Loading...
HomeMy WebLinkAbout125216 WALSH ENVIRONMENTAL SCIENTISTS - PURCHASE ORDER - 9953929Date: 6/29/2009 City of FF:16--rt„Collins Page Number: 1 Purchase Order Number: 9953929 Delivery Date: 6/29/2009 Buyer: O'NEILL,JAMES Purchase Order number must appear on invoices, packing lists, labels, bills of lading, and all correspondence. Note Line Qty/Units Description Extended Price 1 EPIC 8,601.50 Sampling Total $8,601.50 City of Fort CoPrif Director of Purchasing and Risk Management City of Fort Collins This order is HQValid over $5000 unless signed by James B. O'Neill II, CPPO Accounting Department City of Fort Collins Purchasing, PO Box 580, Fort Collins, CO 80522-0580 PO Box 580 Phone: 970-221-6775 Fax: 970-221-6707 Email: purchasing@fcgov.com Fort Collins, CO 80522-0580 Purchase Order Terms and Conditions I. COMMERCIAL DETAILS. Tax exemptions. By statute the City of Foil Collins is exempt from state and local taxes. Our Exemption Number is 98-04502. Federal Excise Tax Exemption Certificate of Registry 84-0000587 is registered with the Collector of Internal Revenue, Denver, Colorado (Ref. Colorado Revised Statutes 1973, Chapter 39-16. 114 (a). Goods Rejected. GOODS REJECTED due to failure to meet specifications. either when shipped or (file to defects of damage in transit, may be returned to you for credit and are not to be replaced except upon receipt of written instructions from the City of Pon Collins. Inspection. GOODS are subject to the City of For Collins inspection on arrival. Final Acceptance. Receipt ofthe merchandise, services or equipment in response to this or can result in authorized payment on the part of the City of Foil Collins. However, it is to be understood that FINAL ACCE PTA NC is dependent upon completion of all applicable required inspection procedures. Freight ferns. Shipments must be F.O.B., City of Foil Collins, 700 Wood St., For Collins, CO 80522, unless otherwise specified on this order. Ifpermission is given to prepay freight and charge separately, the original linight bill must accompany invoice. Additional charges for packing will not be accepted. Shipment Distance. Where manufacturers have distributing points in various parts ofthe country, 11 shipt—is expected from the nearest distribution point to destination, and excess freight will be deducted from Invoice when shipmmits are made from greater distance. Permits. Seller shall procure at sellers sole cost all necessary permits, certificates and licenses required by all applicable laws, regulations, ordinances and rules of the state, municipality. ten imiy or political subdivision where the work is performed, or required by any other duly constituted public authority having jurisdiction over the work ol'vendor. Seller further agrees to hold the City of Fort Collins harmless from and against all liability and loss incurred by them by, reason of an asserted or established violation ofany such laws, regulations, ordinances, rules and requirements. Authorization. All parties to this contract agree that the representatives are. in fact. bona fide and possess fill and complete authority to bind said parties. LIMITATION OFTERMS. This Purchase Orderexpiessly limits acceptance to the terns and conditions stated herein set forth and any supplementary or additional terns and conditions annexed hereto or incorporated herein by reference. Any additional or different tems and conditions proposed by seller are objected to and hereby rejected. 2. DELIVERY. PLEASE ADVISE PURCHASING AGENT immediately if you cannot make complete shipment to ar ive oil your promised delivery date as noted. Time is ofthe essence. Delivery and performance must be effected within the time stated on the purchase order and the documents attached hereto. No acts of' (lie Purchasers including, without limitation, acceptance ofpmtial late deliveries, shall operate as a waiver ofthis provision. In the event ofanydelay, the Purchaser shall have, in addition to other legal and equitable remedies, the option of placing this order elsewhere and holding the Seller liable for damages. However, the Seller shall not be liable For damages as a result of dchrys due to causes not reasonably foreseeable which are beyond its reasonable control and without its fault ofnegligence. such acts of God, acts of civil or military authorities, governmental priorities, fires, strikes, flood, epidemics, wnrs or riots provided that notice of the conditions causing such delay is given to the Purchaser within five (5) (lays of the time when the Seller first received knowledge thereof In the event ofany such delay, the date ofdelivery shall lie extended for the period equal to the time actually lost by reason ofthe delay. 3. WARRANTY. The Seller warrants that all goods, articles, materials and work covered by this order will confxnm with applicable drawings. specifications, samples and/or other descriptions given, will be fit for the purposes intended, and pedo nmed with the highest degree of care and competence in accordance with accepted standards for work of a similar nacre. The Seller agrees to hold the purchaser harmless from any loss, damage or expense which the Purchaser many suffer r n incur on account ofthe Sellers breach of warranty. The Seller shall replace. repair or make good, without cost to the purchaser, any defects or faults at within one (1) year or within such longer period of time as nary be prescribed by law or by the tens of any applicable warranty provided by the Seller after the date of acceptance of the goods furnished her (acceptance not to be unreasonably delayed), resulting from imperfect or defective work done or materials furnished by the Seller. Acceptance or use of goods by the Purchaser shall not constitute a waiver ofany claim under this warranty. Except as otherwise provided in this purchase order, the Sellers liability hereunder shall extend to all damages proximately caused by the breach ofany ofthe foregoing warrmitics or guarantees, but such liability shall in no event include loss of profits or loss of use. NO IMPLIED WARRANTY OR MERCHANTABILITY OR OF FITNESS FOR PURPOSE SHALL APPLY. 