HomeMy WebLinkAbout357129 NARANJO CIVIL CONSTRUCTORS INC - CONTRACT - BID - 22955 5908 PLEASANT VALLEY LKE AND CANAL TRAILI
I
0
I
1
[1
1
0
I
i
i
i
1.0
2.0
3.0
SECTION 00100
INSTRUCTIONS TO BIDDERS
DEFINED TERMS
Terms used in these Instructions to Bidder Standard General s which are defined in the
Conditions of the Construction Contract (No. 1910-8, 1990
ed.) have the meanings assigned to them in the General Conditions. The
term "Bidder" means one who submits a Bid to OWNER, as distinct from a sub -
bidder, who submits a Bid to Bidder. The terms the lowest, qualified, responsible "Successful Bidder" means
and responsive Bidder to whom OWNER (on
basis of OWNER's evaluation as hereinafter provided) makes an award. The
term "Bidding Documents" includes the Advertisement or Invitation to Bid,
Instructions to Bidders, the Bid Form, and the proposed Contract Documents
(including all Addenda issued prior to receipt of Bids).
COPIES OF BIDDING DOCUMENTS
2.1• Complete sets of Bidding Documents may be obtained as stated in the
Invitation to Bid. No partial sets will be issued. The Bidding Documents
may be examined at the locations identified in the Invitation to Bid.
2.2. Complete sets of Bidding Documents shall be used in preparing Bids;
neither OWNER nor Engineer assumes any responsibility for errors or
misinterpretations resulting from the use of incomplete sets of Bidding
Documents,
2.3• The submitted Bid proposal shall include Sections 00300, 00410,
00420, and 00430 fully executed.
2.4. OWNER and Engineer, in making
on the above terms, do so only for
Work and do not confer a license or
QUALIFICATION OF BIDDERS
copies of Bidding Documents available
the purpose of obtaining Bids on the
grant for any other use.
3.1 To demonstrate qualifications to perform the Work, each Bidder must
submit at the time of the Bid opening, a written statement of
qualifications including financial data, a summary of previous experience,
previous commitments and evidence of authority to conduct business in the
jurisdiction where the Project is located. Each Bid must contain evidence
Of Bidder's qualification to do business in the state where the Project is
located or covenant to obtain such qualification prior to award of the
contract. The Statement of Qualifications shall be prepared on the form
provided in Section 00420.
3.2. In accordance with Section 8-160
Collins in determining whether a bidder
be considered: (1) The ability, capacity
12/03
Of the Code of the City of Fort
is responsible, the following shall
and skill of the bidder to perform
Section 00100 Page 1
1375 Sherman Street
Denver, Colorado, 80261
Sales and Use Taxes for the State of Colorado.
Regional Transportation District (RTD) and certain
Colorado counties are collected by the State of
Colorado and are included in the Certification of
Exemption.
All applicable Sales and Use Taxes (including State
collected taxes), on any items other than construction
and building materials physically incorporated into the
project are to be paid by CONTRACTOR and are to
be included in appropriate bid items.
Use of Premises:
6.16. CONTRACTOR shall confine construction
equipment, the storage of materials and equipment and the
operations of workers to the site and land and areas
identified in and permitted by the Contract Documents and
other land and areas permitted by Laws and Regulations,
rights -of -way, permits and easements, and shall not
unreasonably encumber the premises with construction
equipment or other materials or equipment.
CONTRACTOR shall assume full responsibility for any
damage to any such land or area, or to the owner or
occupant thereof or of any adjacent land or areas, resulting
fi-om the performance of the Work. Should any claim be
made by any such owner or occupant because of the
performance of the Work, CONTRACTOR shall promptly
settle with such other patty by negotiation or otherwise
resolve the claim by arbitration or other dispute resolution
proceeding or at law. CONTRACTOR shall, to the fullest
extent permitted by Laws and Regulations, indemnify and
hold harmless OWNER, ENGINEER, ENGINEER's
Consultant and anyone directly or indirectly employed by
any of them from and against all claims, costs, losses and
damages arising out of or resulting from any claim or
action, legal or equitable, brought by any such owner or
occupant against OWNER, ENGINEER or any other party
indemnified hereunder to the extent caused by or based
upon CONTRACTOR's performance of the Work.
6.17. During the progress of the Work, CONTRACTOR
shall keep the premises free from accumulations of waste
materials, rubbish and other debris resulting from the
Work. At the completion of the Work CONTRACTOR
shall remove all waste materials, rubbish and debris fi-om
and about the premises as well as all tools, appliances,
construction equipment and machinery and surplus
materials. CONTRACTOR shall leave the site clean and
ready for occupancy by OWNER at Substantial
Completion of the Work. CONTRACTOR shall restore to
original condition all property not designated for alteration
by the Contract Documents.
6.18. CONTRACTOR shall not load nor permit any part
of any structure to be loaded in any manner that will
endanger the structure, nor shall CONTRACTOR subject
any part of the Work or adjacent property to stresses or
pressures that will endanger it.
Record Documents:
E.ICDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
6.19. CONTRACTOR shall maintain in a safe place at
the site one record copy of all Drawings, Specifications,
Addenda, Written Amendments, Change Orders, Work
Change Directives, Field Orders and written
interpretations and clarifications (issued pursuant to
paragraph 9.4) in good order and annotated to show al I
changes made during construction. These record
documents together with all approved Samples and a
counterpart of all approved Shop Drawings will be
available to ENGINEER for reference. Upon completion
of the Work, and prior to release of final payment, these
record documents, Samples and Shop Drawings will be
delivered to ENGINEER for OWNER.
Safety and Protection:
6.20. CONTRACTOR shall be responsible for
initiating, maintaining and supervising all safety
precautions and programs in connection with the Work.
CONTRACTOR shall take all necessary precautions for
the safety of, and shall provide the necessary protection to
prevent damage, injury or loss to:
6.20.1. all persons on the Work site or who may be
affected by the Work;
6.20.2. all the Work and materials and equipment to
be incorporated therein, whether in storage on or off
the site; and
6.20.3. other property at the site or adjacent thereto,
including trees, shrubs, lawns, walks, pavements,
roadways, structures, utilities and Underground
Facilities not designated for removal, relocation or
replacement in the course of construction.
CONTRACTOR shall comply with all applicable Laws
and Regulations of any public body having jurisdiction for
safety of persons or property or to protect them from
damage, injury or loss; and shall erect and maintain all
necessary safeguards for such safety and protection.
CONTRACTOR shall notify owners of adjacent property
and of Underground Facilities and utility owners when
prosecution of the Work may affect them, and shall
cooperate with them in the protection, removal, relocation
and replacement of their property. All damage, injury or
loss to any property referred to in paragraphs 6.20.2 or
6.20.3 caused, directly or indirectly, in whole or in part, by
CONTRACTOR, any Subcontractor, Supplier or any
other person or organization directly or indirectly
employed by any of them to perform or furnish any of the
Work or anyone for whose acts any of them may be liable,
shall be remedied by CONTRACTOR (except damage or
loss attributable to the fault of Drawings or Specifications
or to the acts or omissions of OWNER or ENGINEER or
ENGINEER's Consultant or anyone employed by any of
them or anyone for whose acts any of them may be liable,
and not attributable, directly or indirectly, in whole or in
part, to the fault or negligence of CONTRACTOR or any
Subcontractor, Supplier or other person or organization
directly or indirectly employed by any of them).
CONTRACTOR's duties and responsibilities for the safety
and protection of the Work shall continue until such time
as all the Work is completed and ENGINEER has issued a
15
notice to OWNER and CONTRACTOR in accordance
with paragraph 14.13 that the Work is acceptable (except as
otherwise expressly provided in connection with
Substantial Completion).
6.21, Safety Representative:
CONTRACTOR shall designate a qualified and
experienced safety representative at the site whose duties
and responsibilities shall be the prevention of accidents and
the maintaining and supervising of safety precautions and
programs.
Hazard Communication Programs:
6.22. CONTRACTOR shall be responsible for
coordinating any exchange of material safety data sheets or
other hazard communication information required to be
made available to or exchanged between or among
employers at the site in accordance with Laws or
Regulations.
Emergencies:
6.23. In emergencies affecting the safety or protection of
persons or the Work or property at the site or adjacent
thereto, CONTRACTOR, without special instruction or
authorization from OWNER or ENGINEER, is obligated to
act to prevent threatened damage, injury or loss.
CONTRACTOR shall give ENGINEER prompt written
notice if CONTRACTOR believes that any significant
changes in the Work or variations from the Contract
Documents have been caused thereby. If ENGINEER
determines that a change in the Contract Documents is
required because of the action taken by CONTRACTOR in
response to such an emergency, a Work Change Directive
or Change Order will be issued to document the
consequences of such action.
6.24. Shop Drawings and Samples:
6.24.1. CONTRACTOR shall submit Shop Drawings
to ENGINEER for review and approval in accordance
with the accepted schedule of Shop Drawings and
Sample submittals (see paragraph 2.9). All submittals
will be identified as ENGINEER may require and in
the number of copies specified in the General
Requirements. The data shown on the Shop Drawings
will be complete with respect to quantities,
dimensions, specified performance and design criteria,
materials and similar data to show ENGINEER the
materials and equipment CONTRACTOR proposes to
provide and to enable ENGINEER to review the
information for the limited purposes required by
paragraph 6.26.
6.24.2. CONTRACTOR shall also submit Samples to
ENGINEER for review and approval in accordance
with said accepted schedule of Shop Drawings and
Sample submittals. Each Sample will be identified
clearly as to material, Supplier, pertinent data such as
catalog numbers and the use for which intended and
otherwise as ENGINEER may require to enable
ENGINEER to review the submittal for the limited
EICDC GENERAL CONDITIONS 1910-8 (1990 Edition)
16 w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
purposes required by paragraph 6.26. The numbers
of each Sample to be submitted will be as specified in
the Specifications.
6.25. Submittal Procedures:
6.25.1. Before submitting each Shop Drawing or
Sample, CONTRACTOR shall have determined and
verified:
6.25.1.1. all field measurements, quantities,
dimensions, specified performance criteria,
installation requirements, materials, catalog
numbers and similar information with respect
thereto,
6.25.1.2. all materials with respect to intended
use, fabrication, shipping, handling, storage,
assembly and installation pertaining to the
performance of the Work, and
6,25.1.3. all information relative to
CONTRACTOR's sole responsibilities in respect
of means, methods, techniques, sequences and
procedures of construction and safety precautions
and programs incident thereto.
CONTRACTOR shall also have reviewed and
coordinated each Shop Drawing or Sample with other
Shop Drawings and Samples and with the
requirements of the Work and the Contract
Documents.
6.25.2. Each submittal will bear a stamp or specific
written indication that CONTRACTOR has satisfied
CONTRACTOR's obligations under the Contract
Documents with respect to CONTRACTOR's review
and approval of that submittal.
6.25.3. At the time of each submission,
CONTRACTOR shall give ENGINEER specific
written notice of such variations, if any, that the Shop
Drawing or Sample submitted may have from the
requirements of the Contract Documents, such notice
to be in a written communication separate from the
submittal; and, in addition, shall cause a specific
notation to be made on each Shop Drawing and
Sample submitted to ENGINEER for review and
approval of each such variation.
6.26. ENGINEER will review and approve Shop
Drawings and Samples in accordance with the schedule of
Shop Drawings and Sample submittals accepted by
ENGINEER as required by paragraph 2.9. ENGINEER's
review and approval will be only to determine if the items
covered by the submittals will, after- installation or
incorporation in the Work, conform to the information
given in the Contract Documents and be compatible with
the design concept of the completed Project as a
functioning whole as indicated by the Contact
Documents. ENGINEER's review and approval will not
extend to means, methods, techniques, sequences or
procedures of construction (except where a particular
means, method, technique, sequence or procedure of
construction is specifically and expressly called for by the
Contract Documents) or to safety precautions or programs
incident thereto. The review and approval of a separate
item as such will not indicate approval of the assembly in
which the item functions. CONTRACTOR shall make
corrections required by ENGINEER, and shall return the
required number of corrected copies of Shop Drawings and
submit as required new Samples for review and approval.
CONTRACTOR shall direct specific attention in writing to
revisions other than the corrections called for by
ENGINEER on previous submittals.
6.27. ENGINEER's review and approval of Shop
Drawings or Samples shall not relieve CONTRACTOR
fi-om responsibility for any variation from the requirements
of the Contract Documents unless CONTRACTOR has in
writing called ENGINEER's attention to each such
variation at the time of submission as required by
paragraph 6.25.3 and ENGINEER has given written
approval of each such variation by a specific written
notation thereof incorporated in or accompanying the Shop
Drawing or Sample approval; not- will any approval by
ENGINEER relieve CONTRACTOR from responsibility
for complying with the requirements of paragraph 6.25.1.
6.28. Where a Shop Drawing or Sample is required by
the Contract Documents or the schedule of Shop Drawing
and Sample submissions accepted by ENGINEER as
required by paragraph 2.9, any related Work performed
pilot- to ENGINEER's review and approval of the pertinent
submittal will be at the sole expense and responsibility of
CONTRACTOR.
Continuing the Work:
6.29. CONTRACTOR shall carry on the Work and
adhere to the progress schedule during all disputes or
disagreements with OWNER. No Work shall be delayed or
postponed pending . resolution of any disputes or
disagreements, except as permitted by paragraph 15.5 or as
OWNER and CONTRACTOR may otherwise agree in
writing.
6.30. CONTRACTOR's General Warranty and
Guarantee:
6.30.1. CONTRACTOR wan -ants and guarantees to
OWNER, ENGINEER and ENGINEER's Consultants
that all Work will be in accordance with the Contract
Documents and will not be defective.
CONTRACTOR's warranty and guarantee hereunder
excludes defects or damage caused by:
6.30.1.1. abuse, modification or improper
maintenance or operation by persons other than
CONTRACTOR, Subcontractors or Suppliers; or
6.30.1.2. normal wear and tear under normal
usage.
6.30.2. CONTRACTOR's obligation to perform and
complete the Work in accordance with the Contract
Documents shall be absolute. None of the following
will constitute an acceptance of Work that is not in
E.ICDC GENERAL CON DITIONS 1910-8 (1990 Edition)
w/CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
accordance with the Contract Documents or a release
of CONTRACTOR's obligation to perform the Work
in accordance with the Contract Documents:
6.30.2.1. observations by ENGINEER;
6.30.2.2. recommendation of any progress or
final payment by ENGINEER;
6.30.2.3. the issuance of a certificate of
Substantial Completion or any payment by
OWNER to CONTRACTOR under the Contract
Documents;
6.30.2.4. use or occupancy of the Work or any
part thereof by OWNER;
6.30.2.5. any acceptance by OWNER or any
failure to do so;
6,30.2.6. any review and approval of a Shop
Drawing or Sample submittal or the issuance of a
notice of acceptability by ENGINEER pursuant
to paragraph 14.13;
6.30.2.7. any inspection, test or approval by
others; or
6.30.2.8. any correction of defective Work by
OWNER.
Indemnification:
6.31. To the fullest extent permitted by Laws and
Regulations, CONTRACTOR shall indemnify and hold
harmless OWNER, ENGINEER, ENGINEER's
Consultants and the officers, directors, employees, agents
and other consultants of each and any of them from and
against all claims, costs, losses and damages (including,
but not limited to, all fees and charges of engineers,
architects, attorneys and other professionals and all court
or arbitration or other dispute resolution costs) caused by,
arising out of or resulting from the performance of the
Work, provided that any such claim, cost, loss or damage:
(i) is attributable to bodily injury, sickness, disease or
death, or to injury to or destruction of tangible property
(other than the Work itself), including the loss of use
resulting therefrom, and (ii) is caused in whole or in part
by any negligent act or omission of CONTRACTOR, any
Subcontractor, any Supplier, any person or organization
directly or indirectly employed by any of them to perform
or furnish any of the Work or anyone for whose acts any
of them may be liable, regardless of whether or not caused
in part by any negligence or omission of a person or entity
indemnified hereunder or whether liability is imposed
upon such indemnified party by Laws and Regulations
regardless of the negligence of any such person or entity.
6.32. In any and all claims against OWNER or
ENGINEER or any of their respective consultants, agents,
officers, directors or employees by any employee (or the
survivor or personal representative of such employee) of
CONTRACTOR, any Subcontractor, any Supplier, any
person or organization directly or indirectly employed by
17
any of them to perform or furnish any of the Work or
anyone for whose acts any of them may be liable, the
indemnification obligation under paragraph 6.31 shall not
be limited in any way by any limitation on the amount or
type of damages, compensation or benefits payable by or
for CONTRACTOR or any such Subcontractor, Supplier or
other person or organization under workers' compensation
acts, disability benefit acts or other employee benefit acts.
6.33. The indemnification obligations of
CONTRACTOR under paragraph 6.31 shall not extend to
the liability of ENGINEER and ENGINEER's Consultants,
officers, directors, employees or agents caused by the
professional negligence, errors or omissions of any of them.
Survival of Obligations:
6.34. All representations, indemnifications, warranties
and guarantees made in, required by or given in accordance
with the Contract Documents, as well as all continuing
obligations indicated in the Contract Documents, will
survive final payment, completion and acceptance of the
Work and termination or completion of the Agreement.
ARTICLE 7--OTHER WORK
Related Work at Site:
7.1. OWNER may perform other work related to the
Project at the site by OWNER's own forces, or let other
direct contracts therefor which shall contain General
Conditions similar to these, or have other work performed
by utility owners. If the fact that such other work is to be
performed was not noted in the Contract Documents, then:
(i) written notice thereof will be given to CONTRACTOR
prior to starting any such other work and
(ii) CONTRACTOR may make a claim therefor as
provided in Articles l l and 12 if CONTRACTOR believes
that such performance will involve additional expense to
CONTRACTOR or requires additional time and the parties
are unable to agree as to the amount or extent thereof.
