Loading...
HomeMy WebLinkAboutRFP - P1123 GENERAL CONTRACTOR FOR FIRE STATION EXPANSION AND RENOVATION PROJECT (3)STD WO SA WO rev06/07 1 SERVICES AGREEMENT WORK ORDER TYPE THIS AGREEMENT made and entered into the day and year set forth below, by and between THE CITY OF FORT COLLINS, COLORADO, a Municipal Corporation, Acting on Behalf of the Poudre Fire Authority, hereinafter referred to as the "City" and Drahota Commercial, LLC hereinafter referred to as "Service Provider". WITNESSETH: In consideration of the mutual covenants and obligations herein expressed, it is agreed by and between the parties hereto as follows: 1. Services to be Performed. a. This Agreement shall constitute the basic agreement between the parties for services for P1123 Poudre Fire Authority Fire Station Expansion and Renovation Projects. The conditions set forth herein shall apply to all services performed by the Service Provider on behalf of the City and particularly described in Work Orders agreed upon in writing by the parties from time to time. Such Work Orders, a sample of which is attached hereto as Exhibit "A", consisting of one (1) page and incorporated herein by this reference, shall include a description of the services to be performed, the location and time for performance, the amount of payment, any materials to be supplied by the City and any other special circumstances relating to the performance of services. The only services authorized under this agreement are those which are performed after receipt of such Work Order, except in emergency circumstances where oral work requests may be issued. Oral requests for emergency actions will be confirmed by issuance of a written Work Order within two (2) working days. b. The City may, at any time during the term of a particular Work Order and without invalidating the Agreement, make changes within the general scope of the particular services assigned and the Service Provider agrees to perform such changed services. STD WO SA WO rev06/07 2 2. Changes in the Work. The City reserves the right to independently bid any services rather than issuing work to the Service Provider pursuant to this Agreement. Nothing within this Agreement shall obligate the City to have any particular service performed by the Service Provider. 3. Time of Commencement and Completion of Services. The services to be performed pursuant to this Agreement shall be initiated as specified by each written Work Order or oral emergency service request. Oral emergency service requests will be acted upon without waiting for a written Work Order. Time is of the essence. 4. Contract Period. This Agreement shall commence July 1, 2008 and shall continue in full force and effect until June 30, 2008, unless sooner terminated as herein provided. In addition, at the option of the City, the Agreement may be extended for additional one year periods not to exceed four (4) additional one year periods. Renewals and pricing changes shall be negotiated by and agreed to by both parties. The Denver Boulder Greeley CPIU published by the Colorado State Planning and Budget Office will be used as a guide. Written notice of renewal shall be provided to the Service Provider and mailed no later than 90 days prior to contract end. 5. Delay. If either party is prevented in whole or in part from performing its obligations by unforeseeable causes beyond its reasonable control and without is fault or negligence, then the party so prevented shall be excused from whatever performance is prevented by such cause. To the extent that the performance is actually prevented, the Service Provider must provide written notice to the City of such condition within fifteen (15) days from the onset of such condition. 6. Early Termination by City/Notices. Notwithstanding the time periods contained herein, the City may terminate this Agreement at any time without cause by providing written notice of termination to the Service Provider. Such notice shall be mailed at least fifteen (15) days prior to the termination date contained in said notice unless otherwise agreed in writing by STD WO SA WO rev06/07 3 the parties. All notices provided under this Agreement shall be effective when mailed, postage prepaid and sent to the following address: City Service Provider City of Fort Collins Attn: Purchasing PO Box 580 Fort Collins, CO 80522 Drahota Commercial, LLC Attn: Terry Drahota PO Box 272269 4700 Innovation Drive Bld C Fort Collins ,CO 80527 In the event of early termination by the City, the Service Provider shall be paid for services rendered to the termination date, subject only to the satisfactory performance of the Service Provider's obligations under this Agreement. Such payment shall be the Service Provider's sole right and remedy for such termination. 7. Contract Sum. This is an open-end indefinite quantity Agreement with no fixed price. The actual amount of work to be performed will be stated on the individual Work Orders and in accordance to Exhibit C consisting of five (5) pages and incorporated herein by this reference. The City makes no guarantee as to the number of Work Orders that may be issued or the actual amount of services which will in fact be requested. 