defined in Section 2(4.5) of Article XXVIII intentionally violates Section 15 of Section 17(2) of Article XXVIII, then the [Contractor] agrees it shall be ineligible to hold any sole source government contract, or public employment with the state of Colorado or any of its political subdivisions, for three years 9. ASSIGNMENT. Neither party shall assign, transfer, or convey this order, or any monies due or to become due hereunder without the prior written consent of the other party. In. TITLE The Seller warrants full, clear and unrestricted title to the Purchaser for all equipment, materials, and items; furnished in performance of this agreement. free and clear of any mid all liens, restrictions, reservations, security interest encumbrances and claims of others. I I. NONWAIVER. Failure of the Purchaser to insist upon strict perfornnance of the terms and conditions hereof, failure or delay to exercise any rights or remedies provided herein or by law. failure to promptly notify the Seller in the event ofa breach, the acceptance of or payment for goods hereunder or approval ofthe design, shall not release the Seller of any ofthe warranties or obligations ofthis purchase order and shall not be deemed a waiver ofany right ofthe purchaser to insist upon strict performance hereof or any of its rights of remedies as to any such goods, regardless of when shipped, received or accepted, as to any prior or subsequent default hereunder, nor shall any purported oral modification or rescission ofthis purchase order by the Purchaser operate as a waiver of any ofthe terns hereof. 12. ASSIGNMENT OF ANTITRUST CLAIMS. Seller and the Purchaser recognize that in actual economic practice, overcharges resulting from antitrust violations are in fact borne by the Purchaser. Theretofore, for good cause and as consideration for executing this purchase order, the Seller hereby assigns to the Purchaser any mid all claims it may now have or hereafter acquired under federal or state antitrust Imes fir such overcharges relating to the particular goods or services purchased or acquired by the Purchaser pursuant to this purchase order. 13 PURCHASERS PERFORMANCE OF SELLERS OBLIGATIONS. If the Purchaser directs the Seller to correct nonconforming or defective goods by a date to be agreed upon by the Purchaser.and the Seller, and the Seller thereafter indicates its inability or unwillingness to comply, the Purchwamay cause the work to be performed by the most expeditious means available to it, and the Seller shall pay all costs associated with such work. The Seller shall release the Purchaser and its contractors ofany tier from all liability and claims ofany nature resulting from the performance of such work. This release shall apply even in the event of fault ofnegligence ofthe party released and shall extend to the directors, officers and employees of such party. The Seller's contractual obligations, including warranty. shall not be deemed to be reduced, in any way. because such work is performed or caused to be performed by the Purchaser. 14. PATENTS. Whenever the Seller is required to use any design, device, material or process covered by letter, patent, trademark or copyright, the Seller shall indemnify and save harmless the Purchaser from any and all claims for infiingement by reason ofthe use of such patented design, device, material or process in connection with the contract, and shall indemnify the Purchaser for any cost. expense or damage which it maybe obliged to pay by reason of such infringement at any time during the prosecution or after the completion ofthe work. In case said equipment, or any part thei eof or the intended use ofthe goods• is in such suit held to constitute infringement and the use of said equipment or part is enjoined, the Seller shall, at its own expense and at its option, either procure for the Purchaser the right to continue using said equipment or pars. replace the same with substantially equal but non -infringing equipment, or modify it so it becomes nun -infringing. 15. INSOLVENCY If the Seller shall become insolvent or bankrupt, make an assignment for the benefit of creditors, appoint a receiver or trustee firany ofthe Sellers property or business, this order may forthwith be canceled by the Purchaser without liability. 16. GOVERNING LAW. The definitions of terms used or the interpretation of the agreement and the rights of all parties hereunder shall be construed under and governed by the laws of the State of Colorado, USA. The following Additional Conditions apply only in cases where the Seller is to perform work hereunder, including the services of Sellers Representative(s), on the premises of others. 17. SELLERS RESPONSIBILITY. The Seller shall carry on said work at Seller's own risk until the same is fully completed and accepted, and shall, in case of any accident, destruction of injury to the work and/or materials before Seller's final completion and acceptance, complete the work at Seller's own expense and to the satisfaction ofthe Purchaser. When materials and equipment are furnished by others for installation or erection by the Seller, the Seller shall receive, unload, store and handle same at the site and become responsible therefor as though such materials and/or equipment were being furnished by the Seller under the order 18. INSURANCE. The Seller shall, at his own expense. provide for the payment ofworkers compensation, including occupational disease benefits, to its employees employed on or in connection with the work covered by this purchase order, and/or to their dependents in accordance with the laws of the state in which the work is to be done. The Seller shall also carry comprehensive general liability including, but not limited to, contractual and automobile public liability insurance with bodily injury and death limits of at least $300,000 for any one person, $500.000 for any one accident and property dotage limit per accident of $400,000, The Seller shall likewise require his contractors, if any. to provide for such compensation and insurance. Before any of the Sellers or his contractors employees shall do any work upon the premises of others, the Seller shall furnish the Purchaser with a certificate that such compensation and insurance have been provided Such certificates shall specify the date when such compensation and insurance have been provided. Such certificates shall specify the date when such compensation and insurance expires. The Seller agrees that such compensation and insurance shall he maintained until after the entire work is completed and accepted. 19 PROTECTION AGAINST ACCIDENTS AND DAMAGES. The Seller hereby assumes the entire responsibility and liability for any and all damage, loss or injury of any kind or nature whatsoever to persons or property caused by or resulting from the execution of the work provided for in this purchase order or in connection herewith. The Seller will indemnify and hold harmless the Purchaser and any or all of the Purchasers officers. agents and employees from and against any and all claims, losses, damages, charges or expenses, whether direct or indirect, and whether to persons or property to which the Purchaser maybe put or subject by reason of any act, action, neglect, omission or default on the part ofthe Seller, any of his contractors, or any of the Sellers or contractor officers, agents or employees. In case any suit or other proceedings shall be brought against the Purchaser, or its officers.agents or employees at any time on account or by reason ofany act, action, neglect, omission or default of the Seller of any of his contractors or any of its or their officers, agents or employees as aforesaid, the Seller hereby agrees to assume the defense thereof and to defend the same at the Sellers own expense, to pay any and all costs, charges, attorneys fees and other expenses, any and alljudgments that may beincurred by or obtained against the Purchaser or any of its or their officers, agents or employees in such suits or other proceedings, and in case judgment or other lien be placed upon or obtained against the property ofthe Purchaser, or said parties in or as a result ofsuch suits or other proceedings, the Seller will at once cause the same to be dissolved and discharged bygiving bond or otherwise. The Seller and his contractors shall take all safety precautions, furnish and install all guards necessary for the prevention of accidents, comply with all laws and regulations with regard to safety including, but without limitation, the Occupational Safety and Health Act of 1970 and all rules and regulations issued pursuant thereto. Revised 04/2009