7.2. CONTRACTOR shall afford each other contractor
who is a party to such a direct contract and each utility
owner (and OWNER, if OWNER is performing the
additional work with OWNER's employees) proper and
safe access to the site and a reasonable opportunity for the
introduction and storage of materials and equipment and
the execution of such other work and shall properly connect
and coordinate the Work with theirs. Unless otherwise
provided in the Contract Documents, CONTRACTOR
shall do all cutting, fitting and patching of the Work that
may be required to make its several parts come together
properly and integrate with such other work.
CONTRACTOR shall not endanger any work of others by
cutting, excavating or otherwise altering their work and
will only cut or alter their work with the written consent of
ENGINEER and the others whose work will be affected.
The duties and responsibilities of CONTRACTOR under
this paragraph are for the benefit of such utility owners and
other contractors to the extent that there are comparable
EICDC GENERAL CONDITIONS 1910-8 (1990 Edition) 18
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
provisions for the benefit of CONTRACTOR in said
direct contracts between OWNER and such utility owners
and other contractors.
7.3. If the proper execution or results of any part of
CONTRACTOR's Work depends upon work performed
by others under this Article 7, CONTRACTOR shall
inspect such other work and promptly report to
ENGINEER in writing any delays, defects or deficiencies
in such other work that render it unavailable or unsuitable
for the proper execution and results of CONTRACTOR's
Work. CONTRACTOR's failure so to report will
constitute an acceptance of such other work as fit and
proper for integration with CONTRACTOR's Work
except for latent or nonapparent defects and deficiencies
in such other work.
Coordination:
7.4. If OWNER contracts with others for the
performance of other work on the Project at the site, the
following will be set forth in Supplementary Conditions:
7.4.1. the person, firm or corporation who will have
authority and responsibility for coordination of the
activities among the various prime contractors will be
identified;
7.4.2. the specific matters to be covered by such
authority and responsibility will be itemized; and
7.4.3. the extent of such authority and
responsibilities will be provided.
Unless otherwise provided in the Supplementary
Conditions, OWNER shall have sole authority and
responsibility in respect of such coordination.
ARTICLE 8—OWNER'S RESPONSIBILITIES
8.1. Except as otherwise provided in these General
Conditions, OWNER shall issue all communications to
CONTRACTOR through ENGINEER.
8.2. In case of termination of the employment of
ENGINEER, OWNER shall appoint an engineer against
whose status under the Contract Documents shall be that
of the former ENGINEER.
8.3. OWNER shall furnish the data required of
OWNER under the Contract Documents promptly and
shall make payments to CONTRACTOR promptly when
they are due as provided in paragraphs 14.4 and 14.13.
8.4. OWNER's duties in respect of providing lands
and easements and providing engineering surveys to
establish reference points are set forth in paragraphs 4.1
and 4.4. Paragraph4.2 refers to OWNER's identifying
and making available to CONTRACTOR copies of
reports of explorations and tests of subsurface conditions
at the site and drawings of physical conditions in existing
ry
r
structures at or contiguous to the site that have been utilized
by ENGINEER in preparing the Contract Documents.
83. OVrrE s_ :waitiesi Fespeet
and maintaining liability atid IiFepeFty insufanee are set
8.6. OWNER is obligated to execute Change Orders as
indicated in paragraph 10.4.
8.7. OWNER's responsibility in respect of certain
inspections, tests and approvals is set forth in
paragraph 13.4.
8.8. In connection with OWNER's right to stop Work or
suspend Work, see paragraphs 13.10 and 15.1.
Paragraph 15.2 deals with OWNEWs right to terminate
services of CONTRACTOR under certain circumstances.
8.9. The OWNER shall not supervise, direct or have
control or authority over, nor be responsible for,
CONTRACTOR's means, methods, techniques, sequences
or procedures of construction or the safety precautions and
programs incident thereto, or for any failure of
CONTRACTOR to comply with Laws and Regulations
applicable to the furnishing or performance of the Work.
OWNER will not be responsible for CONTRACTOR's
failure to perform or furnish the Work in accordance with
the Contract Documents.
.s 1_.
me—MMIZE".
WIN
140111 PUMP"
._ ..�_.
ARTICLE 9--ENGINEER'S STATUS DURING
CONSTRUCTION
OIYNER's Representative:
9.1. ENGINEER will be OWNER's representative
during the construction period. The duties and
responsibilities and the limitations of authority of
ENGINEER as OWNER's representative during
construction are set forth in the Contract Documents and
shall not be extended without written consent of OWNER
and ENGINEER.
Visits to Site:
9.2. ENGINEER will make visits to the site at intervals
appropriate to the various stages of construction as
ENGINEER deems necessary in order to observe as an
experienced and qualified design professional the progress
E.ICDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
that has been made and the quality of the various aspects
of CONTRACTOR's executed Work. Based on
information obtained during such visits and observations,
ENGINEER will endeavor for the benefit of OWNER to
determine, in general, if the Work is proceeding in
accordance with the Contract Documents. ENGINEER
will not be required to make exhaustive or continuous on -
site inspections to check the quality or quantity of the
Work. ENGINEER's efforts will be directed toward
providing for OWNER a greater degree of confidence that
the completed Work will conform generally to the
Contract Documents. On the basis of such visits and on -
site observations, ENGINEER will keep OWNER
informed of the progress of the Work and will endeavor to
guard OWNER against defective Work. ENGINEER's
visits and on -site observations are subject to all the
limitations on ENGINEERS authority and responsibility
set forth in paragraph 9.13, and particularly, but without
limitation, during or as a result of ENGINEER's on -site
visits or observations of CONTRACTOR's Work
ENGINEER will not supervise, direct, control or have
authority over or be responsible for CONTRACTOR's
means, methods, techniques, sequences or procedures of
construction, or the safety precautions and programs
incident thereto, or for any failure of CONTRACTOR to
comply with Laws and Regulations applicable to the
furnishing or performance of the Work.
Project Representative:
9.3. If OWNER and ENGINEER agree, ENGINEER
will furnish a Resident Project Representative to assist
ENGINEER in providing more continuous observation of
the Work. The responsibilities and authority and
limitations thereon of any such Resident Project
Representative and assistants will be as provided in
paragraphs 9.3 and 9.13 and :n the Stipp lementai-
EetrditieHs of these General Conditions. If OWNER
designates another representative or agent to represent
OWNER at the site who is not ENGINEER's Consultant,
agent or employee, the responsibilities and authority and
limitations thereon of such other person will be as
provided in the a ._.some... _, Ganditian paragraph 9.3
9.3.1. The Representative's dealings in matters
pertaining to the on -site work will, in general, be with
the ENGINEER and CONTRACTOR. But, the
Representative will keep the OWNER properly
advised about such matters. The Representative's
dealings with subcontractors will only be through or
with the full knowledge and approval of the
CONTRACTOR.
9.3.2. Duties and Responsibilities. Representative
will:
9.3.2. 1. Schedules - Review the progress
19
schedule and other schedules prepared by the
CONTRACTOR and consult with the
ENGINEER concerning acceptability.
9.3.2.2, Conferences and Meeting - Attend
meeting with the CONTRACTOR such as
preconstruction conferences, progress meetings
and other job conferences and prepare and
circulate copies of minutes of meetings.
9.3.2.3. Liaison
9.3.2.3.1. Serve as ENGINEER'S liaison
with CONTRACTOR, working principally
through CONTRACTOR'S superintendent to
assist the CONTRACTOR in understanding
the Contract Documents.
9.3.2.3.2. Assist in obtaining fi-om OWNER
additional details or information, when
required, for proper execution of the Work.
9.3.2.3.3. Advise the ENGINEER and
CONTRACTOR of the commencement of
any Work requiring a Shop Drawing or
sample submission if the submission has not
been approved by the ENGINEER.
9 3 2 4 Review of Work, Reiection of Defective
Work, Inspections and Tests -
9.3.2.4.1. Conduct on -site observations of
the Work in progress to assist the ENGINEER
in determining that the Work is proceeding in
accordance with the Contract Documents.
9 3 2 4.3 Accompany visiting inspectors
representing public or other agencies having
jurisdiction over the Proiect record the results
of these inspections and report to the
ENGINEER.
9 3.2 5 Interpretation of Contract
Documents Report to ENGINEER when
clarifications and interpretations of the Contract
Documents are needed and transmit to
CONTRACTOR clarification and interpretation
of the Contract Documents as issued by the
ENGINEER
9.3.2.6. Modifications. Consider and
evaluate CONTRACTOR'S suggestions for
EJCDC GENERAL CONDITIONS 1910-8 (1990 Edition)
20 w/CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
modification in Drawings or Specifications and
report these recommendations to ENGINEER.
Accurately transmit to CONTRACTOR
decisions issued by the ENGINEER.
9.3.2.7. Records.
9.3.2.7.1. Maintain at the Representative's
office orderly files conceming
correspondence, reports of job conferences,
Shop Drawings and samples reproductions
9.3.2.7.3. Record names,
addresses and telephone numbers of all
CONTRACTORS, subcontractors and
major suppliers of equipment and materials
9.3.2.8. Reports.
9.3.2 8 1 Furnish ENGINEER periodic
reports as required, of the progress of the
Work and of the CONTRACTOR'S
compliance with the progress schedule and
schedule of shop Drawing and sample
submittals.
9.3.2.8.2. Consult with ENGINEER in 4
advance of scheduling major tests,
inspections or start of important phases of the
Work.
9 3.2.8 3 Draft proposed Change Orders
and Work Directive Changes, obtaining
backup material fiom the CONTRACTOR
and recommend to ENGINEER Change
Orders Work Directive Changes and field
orders.
9 3 2 8 4 Report immediately to
ENGINEER and OWNER the occurrence of
any accident.
9 3 2 9 Payment Requests Review applications
for payment with CONTRACTOR for compliance ^
with the established procedure for their
submission and forward with recommendation to
ENGINEER, noting particularly the relationsNp of
the payment requested to the schedule of values,
work completed and materials and equipment
delivered at the site but not incorporated in the
Work.
9.3.2.10. Completion.
9.3.2.10.1. Before ENGINEER issues a
Certificate of Substantial Completion, submit
to CONTRACTOR a list of observed items
requiring correction or completion.
9.3.2.10.2. Conduct final inspection in the
company of the ENGINEER, OWNER and
CONTRACTOR and prepare a final list of
items to be corrected or completed.
9.3.2.10.3. Observe that all items on the
final list have been corrected or completed and
make recommendations to ENGINEER
concerning acceptance.
9.3.3. Limitation of Authority: The Representative shall
not:
9.3.3.1. Authorize any deviations fi-om the
Contract Documents or accept any substitute
materials or equipment, unless authorized by the
ENGINEER.
9.3.3.2. Exceed limitations of ENGINEER'S
authority as set forth in the Contract Documents.
9.3.3.3, Undertake any of the responsibilities
of the CONTRACTOR, Subcontractors, or
CONTRACTOR'S superintendent.
9.3.3.4. Advise on, or issue directions relative
to, or assume control over any aspect of the
means, methods, techniques, sequences or -
procedures for construction unless such is
specificalty called for in the Contract Documents.
9.3.3.5. Advise on or issue directions
regarding or assume control over safety
precautions and programs in connections with the
Work.
9.3.3.6. Accept Shop Drawings or sample
submittals from anyone other than the
CONTRACTOR.
9.3.3.7. Authorize OWNER to occupy the
Work in whole or in part.
9.3.3.8. Participate in specialized field or
laboratory tests or inspections conducted by others
except as specifically authorized by the
ENGINEER.
Clarifications and Interpretations:
9.4. ENGINEER will issue with reasonable promptness
such written clarifications or interpretations of the
E.ICDCGENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
requirements of the Contract Documents (in the form of
Drawings or otherwise) as ENGINEER may determine
necessary, which shall be consistent with the intent of and
reasonably inferable fi-om the Contract Documents. Such
written clarifications and interpretations will be binding on
OWNER and CONTRACTOR. If OWNER or
CONTRACTOR believes that a written clarification or
interpretation justifies an adjustment in the Contract Price
or the Contract Times and the parties are unable to agree
to the amount or extent thereof, if any, OWNER or
CONTRACTOR may make a written claim therefor as
provided in Article 11 or Article 12.
Authorized Variations in Work:
9.5. ENGINEER may authorize minor variations in
the Work from the requirements of the Contract
Documents which do not involve an adjustment in the
Contract Price or the Contract Times and are compatible
with the design concept of the completed Project as a
functioning whole as indicated by the Contract
Documents. These may be accomplished by a Field Order
and will be binding on OWNER and also on
CONTRACTOR who shall perform the Work involved
promptly. If OWNER or CONTRACTOR believes that a
Field Order justifies an adjustment in the Contract Price or
the Contract Times and the parties are unable to agree as
to the amount or extent thereof, OWNER or
CONTRACTOR may make a written claim therefor as
provided in Article 11 or 12.
Rejecting Defective Work:
9.6. ENGINEER will have authority to disapprove or
reject Work which ENGINEER believes to be defective,
or that ENGINEER believes will not produce a completed
Project that conforms to the Contract Documents or that
will prejudice the integrity of the design concept of the
completed Project as a functioning whole as indicated by
the Contract Documents. ENGINEER will also have
authority to require special inspection or testing of the
Work as provided in paragraph 13.9, whether or not the
Work is fabricated, installed or completed.
Shop Drawings, Change Orders and Payments:
9.7. In connection with ENGINEERSs authority as to
Shop Drawings and Samples, see paragraphs 6.24 through
6.28 inclusive.
9.8. In connection with ENGINEERS authority as to
Change Orders, see Articles 10, 11, and 12.
9.9. In connection with ENGINEERSs authority as to
Applications for Payment, see Article 14.
Deterntinations,for Unit Prices:
9.10. ENGINEER will determine the actual quantities
and classifications of Unit Price Work performed by
CONTRACTOR. ENGINEER will review with
CONTRACTOR the ENGINEERS preliminary
determinations on such matters before rendering a written
decision thereon (by recommendation of an Application
21
for Payment or otherwise). ENGINEER's written decision
thereon will be final and binding upon OWNER and
CONTRACTOR, unless, within ten days after the date of
any such decision, either OWNER or CONTRACTOR
delivers to the other and to ENGINEER written notice of
intention to appeal from ENGINEER's decision and: (i) an
appeal from ENGINEER's decision is taken within the time
limits and in accordance with the procedures set forth in
Exhibit GC -A, "Dispute Resolution Agreement", entered
into between OWNER and CONTRACTOR pursuant to
Article 16, or (ii) if no such Dispute Resolution Agreement
has been entered into, a formal proceeding is instituted by
the appealing party in a forum of competent jurisdiction to
exercise such rights or remedies as the appealing party may
have with respect to ENGINEER's decision, unless
otherwise agreed in writing by OWNER and
CONTRACTOR. Such appeal will not be subject to the
procedures of paragraph 9.11.
Decisions on Disputes:
9.11. ENGINEER will be the initial interpreter of the
requirements of the Contract Documents and judge of the
acceptability of the Work thereunder. Claims, disputes and
other matters relating to the acceptability of the Work or
the interpretation of the requirements of the Contract
Documents pertaining to the performance and furnishing of
the Work and claims under Articles I 1 and 12 in respect of
changes in the Contract Price or Contract Times will be
referred initially to ENGINEER in writing with a request
for a formal decision in accordance with this paragraph.
Written notice of each such claim, dispute or other matter
will be delivered by the claimant to ENGINEER and the
other patty to the Agreement promptly (but in no event
later than thirty days) after the start of the occurrence or
event giving rise thereto, and written supporting data will
be submitted to ENGINEER and the other party within
sixty days after the start of such occurrence or event unless
ENGINEER allows an additional period of time for the
submission of additional or more accurate data in support
of such claim, dispute or other matter. The opposing party
shall submit any response to ENGINEER and the claimant
within thirty days after receipt of the claimant's last
submittal (unless ENGINEER allows additional time).
ENGINEER will render a formal decision in writing within
thirty days after receipt of the opposing party's submittal, if
any, in accordance with this paragraph. ENGINEER's
written decision on such claim, dispute or other matter will
be final and binding upon OWNER and CONTRACTOR
unless: (i) an appeal from ENGINEER's decision is taken
within the time limits and in accordance with the
procedures set forth in EXHIBIT GC -A, "Dispute
Resolution Agreement", entered into between OWNER and
CONTRACTOR pursuant to Article 16, or (ii) if no such
Dispute Resolution Agreement has been entered into, a
written notice of intention to appeal from ENGINEER's
written decision is delivered by OWNER or
CONTRACTOR to the other and to ENGINEER within
thirty days after the date of such decision and a formal
proceeding is instituted by the appealing party in a forum of
competent jurisdiction to exercise such rights or remedies
as the appealing party may have with respect to such claim,
dispute or other matter in accordance with applicable Laws
and Regulations within sixty days of the date of such
EICDC GENERAL CONDITIONS 1910-8 (1990 Edition)
22 w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
decision, unless otherwise agreed in writing by OWNER
and CONTRACTOR.
9.12. When functioning as interpreter and judge under
paragraphs 9.10 and 9.11, ENGINEER will not show
partiality to OWNER or CONTRACTOR and will not be
liable in connection with any interpretation or decision
rendered in good faith in such capacity. The rendering of
a decision by ENGINEER pursuant to paragraphs 9.10 or
9.11 with respect to any such claim, dispute or other
matter (except any which have been waived by the making
or acceptance of final payment as provided in
paragraph 14.15) will be a condition precedent to any
exercise by OWNER or CONTRACTOR of such rights or
remedies as either may otherwise have under the Contract
Documents or by Laws or Regulations in respect of any
such claim, dispute or other matter puFsuant t A ftielo t
9.13. Limitations on ENGINEER's Authority and
Responsibilities:
9.13.1. Neither ENGINEER's authority or
responsibility under this Article 9 or under any other
provision of the Contract Documents nor any decision
made by ENGINEER in good faith either to exercise
or not exercise such authority or responsibility or the
undertaking, exercise or performance of any authority
or responsibility by ENGINEER shall create, impose
or give rise to any duty owed by ENGINEER to
CONTRACTOR, any Subcontractor, any Supplier,
any other person or organization, or to any surety for
or employee or agent of any of them.