8. Payments. a. The City agrees to pay and the Service Provider agrees to accept as full payment for all work done and all materials furnished and for all costs and expenses incurred in performance of the work the sums set forth for the hourly labor rate and material costs, with markups, stated within the Bid Schedule Proposal Form, attached hereto as Exhibit "C", consisting of five (5) pages, and incorporated herein by this reference. Payment shall be made by the City only upon acceptance of the work by the City and upon the Service Provider furnishing satisfactory evidence of payment of all wages, taxes, supplies and materials, and other costs incurred in connection with the performance of such work. STD WO SA WO rev06/07 4 9. City Representative. The City's representative will be shown on the specific Work Order and shall make, within the scope of his or her authority, all necessary and proper decisions with reference to the work requested. All requests concerning this Agreement shall be directed to the City Representative. 10. Independent Contractor. It is agreed that in the performance of any services hereunder, the Service Provider is an independent contractor responsible to the City only as to the results to be obtained in the particular work assignment and to the extend that the work shall be done in accordance with the terms, plans and specifications furnished by the City. 11. Personal Services. It is understood that the City enters into the Agreement based on the special abilities of the Service Provider and that this Agreement shall be considered as an agreement for personal services. Accordingly, the Service Provider shall neither assign any responsibilities nor delegate any duties arising under the Agreement without the prior written consent of the city. 12. Acceptance Not Waiver. The City's approval or acceptance of, or payment for any of the services shall not be construed to operate as a waiver of any rights under the Agreement or of any cause of action arising out of the performance of this Agreement. 13. Warranty. a. Service Provider warrants that all work performed hereunder shall be performed with the highest degree of competence and care in accordance with accepted standards for work of a similar nature. b. Unless otherwise provided in the Agreement, all materials and equipment incorporated into any work shall be new and, where not specified, of the most suitable grade of their respective kinds for their intended use, and all workmanship shall be acceptable to City. c. Service Provider warrants all equipment, materials, labor and other work, provided under STD WO SA WO rev06/07 5 this Agreement, except City-furnished materials, equipment and labor, against defects and nonconformances in design, materials and workmanship/workwomanship for a period beginning with the start of the work and ending twelve (12) months from and after final acceptance under the Agreement, regardless whether the same were furnished or performed by Service Provider or by any of its subcontractors of any tier. Upon receipt of written notice from City of any such defect or nonconformances, the affected item or part thereof shall be redesigned, repaired or replaced by Service Provider in a manner and at a time acceptable to City. 14. Default. Each and every term and condition hereof shall be deemed to be a material element of this Agreement. In the event either party should fail or refuse to perform according to the terms of this agreement, such party may be declared in default thereof. 15. Remedies. In the event a party has been declared in default, such defaulting party shall be allowed a period of ten (10) days within which to cure said default. In the event the default remains uncorrected, the party declaring default may elect to (a) terminate the Agreement and seek damages; (b) treat the Agreement as continuing and require specific performance; or (c) avail himself of any other remedy at law or equity. If the non-defaulting party commences legal or equitable actions against the defaulting party, the defaulting party shall be liable to the non-defaulting party for the non-defaulting party's reasonable attorney fees and costs incurred because of the default. 16. Binding Effect. This writing, together with the exhibits hereto, constitutes the entire agreement between the parties and shall be binding upon said parties, their officers, employees, agents and assigns and shall inure to the benefit of the respective survivors, heirs, personal representative, successors and assigns of said parties. 17. Indemnity/Insurance. STD WO SA WO rev06/07 6 a. The Service Provider agrees to indemnify and save harmless the City, its officers, agents and employees against and from any and all actions, suits, claims, demands or liability of any character whatsoever, brought or asserted for injuries to or death of any person or persons, or damages to property arising out of, result from or occurring in connection with the performance of any service hereunder. b. The Service Provider shall take all necessary precautions in performing the work hereunder to prevent injury to persons and property. c. Without limiting any of the Service Provider's obligations hereunder, the Service Provider shall provide and maintain insurance coverage naming the City as an additional insured under this Agreement of the type and with the limits specified within Exhibit "B", consisting of one (1) page, attached hereto and incorporated herein by this reference. The Service Provider before commencing services hereunder, shall deliver to the City's Director of Purchasing and Risk Management, P. O. Box 580, Fort Collins, Colorado 80522 one copy of a certificate evidencing the insurance coverage required from an insurance company acceptable to the city. 18. Entire Agreement. This Agreement, along with all Exhibits and other documents incorporated herein, shall constitute the entire Agreement of the parties. Covenants or representations not contained in this Agreement shall not be binding on the parties. STD WO SA WO rev06/07 7 19. Law/Severability. This Agreement shall be governed in all respect by the laws of the State of Colorado. In the event any provision of this Agreement shall be held invalid or unenforceable by any court of competent jurisdiction such holding shall not invalidate or render unenforceable any other provision of this Agreement. 