4. CHANGES IN LEGAL TERMS. The Purchaser may make changes to legal terns by written change order. . 5. CHANGES IN COMMERCIAL TERMS. The Purchaser may make airy changes to the terms, other than legal terns, including additions to or deletions from the quantities originally ordered in the specifications or drawings, by verbal or written change order. If any such change affects the amount due or the time of performance hereunder, air equitable adjustment shall be made. 6. TERMINATIONS. The Purchaser may at anytime by written change order, terminatethis agreement as to any of all portions ofthe goods then not shipped, subject to any equitable adjustment between the parties as to any work or materials then in progress provided that the Purchaser shall not be liable for any claims for anticipated profits on the uncompleted Ixrtion of the goods and/or work, for incidental or consequential damages, and that no such adjustment be ninde in favor ofthe Seller with respect to any goods which are the Sellers standard stock. No such termination shall relieve the Purchaser or the Seller of any of their obligations as to any goods delivered hereunder. 7. CLAIMS FOR ADJUSTMENT. Any claim for adjustment must be asserted within thirty (30) days from the date the change or termination is ordered. 8. COMPLIANCE WITH LAW. The Seller warrants that all goods sold hereunder shall have been produced, sold, delivered and furnished in strict compliance with all applicable laws and regulations to which the goods arc subject. The Sclicr shall execute;aid delivei such documents as may be required to effect or evidence compliance. All laws and regulations requi—I to be incorporated in agreements of this character are hereby incorporated herein by this reference. The Seller agrees to indemnify and hold the Purchaser harmless from all costs and damages suffered by the Purchaser as n result of the Sellers failure to comply with such law. If and only to the extent this [Agreement] constitutes a "sole source government contract" within the meaning of Article XX V II I ofthe Colorado Constitution ("Article XXV I I I"), then the provisions of Section 15 ofArticle XN V I I I are hereby incorporated into this [Agreement]. In such a case, if the [Contractor] or any other per ryho is -a "contract holder" as defined in Section 2(4.5) ofArticle XXVIII intentionally violates Section 15 or Section 17(2) of Article XXVIII, then the [Contractor] agrees it shall be ineligible to hold any sole source government contract, or public employment with the state of Colorado or any of its political subdivisions, for three years. - 9. ASSIGNMENT. Neither party shall assign, transfer, or convey this order, or any monies due or to become due hereunder without the prior written consent of the other party. ' 10. TITLE The Seller warrants fill, clear anti unrestricted title to the Purchaser for all equipment, materials, and item furnished in per of this agreement, fine and clear of any and all liens, restrictions, reservations, security interest encumbrances and claims of others. I I. NONWAIVER. - Failure of the Purchaser to insist upon strict performance ofthe tens and conditions hereof failure or delay to exercise any rights or remedies provided herein or by law, failure to promptly notify the Seller in the event of a breach, the acceptance of or payment fix goods hereunder or approval ofthe design, shall not release the Seller of any of the warranties or obligations of this purchase order and shall not be deemed a waiver of any right ofthe purchaser to insist upon strict performance hereof of any of its rights or remedies as to any such goods, regardless of when shipped, received or accepted. as to any prior or subsequent default hereunder, nor shall any purported oral modification or rescission of this purchase order by the Purchaser operate as a waiver ofany ofthe tents hereof. 12. ASSIGNMENT 01: ANTITRUST CLAIMS. Seller and the Purchaser recognize that in rctual economic practice, overcharges resulting fi-om antinvst violations are in fact borne by the Purchaser. Thei ctolimre, for good cause and as consideration for executing this put clime order, the Seller hereby assigns to the Purchaser any and all claims it may now have or hereafter acquired under federal or state antitrust Errs for such overcharges relating to the particular goods or services purchased or acquired by the Purchaser pursuant to this purchase order. 13. PURCHASERS PERFORMANCE OF SELLERS OBLIGATIONS. If the Purchaser directs the Seller to correct nonconforming or defective goods by a date to be agreed upon by the Purchaser and the Seller, and the Seller thereafter indicates its inabilityor unwillingness to comply, the Purchaser nray cause the work to be per by the most expeditious means available to it, and the Seller shall pay all costs associated with such work. The Seller shall release the Purchaser and its contractors ofany tier from all liabilityand claims ofany nature resulting floor the performance of such work. ]'his release shall apply even in the event of fault of negligence ofthe party released and shall extend to the directors, officers and employees ofsuch party. The Seller's contractual obligations, including warranty, shall not be deemed to be reduced, in anyway. because such work is per or caused to be per lbrined by the Purchaser. 