9,13.2. ENGINEER will not supervise, direct,
control or have authority over or be responsible for
CONTRACTOR's means, methods, techniques,
sequences or procedures of construction, or the safety
precautions and programs incident thereto, or for any
failure of CONTRACTOR to comply with Laws and
Regulations applicable to the furnishing or
performance of the Work. ENGINEER will not be
responsible for CONTRACTOR's failure to perform
or furnish the Work in accordance with the Contract
Documents.
9.13.3. ENGINEER will not be responsible for the
acts or omissions of CONTRACTOR or of any
Subcontractor, any Supplier, or of any other person or
organization performing or furnishing any of the
Work.
9.13.4. ENGINEER's review of the final Application
for Payment and accompanying documentation and
all maintenance and operating instructions, schedules,
guarantees, Bonds and certificates of inspection, tests
and approvals and other documentation required to be
delivered by paragraph 14.12 will only be to
determine generally that their content complies with
the requirements of, and in the case of certificates of
inspections, tests and approvals that the results
certified indicate compliance with, the Contract
Documents.
9.13.5. The limitations upon authority and
responsibility set forth in this paragraph 9.13 shall also
apply to ENGINEER's Consultants, Resident Project
Representative and assistants.
ARTICLE 10--CHANGES IN THE WORK
10.1. Without invalidating the Agreement and without
notice to any surety, OWNER may, at any time or from
time to time, order additions, deletions or revisions in the
Work. Such additions, deletions or revisions will be
authorized by a Written Amendment, a Change Order, or a
Work Change Directive. Upon receipt of any such
document, CONTRACTOR shall promptly proceed with
the Work involved which will be performed under the
applicable conditions of the Contract Documents (except as
otherwise specifically provided).
10.2. If OWNER and CONTRACTOR are unable to
agree as to the extent, if any, of an adjustment in the
Contract Price or an adjustment of the Contract Times that
should be allowed as a result of a Work Change Directive,
a claim may be made therefor as provided in Article 11 or
Article 12.
103. CONTRACTOR shall not be entitled to an increase
in the Contract Price or an extension of the Contract Times
with respect to any Work performed that is not required by
the Contract Documents as amended, modified and
supplemented as provided in paragraphs 3.5 and 3.6, except
in the case of an emergency as provided in paragraph 6.23
or in the case of uncovering Work as provided in
paragraph 13.9.
10.4. OWNER and CONTRACTOR shall execute
appropriate Change Orders recommended by ENGINEER
(or Written Amendments) covering:
10.4.1. changes in the Work which are (i) ordered
by OWNER pursuant to paragraph 10.1, (ii) required
because of acceptance of defective Work under
paragraph 13.13 or correcting defective Work under
paragraph 13.14, or (iii) agreed to by the parties;
10.4.2. changes in the Contract Price or Contract
Times which are agreed to by the parties; and
10.4.3. changes in the Contract Price or Contact
Times which embody the substance of any written
decision rendered by ENGINEER pursuant to
paragraph 9.11;
provided that, in lieu of executing any such Change Order,
an appeal may be taken from any such decision in
accordance with the provisions of the Contract Documents
and applicable Laws and Regulations, but during any such
appeal, CONTRACTOR shall carry on the Work and
adhere to the progress schedule as provided in
paragraph 6,29.
10.5. If notice of any change affecting the general scope
of the Work or the provisions of the Contract Documents
E.ICDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
(including, but not limited to, Contract Price or Contract
Times) is required by the provisions of any Bond to be
given to a surety, the giving of any such notice will be
CONTRACTOR's responsibility, and the amount of each
applicable Bond will be adjusted accordingly.
ARTICLE 11--CHANGE OF CONTRACT PRICE
11.1. The Contract Price constitutes the total
compensation (subject to authorized adjustments) payable
to CONTRACTOR for performing the Work. All duties,
responsibilities and obligations assigned to or undertaken
by CONTRACTOR shall be at CONTRACTOR's expense
without change in the Contract Price.
11.2. The Contract Price may only be changed by a
Change Order or by a Written Amendment. Any claim
for an adjustment in the Contract Price shall be based on
written notice delivered by the party making the claim to
the other party and to ENGINEER promptly (but in no
event later than thirty days) after the start of the
occurrence or event giving rise to the claim and stating the
general nature of the claim. Notice of the amount of the
claim with supporting data shall be delivered within sixty
days after the start of such occurrence or event (unless
ENGINEER allows additional time for claimant to submit
additional or more accurate data in support of the claim)
and shall be accompanied by claimant's written statement
that the adjustment claimed covers all known amounts to
which the claimant is entitled as a result of said
occurrence or event. All claims for adjustment in the
Contract Price shall be determined by ENGINEER in
accordance with paragraph 9.11 if OWNER and
CONTRACTOR cannot otherwise agree on the amount
involved. No claim for an adjustment in the Contract
Price will be valid if not submitted in accordance with this
paragraph 11.2.
11.3. The value of any Work covered by a Change
Order or of any claim for an adjustment in the Contract
Price will be determined as follows:
11.3.1. where the Work involved is covered by unit
prices contained in the Contract Documents, by
application of such unit prices to the quantities of the
items involved (subject to the provisions of
23
paragraphs 11.9.1 through 11.9.3,inclusive);
11.3.2. where the Work involved is not covered by
unit prices contained in the Contract Documents, by a
mutually agreed payment basis, including lump sum
(which may include an allowance for overhead and
profit not necessarily in accordance with
paragraph 11.6.2);
11.3.3. where the Work involved is not covered by unit
prices contained in the Contract Documents and
agreement to a lump sum is not reached under
paragraph 11.3.2, on the basis of the Cost of the Work
(determined as provided in paragraphs 11.4 and 11.5)
plus a CONTRACTOR's fee for overhead and profit
(determined as provided in paragraph 11.6).
Cost of the Work:
11.4. The term Cost of the Work means the sum of all
costs necessarily incurred and paid by CONTRACTOR in
the proper performance of the Work. Except as otherwise
may be agreed to in writing by OWNER, such costs shall
be in amounts no higher than those prevailing in the
locality of the Project, shall include only the following
items and shall not include any of the costs itemized in
paragraph 11.5:
11A.1.Payroll costs for employees in the direct
employ of CONTRACTOR in the performance of the
Work under schedules of job classifications agreed
upon by OWNER and CONTRACTOR. Such
employees shall include without limitation
superintendents, foremen and other personnel
employed full-time at the site. Payroll costs for
employees not employed full-time on the Work shall
be apportioned on the basis of their time spent on the
Work. Payroll costs shall inelude, butnetbe limited to-,
salaries and wages plus the cost of fringe benefits
which shall include social security contributions,
unemployment, excise and payroll taxes, workers'
compensation, health and •R„a etiremen benefits, bonuses,
siek vaeatian and holiday ^ u applicable thereto.
The expenses of performing Work after regular
working hours, on Saturday, Sunday or legal holidays,
shall be included in the above to the extent authorized
by OWNER.
11.4.2. Cost of all materials and equipment furnished
and incorporated in the Work, including costs of
transportation and storage thereof, and Suppliers' field
services required in connection therewith. All cash
discounts shall accrue to CONTRACTOR unless
OWNER deposits fiords with CONTRACTOR with
which to make payments, in which case the cash
discounts shall accrue to OWNER. All trade
discounts, rebates and refunds and returns from sale of
surplus materials and equipment shall accrue to
OWNER, and CONTRACTOR shall make provisions
so that they may be obtained.
11.4.3. Payments made by CONTRACTOR to the
Subcontractors for Work performed or furnished by
Subcontractors. If required by OWNER,
E.ICDC GENERAL CONDITIONS 1910-8 (1990 Edition)
24 w/CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
CONTRACTOR shall obtain competitive bids from
Subcontractors acceptable to OWNER and
CONTRACTOR and shall deliver such bids to
OWNER who will then determine, with the advice of
ENGINEER, which bids, if any, will be accepted. If
any subcontract provides that the Subcontractor is to
be paid on the basis of Cost of the Work plus a fee,
the Subcontractor's Cost of the Work and fee shall be
determined in the same manner as CONTRACTOR's
Cost of the Work and fee as provided in
paragraphs 11.4, 11.5, 11.6 and 11.7. All
subcontracts shall be subject to the other provisions of
the Contract Documents insofar- as applicable.
11.4.4. Costs of special consultants (including but
not limited to engineers, architects, testing
laboratories, surveyors, attorneys and accountants)
employed for set -vices specifically related to the
Work.
11.4.5. Supplemental costs including the following:
11.4.5.1. The proportion of necessary
transportation, travel and subsistence expenses of
CONTRACTOR's employees incurred in
discharge of duties connected with the Work.
11.4.5.2. Cost, including transportation and
maintenance, of all materials, supplies,
equipment, machinery, appliances, office and
temporary facilities at the site and hand tools not
owned by the workers, which are consumed in the
performance of the Work, and cost less market
value of such items used but not consumed which
remain the property of CONTRACTOR.
11.4.5.3. Rentals of all construction
equipment and machinery and the parts thereof
whether rented fi-om CONTRACTOR or others in
accordance with rental agreements approved by
OWNER with the advice of ENGINEER, and the
costs of transportation, loading, unloading,
installation, dismantling and removal thereof --all
in accordance with terms of said rental
agreements. The rental of any such equipment,
machinery or parts shall cease when the use
thereof is no longer necessary for the Work.
11.4.5.4. Sales, consumer, use or similar taxes
related to the Work, and for which
CONTRACTOR is liable, imposed by Laws and
Regulations.
11.4.5.5. Deposits lost for causes other than
negligence of CONTRACTOR, any
Subcontractor or anyone directly or indirectly
employed by any of them or for whose acts any
of them may be liable, and royalty payments and
fees for permits and licenses.
11.4.5.6. Losses and damages (and related
expenses) caused by damage to the Work, not
compensated by insurance or otherwise, sustained
by CONTRACTOR in connection with the
the contract or provide the services required, (2) whether the bidder can
perform the contract or provide the service promptly and within the time
specified without delay or interference, (3) the character, integrity,
reputation, judgment, experience and efficiency of the bidder, (4) the
quality of the bidder's performance of previous contracts or services, (5)
the previous and existing compliance by the bidder with laws and ordinances
relating to the contract or service, (6) the sufficiency of the financial
resources and ability of the bidder to perform the contract or provide the
service, (7) the quality, availability and adaptability of the materials
and services to the particular use required, (8) the ability of the bidder
to provide future maintenance and service for the use of the subject of the
contract, and (9) any other circumstances which will affect the bidder's
performance of the contract.
3.3. Each Bidder may be required to show that he has handled former Work
so that no just claims are pending against such Work. No Bid will be
accepted from a Bidder who is engaged on any other Work which would impair
his ability to perform or finance this Work.
3.4 No Bidder shall be in default on the performance of any other contract
with the City or in the payment of any taxes, licenses or other monies due
to the City.
4.0 EXAMINATION OF CONTRACT DOCUMENTS AND SITE
4.1. It is the responsibility of each Bidder, before submitting a Bid, to
(a) examine the Contract Documents thoroughly, (b) visit the site to
familiarize himself with local conditions that may in any manner affect
cost, progress or performance of the Work, (c) familiarize himself with
federal, state and local laws, ordinances, rules and regulations that may
in any manner affect cost, progress or performance of the Work, (d) study
and carefully correlate Bidder's observations with the Contract Documents,
and (e) notify Engineer of all conflicts, errors or discrepancies in the
Contract Documents.
4.2. Reference is made to the Supplementary Conditions for identification
of: Subsurface and Physical Conditions SC-4.2.
4.3. The submission of a Bid will constitute an incontrovertible
representation by Bidder that Bidder has complied with every requirement of
this Article 4, that without exception the Bid is premised upon performing
and furnishing the Work required by the Contract Documents and such means,
methods, techniques, sequences or procedures of construction as may be
indicated in or required by the Contract Documents, and that the Contract
Documents are sufficient in scope and detail to indicate and convey
understanding of all terms and conditions for performance and furnishing of
the Work.
5.0 INTERPRETATIONS AND ADDENDA.
5.1. All questions about the meaning or intent of the Bidding Documents are to
12/03 Section 00100 Page 2
performance and furnishing of the Work (except
losses and damages within the deductible amounts
of property insurance established by OWNER in
accordance with paragraph 5.9), provided they
have resulted from causes other than the
negligence of CONTRACTOR, any
Subcontractor, or anyone directly or indirectly
employed by any of them or for whose acts any of
them may be liable. Such losses shall include
settlements made with the written consent and
approval of OWNER. No such losses, damages
and expenses shall be included in the Cost of the
Work for the put -pose of determining
CONTRACTOR's fee. If, however, any such loss
or damage requires reconstruction and
CONTRACTOR is placed in charge thereof,
CONTRACTOR shall be paid for services a fee
proportionate to that stated in paragraph 11.6.2.
11.4.5.7. The cost of utilities, fuel and sanitary
facilities at the site.
11.4.5.8, Minor expenses such as telegrams,
long distance telephone calls, telephone service at
the site, expressage and similar petty cash items in
connection with the Work.
11.4.5.9. Cost of premiums for additional Bonds
and insurance required because of changes in the
Work.
11.5. The term Cost of the Work shall not include any of
the following:
11.5.1. Payroll costs and other compensation of
CONTRACTOR's officers, executives, principals (of
partnership and sole proprietorships), general managers,
engineers, architects, estimators, attorneys, auditors,
accountants, purchasing and contracting agents,
expediters, timekeepers, clerks and other personnel
employed by CONTRACTOR whether at the site or in
CONTRACTOR's principal or a branch office for
general administration of the Work and not specifically
included in the agreed upon schedule of job
classifications referred to in paragraph 11.4.1 or
specifically covered by paragraph 11.4.4--all of which
are to be considered administrative costs covered by the
CONTRACTOR's fee.
11.5.2. Expenses of CONTRACTOR's principal and
branch offices other than CONTRACTOR's office at
the site.
11.5.3. Any part of CONTRACTOR'S capital
expenses, including interest on CONTRACTOR'S
capital employed for the Work and charges against
CONTRACTOR for delinquent payments.
11.5.4. Cost of premiums for all Bonds and for all
insurance whether or not CONTRACTOR is required
by the Contract Documents to purchase and maintain
the same (except for the cost of premiums covered by
subparagraph 11.4.5.9 above).
E.ICDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
11.5.5. Costs due ' to the negligence of
CONTRACTOR, any Subcontractor, or anyone
directly or indirectly employed by any of them or for
whose acts any of them may be liable, including but
not limited to, the correction of defective Work,
disposal of materials or equipment wrongly supplied
and making good any damage to property.
11.5.6. Other overhead or general expense costs of
any kind and the costs of any item not specifically and
expressly included in paragraph 11.4.
11.6. The CONTRACTOR's fee allowed to
CONTRACTOR for overhead and profit shall be
determined as follows.
11.6.1. a mutually acceptable fixed fee; or
11.6.2. if a fixed fee is not agreed upon, then a fee
based on the following percentages of the various
portions of the Cost of the Work:
11.6.2.1. for costs incurred under
paragraphs 11.4.1 and 11.4.2, the
CONTRACTOR's fee shall be fifteen percent;
11.6.2.2. for costs incurred under
paragraph 11.4.3, the CONTRACTOR's fee shall
be five percent;
11.6.2.3. where one or more tiers of
subcontracts are on the basis of Cost of the Work
plus a fee and no fixed fee is agreed upon, the
intent of paragraphs 11.4.1, 11.4.2, 11.4.3 and
11.6.2 is that the Subcontractor who actually
performs or furnishes the Work, at whatever tier,
will be paid a fee of fifteen percent of the costs
incurred by such Subcontractor under paragraphs
11.4.1 and 11.4.2 and that any higher tier
Subcontractor and CONTRACTOR will each be
paid a fee 8f a, e o e..t of the , tit paid to
the next lever t:.... c .b..enti-aet„ to be negotiated
in good faith with the OWNER but not to exceed
five percent of the amount paid to the next lower
tier Subcontractor.
11.6.2.4. no fee shall be payable on the basis
of costs itemized under paragraphs 11.4.4, 11.4.5
and 11.5;
11.6.2.5. the amount of credit to be allowed
by CONTRACTOR to OWNER for any change
which results in a net decrease in cost will be the
amount of the actual net decrease in cost plus a
deduction in CONTRACTOR's fee by an amount
equal to five percent of such net decrease; and
11.6.2.6. when both additions and credits are
involved in any one change, the adjustment in
CONTRACTOR's fee shall be computed on the
basis of the net change in accordance with
paragraphs 11.6.2.1 through 11.6.2.5, inclusive.
11.7. Whenever the cost of any Work is to be
25
determined pursuant to paragraphs 11.4 and 11.5,
CONTRACTOR will establish and maintain records
thereof in accordance with generally accepted accounting
practices and submit in form acceptable to ENGINEER an
itemized cost breakdown together with supporting data.
Cash Allowances:
11.8. It is understood that CONTRACTOR has included
in the Contract Price all allowances so named in the
Contract Documents and shall cause the Work so covered
to be furnished and performed for such sums as may be
acceptable to OWNER and ENGINEER. CONTRACTOR
agrees that:
11.8.1. the allowances include the cost to
CONTRACTOR (less any applicable trade discounts)
of materials and equipment required by the allowances
to be delivered at the site, and all applicable taxes; and
11.8.2. CONTRACTOR's costs for unloading and
handling on the site, labor, installation costs, overhead,
profit and other expenses contemplated for the
allowances have been included in the Contract Price
and not in the allowances and no demand for
additional payment on account of any of the foregoing
will be valid.
Prior to final payment, an appropriate Change Order will be
issued as recommended by ENGINEER to reflect actual
amounts due CONTRACTOR on account of Work covered
by allowances, and the Contract Price shall be
correspondingly adjusted.
11.9. Unit Price Work:
11.9.1. Where the Contract Documents provide that all
or part of the Work is to be Unit Price Work, initially
the Contract Price will be deemed to include for all
Unit Price Work an amount equal to the sum of the
established unit prices for each separately identified
item of Unit Price Work times the estimated quantity
of each item as indicated in the Agreement. The
estimated quantities of items of Unit Price Work are
not guaranteed and are solely for the purpose of
comparison of Bids and determining an initial Contract
Price. Determinations of the actual quantities and
classifications of Unit Price Work performed by
CONTRACTOR will be made by ENGINEER in
accordance with paragraph 9.10.