20. Prohibition Against Employing Illegal Aliens. Pursuant to Section 8-17.5-101, C.R.S., et. seq., Contractor represents and agrees that: a. As of the date of this Agreement: 1. Contractor does not knowingly employ or contract with an illegal alien; and 2. Contractor has participated or attempted to participate in the basic pilot employment verification program created in Public Law 208, 104th Congress, as amended, and expanded in Public Law 156, 108th Congress, as amended, administered by the United States Department of Homeland Security (the “Basic Pilot Program”) in order to confirm the employment eligibility of all newly hired employees. b. Contractor shall not knowingly employ or contract with an illegal alien to perform work under this Agreement or knowingly enter into a contract with a subcontractor that knowingly employs or contracts with an illegal alien to perform work under this Agreement. c. Contractor shall continue to apply to participate in the Basic Pilot Program and shall in writing verify same every three (3) calendar months thereafter, until Contractor is accepted or the public contract for services has been completed, whichever is earlier. The requirements of this section shall not be required or effective if the Basic Pilot Program is discontinued. d. Contractor is prohibited from using Basic Pilot Program procedures to undertake STD WO SA WO rev06/07 8 pre-employment screening of job applicants while this Agreement is being performed. e. If Contractor obtains actual knowledge that a subcontractor performing work under this Agreement knowingly employs or contracts with an illegal alien, Contractor shall: 1. Notify such subcontractor and the City within three days that Contractor has actual knowledge that the subcontractor is employing or contracting with an illegal alien; and 2. Terminate the subcontract with the subcontractor if within three days of receiving the notice required pursuant to this section the subcontractor does not cease employing or contracting with the illegal alien; except that Contractor shall not terminate the contract with the subcontractor if during such three days the subcontractor provides information to establish that the subcontractor has not knowingly employed or contracted with an illegal alien. f. Contractor shall comply with any reasonable request by the Colorado Department of Labor and Employment (the “Department”) made in the course of an investigation that the Department undertakes or is undertaking pursuant to the authority established in Subsection 8-17.5-102 (5), C.R.S. g. If Contractor violates any provision of this Agreement pertaining to the duties imposed by Subsection 8-17.5-102, C.R.S. the City may terminate this Agreement. If this Agreement is so terminated, Contractor shall be liable for actual and consequential damages to the City arising out of Contractor’s violation of Subsection 8-17.5-102, STD WO SA WO rev06/07 9 STD WO SA WO rev06/07 10 EXHIBIT "A" WORK ORDER FORM PURSUANT TO AN AGREEMENT BETWEEN THE CITY OF FORT COLLINS AND Drahota Commercial, LLC DATED: July 1, 2008 Work Order Number: Purchase Order Number: Project Title: Commencement Date: Completion Date: Maximum Fee: (time and reimbursable direct costs): Project Description: ____________________________________________________________________________ ____________________________________________________________________________ Scope of Services: ____________________________________________________________________________ User Acceptance ______________________ Professional agrees to perform the services identified above and on the attached forms in accordance with the terms and conditions contained herein and in the Professional Services Agreement between the parties. In the event of a conflict between or ambiguity in the terms of the Professional Services Agreement and this work order (including the attached forms) the Professional Services Agreement shall control. Professional By:________________________________ Date:_______________________________ The attached forms consisting of ___ (_) pages are hereby accepted and incorporated herein, by this reference, and Notice to Proceed is hereby given. City of Fort Collins By:_________________________________ Date:_______________________________ By: ________________________________ Director of Purchasing and Risk Management (over $60,000.00) Date: ______________________________ STD WO SA WO rev06/07 11 EXHIBIT B INSURANCE REQUIREMENTS 1. The Service Provider will provide, from insurance companies acceptable to the City, the insurance coverage designated hereinafter and pay all costs. Before commencing work under this bid, the Service Provider shall furnish the City with certificates of insurance showing the type, amount, class of operations covered, effective dates and date of expiration of policies, and containing substantially the following statement: "The insurance evidenced by this Certificate will not be cancelled or materially altered, except after ten (10) days written notice has been received by the City of Fort Collins." In case of the breach of any provision of the Insurance Requirements, the City, at its option, may take out and maintain, at the expense of the Service Provider, such insurance as the City may deem proper and may deduct the cost of such insurance from any monies which may be due or become due the Service Provider under this Agreement. The City, its officers, agents and employees shall be named as additional insureds on the Service Provider's general liability and automobile liability insurance policies for any claims arising out of work performed under this Agreement. 