14. PATENTS. Whenever the Seller is required to use any design, device, material or process covered by letter, patent, trademark or copyright, the Seller shaft indemnify and save harmless the Purchaser fi oar any and all claims for infiingenlent by reason ofthe use of such patented design, device, material or process in connection with the contract, and shall indemnify the Purchaser for any cost, expense or damage which it maybe obliged to pay by reason of such infringenent at any time during the prosecution or after the completion ofthe work. In case said equipment, or any part thereofer the intended use ofthe goods, is in such suit held to constitute infringement and the use of said equipment or pail is enjoined, the Setter shall, at its own expense and at its option, either procure for the Purchaser the right to continue using said equipment m parts, replace the s;une with substantially equal but non-infi inging equipmment, or modify it so it becomes non-iafiinginu. 15. INSOLVENCY. If the Seller shall become insolvent of bankrupt, mike an assignment for the benefit ofcieditois, appoint a receiver or trustee for any of the Sellers property or business, this order may forthwith be canceled by the Purchaser without liability. 16. GOVERNING LAW. The definitions of terns used or the interpretation ofthe agreement and the rights of all parties hereunder shall be construed under and governed by the laws ofthe State of Colorado, USA. The following Additional Conditions apply only in cases where the Seller is to perform work hereunder, including the services of Sellers Repiesentative(s), on the premises ofothers. r 17. SELLERS RESPONSIBILITY. The Seller shall canyon said work at Seller's own risk until the same is fully completed and accepted, and shall, incase ofany accident, destruction or injury to the work and/or materials before Seller's final completion and acceptance. mplctc the work at Seller'sown expense and to the satisfaction of the Pw chaser. When materiats and equipment are Furnished by others for installation or erection by the Seller, the Seller shall receive, unload, store and handle same at the site and become responsible therefor as though such materials and/or equipment were being furnished by the Seller ,,ad,, tire order. IS INSURANCE. 'Ile Seller shall, at his own expense, provide for the payment of workers compensation, including occupational disease benefits, to its employees employed on or in connection with the work covered by this purchase order, mid/or to their dependents in accordance with the laws of the state in which the work is to be done. The Seller shall also carry conmprehensive general liability including, but not limited to, contractual and automobile public liability insurance with bodily injury and death limits of at least $300,000 for any one person. $500,000 for any one accident and property dammage limit per accident of $400.000. The Seller shall likewise require his contractors. if any, to provide for such compensation and insurance. Before any of the Sellers or his contractors employees shall do any work upon the premises of others. the Seller shall furnish the Purchaser with a cenificate that such compensation and insurance have been provided. Such certificates shall specify the date when such compensation and insurance have been provided. Such certificates shall specify the date when such compensation and insurance expires. The Seller agrees that such compensation and insurance shall be maintained until after the entire work is completed and accepted. 19. PROTECTION AGAINST ACCIDENTS AND DAMAGES. The Seller hereby assumes the entire responsibility and liability for any and all damage, loss or injury ofany kind of - nature whatsoever to persons or property caused by or resulting from the execution ofthe work provided for in this purchase order m in connection hci ewith.'file Seller will indennify and hold harmless the Purchaser and any m all of the Purchasers officers, agents and employees from and against any and all claims, losses, damages, charges or expenses, whether direct or indirect, and whether to persons or property to which the Purchaser nray be put or subject by reason of any act, action, neglect, omission or default on the pail ofthe Seller, any ofhis contractors, or airy ofthe Sellers or contractors officers. agents or employees. In case any suit or other proceedings shall be brought against the Purchaser, or its officers, agents or employees at anytime on account or by reason of any act, action, neglect, omission or default of the Seller ofany of his contractors or any of its or their officers, agents or employees as aforesaid, the Seller hereby agrees to assume the defense thereof and to defend the same at the Sellers own expense, to pay any and all costs. charges, attorneys fees and other expenses, any and alljudgments that may be incurred by or obtained against the Purchaser or any of its or their officers; agents or employees in such suits or other proceedings, and in case judgment or other lien be placed upon or obtained against the property of the Purchaser, or said parties in or m a result of such suits or other proceedings, the Seller will at once cause the same to be dissolved and discharged bygiving bond or otherwise. The Seller and his contractors shall take all safety precautions, famish and install all guards necessary for the prevention of accidents, comply with all laws and regulations with regard to safety including, but without limitation, the Occupational Safety and Health Act of 1970 and all rules and regulations issued pursuant thereto. Revised 04/2009