11.9.2. Each unit price will be deemed to include an
amount considered by CONTRACTOR to be adequate
to cover CONTRACTOR's overhead and profit for
each separately identified item.
11.9.3.OWNER or CONTRACTOR may make a
claim for an adjusment in the Contract Price in
accordance with Article I I if.
11.9.3.1. the quantity of any item of Unit Price
Work performed by CONTRACTOR differs
materially and significantly from the estimated
quantity of such item indicated in the Agreement;
E1CDC GENERAL CONDITIONS 1910-8 (1990 Edition)
26 w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
and
11.9.3.2. there is no cot -responding adjustment
with respect to any other item of Work; and
11.9.3.3. if CONTRACTOR believes that
CONTRACTOR is entitled to an increase in
Contract Price as a result of having incurred
additional expense or OWNER believes that
OWNER is entitled to a decrease in Contract Price
and the parties are unable to agree as to the
amount of any such increase or decrease.
11.9 3 4 CONTRACTOR acknowledges that
the OWNER has the right to add or delete items in
the Bid or change quantities at OWNER'S sole
discretion without affecting the Contract Price of
any remaining item so long as the deletion or
addition does not exceed twenty-five percent of
the original total Contract Price.
ARTICLE 12--CHANGE OF CONTRACT TIMES
12.1. The Contract Times (or Milestones) may only be
changed by a Change Order or a Written Amendment.
Any claim for an adjustment of the Contract Times (or
Milestones) shall be based on written notice delivered by
the party making the claim to the other party and to
ENGINEER promptly (but in no event later than thirty
days) after the occurrence of the event giving rise to the
claim and stating the general nature of the claim. Notice
of the extent of the claim with supporting data shall be
delivered within sixty days after such occurrence (unless
ENGINEER allows additional time to ascertain more
accurate data in support of the claim) and shall be
accompanied by the claimant's written statement that the
adjustment claimed is the entire adjustment to which the
claimant has reason to believe it is entitled as a result of
the occurrence of said event. All claims for adjustment in
the Contract Times (or Milestones) shall be determined by
ENGINEER in accordance with paragraph 9.11 if
OWNER and CONTRACTOR cannot otherwise agree.
No claim for an adjustment in the Contract Times (or
Milestones) will be valid if not submitted in accordance
with the requirements of this paragraph 12.1.
12.2. All time limits stated in the Contract Documents
are of the essence of the Agreement.
12.3. Where CONTRACTOR is prevented from
completing any part of the Work within the Contract
Times (or Milestones) due to delay beyond the control of
CONTRACTOR, the Contract Times (or Milestones) will
be extended in an amount equal to time lost due to such
delay if a claim is made therefor as provided in
paragraph 12.1. Delays beyond the control of
CONTRACTOR shall include, but not be limited to, acts
or neglect by OWNER, acts or neglect of utility owners or
other contractors performing other work as contemplated
by Article 7, fires, floods, epidemics, abnormal weather
conditions or acts of God. Delays attributable to and
within the control of a Subcontractor or Supplier shall be
deemed to be delays within the control of CONTRACTOR.
12.4. Where CONTRACTOR is prevented from
completing any part of the Work within the Contract Times
(or Milestones) due to delay beyond the control of both
OWNER and CONTRACTOR, an extension of the
Contract Times (or Milestones) in an amount equal to the
time lost due to such delay shall be CONTRACTOR's sole
and exclusive remedy for such delay. In no event shall
OWNER be liable to CONTRACTOR, any Subcontractor,
any Supplier, any other person or organization, or to any
surety for or employee or agent of any of them, for
damages arising out of or resulting from (i) delays caused
by or within the control of the CONTRACTOR, or
(ii) delays beyond the control of both patties including, but
not limited to, fires, floods, epidemics, abnormal weather
conditions, acts of God or acts or neglect by utility owners
or other contractors performing other work as contemplated
by Article 7.
ARTICLE 13—TESTS AND INSPECTIONS;
CORRECTION, REMOVAL OR ACCEPTANCE OF
DEFECTIVE WORK
13.1. Notice of Defects:
Prompt notice of all defective Work of which OWNER or
ENGINEER have actual knowledge will be given to
CONTRACTOR. All defective Work may be rejected,
corrected or accepted as provided in this Article 13.
Access to Work:
13.2. OWNER, ENGINEER, ENGINEER's Consultants,
other representatives and personnel of OWNER,
independent testing laboratories and governmental agencies
with jurisdictional interests will have access to the Work at
i,easonable time for their observation, inspecting and
testing. CONTRACTOR shall provide them proper and
safe conditions for such access and advise them of
CONTRACTOR's site safety procedures and programs so
that they may comply therewith as applicable.
Tests and Inspections:
13.3. CONTRACTOR shall give ENGINEER timely
notice of readiness of the Work for all required inspections,
tests or approvals, and shall cooperate with inspection and
testing personnel to facilitate required inspections or tests.
13.4. OWNER shall employ and pay for the services of
an independent testing laboratory to perform all
inspections, tests, or approvals required by the Contract
Documents except:
13.4.1. for inspections, tests or approvals covered
by paragraph 13.5 below;
13.4.2. that costs incurred in connection with tests
or inspections conducted pursuant to paragraph 13.9
E.ICDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
below shall be paid as provided in said
paragraph 13.9; and
13.4.3. as otherwise specifically provided in the
Contract Documents.
13.5. If Laws or Regulations of any public body having
jurisdiction require any Work (or pail thereof) specifically
to be inspected, tested or approved by an employee or
other representative of such public body, CONTRACTOR
shall assume full responsibility for arranging and
obtaining such inspections, tests or approvals, pay all costs
in connection therewith, and furnish ENGINEER the
required certificates of inspection, or approval.
CONTRACTOR shall also be responsible for aranging
and obtaining and shall pay all costs in connection with
any inspections, tests or approvals required for OWNER's
and ENGINEER's acceptance of materials or equipment to
be incorporated in the Work, or of materials, mix designs,
or equipment submitted for approval prior to
CONTRACTOR's purchase thereof for incorporation in
the Work.
13.6. If any Work (or the work of others) that is to be
inspected, tested or approved is covered by
CONTRACTOR without written concurrence of
ENGINEER, it must, if requested by ENGINEER, be
uncovered for observation.
13.7. Uncovering Work as provided in paragraph 13.6
shall be at CONTRACTOR's expense unless
CONTRACTOR has given ENGINEER timely notice of
CONTRACTOR's intention to cover the same and
ENGINEER has not acted with reasonable promptness in
response to such notice.
Uncovering Work:
13.8. If any Work is covered contrary to the written
request of ENGINEER, it must, if requested by
ENGINEER, be uncovered for ENGINEERS observation
and replaced at CONTRACTOR's expense.
13.9. If ENGINEER considers it necessary or advisable
that covered Work be observed by ENGINEER or
inspected or tested by others, CONTRACTOR, at
ENGINEER's request, shall uncover, expose or otherwise
make available for observation, inspection or testing as
ENGINEER may require, that portion of the Work in
question, furnishing all necessary labor, material and
equipment. If it is found that such Work is defective,
CONTRACTOR shall pay all claims, costs, losses and
damages caused by, arising out of or resulting from such
uncovering, exposure, observation, inspection and testing
and of satisfactory replacement or reconstruction,
(including but not limited to all costs of repair or
replacement of work of others); and OWNER shall be
entitled to an appropriate decrease in the Contract Price,
and, if the parties are unable to agree as to the amount
thereof, may make a claim therefor as provided in
Article 11. If, however, such Work is not found to be
defective, CONTRACTOR shall be allowed an increase in
the Contract Price or an extension of the Contract Times
(or Milestones), or both, directly attributable to such
27
uncovering, exposure, observation, inspection, testing,
replacement and reconstruction; and, if the parties are
unable to agree as to the amount or extent thereof,
CONTRACTOR may make a claim therefor as provided in
Articles I and 12.
OWNER May Stop the Work:
13.10. If the Work is defective, or CONTRACTOR fails
to supply sufficient skilled workers or suitable materials or
equipment, or fails to furnish or perform the Work in such a
way that the completed Work will conform to the Contract
Documents, OWNER may order CONTRACTOR to stop
the Work, or any portion thereof, until the cause for such
order has been eliminated; however, this right of OWNER
to stop the Work shall not give rise to any duty on the part
of OWNER to exercise this right for the benefit of
CONTRACTOR or any surety or other party.
Correction or Removal of Defective Work.
13.11. If required by ENGINEER, CONTRACTOR shall
promptly, as directed, either correct all defective Work,
whether or not fabricated, installed or completed, or, if the
Work has been rejected by ENGINEER, remove it from the
site and replace it with Work that is not defective.
CONTRACTOR shall pay all claims, costs, losses and
damages caused by or resulting from such correction or
removal (including but not limited to all costs of repair or
replacement of work of others).
13.12. Correction Period:
13.12.1.If within erteyear two year after the date of
Substantial Completion or such longer period of time as
may be prescribed by Laws or Regulations or by the
terms of any applicable special guarantee required by
the Contract Documents or by any specific provision of
the Contract Documents, any Work is found to be
defective, CONTRACTOR shall promptly, without cost
to OWNER and in accordance with OWNER's written
instructions: (i) correct such defective Work, or, if it has
been rejected by OWNER, remove it from the site and
replace it with Work that is not defective, and (ii)
satisfactorily correct or remove and replace any damage
to other Work or the work of others resulting therefrom.
If CONTRACTOR does not promptly comply with the
terms of such instructions, or in an emergency where
delay would cause serious risk of loss or damage,
OWNER may have the defective Work corrected or the
rejected Work removed and replaced, and all claims,
costs, losses and damages caused by or resulting from
such removal and replacement (including but not
limited to all costs of repair or replacement of work of
others) will be paid by CONTRACTOR.
13.12.2.In special circumstances where a particular
item of equipment is placed in continuous service
before Substantial Completion of all the Work, the
correction period for that item may start to run from an
earlier date if so provided in the Specifications or by
Written Amendment.
13,12.3. Where defective Work (and damage to other
E.ICDC GENERAL CONDITIONS 1910-8 (1990 Edition)
28 w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
Work resulting therefrom) has been corrected,
removed or replaced under this paragraph 13.12, the
correction period hereunder with respect to such Work
will be extended for an additional period of ene yeav
twoyears after such correction or removal and
replacement has been satisfactorily completed.
Acceptance of Defective Work:
13.13. If, instead of requiring correction or removal and
replacement of defective Work, OWNER (and, prior to
ENGINEER's recommendation of final payment, also
ENGINEER) prefers to accept it, OWNER may do so.
CONTRACTOR shall pay all claims, costs, losses and
damages attributable to OWNER's evaluation of and
determination to accept such defective Work (such costs to
be approved by ENGINEER as to reasonableness). If any
such acceptance occurs prior to ENGINEER's
recommendation of final payment, a Change Order will be
issued incorporating the necessary revisions in the
Contract Documents with respect to the Work; and
OWNER shall be entitled to an appropriate decrease in the
Contract Price, and, if the parties are unable to agree as to
the amount thereof, OWNER may make a claim therefor
as provided in Article 11. If the acceptance occurs after
such recommendation, an appropriate amount will be paid
by CONTRACTOR to OWNER.
OWNER May Correct Defective Work:
13.14. If CONTRACTOR fails within a reasonable time
after written notice from ENGINEER to correct defective
Work or to remove and replace rejected Work as required
by ENGINEER in accordance with paragraph 13.11, or if
CONTRACTOR fails to perform the Work in accordance
with the Contract Documents, or if CONTRACTOR fails
to comply with any other provision of the Contract
Documents, OWNER may, after seven days' written
notice to CONTRACTOR, correct and remedy any such
deficiency. In exercising the rights and remedies under
this paragraph OWNER shall proceed expeditiously. In
connection with such corrective and remedial action,
OWNER may exclude CONTRACTOR from all or part of
the site, take possession of all or part of the Work, and
suspend CONTRACTOR's services related thereto, take
possession of CONTRACTOR's tools, appliances,
construction equipment and machinery at the site and
incorporate in the Work all materials and equipment
stored at the site or for which OWNER has paid
CONTRACTOR but which are stored elsewhere.
CONTRACTOR shall allow OWNER, OWNER's
representatives, agents and employees, OWNER's other
contractors and ENGINEER and ENGINEER's
Consultants access to the site to enable OWNER to
exercise the rights and remedies under this paragraph. All
claims, costs, losses and damages incurred or sustained by
OWNER in exercising such rights and remedies will be
charged against CONTRACTOR and a Change Order will
be issued incorporating the necessary revisions in the
Contract Documents with respect to the Work; and
OWNER shall be entitled to an appropriate decrease in the
Contract Price, and, if the parties are unable to agree as to
the amount thereof, OWNER may make a claim therefor
as provided in Article 11. Such claims, costs, losses and
damages will include but not be limited to all costs of
repair or replacement of work of others destroyed or
damaged by correction, removal or replacement of
CONTRACTOR's defective Work. CONTRACTOR shall
not be allowed an extension of the Contract Times (or
Milestones) because of any delay in performance of the
Work attributable to the exercise by OWNER of OWNER's
rights and remedies hereunder.
ARTICLE 14—PAYMENTS TO CONTRACTOR AND
COMPLETION
Schedule of Values:
14.1. The schedule of values established as provided in
paragraph 2.9 will serve as the basis for progress payments
and will be incorporated into a form of Application for
Payment acceptable to ENGINEER. Progress payments on
account of Unit Price Work will be based on the number of
units completed.
Application for Progress Payment:
14.2. At least twenty days before the date established for
each progress payment (but not more often than once a
month), CONTRACTOR shall submit to ENGINEER for
review an Application for Payment filled out and signed by
CONTRACTOR covering the Work completed as of the
date of the Application and accompanied by such
supporting documentation as is required by the Contract
Documents. If payment is requested on the basis of
materials and equipment not incorporated in the Work but
delivered and suitably stored at the site or at another
location agreed to in writing, the Application for Payment
shall also be accompanied by a bill of sale, invoice or other
documentation warranting that OWNER has received the
materials and equipment fi-ee and clear of all Liens and
evidence that the materials and equipment are covered by
appropriate property insurance and other arrangements to
protect OWNER's interest therein, all of which will be
satisfactory to OWNER. The amount of retainage with
respect to progress payments will be as stipulated in the
Agreement. Any funds that are withheld by the OWNER
shall not be subject to substitution by the CONTRACTOR
with securities or any arrangements involving an escrow or
custodianship By executing the apalication for payment
form the CONTRACTOR expressly waives his right to the
benefits of Colorado Revised Statutes, Section 24-91-101,
et seg.
CONTRACTOR's Warranty of Title:
14.3. CONTRACTOR warrants and guarantees that title
to all Work, materials and equipment covered by any
Application for Payment, whether incorporated in the
Project or not, will pass to OWNER no later than the time
of payment free and clear of all Liens.
Review of Applieations./or Progress Payment:
14.4. ENGINEER will, within ten days after receipt of
each Application for Payment, either indicate in writing a
E.ICDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
recommendation of payment and present the Application
to OWNER, or return the Application to CONTRACTOR
indicating in writing ENGINEER's reasons for refusing to
recommend payment. In the latter case, CONTRACTOR
may make the necessary corrections and resubmit the
Application. Ten days after presentation of the
Application for Payment to OWNER with ENGINEER's
recommendation, the amount recommended will (subject
to the provisions of the last sentence of paragraph 14.7)
become due and when due will be paid by OWNER to
CONTRACTOR.
14.5. ENGINEER's recommendation of any payment
requested in an Application for Payment will constitute a
representation by ENGINEER to OWNER, based on
ENGINEER's on -site observations of the executed Work
as an experienced and qualified design professional and on
ENGINEER's review of the Application for Payment and
the accompanying data and schedules, that to the best of
ENGINEER's knowledge, information and belief:
14.5.1. the Work has progressed to the point
indicated,
14.5.2. the quality of the Work is generally in
accordance with the Contract Documents (subject to
an evaluation of the Work as a functioning whole
prior to or upon Substantial Completion, to the results
of any subsequent tests called for in the Contract
Documents, to a final determination of quantities and
classifications for Unit Price Work under
paragraph 9.10, and to any other qualifications stated
in the recommendation), and
14.5.3. the conditions precedent to
CONTRACTOR's being entitled to such payment
appear to have been fulfilled insofar as it is
ENGINEER's responsibility to observe the Work.
However, by reconunending any such payment
ENGINEER will not thereby be deemed to have
represented that: (i) exhaustive or continuous on -site
inspections have been made to check the quality or the
quantity of the Work beyond the responsibilities
specifically assigned to ENGINEER in the Contract
Documents or (ii) that there may not be other matters or
issues between the parties that might entitle
CONTRACTOR to be paid additionally by OWNER or
entitle OWNER to withhold payment to CONTRACTOR.
14.6. ENGINEER's recommendation of any payment,
including final payment, shall not mean that ENGINEER
is responsible for CONTRACTOR's means, methods,
techniques, sequences or procedures of construction, or
the safety precautions and programs incident thereto, or
for any failure of CONTRACTOR to comply with Laws
and Regulations applicable to the furnishing or
performance of Work, or for any failure of
CONTRACTOR to perform or furnish Work in
accordance with the Contract Documents.
14.7. ENGINEER may refuse to recommend the whole
or any part of any payment if, in ENGINEER's opinion, it
would be incorrect to make the representations to
29
OWNER referred to in paragraph 14.5. ENGINEER may
also refuse to recommend any such payment, or, because of
subsequently discovered evidence or the results of
subsequent inspections or tests, nullify any such payment
previously recommended, to such extent as may be
necessary in ENGINEER's opinion to protect OWNER
fi-om loss because:
14.7.L the Work is defective, or completed Work has
been damaged requiring correction or replacement,
14.7.2. the Contract Price has been reduced by
Written Amendment or Change Order,
14.7.3. OWNER has been required to correct
defective Work or complete Work in accordance with
paragraph 13.14, or
14.7.4. ENGINEER has actual knowledge of the
occurrence of any of the events enumerated in
paragraphs 15.2.1 through 15.2.4 inclusive.