2. Insurance coverages shall be as follows: A. Workers' Compensation & Employer's Liability. The Service Provider shall maintain during the life of this Agreement for all of the Service Provider's employees engaged in work performed under this agreement: 1. Workers' Compensation insurance with statutory limits as required by Colorado law. 2. Employer's Liability insurance with limits of $100,000 per accident, $500,000 disease aggregate, and $100,000 disease each employee. B. Commercial General & Vehicle Liability. The Service Provider shall maintain during the life of this Agreement such commercial general liability and automobile liability insurance as will provide coverage for damage claims of personal injury, including accidental death, as well as for claims for property damage, which may arise directly or indirectly from the performance of work under this Agreement. Coverage for property damage shall be on a "broad form" basis. The amount of insurance for each coverage, Commercial General and Vehicle, shall not be less than $500,000 combined single limits for bodily injury and property damage. In the event any work is performed by a subcontractor, the Service Provider shall be responsible for any liability directly or indirectly arising out of the work performed under this Agreement by a subcontractor, which liability is not covered by the subcontractor's insurance. STD WO SA WO rev06/07 12 EXHIBIT C DESIGN PHASE COST AND CONSTRUCTION COST FACTORS STD WO SA WO rev06/07 13 Exhibit D P1123 General Contractor for Fire Station Expansion and Renovation Projects PROJECT REQUIREMENTS A formal Partnering Session will be held with the selected contractor, PFA team members and Belford-Watkins Architects as soon as the selection process is completed. During the design phase(s), the contractor will be part of the design team with PFA and Belford- Watkins Architects, participating in the final design effort by assisting in the following areas:  Review of designs for constructability  Estimating costs of different alternatives and components  Providing opinions and recommendations on suitable methods and approaches to accomplishing the work  Offer value engineering suggestions to accomplish the desired objectives in the most cost-effective manner possible.  Provide on-going cost status of the project to the design team as the project proceeds. The contractor is required to commit key staff members to assist the project team by attending regularly scheduled project meetings and preparing information or responses to issues in advance of meetings. Normally, attendance will be required by the contractor’s project manager and superintendent. In the event key technical functions are subcontracted, the subcontractor shall assist the general contractor firm in fulfilling its responsibilities under the agreement during the design phase(s), including participation in design discussions. The PFA staff works very closely with the Architect/Engineer (Belford-Watkins Architects) and the contractor on a day to day basis as part of a tem during design and construction of projects. Traditional adversarial roles are not an acceptable way of doing business. You are encouraged to call or visit to discuss further or to ask any questions that you have about the process. The Poudre Fire Authority utilizes the services of a general contractor on an as needed basis. The type and complexity of the work varies, dependent upon the specific needs of he PFA at any given time. Several projects including a facilities warehouse structure, additional fire stations, significant remodels and additions to existing fire stations, and the replacement of the burn building are all possible during the terms of any agreement. Currently some of these projects have approval.  Prototype Fire Stations (Stations 12 & 14) -- ~10,500 sq foot fire stations with living quarters, apparatus bays, community rooms, offices and support areas, typically located 1 to 1.5 acre sites. 2 of these facilities completed in last 6 years. STD WO SA WO rev06/07 14  Training Center Facilities -- 20,000 sq. ft. storage, warehouse and office facility for training staff.  Live Fire Training building – Significant repairs to this structure to extend its useful life.  Flag Poles – The installation of Flag Poles at several facilities. The list of projects is not exhaustive of the projects completed under the current agreement and is no guarantee of similar projects in the future. Most of these projects were completed using a team approach with the Authorities design firm, however some projects were strictly design build by the contractor and others a combination of design build and design team approaches. The selected contractor may be retained for multiple phases of the work over the next five (5) years. The City of Fort Collins may utilize the selected contract for similar projects required in the next five (5) years, but not specifically listed.