OWNER may refuse to make payment of the full amount
recommended by ENGINEER because:
14.7.5. claims have been made against OWNER on
account of CONTRACTOR's performance or furnishing
of the Work,
14.7.6. Liens have been filed in connection with the
Work, except where CONTRACTOR has delivered a
specific Bond satisfactory to OWNER to secure the
satisfaction and discharge of such Liens,
14.7.7. there are other items entitling OWNER to a set-
off against the amount recommended, or
14.7.8. OWNER has actual knowledge of the
occurrence of any of the events enumerated in
paragraphs 14.7.1 through 14.7.3 or paragraphs 15.2.1
through 15.2.4 inclusive;
but OWNER must give CONTRACTOR immediate
written notice (with a copy to ENGINEER) stating the
reasons for such action and promptly pay CONTRACTOR
the amount so withheld, or any adjustment thereto agreed
to by OWNER and CONTRACTOR, when
CONTRACTOR corrects to OWNER's satisfaction the
reasons for such action.
Substantial Completion:
14.8. When CONTRACTOR considers the entire Work
ready for its intended use CONTRACTOR shall notify
OWNER and ENGINEER in writing that the entire Work
is substantially complete (except for items specifically
listed by CONTRACTOR as incomplete) and request that
ENGINEER issue a certificate of Substantial Completion.
Within a reasonable time thereafter, OWNER,
CONTRACTOR and ENGINEER shall make an inspection
of the Work to determine the status of completion. If
ENGINEER does not consider the Work substantially
complete, ENGINEER will notify CONTRACTOR in
writing giving the reasons therefor. If ENGINEER
E.ICDCGENERAL CONDITIONS 1910-8 (1990 Edition)
30 w/CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
considers the Work substantially complete, ENGINEER
will prepare and deliver to OWNER a tentative certificate
of Substantial Completion which shall fix the date of
Substantial Completion. There shall be attached to the
certificate a tentative list of items to be completed or
corrected before final payment. OWNER shall have seven
days after receipt of the tentative certificate during which
to make written objection to ENGINEER as to any
provisions of the certificate or attached list. If, after
considering such objections, ENGINEER concludes that
the Work is not substantially complete, ENGINEER will
within fourteen days after submission of the tentative
certificate to OWNER notify CONTRACTOR in writing,
stating the reasons therefor. If, after consideration of
OWNER's objections, ENGINEER considers the Work
substantially complete, ENGINEER will within said
fourteen days execute and deliver to OWNER and
CONTRACTOR a definitive certificate of Substantial
Completion (with a revised tentative list of items to be
completed or corrected) reflecting such changes fi-om the
tentative certificate as ENGINEER believes justified after
consideration of any objections from OWNER. At the
time of delivery of the tentative certificate of Substantial
Completion ENGINEER will deliver to OWNER and
CONTRACTOR a written recommendation as to division
of responsibilities pending final payment between
OWNER and CONTRACTOR with respect to security,
operation, safety, maintenance, heat, utilities, insurance
and warranties and guarantees. Unless OWNER and
CONTRACTOR agree otherwise in writing and so inform
ENGINEER in writing prior to ENGINEER's issuing the
definitive certificate of Substantial Completion,
ENGINEER's aforesaid recommendation will be binding
on OWNER and CONTRACTOR until final payment.
14.9. OWNER shall have the right to exclude
CONTRACTOR from the Work after the date of
Substantial. Completion, but OWNER shall allow
CONTRACTOR reasonable access to complete or correct
items on the tentative list.
Partial Utilization:
14.10. Use by OWNER at OWNER's option of any
substantially completed part of the Work, which: (i) has
specifically been identified in the Contract Documents, or
(ii) OWNER, ENGINEER and CONTRACTOR agree
constitutes a separately functioning and usable part of the
Work that can be used by OWNER for its intended
put -pose without significant interference with
CONTRACTOR's performance of the remainder of the
Work, may be accomplished prior to Substantial
Completion of all the Work subject to the following:
14.10.LOWNER at any time may request
CONTRACTOR in writing to permit OWNER to use
any such part of the Work which OWNER believes to
be ready for its intended use and substantially
complete. If CONTRACTOR agrees that such part of
the Work is substantially complete, CONTRACTOR
will certify to OWNER and ENGINEER that such
part of the Work is substantially complete and request
ENGINEER to issue a certificate of Substantial
Completion for that part of the Work.
CONTRACTOR at any time may notify OWNER and
ENGINEER in writing that CONTRACTOR considers
any such part of the Work ready for its intended use
and substantially complete and request ENGINEER to
issue a certificate of Substantial Completion for that
part of the Work. Within a reasonable time after either
such request, OWNER, CONTRACTOR and
ENGINEER shall make an inspection of that part of
the Work to determine its status of completion. If
ENGINEER does not consider that part of the Work to
be substantially complete, ENGINEER will notify
OWNER and CONTRACTOR in writing giving the
reasons therefor. If ENGINEER considers that part of
the Work to be substantially complete, the provisions
of paragraphs 14.8 and 14.9 will apply with respect to
certification of Substantial Completion of that part of
the Work and the division of responsibility in respect
thereof and access thereto.
14.10.2. No occupancy or separate operation of part
of the Work will be accomplished prior to compliance
with the requirements of paragraph 5.15 in respect of
property insurance.
Final Inspection:
14.11. Upon written notice from CONTRACTOR that the
entire Work or an agreed portion thereof is complete,
ENGINEER will make a final inspection with OWNER
and CONTRACTOR and will notify CONTRACTOR in
writing of all particulars in which this inspection reveals
that the Work is incomplete or defective. CONTRACTOR
shall immediately take such measures as are necessary to
complete such work or remedy such deficiencies.
Final Application for Payment:
14.12. After CONTRACTOR has completed all such
corrections to the satisfaction of ENGINEER and delivered
in accordance with the Contract Documents all
maintenance and operating instructions, schedules,
guarantees, Bonds, certificates or other evidence of
insurance required by paragraph 5.4, certificates of
inspection, marked -up record documents (as provided in
paragraph 6.19) and other documents, CONTRACTOR
may make application for final payment following the
procedure for progress payments. The final Application for
Payment shall be accompanied (except as previously
delivered) by: (i) all documentation called for in the
Contract Documents, including but not limited to the
evidence of insurance required by subparagraph 5.4.13,
(ii) consent of the surety, if any, to final payment, and
(iii) complete and legally effective releases or waivers
(satisfactory to OWNER) of all Liens arising out of or filed
in connection with the Work. In lieu of such releases or
waivers of Liens and as approved by OWNER,
CONTRACTOR may furnish receipts or releases in full
and affidavit of CONTRACTOR that: (i) the releases and
receipts include all labor, services, material and equipment
for which a Lien could be filed, and (ii) all payrolls,
material and equipment bills, and other indebtedness
connected with the Work for which OWNER or OWNER's
property might in any way be responsible have been paid or
otherwise satisfied. If any Subcontractor or Supplier fails
E.ICDCGENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
to furnish such a release or receipt in full,
CONTRACTOR may furnish a Bond or other collateral
satisfactory to OWNER to indemnify OWNER against
any Lien. Releases or waivers of liens and the consent of
the surety to finalize payment are to be submitted on
forms conforming to the format of the OWNER'S standard
forms bound in the Project manual
Final Payment and Acceptance:
14.13. If, on the basis of ENGINEER's observation of
the Work during construction and final inspection, and
ENGINEER's review of the final Application for Payment
and accompanying documentation as required by the
Contract Documents, ENGINEER is satisfied that the
Work has been completed and CONTRACTOR's other
obligations under the Contract Documents have been
fulfilled, ENGINEER will, within ten days after receipt of
the final Application for Payment, indicate in writing
ENGINEER's recommendation of payment and present
the Application to OWNER for payment. At the same
time ENGINEER will also give written notice to OWNER
and CONTRACTOR that the Work is acceptable subject
to the provisions of paragraph 14.15. Otherwise,
ENGINEER will return the Application to
CONTRACTOR, indicating in writing the reasons for
refusing to recommend final payment, in which case
CONTRACTOR shall make the necessary corrections and
resubmit the Application. Thirty days after presentation to
OWNER of the Application and accompanying
documentation, in appropriate form and substance and
with ENGINEER's recommendation and notice of
acceptability, the amount recommended by ENGINEER
will become due and will be paid by OWNER to
CONTRACTOR subiect to paragraph 17.6.2 of these
General Conditions.
14.14. If, through no fault of CONTRACTOR, final
completion of the Work is significantly delayed and if
ENGINEER so confirms, OWNER shall, upon receipt of
CONTRACTOR's final Application for Payment and
recommendation of ENGINEER, and without terminating
the Agreement, make payment of the balance due for that
portion of the Work fully completed and accepted. If the
remaining balance to be held by OWNER for Work not
fully completed or corrected is less than the retainage
stipulated in the Agreement, and if Bonds have been
furnished as required in paragraph 5.1, the written consent
Of the surety to the payment of the balance due for that
portion of the Work fully completed and accepted shall be
submitted by CONTRACTOR to ENGINEER with the
Application for such payment. Such payment shall be
made under the terms and conditions governing final
payment, except that it shall not constitute a waiver of
claims.
Waiver of Claims:
14.15. The making and acceptance of final payment will
constitute:
14.15.1. a waiver of all claims by OWNER against
CONTRACTOR, except claims arising fi•om
unsettled Liens, from defective Work appearing after
31
final inspection pursuant to paragraph 14.11, from
failure to comply with the Contract Documents or the
ternis of any special guarantees specified therein, or
from CONTRACTOR's continuing obligations under
the Contract Documents; and
14.15.2. A waiver of all claims by CONTRACTOR
against OWNER other than those previously made in
writing and still unsettled.
ARTICLE 15--SUSPENSION OF WORK AND
TERMINATION
OWNER May Suspend Work:
15.1. At any time and without cause, OWNER may
suspend the Work or any portion thereof for a period of not
more than ninety days by notice in writing to
CONTRACTOR and ENGINEER which will fix the date
on which Work will be resumed. CONTRACTOR shall
resume the Work on the date so fixed. CONTRACTOR
shall be allowed an adjustment in the Contract Price or an
extension of the Contract Times, or both, directly
attributable to any such suspension if CONTRACTOR
makes an approved claim therefor as provided in
Articles 11 and 12.
OWNER May Terminate:
15.2. Upon the occurrence of any one or more of the
following events:
15.2.1. if CONTRACTOR persistently fails to perform
the Work in accordance with the Contract Documents
(including, but not limited to, failure to supply sufficient
skilled workers or suitable materials or equipment or
failure to adhere to the progress schedule established
under paragraph 2.9 as adjusted from time to time
pursuant to paragraph 6.6);
15.2.2. if CONTRACTOR disregards Laws or
Regulations of any public body having jurisdiction;
15.2.3. if CONTRACTOR disregards the authority of
ENGINEER; or
15.2.4. if CONTRACTOR otherwise violates in any
substantial way any provisions of the Contract
Documents;
OWNER may, after giving CONTRACTOR (and the
surety, if any) seven days' written notice and to the extent
permitted by Laws and Regulations, terminate the services
of CONTRACTOR, exclude CONTRACTOR fi-om the site
and take possession of the Work and of all
CONTRACTOR's tools, appliances, construction
equipment and machinery at the site and use the same to
the full extent they could be used by CONTRACTOR
(without liability to CONTRACTOR for trespass or
conversion), incorporate in the Work all materials and
equipment stored at the site or for which OWNER has paid
EJCDC GENERAL CONDITIONS 1910-8 (1990 Edition)
32 w/CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
CONTRACTOR but which are stored elsewhere, and
finish the Work as OWNER may deem expedient. In such
case CONTRACTOR shall not be entitled to receive any
further payment until the Work is finished. If the unpaid
balance of the Contract Price exceeds all claims, costs,
losses and damages sustained by OWNER arising out of
or resulting from completing the Work such excess will be
paid to CONTRACTOR. If such claims, costs, losses and
damages exceed such unpaid balance, CONTRACTOR
shall pay the difference to OWNER. Such claims, costs,
losses and damages incurred by OWNER will be reviewed
by ENGINEER as to their reasonableness and when so
approved by ENGINEER incorporated in a Change Order,
provided that when exercising any rights or remedies
under this paragraph OWNER shall not be required to
obtain the lowest price for the Work performed.
15.3. Where CONTRACTOR's services have been so
terminated by OWNER, the termination will not affect
any rights or remedies of OWNER against
CONTRACTOR then existing or which may thereafter
accrue. Any retention or payment of moneys due
CONTRACTOR by OWNER will not release
CONTRACTOR from liability.
15.4. Upon seven days' written notice to
CONTRACTOR and ENGINEER, OWNER may,
without cause and without prejudice to any other right or
remedy of OWNER, elect to terminate the Agreement. In
such case, CONTRACTOR shall be paid (without
duplication of any items):
15.4.1. for completed and acceptable Work executed
in accordance with the Contract Documents prior to
the effective date of termination, including fair and
reasonable sums for overhead and profit on such
Work;
15.4.2. for expenses sustained prior to the effective
date of termination in performing services and
furnishing labor, materials or equipment as required
by the Contract Documents in connection with
uncompleted Work, plus fair and reasonable sums for
overhead and profit on such expenses;
15.4.3. for all claims, costs, losses and damages
incurred in settlement of terminated contacts with
Subcontractors, Suppliers and others; and
15.4.4. for reasonable expenses directly attributable
to termination.
CONTRACTOR shall not be paid on account of loss of
anticipated profits or revenue or other economic loss
arising out of or resulting fi-om such termination.
CONTRACTOR May Stop Work or Terminate:
15.5. If, through no act or fault of CONTRACTOR, the
Work is suspended for a period of more than ninety days
by OWNER or under an order of court or other public
authority, or ENGINEER fails to act on any Application
for Payment within thirty days after it is submitted or
OWNER fails for thirty days to pay CONTRACTOR any
sum finally determined to be due, then CONTRACTOR
may, upon seven days' written notice to OWNER and
ENGINEER, and provided OWNER or ENGINEER do not
remedy such suspension or failure within that time,
terminate the Agreement and recover from OWNER
payment on the same terms as provided in paragraph 15.4.
In lieu of terminating the Agreement and without prejudice
to any other right or remedy, if ENGINEER has failed to
act on an Application for Payment within thirty days after it
is submitted, or OWNER has failed for thirty days to pay
CONTRACTOR any sum finally determined to be due,
CONTRACTOR may upon seven days' written notice to
OWNER and ENGINEER stop the Work until payment of
all such amounts due CONTRACTOR, including interest
thereon. The provisions of this paragraph 15.5 are not
intended to preclude CONTRACTOR from making claim
under Articles I 1 and 12 for an increase in Contract Price
or Contract Times or otherwise for expenses or damage
directly attributable to CONTRACTOR's stopping Work as
permitted by this paragraph.
ARTICLE 16—DISPUTE RESOLUTION
If and to the extent that OWNER and CONTRACTOR
have agreed on the method and procedure for resolving
disputes between them that may arise under this
Agreement, such dispute resolution method and procedure,
if any, shall be as set forth in Exhibit GC -A, "Dispute
Resolution Agreement", to be attached hereto and made a
part hereof. If no such agreement on the method and
procedure for resolving such disputes has been reached,
and subject to the provisions of paragraphs 9.10, 9.11 and
9.12, OWNER and CONTRACTOR may exercise such
rights or remedies as either may otherwise have under the
Contract Documents or by Laws or Regulations in respect
of any dispute.
ARTICLE 17—MISCELLANEOUS
Giving Notice:
17.1. Whenever any provision of the Contract
Documents requires the giving of written notice, it will be
deemed to have been validly given if delivered in person to
the individual or to a member of the firm, or to an officer of
the corporation for whom it is intended, or if delivered at or
sent by registered or certified mail, postage prepaid, to the
last business address known to the giver of the notice.
17.2. Computation of Time:
17.2.1. When any period of time is referred to in the
Contract Documents by days, it will be computed to
exclude the first and include the last day of such
period. If the last day of any such period falls on a
Saturday or Sunday or on a day made a legal holiday
by the law of the applicable jurisdiction, such day will
be omitted from the computation.
E.ICDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
17.2.2. A calendar day of twenty-four hours measured
from midnight to the next midnight will constitute a
day.
Notice of Claim:
17.3. Should OWNER or CONTRACTOR suffer injury
or damage to person or property because of any error,
omission or act of the other party or of any of the other
party's employees or agents or others for whose acts the
other party is legally liable, claim will be made in writing
to the other party within a reasonable time of the first
observance of such injury or damage. The provisions of
this paragraph 17.3 shall not be construed as a substitute
for or a waiver of the provisions of any applicable statute
of limitations or repose. Cumulative Remedies:
17.4. The duties and obligations imposed by these
General Conditions and the rights and remedies available
hereunder to the parties hereto, and, in particular but
without limitation, the warranties, guarantees and
obligations imposed upon CONTRACTOR by
paragraphs 6.12, 6.16, 6.30, 6.31, 6.32, 13.1, 13.12, 13.14,
14.3 and 15.2 and all of the rights and remedies available
to OWNER and ENGINEER thereunder, are in addition
to, and are not to be construed in any way as a limitation
of, any rights and remedies available to any or all of them
which are otherwise imposed or available by Laws or
Regulations by special warranty or guarantee or by other
provisions of the Contract Documents, and the provisions
of this paragraph will be as effective as if repeated
specifically in the Contract Documents in connection with
each particular duty, obligation, right and remedy to which
they apply.
Professional Fees and Court Costs Included:
17.5. Whenever reference is made to "claims, costs,
losses and damages", it shall include in each case, but not
be limited to, all fees and charges of engineers, architects,
attorneys and other professionals and all court or
arbitration or other dispute resolution costs.
17.6. The laws of the State of Colorado apply to this
Agreement. Reference to two pertinent Colorado statutes
are as follows:
17.6.1. Colorado Revised Statutes (CRS 8-17-101)
require that Colorado labor be employed to perform
the Work to the extent of not less than 80 percent
(80%) of each tvve or class of labor in the several
classifications of skilled and common labor employed
on the project. Colorado labor means any person who
is a bona fide resident of the State of Colorado at the
time of employment, without discrimination as to race
color, creed, age, religion or sex.
17.6.2. If a claim is filed, OWNER is required by
law (CRS 38-26-107) to withhold fi-om all payments to
CONTRACTOR sufficient funds to insure the
payment of all claims for labor, materials, team hire,
Sustenance, provisions, provender, or other supplies
used or consumed by CONTRACTOR or his
33
EJCDC GENERAL CONDITIONS 1910-8 (1990 Edition)
34 w/CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
be submitted in writing to the Engineer and the OWNER. Interpretation or
clarifications considered necessary in response to such questions will be
issued only by Addenda. Questions received less than seven days prior to
the date for opening of the Bids may not be answered. Onl
answered by formal written Addenda will be bindin y questions
interpretations or clarifications will be without legal effect and other
5.2• All questions concerning the scope of this project should be directed
to the Engineer. Questions regarding submittal of bids should be directed
to the City of Fort Collins' Purchasing Division.
5.3. Addenda may also be issued to modify the Bidding Documents as deemed
advisable by OWNER or Engineer.
5.4. Addenda will be mailed or delivered to all parties recorded by the
OWNER as having received the Bidding documents.
6.0 BID SECURITY
6.1. Each Bid must be accompanied by Bid Security made payable to OWNER in
the amount stated in the Invitation to Bid. The required security
in the form of a certified or bank cashier's check payable to OWNER or a
Bid Bond on the form enclosed herewith. The Bid Bond must be executed sbyba
surety meeting the requirements of the General Conditions for surety bonds.
6.2• The Bid Security of the successful Bidder will be retained until such
Bidder has executed the Agreement and furnished the required contract
security, whereupon Bid Security If the successful
will be returned.
Bidder fails to execute and deliver the If
and furnish the re
contract security within 15 days of the Notice. of Award
the Notice of required
Award and the Bid Security , OWNER may annul
The Bid Security of other Bidders whomy of that Bidder will be forfeited.
chance receiving OWNER believes to have reasonable
the seventh day the award may be retained by OWNER until the earlier of
y after the effective date of the Agreement or the thirty-
first day after the Bid Opening, whereupon Bid Security furnished b
Bidders will be returned. Bid Security with Bids which are not competitive
will be returned within seven days after the Bid opening, y such
7.0 CONTRACT TIME.
The number of days within which, or the date by which the Work is to be
substantially complete and also completed and ready for Final Payment (the
Contract Times) are set forth in the Agreement.
8.0 LIQUIDATED DAMAGES.
Provisions for liquidated damages are set forth in the Agreement.
9.0 SUBSTITUTE ("OR EQUAL") MATERIAL AND EQUIPMENT
The Contract, if awarded, will be on the basis of material and equipment
12/03
Section 00100 Page 3
(This page left blank intentionally.)
E,ICDC GENERAL CONDITIONS 1910-8 (1990 Edition) 35
w/CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
EXHIBIT GC -A to General Conditions
of the Construction Contract Between
OWNER and CONTRACTOR
DISPUTE RESOLUTION AGREEMENT
OWNER and CONTRACTOR hereby agree that
Article 16 of the General Conditions of the Construction
Contract between OWNER and CONTRACTOR is
amended to include the following agreement of the parties:
16.1. All claims, disputes and other matters in
question between OWNER and CONTRACTOR arising
out of or relating to the Contract Documents or the breach
thereof (except for claims which have been waived by the
making or acceptance of final payment as provided by
paragraph 14.15) will be decided by arbitration in
accordance with the Construction Industry Arbitration
Rules of the American Arbitration Association then
obtaining, subject to the limitations of the Article 16. This
agreement so to arbitrate and any other agreement or
consent to arbitrate entered into in accordance herewith as
provided in this Article 16 will be specifically enforceable
under the prevailing law of any court having jurisdiction.
16.2. No demand for arbitration of any claim, dispute
or other matter that is required to be referred to
ENGINEER initially for decision in accordance with
paragraph 9.11 will be made until the earlier of (a) the date
on which ENGINEER has rendered a written decision or
(b) the thirty-first day after the parties have presented their
evidence to ENGINEER if a written decision has not been
rendered by ENGINEER before that date. No demand for
arbitration of any such claim, dispute or other matter will
be made later than thirty days after the date on which
ENGINEER has rendered a written decision in respect
thereof in accordance with paragraph 9.11; and the failure
to demand arbitration within said thirty days' period will
result in ENGINEER's decision being final and binding
upon OWNER and CONTRACTOR. If ENGINEER
renders a decision after arbitration proceedings have been
initiated, such decision may be entered as evidence but will
not supersede the arbitration proceedings, except where the
decision is acceptable to the parties concerned. No demand
for arbitration of any written decision of ENGINEER
rendered in accordance with paragraph 9.10 will be made
later than ten days after the party making such demand has
delivered written notice of intention to appeal as provided
in paragraph 9.10.
16.3. Notice of die demand for arbitration will be
filed in writing with the other party to the Agreement and
with the American Arbitration Association, and a copy will
be sent to ENGINEER for information. The demand for
arbitration will be made within the thirty -day or ten-day
period specified in paragraph 16.2 as applicable, and in all
other cases within a reasonable time after the claim, dispute
or other matter in question has arisen, and in no event shall
any such demand be made after the date when institution of
legal or equitable proceedings based on such claim, dispute
or other matter in question would be barred by the
applicable statute of limitations.
E.ICDC GENERAL CONDITIONS 1910-3 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9199)
16.4. Except as provided in paragraph 16.5 below,
no arbitration arising out of or relating to the Contract
Documents shall include by consolidation, joinder or in any
other manner any other person or entity (including
ENGINEER, ENGINEER's Consultant and the officers,
directors, agents, employees or consultants of any of them)
who is not a party to this contract unless:
16.4.1. the inclusion of such other person or entity is
necessary if complete relief is to be afforded among
those who are already parties to the arbitration, and
16.4.2. such other person or entity is substantially
involved in a question of law or fact which is common
to those who are already parties to the arbitration and
which will arise in such proceedings, and
16.43. the written consent of the other person or
entity sought to be included and of OWNER and
CONTRACTOR has been obtained for such inclusion,
which consent shall make specific reference to this
paragraph; but no such consent shall constitute consent
to arbitration of any dispute not specifically described
in such consent or to arbitration with any party not
specifically identified in such consent.
16.5. Notwithstanding paragraph 16.4, if a claim,
dispute or other matter in question between OWNER and
CONTRACTOR involves the Work of a Subcontractor,
either OWNER or CONTRACTOR may join such
Subcontractor as a party to the arbitration between OWNER
and CONTRACTOR hereunder. CONTRACTOR shall
include in all subcontracts required by paragraph 6.11 a
specific provision whereby the Subcontractor consents to
being joined in an arbitration between OWNER and
CONTRACTOR involving the Work of such
Subcontractor. Nothing in this paragraph 16.5 nor in the
provision of such subcontract consenting to joinder shall
create any claim, right or cause of action in favor of
Subcontractor and against OWNER, ENGINEER or
ENGINEER's Consultants that does not otherwise exist.
16.6. The award rendered by the arbitrators will be
final, judgment may be entered upon it in any court having
jurisdiction thereof, and it will not be subject to
modification or appeal.
16.7. OWNER and CONTRACTOR agree that they
shall first submit any and all unsettled claims,
counterclaims, disputes and other matters in question
between them arising out of or relating to the Contract
Documents or the breach thereof ("disputes"), to mediation
by the American Arbitration Association under the
Construction Industry Mediation Rules of the American
Arbitration Association prior to either of them initiating
against the other a demand for arbitration pursuant to
paragraphs 16.1 through 16.6, unless delay in initiating
arbitration would irrevocably prejudice one of the parties.
The respective thirty and ten day time limits within which
to file a demand for arbitration as provided in paragraphs
16.2 and 16.3 above shall be suspended with respect to a
dispute submitted to mediation within those same
applicable time limits and shall remain suspended until ten
days after the termination of the mediation. The mediator
of any dispute submitted to mediation under this Agreement
shall not serve as arbitrator of such dispute unless otherwise
agreed,
GC -Al
SECTION 00800
SUPPLEMENTARY CONDITIONS
SECTION 00800
SUPPLEMENTARY CONDITIONS
Conditions of the Contract
These Supplementary Conditions amend or supplement the General
Conditions of the Construction Contract (EJCDC General Conditions
1910-8, 1990 edition with City of Fort Collins modifications) and
other provisions of the Contract Documents as indicated below.
SC-5.4.6 Limits of Liability
A. Add the following language at the end of paragraph 5.4.8.
The limits of liability for the insurance required by the
paragraph numbers of the General Conditions listed below are as
follows:
5.4.1 and 5.4.2
Coverage A - Statutory Limits
Coverage B - $100,000/$100,000/$500,000
5.4.3 and 5.4.5 Commercial General Liability policy will have
limits of $1,000,000 combined single limits (CSL). This policy
will include coverage for Explosion, Collapse, and Underground
coverage unless waived by the Owner.
5.4.6The Comprehensive Automobile Liability Insurance policy will
have limits of $1,000,000 combined single limits (CSL).
5.4.9This policy will include completed operations
coverage/product liability coverage with limits of $1,000,000
combined single limits (CSL)..
SC-12.3 Add the following language to the end of paragraph 12.3.
Contractor will include in the project schedule 10 days lost due
to abnormal weather conditions.
SECTION 00900
ADDENDA, MODIFICATIONS AND PAYMENT
00950Contract Change Order
00960Application for Payment
9/99
SECTION 00950
CHANGE ORDER NO.
PROJECT TITLE: PLEASANT VALLEY LAKE AND CANAL TRAIL; BID NO. 5908
CONTRACTOR:
PROJECT NUMBER:
DESCRIPTION:
1. Reason for change:
2. Description of Change:
3. Change in Contract Cost
4. Change in Contract Time:
ORIGINAL CONTRACT COST $ .00
TOTAL APPROVED CHANGE ORDER 0.00
TOTAL PENDING CHANGE ORDER 0.00
TOTAL THIS CHANGE ORDER 0.00
TOTAL o OF THIS CHANGE ORDER
TOTAL C.O.o OF ORIGNINAL CONTRACT
ADJUSTED CONTRACT COST $ 0.00
(Assuming all change orders approved)
ACCEPTED BY: DATE:
Contractor's Representative
ACCEPTED BY: DATE:
Project Manager
Title:
APPROVED BY:
Title:
APPROVED BY:
Purchasing Agent over $30,
cc: City Clerk Contractor
Project File Architect
Engineer Purchasing
DATE:
DATE:
DATE:
9/99 Section 00950 Page 1
Section 00960
Application for Payment
Insert pages 1 - 4
9/99
APPLICATION FOR PAYMENT
PAGE 1 OF 4
OWNER: City of Fort Collins PROJECT:
APPLICATION NUMBER:
APPLICATION DATE:
ENGINEER: CONTRACTOR:
PERIOD BEGINNING:
PERIOD ENDING:
PROJECT NUMBER:
CHANGE ORDERS
Application is made for Payment as shown below in connection with Contract
NUMBER DATE AMOUNT
The present status of the account for this Contract is as follows:
1
Z
Original Contract Amount:
3
Net Change by Change Order:
Current contract Amount:
$0.00
Total Completed and Stored to Date:
Less Previous Applications:
Amount Due this Application - Before Retainage:
$0.00
Less Retainage:
Net Change by Change Order $0.00
AMOUNT DUE THIS APPLICATION:
$0.00
CERTIFICATION:
The undersigned CONTRACTOR certifies that all obligations of CONTRACTOR incurred in connection with
the Work have been satisfied as required in Paragraph 14.3. of the General Conditions of the Contract.
The above Amount Due This Application is requested by the CONTRACTOR.
Date: By:
Payment of the above Amount Due This Application is recommended by the ENGINEER.
Date: By.
Payment of the above Amount Due This Application has been reviewed by the OWNER'S Project Manager.
Date: By.
Payment of the above Amount Due This Application is approved by the OWNER.
Date: By.
Bid
Item
Number Description Quantity Units Unit Price Amount
Work Completed
This Month
Qty. Amount
Work Completed
Previous Periods
Qty. Amount
Work Completed
To Date
Qty. Amount
Stored
Materials
This
Period
Total
Earned Percent
To Date Billed
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0,00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$o.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00.
TOTALS $0.00
$0.00
$0.00
$0.00
$0.00
CHANGE ORDERS
APPLICATION FOR PAYMENT
PAGE 3 OF 4
Work Completed
Work Completed
Work Completed Stored
Bid
This Month
Previous Periods
To Date Materials
Total
Item
This
Earned Percent
Number Description Quantity Units
Unit Price Amount
Qty. Amount
Qty. Amount
Qty. Amount Period
To Date Billed
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0 00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0 00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$o.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$o.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
Koo
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
Koo
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
Wool
$0.00
$0.00
TOTALS CHANGE ORDERS
$0.00
$0.00
$0.00
$0.00
$0.00
PROJECT TOTALS
$0.00
$0.00
$0.00
$0.0o
$0.00
described on the Drawings or specified in the Specifications without
consideration of possible substitute or "or equal" items. Whenever it is
indicated on the Drawings or specified in the Specifications that a
substitute or "or equal" item of material or equipment may be furnished or Y
used by CONTRACTOR if acceptable to Engineer, application for such
acceptance will not be considered by Engineer until after the "effective
date of the Agreement". The procedure for submittal of any such
application by CONTRACTOR and consideration by Engineer is set forth in the '
General Conditions which may be supplemented in the General Requirements.
10.0 SUBCONTRACTORS, SUPPLIERS AND OTHERS
10.1. Each Bidder shall submit at the Bid opening to OWNER a list of
principal subcontractors he proposes to use in the Work. Refer to Section
00430 contained within these Documents.
10.2. If OWNER or Engineer after due investigation has reasonable
objection to any proposed Subcontractor, either may, before the Notice of -.
Award is given, request the apparent successful Bidder to submit an
acceptable substitute without an increase in Bid price. If the apparent
successful Bidder declines to make any substitution, OWNER may award the
contract to the next lowest responsive and responsible Bidder that proposes
to use acceptable subcontractors. Subcontractors, suppliers, other persons
or organization listed and to whom OWNER or Engineer does not make written
objection prior to the giving of the Notice of Award will be deemed
acceptable to OWNER and ENGINEER subject to revocation of such acceptance
after the effective date of the Agreement as provided in the General
Conditions.
10.3. CONTRACTOR shall not be required to employ any subcontractor,
supplier or other persons or organizations against whom he has reasonable
objection. The use of subcontractors listed by the Bidder and accepted by
OWNER prior to the Notice of Award will be required in the performance of
the Work.
11.0 BID FORM.
11.1. A copy of the Bid Form is bound in the Contract Documents which may
be retained by the Bidder. A separate unbound copy is enclosed for
submission with the Bid.
11.2. Bid Forms must be complete in ink or typed. All lump sum prices on _
the form must be stated in words and numerals; in case of conflict, words
will take precedence. Unit prices shall govern over extensions of sums.
11.3. Bids by corporations must be executed in the corporate name by the
president or a vice-president (or other appropriate officer accompanied by
evidence of authority to sign) and the corporate seal shall be affixed and
attested by the secretary or an assistant secretary. The corporate address
and state of incorporation shall be shown below the corporate name.
12/03 Section 00100 Page 4
STORED MATERIALS SUMMARY
On Hand Received
Item Invoice Previous This
Number Number Description Application Period
PAGE 4 OF 4
Installed On Hand
This This
Period Application
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
TOTALS $0.00 $0.00
$0.00 $0.00
IIt I I I I I I i I I I I I I I I I I I I I
TABLE OF CONTENTS
TECHNICAL SPECIFICATIONS
DIVISION 1 GENERAL REQUIREMENTS
Schedule of Drawings
Section 01000
Project Summary
Section 01100
Summary of Work
Section 01160
Site Conditions
Section 01200
Measurement and Payment
Section 01300
Coordination and Project Meetings
Section 01310
Construction Schedules
Section 01330
Shop Drawings, Product Data and Samples
Section 01340
Survey Data
Section 01400
Quality Control and Testing
Section 01500
Temporary Controls
Section 01510
Temporary Utilities
Section 01570
Traffic Control
Section 01600
Material and Equipment
Section 01700
Contract Close -Out
Section 01800
Definition of Bid Items
DIVISION 2 SITEWORK
Section 02000
Section 02050
Section 02110
Section 02200
Section 02304
Section 02520
Section 02850
Section 02900
Section 07900
SCHEDULE OF DRAWINGS
Project Location Map
Bridge Plan and Profile 1 of 4
Trail Plan and Profiles 2 of 4
Trail Plan and Profiles 3 of 4
Trail Plan and Profiles 4 of 4
City of Fort Collins
Park Planning and Development
Mobilization
Demolition
Clearing and Grubbing
Earthwork and Grading
Aggregate Base Course
Portland Cement Concrete Paving
Pedestrian and Light Vehicle Bridge — Ipe Decking
Site Re -vegetation
Joint Sealers
1
2
3
4
5
Table of Contents
Page 1 of 1
DIVISION 1
SECTION 01000 — PROJECT SUMMARY
PART 1-GENERAL
1.01 Scope
A. This section contains general requirements that are applicable to this project.
1.02 Description of Work
A. The Contractor shall provide all labor, materials and equipment necessary to perform the work items
called for on the bid schedule.
1.03 City Furnished Materials
A. None.
1.04
Conditions of Work
A.
Area of Work: The Contractor shall confine his operations to the immediate work area. Material
storage shall be confined to areas shown on the Drawings or designated by the City.
T B.
Regulations: The Contractor shall comply with all applicable Federal, State, and local regulations
pertaining to safety, traffic control, fire prevention, erosion control and environmental protection.
C.
Working Hours: The Contractor's working hours shall be between 7:00 a.m. and 5:00 p.m., with no
work on weekends or Federal holidays, unless otherwise approved by the City.
D.
Material Storage: The Contractor's material and equipment storage site shall be limited to the area of
the project site. The area shall be kept orderly and free of litter.
1.05
Project Cleanup
A.
The Contractor is responsible to maintain the construction site in a clean and orderly condition from the
start of the project to completion. Daily cleanups are required.
1. The City may require Contractor to perform cleanup within 100 feet of the progress of the work
and perform cleanup of the site daily prior to work stoppage.
B.
Store volatile wastes in covered containers and dispose off -site.
I. Provide on -site covered containers for the collection of waste materials, debris and rubbish.
2. Neatly store construction materials, such as concrete forms, when not in use.
C.
Wastes shall not be buried or burned on the site or disposed of into storm drains, sanitary sewers,
streams or waterways.
T D.
At project completion the Contractor shall remove all equipment, materials, and debris from the site
including toilets and dumpsters. Areas around work sites shall be cleaned with dirt and grass surfaces
raked clean of any slag from the Contractor's operations. Broom clean exterior paved surfaces.
Remaining dirt and fill material shall be removed, or may be scattered, with the approval of the City.
1.06
Trash Removal
A.
All non -salvageable items and trash shall be hauled off the site and disposed of in accordance with
applicable state and local regulations. Items shall be transported in tarp -covered or closed vehicles.
Any materials dropped or blown off vehicles shall be picked up immediately by Contractor.
City of Fort Collins
Park Planning
r
SECTION 01000 - PROJECT SUMMARY
& Development Division Page i of 3
1.07 Verification of Dimensions
A. The Contractor shall he responsible for the coordination and proper relation of the work. He shall field
verify all dimensions and advise the City of any discrepancies prior to proceeding with that phase of the
work.
1.08 Fire Hydrants
A. Fire Hydrant Connections: City's permission is required for connection to fire hydrants. Only _
compatible adapters shall be utilized for hydrant connections. A gate valve shall be provided and _
installed by the Contractor between the hydrant and supply hoses to control flow. Connection shall
include backflow protection. Temporary connections to fire hydrants shall he disconnected at the end
of each working day. No quick closing valves such as plug or butterfly valves will he used.
1.09 Outages
A. Utility outages necessitated by the work shall be requested in writing at least fifteen (15) working days
prior to the proposed outage. The request shall be directed to the City and shall stipulate the specific
utility system(s) and circuits to be affected, the location of the work, the time at which the shutdown
will occur, and the duration of the outage for each system. Outages shall be kept to a minimum both in
number and in duration. Where multiple outages are required, as many outages as can be accurately
scheduled shall he submitted as a group.
1.10 Fill Material
A. Excess fill material, including rock, gravel, sod, broken concrete or asphalt, plaster, etc., shall be
hauled off the site and disposed of in accordance with applicable State and local regulations.
B. Additional fill material, if required, shall be hauled to the site from off the site as a necessary part of the
work. Material composition shall be subject to the requirements of the specifications.
1.11 Parking -�
A. Parking of the Contractor's vehicles shall be restricted to an area designated by the City.
1.12 Telephone
A. Business Telephone: At the beginning of construction, the Contractor shall provide the City with a w
telephone number at which the Contractor or his representative may be contacted at any time during
regular working hours. The Contractor shall also provide a phone number for after -duty hours contact.
1.13 Sanitary Provisions
A. The Contractor shall provide temporary toilets for the use of construction personnel. Location, type,
proposed maintenance, etc., shall be approved by the City prior to placing toilets. Temporary toilets
shall be removed at the completion of construction and the adjacent area restored to the condition
existing prior to the start of constriction or as indicated on the plans.
1.14 Pollution Abatement
A. Transporting materials to or from the site shall be accomplished in a manner preventing materials or `
particles from becoming airborne. Earth materials shall be covered, wetted or otherwise protected.
Gravel, sand and concrete shall be contained within vehicles to prevent spillage.
B. Prevent the deposit of dirt, mud or debris on improved streets and roads, and remove all should such
deposition occur.
c
C. Burning of any material on site is prohibited.
City of Fort Collins SECTION 01000 — PROJECT SUMMARY
Park Planning & Development Division Page 2 of 3 _
D. Stream beds, lakes, drainage ways, sanitary and stone sewers, etc., shall not be polluted by fuels, oils,
bitumen, acids, or other hannfiil materials. Surface drainage from the construction site, which contains
harmful amounts of sediment, shall not be allowed to drain onto adjacent areas. All grading shall be
accomplished to allow sedimentation to settle out prior to flowing onto adjacent areas.
E. Flushing of concrete trucks is allowed only at the project site or the designated contractor storage area,
with the responsibility of control and cleanup resting with the Contractor.
F. Toxic, corrosive and flammable materials for construction other than specified shall not be used
without prior approval of the City of Fort Collins. When approved, disposal of these materials or their
containers will be off site and conform to state and federal regulations.
1.15 Protection of Property
A. Initiate, maintain and supervise necessary protection to prevent damage, injury or loss to:
1. The Work and materials and equipment to be incorporated in the project, whether in storage on or
off the site: and
2. Property at the site or adjacent thereto, including fences, patios, driveways, sidewalks, pavement,
trees, shrubs, lawns, walks, structures, utilities and underground facilities not designated for
removal, relocation or replacement in the course of constriction.
B. Maintain, protect, and support existing utilities and other appurtenances against damage by shoring,
bracing, or other means.
C. Do not stockpile excavated material against existing appurtenances.
1.16 Survey Requirements
A. Contractor shall perform all surveying necessary to complete the work.
1.17 Construction Superintendent
A. The construction superintendent shall beat the job site anytime work is being accomplished by any of
the trades.
PART 2 - MATERIALS (Not Used)
PART 3 - EXECUTION (Not Used)
PART 4 - MEASUREMENT & PAYMENT (Not Used)
END OF SECTION
City of Fort Collins
Park Planning & Development Division
SECTION 01000 - PROJECT SUMMARY
Page 3 of 3
.. _ � _. .. _.-_ _,...- _.., -..-- .. ..�-,-n.-^.. ....;i x-w—�.-..{.. v... �.� c. •�..: r.. ,._ � e. �..+ mm%..v...'WyS: .,.-:.'^ ^.x^m"T+{ "�.,�'.".iABti.
DIVISION 1
SECTION 01010 - SUMMARY OF WORK
PART 1 - GENERAL
1.01 Description of Work
A. The City of Fort Collins Pleasant Valley Lake & Canal Trail construction includes demolition of
existing trail, minor earthwork, stump and shrub removal, minor sub -grade prep, new 8' wide concrete
trail, new 8' wide pedestrian bridge w/ abutments, fine grading, hydro -seeding and landscape _
restoration for any areas disturbed by construction.
B. Protection and Restoration.
1. Replace to equal or better conditions all items removed and replaced or damaged during
construction. Restore all areas disturbed to match surrounding surface conditions.
1.02 Notices to Private Owners and Authorities
A. Notify private owners of adjacent property, utilities, affected govermnental agencies, and school district -
when execution of the work may affect them.
B. Give notification 48 hours in advance to enable affected persons to provide for their needs when it is
necessary to temporarily deny access or services.
C. Contact utilities at least 48 hours prior to excavating near underground utilities.
D. Contact all agencies at least 72 hours prior to start of construction. Notify all agencies of the proposed
scope of work schedule and any items that would affect their daily operation.
E. Names and telephone numbers of affected agencies and utilities in the area are listed below for
Contractor's convenience.
Water - City of Fort Collins, Colorado 221-6681
Storm Sewer - City of Fort Collins, Colorado 221-6605 "
Sanitary Sewer - City of Fort Collins, Colorado 221-6681 ~
Electrical - City of Fort Collins, Colorado 482-5922, 221-8553
Gas - Public Service Company of Colorado 482-5922, 221-8553
Telephone - U.S. West Communications 484-0300, 226-6310
Roads - City of Ft. Collins, Colorado 221-6815 --
Cable Television - AT&T Cable Services 493-7400
Utility Locates - One -call System 1-800-922-1987
Safety - Occupational Safety and Health Administration (OSHA) 844-3061
Fire - Poudre Fire Authority Non -Emergency 221-6581/ Emergency 911
Police - City of Fort Collins Police Department Non -Emergency 221-6550 / Emergency 911
Latimer County Sheriffs Department - Non -Emergency 221-7177
Postmaster - United States Postal Service 482-2837
Ambulance - Poudre Valley Hospital Non -Emergency 484-1227 / Emergency 911
Public Transportation - TransFort 221-6620
Traffic Control - Traffic Engineering 221-6815
City of Fort Collins SECTION 01100 — SUMMARY OF WORK
Park Planning & Development Division Page 1 of 2
PART 2 - MATERIALS (Not Used)
PART 3 - EXECUTION (Not Used)
PART 4 - MEASUREMENT & PAYMENT (Not Used)
END OF SECTION
i.9
I
City of Fort Collins SECTION 01100 — SUMMARY OF WORK
Park Planning & Development Division Page 2 of 2
9
DIVISION 1
SECTION 01160 — SITE CONDITIONS
PART 1 - SITE INVESTIGATIONS AND REPRESENTATION
1.01 General Investigations
A. The Contractor acknowledges that he has satisfied himself as to the nature and location of the work, the
general and local conditions, particularly those bearing upon access to the site; handling, storage, and
disposal of materials; availability of water, electricity and roads; uncertainties of weather, or similar
physical conditions at the site; the conformation and conditions of the ground; the equipment and
facilities needed preliminary to and during the execution of the work; and all other matters which can in
any way affect the work or the cost thereof under this Contract.
1.02 Soil Conditions -,
A. The Contractor further acknowledges that he has satisfied himself as to the character, quality and
quantity of surface and subsurface materials to be encountered from his inspection of the site and from �*
reviewing any available records of exploratory work furnished by the Owner or included in these —•
Documents. Failure by the Contractor to acquaint himself with the physical conditions of the site and
all the available information will not relieve him from responsibility for properly estimating the
difficulty or cost of successfully performing the work.
1.03 Contractor Representation
A. The Contractor warrants that as a result of his examination and investigation of all the aforesaid data
that he can perform the work in a good and workmanlike manner and to the satisfaction of the Owner.
The Owner assumes no responsibility for any representations made by any of its officers or agents
during or prior to the execution of this Contract, unless (1) such representations are expressly stated in
the Contract, and (2) the Contract expressly provides that the responsibility therefore is assumed by the
Owner.
PART 2 - INFORMATION ON SITE CONDITIONS
2.01 General
Any information obtained by the Engineer regarding site conditions, subsurface information, _
groundwater elevations, existing construction of site facilities, and similar data will be available for
inspection, as applicable, at the office of the Engineer upon request. Such information is offered as
supplementary information only. Neither the Engineer nor the Owner assumes any responsibility for
the completeness or interpretation of such supplementary information.
A. Differing Subsurface Conditions: -
1. In the event that the subsurface or latent physical conditions are found materially different from —
those indicated in these Documents, and differing materially from those ordinarily encountered and
generally recognized as inherent in the character of work covered in these Contract Documents, the
Contractor shall promptly, and before such conditions are disturbed, notify the Owner in writing of
such changed conditions.
The Engineer will investigate such conditions promptly and following this investigation, the ^
Contractor shall proceed with the work, unless otherwise instructed by the Engineer. if the
Engineer finds that such conditions do so materially differ and cause an increase or decrease in the
cost of or in the time required for performing the work, the Engineer will recommend to the Owner
the amount of adjustment in cost and time lie considers reasonable. The Owner will make the final
City of Fort Collins SECTION 01160 — SITE CONDITIONS
Park Planning & Development Division Page 1 of 3
decision on all Change Orders to the Contract regarding any adjustment in cost or time for
completion.
B.
Underground Utilities:
1. Known utilities and structures adjacent to or encountered in the work are shown on the Drawings.
The locations shown are taken from existing records and the best infonnation available from
existing utility plans, however, it is expected that there may be some discrepancies and omissions
in the locations and quantities of utilities and structures shown. Those shown are for the
convenience of the Contractor only, and no responsibility is assumed by either the Owner or the
Engineer for their accuracy or completeness.
PART 3 - CONTRACTOR'S RESPONSIBILITY FOR UTILITY PROPERTIES AND SERVICE
3.01
General
A.
Where the Contractor's operations could cause damage or inconvenience to railway, telegraph,
telephone, television, oil, gas, electricity, water, sewer, or irrigation systems, the operations shall be
suspended until all arrangements necessary for the protection of these utilities and services have been
made by the Contractor.
B.
Notify all utility offices which are affected by the construction operation at least 48 hours in advance.
Under no circumstances expose any utility without first obtaining permission from the appropriate
agency. Once permission has been granted, locate, expose, and provide temporary support for all
existing underground utilities.
C.
The Contractor shall protect all utility poles from damage. If interference of power poles, telephone
poles, guy wires, or anchors are encountered, notify the Owner's Representative and the appropriate
utility company at least 48 hours in advance of construction operations to permit the necessary
arrangements for protection or relocation of the interfering structure.
D.
The Contractor shall be solely and directly responsible to the Owner and operators of such properties
for any damage, injury, expense, loss, inconvenience, delay, suits, actions, or claims of any character
brought because of any injuries or damage which may result from the construction operations under this
Contract.
E.
Neither the Owner nor its officers or agents shall be responsible to the Contractor for damages as a
result of the Contractor's failure to protect utilities encountered in the work.
F.
If the Contractor while performing the Contract discovers utility facilities not identified in the
Drawings or Specifications, he shall immediately notify the Owners and the utility in writing.
^ G.
In the event of interruption to domestic water, sewer, storm drain, or other utility services as a result of
accidental breakage due to construction operations, promptly notify the proper authority. Cooperate
with said authority in the restoration of service as promptly as possible and bear all costs of repair. In
no case shall interruption of any water or utility service be allowed to exist outside working hours
unless prior approval is granted.
H.
The Contractor shall replace, at his own expense, any and all other existing utilities or structures
„ .
removed or damaged during construction, unless otherwise provided for in these Contract Documents
or ordered by the Engineer.
3.02
Interfering Structures
A.
Take necessary precautions to prevent damage to existing structures whether on the surface,
aboveground, or underground. An attempt has been made to show major structures on the Drawings.
The completeness and accuracy cannot be guaranteed, and it is presented simply as a guide to avoid
known possible difficulties.
City of Fort Collins SECTION 01160 - SITE CONDITIONS
_, Park Planning & Development Division Page 2 of 3
3.03 Field Relocation
A. During the progress of construction, it is expected that minor relocations of the work will be necessary. ^
Such relocations shall be made only by direction of the Owner's Representative. If existing structures
are encountered that prevent the construction, and that are not properly shown on the Drawings, notify
the Owner's Representative before continuing with the construction in order that the Owner's
Representative may make such field revision as necessary to avoid conflict with the existing structures.
If the Contractor shall fail to so notify the Owner's Representative when an existing structure is
encountered, and shall proceed with the construction despite the interference, he shall do so at his own
risk.
3.04 Easements
A. Easements and pennits will be obtained by the Owner where portions of the work are located on public
or private property Easements will provide for the use of the property for construction purposes to the
extent indicated on the easements. Copies of these easements and permits are available upon request to
the Owner. It shall be the Contractor's responsibility to determine the adequacy of the easement
obtained in every case and to abide by all requirements and provisions of the easement. The Contractor T
shall confine his constriction operations to within the easement limits or make special arrangements
with the property owners or appropriate public agency for the additional area required. Any damage to
property, either inside or outside the limits of the easements provided by the Owner, shall be the
responsibility of the Contractor as specified herein. The Contractor shall remove, protect, and replace
all fences or other items encountered on public or private property. Before final payment will be
authorized by the Owner's Representative, the Contractor will be required to furnish the Owner with
written releases from property owners or public agencies where side agreements or special easements
have been made by the Contractor or where the Contractor's operations, for any reason, have not been
kept within the construction right-of-way obtained by the Owner.
B. It is anticipated that the required easements and pennits will be obtained before construction is started. ^
However, should the procurement of any easement or permit be delayed, the Contractor shall schedule
and perform the work around these areas until such a time as the easement or pen -nit has been secured.
3.05 Land Monuments
A. The Contractor shall notify the Owner's Representative of any existing Federal, State, Town, County, ^
and private land monuments encountered. Private monuments shall be preserved, or replaced by a
licensed surveyor at the Contractor's expense. When Goverment monuments are encountered, the
Contractor shall notify the Owner's Representative at least two (2) weeks in advance of the proposed
construction in order that the Owner's Representative will have ample opportunity to notify the proper
authority and reference these monuments for later replacement.
END OF SECTION
City of Fort Collins SECTION 01160 - SITE CONDITIONS
Park Planning & Development Division Page 3 of 3
11.4. Bids by partnerships must be executed in the.partnership signed by a partner, his title must appear under his signature and the
Official address of the P name and
Pa must be shown below the signature.
11.5. Bids by joint venture shall be signed by each partici ant in the
P
joint venture or by an authorized agent of each p of each person or company interested Form. in the Bid hall be list deonull name
11.6. The Bid shall contain an acknowledgement of receipt of all Addenda
(the numbers of which must be filled in on the Bid Form).
11.7. No alterations in Bids, or in
the printed
erasures, interpolations forms therefore, by
or otherwise will be acceptable unless each such
alteration
is signed or initialed by the Bidder; if initialed
OWNER may
require the Bidder to identify any alteration so initialed.
11.8. The address and telephone number for communications regarding the
Bid shall be shown.
12.0 BID PRICING.
Bids must be priced as set forth in the Bid Schedule or Schedules.
13.0 SUBMISSION OF BIDS.
13.1. Bids shall be submitted at the time and place indicated in the
Invitation to Bid and shall be enclosed in an opaque sealed envelope marked
with the Project title, Bid No.
accompanied b , and name and address of the Bidder and
y the Bid Security, Bid Form, Bid Bond, Statement of Bidders
Qualifications, and Schedule of Subcontractors as required in
00430. If the Bid is sent through the mail or other deliver
tem the
sealed envelope Section
p shall be enclosed in a separate envelope with ythe snotation
sealed
ENCLOSED" on the face of it.
13.2. Bids shall be deposited at
and date for the designated location prior to the time
receipt of Bids indicated in the Invitation to
extension thereof made by addendum. Bids received after the time and date
for receipt of Bids will be returned unopened. Bid, or any
responsibility for timely delivery at the locationdesignatedfor shall ureceipt
Of Bids.
13.3. Oral, telephonic, telegraphic, or facsimile Bids are invalid and
will not receive consideration.
13.4. No Bidder may submit more than one Bid. Multiple Bids
under
different names will not be accepted from one firm or association.
14.0 MODIFICATION AND WITHDRAWAL OF BIDS.
12/03
Section 00100 Page 5
DIVISION1
SECTION 01200 - MEASUREMENT AND PAYMENT
PART 1-GENERAL
1.01 Description
A. This section covers the methods employed in determining the payment due for work completed under
this contract.
B. The bid price should cover all work required by this contract based upon the quantities outlined in the
bid form.
C. Where actual quantities differ from those outlined in the bid form; unit prices as stipulated in the bid
form shall be utilized to compute payment.
D. Where unit prices are not set forth on specific work, that work shalt be considered a subsidiary
obligation of the Contractor.
E. Quantities given in the bid form are estimates for the purpose of evaluating bids consequently some
difference may arise in actual and bid quantities.
1.02 Lump Sum Prices
A. Where lump sum (LS) prices are given for an item in the bid schedule or for items added during
construction by change order, the price will include all materials, labor, overhead and any other cost
incurred to complete the construction of the item in accordance with the plans and specifications.
B. All unit prices for each item shall include its pro rata share of profits, taxes, and overhead, and are for
the items installed in place, maintained and guaranteed. Including these factors, unit prices must
accurately reflect actual costs. Unit prices are to be valid for the life of the contract.
PART 2 - PRODUCTS (Not Used)
PART 3 - EXECUTION (Not Used)
END OF SECTION
City of Fort Collins SECTION 01200— MEASUREMENT AND PAYMENT
Park Planning & Development Division Page 1 of 1
.. .... �:...�...._�..... ._„�..a .. -s ✓.. i..�a.--+s..m�n ..... iM1in rt-w5+✓Nvn.T�."nv.♦ vie. .u. .p✓ .�o..xr...'�Yt+. �.. '�n-'g .+n.
DIVISION 1
SECTION 01300 - COORDINATION AND PROJECT MEETINGS
PART 1 -GENERAL
1.01 General —
A. In order to provide for an orderly progression of work, all parties involved in the construction will meet
at various times during the project to discuss pertinent items regarding the work.
B. Coordinate operations under contract in a manner that will facilitate progress of the Work.
C. Conform to the requirements of public utilities and concerned public agencies in respect to the timing
and manner of performance of operations that affect the service of such utilities, agencies, or public
safety.
1.02 Conferences
A. The pre -construction conference will be held at a time to be determined by the Owner, after the award ^
of the contract and prior to the issuance of the Notice to Proceed. The meeting will involve the Owner,
the Engineer, the Contractor and representatives of the owners of utilities and other properties that will
be directly affected by the work. Among the Contractor's representative on the site. The Contractor
will have a complete construction schedule ready for review at the time of the pre -construction
conference.
B. Hold conferences for coordination of the Work when necessary.
C. The City may hold coordination conferences to be attended by all involved when Contractor's
operations affects, or is affected by, the work of others. _
1.03 Progress Meetings
A. Contractor and the City shall schedule and hold regular progress meetings at least weekly and at other _
times as requested by the City or required by the progress of the Work.
B. Attendance shall include:
1. Contractor and Superintendent —
2. Owners Representative
3. Landscape Architect —
4. Others as may be requested by contractor, Landscape Architect or Owner
C. Minimum Agenda shall include: —
1. Review of work progress since last meeting
2. Identification and discussion of problems affecting progress
3. Review of any pending change orders
4. Revisions of Construction Schedule as appropriate
1.04 Job Site Administration
A. Contract administration and construction observation services will be provided by the Owner. The
Owner will make decisions regarding changes in the work and adjustments in contract quantities and/or -
unit prices.
END OF SECTION
City of Fort Collins SECTION 01300 — COORDINATION AND PROJECT MEETINGS
Park Planning & Development Division Page 1 of 1
DIVISION 1
SECTION 01310 - CONSTRUCTION SCHEDULES
PART 1 - GENERAL
1.01 General
A. Prepare detailed schedule of all constriction operations and procurements after review of tentative
schedule by parties attending the pre -construction conference. No work is to begin at the site until
City's acceptance of the Constriction Schedule.
B. For special restrictions on float and time extensions reference is made to the Agreement.
1.02 Format and Submissions
A. Prepare Construction and Procurement schedules in a graphic format suitable for displaying schedule
and actual progress.
B. Submit two copies of each schedule to owner for review. Owner will return one copy to contractor with
revisions suggested or necessary for coordination of the Work with the needs of Owner or others.
1.03 Progress Revisions
A. Submit revised schedules and reports when changes are foreseen, when requested by City, and with
each application for progress payment.
B. Show changes occurring since previous submission.
1. Actual progress of each item to date.
2. Revised projections of progress and completion.
C. Provide a narrative report as needed to define:
1. Anticipated problems, reconunended actions, and their effects on the schedule.
2. The effect of changes on schedules of other work.
1.04 City's Responsibility
A. City's review is only for the purpose of checking conformity with the Contract Documents and assisting
Contractor in coordinating the Work with the needs of the Project.
B. It is not to be construed as relieving Contractor from any responsibility to determine the means,
methods, techniques, sequences, and procedures of construction as provided in the General Conditions.
PART 2 - MATERIALS (Not Used)
PART 3 - EXECUTION (Not Used)
PART 4 - MEASUREMENT & PAYMENT (Not Used)
.;s
END OF SECTION
City of Fort Collins SECTION 01310 — CONSTRUCTION SCHEDULES
Park Planning & Development Division Page 1 of 1
DIVISION 1
SECTION 01330 —SHOP DRAWINGS, PRODUCT DATA AND SAMPLES
PART 1 -GENERAL
1.01 Shop Drawings
A. Submit newly prepared information drawn accurately to scale. Highlight, encircle, or otherwise
indicate deviations from the Contract Documents. Do not reproduce Contract Documents or copy
standard information as the basis of Shop Drawings. Standard information prepared without specific
reference to the Project is not a Shop Drawing. —
B. Shop Drawings include fabrication and installation Drawings, setting diagrams, schedules, patterns,
templates, and similar Drawings. Include the following information:
1. Dimensions.
2. Identification of products and materials included by sheet and detail number.
3. Compliance with specified standards. —
4. Notation of coordination requirements.
5. Notation of dimensions established by field measurement.
6. Sheet Size: Except for templates, patterns and similar Hill -size Drawings, submit Shop Drawings
on sheets at least 8-1/2 by 11 inches but no larger than 24 by 36 inches.
7. Submittal: Submit 3 blue- or black -line prints and 2 additional prints where required for —
maintenance manuals, plus the number of prints needed by the Contractor for distribution. The
Owner's Representative will retain 2 prints and return the remainder.
a. One of the prints returned shall be marked up and maintained as a "Record Document." —
8. Do not use Shop Drawings without an appropriate final stamp indicating action taken.
1.02 Product Data
A. Collect Product Data into a single submittal for each element of construction or system. Product Data
includes printed information, such as manufacturer's installation instructions, catalog cuts, standard
color charts, roughing -in diagrams and templates, standard wiring diagrams, and performance curves.
1. Mark each copy to show applicable choices and options. Where printed Product Data includes
information on several products that are not required, mark copies to indicate the applicable
information. Include the following information:
a. Manufacturer's printed recommendations.
b. Compliance with trade association standards.
C. Compliance with recognized testing agency standards.
d. Application of testing agency labels and seals.
e. Notation of dimensions verified by field measurement.
f. Notation coordination requirements. —
2. Do not submit Product Data until compliance with requirements of the Contract Documents has
been confirmed.
City of Fort Collins SECTION 01330 - SHOP DRAWINGS, PRODUCT DATA AND SAMPLES
Park Planning & Development Division Page 1 of 3
3. Preliminary Submittal: Submit a preliminary single copy of Product Data where selection of
options is required.
4. Submittals: Submit 2 copies of each required submittal; submit 4 copies where required for
maintenance manuals plus additional conies as needed by the Contractor for distribution. The
Owner will retain one and will return the other marked with action taken and corrections or
modifications required.
5. Distribution: Furnish copies of final submittal to installers, subcontractors, suppliers,
manufacturers, fabricators, and others required for performance of construction activities. Show
distribution on transmittal forms.
a. Do not proceed with installation until a copy of Product Data is in the Installer's possession.
b. Do not permit use of unmarked copies of Product Data in connection with construction.
1.03 Samples
A. Submit full-size, full -fabricated Samples cured and finished as specified and physically identical with
the material or product proposed. Samples include partial sections of manufactured or fabricated
components, cuts or containers of materials, color range sets, and swatches showing color, texture, and
pattern.
1. Mount or display Samples in the manner to facilitate review of qualities indicated. Include the
following:
a. Specification Section number and reference.
b. Generic description of the Sample.
c. Sample source.
d. Product name or name of the manufacturer.
e. Compliance with recognized standards.
f. Availability and delivery time.
2. Submit Samples for review of size, kind, color, pattern, and texture. Submit Samples for a final
check of these characteristics with other elements and a comparison of these characteristics
between the final submittal and the actual component as delivered and installed.
a. Where variation in color, pattern, or other characteristic is inherent in the material or product
.represented, submit at least 3 multiple units that show approximate limits of the variations.
b. Refer to other Specification Sections for requirements for Samples that illustrate
workmanship, fabrication techniques, details of assembly, connections, operation, and similar
construction characteristics.
c. Refer to other Sections for Samples to be retuned to the Contractor for incorporation in the
Work. Such Samples must be undamaged at time of use. On the transmittal, indicated special
requests regarding disposition of Sample submittals.
d. Samples not incorporated into the Work, or otherwise designated as the Owner's property, are
the property of the Contractor and shall be removed from the site prior to Substantial
Completion.
3. Preliminary Submittals: Submit a full set of choices where Samples are submitted for selection of
color, pattern, texture, or similar characteristics from a range of standard choices. The Owner will
review and return preliminary submittals with the Owner's notation, indicating selection and other
action.
City of Fort Collins SECTION 01330 - SHOP DRAWINGS, PRODUCT DATA AND SAMPLES
Park Planning & Development Division Page 2 of 3
4. Submittals: Except for Samples illustrating assembly details, workmanship, fabrication
techniques, connections, operation, and similar characteristics, submit 3 sets. The Owner will
return one set marked with the action taken.
5. Maintain sets of Samples, as returned, at the Project Site, for quality comparisons throughout the
course of construction.
a. Unless noncompliance with Contract Document provisions is observed, the submittal may
serve as the final submittal.
b. Sample sets may be used to obtain final acceptance of the construction associated with each
set.
B. Distribution of Samples: Prepare and distribute additional sets to subcontractors, manufacturers,
fabricators, suppliers, installers, and others as required for performance of the Work. Show distribution
on transmittal forms.
1.04 Quality Assurance Submittals
A. Submit quality -control submittals, including design data, certifications, manufacturer's instructions,
manufacturer's field reports, and other quality -control submittals as required under other Sections of —
the Specifications.
B. Certifications: Where other Sections of the Specifications require certification that a product, material,
or installation complies with specified requirements, submit a notarized certification from the
manufacturer certifying compliance with specified requirements.
1. Signature: an officer of the manufacturer or other authorized individual shall sign Certification
documents.
C. Inspection and Test Reports: Requirements for submittal of inspection and test reports from
independent testing agencies are specified in Division 1 Section "Quality Control and Testing," and in
the applicable technical specifications.
PART 2 - PRODUCTS (Not Applicable)
PART 3 - EXECUTION (Not Applicable)
END OF SECTION 01330
City of Fort Collins SECTION 01330 — SHOP DRAWINGS, PRODUCT DATA AND SAMPLES
Park Planning & Development Division Page 3 of 3
HPv
DIVISION 1
SECTION 01340 - SURVEY DATA
PART 1-GENERAL
1.01 Survey Requirements
A. Contractor is not responsible for the layout of the Work. The City will provide the surveying.
1.02 Submittals
A. Submit to City all survey data with other documentation required for final acceptance.
PART 2 - MATERIALS (Not Used)
PART 3 - EXECUTION (Not Used)
PART 4 - MEASUREMENT & PAYMENT (Not Used)
END OF SECTION
City of Fort Collins SECTION 01340 - SURVEY DATA
Park Planning & Development Division Page 1 of 1
DIVISION 1
SECTION 01400 - QUALITY CONTROL AND TESTING
PART 1 -GENERAL
1.01 General
A. Provide such equipment and facilities as the City may require for conducting field tests and for collecting
and forwarding samples. Do not use any materials or equipment represented by samples until tests, if
required, have been made and the materials or equipment are found to be acceptable. Any product that
becomes unfit for use after approval hereof shall not be incorporated into the work.
B. All materials or equipment proposed to be used may be tested at any time during their preparation or use.
Furnish the required samples without charge and give sufficient notice of the placing of orders to permit the
testing. Products may be sampled either prior to shipment or after being received at the site of the work. _
C. Tests shall be made by an accredited testing laboratory selected by the Owner. Except as otherwise provided,
sampling and testing of all materials and the laboratory methods and testing equipment shall be in
accordance with the latest standards and tentative methods of the American Society for Testing Materials
(ASTM).
D. Where additional or specified information concerning testing methods, sample sizes, etc., is required, such
information is included under the applicable sections of the Specifications. Any modification of, or
elaboration on, these test procedures which may be included for specific materials under their respective
sections in the Specifications shall take precedence over these procedures.
1.02 Test Reports
A. Submit 2 copies of the reports of all tests made by testing laboratories, plus copies to be returned to the
contractor.
1.03 City's Responsibilities
A. City of Fort Collins shall be responsible for and shall pay all costs in comiection with the following testing: ^
1. Soils compaction tests.
2. Tests not called for by the Specifications of materials delivered to the site.
3. Concrete test ^
1.04 Contractor's Responsibilities
A. In addition to those inspections and tests called for in the General Conditions, Contractor shall also be
responsible for and shall pay all costs in comrection with testing required for the following:
1. All performance and field testing specifically called for by the. specifications.
2. All re -testing for Work or materials found defective or unsatisfactory, including tests covered under
1.03 above.
3. Testing of pipe. ^
4. Vacuum testing of manholes.
5. Concrete materials and mix designs.
6. Gradation tests for embedment, fill and backfill materials.
7. Material Substitution - any test for basic material or fabrication of equipment offered as a substitution
for a specified item on which a test may be required in order to prove it compliant with the
specifications.
City of Fort Collins SECTION 01400 - QUALITY CONTROL AND TESTING
Park Planning & Development Division Page 1 of 2
Nothing contained herein is intended to imply that the Contractor does not have the right to have tests
performed on any material at any time for his/her own information and job control so long as the Owner
does not assume responsibility for the cost or for giving them consideration when appraising quality
materials.
1.05 Transmittal of Test Reports
A. Submit 2 copies of each report of tests and engineering data furnished by the Contractor for City
Representative's review. The Owner's Representative will retain one and will return the other marked with
action taken and corrections or modifications required.
The testing laboratory retained by the Owner will furnish three (3) copies of a written report of each test
performed by laboratory personnel in the field or laboratory. Two (2) copies of each test report will be
transmitted to the City Representative and one (1) copy to the Contractor within seven (7) days after each
test is completed.
1.06 Contractor's Quality Control System
A. General: The Contractor shall establish a quality control system to perform sufficient inspection and tests of
all items of work, including that of his subcontractors, to ensure conformance to the functional performance
of this project. This control shall be established for all construction except where the Contract Documents
provide for specific compliance tests by testing laboratories or engineers employed by the City. Contractor's
control system shall specifically include all testing required by the various sections of the Specifications.
B. Contractor's quality control system is the means by which he assures himself that his construction complies
with the requirements of the Contract Documents. Controls shall be adequate to cover all construction
operations and should be keyed to the proposed constriction schedule.
C. Records: maintain correct records on an appropriate form for all inspections and tests performed,
instructions received from the City and actions taken as a result of those instructions. These records shall
include evidence that the required inspections or tests have been performed (including type and number of
inspections or test, nature of defects, causes for rejection, etc.) proposed or directed remedial action, and
corrective action taken. Document inspections and tests as required by each section of the Specifications.
Provide copies to City in a reasonable time.
D. Pipe alignment and grade is to be maintained through the use of suitable surveying instruments or laser
equipment operated continuously during construction. Horizontal tolerances of + 0.3 feet and vertical
tolerances of+ 0.1 feet maximum deviation from plan and construction staking are to be maintained, except
that visible "snaking" of the horizontal aligmment and changes in directions of slope will not be permitted.
PART 2 - MATERIALS (Not Used)
PART 3 - EXECUTION (Not Used)
PART 4 - MEASUREMENT & PAYMENT (Not Used)
END OF SECTION
City of Fort Collins SECTION 01400 — QUALITY CONTROL AND TESTING
Park Planning & Development Division Page 2 of 2
DIVISION 1
SECTION 01500 -TEMPORARY CONTROLS
1.01 Noise Control
A. Take reasonable measures to avoid unnecessary noise when constriction activities are being performed
in populated areas.
B. Constriction machinery and vehicles shall be equipped with practical sound muffling devices, and
operated in a manner to cause the least noise consistent with efficient performance of the work.
C. Cease operation of all machinery and vehicles between the hours of 6:00 p.m. and 7:00 a.m.
1.02 Dust Control
A. Dusty materials in piles or in transit shall be covered to prevent blowing.
B. Earth and road surfaces subject to dusting due to construction activities and detouring of traffic shall be
kept moist with water or by application of a chemical dust suppressant.
1. Chemical dust suppressant shall not be injurious to existing or future vegetation.
1.03 Pollution Control
A. Prevent the pollution of drains and watercourses by sanitary wastes, concrete, sediment, debris and
other substances resulting from construction activities.
1. Retain all spent oils, hydraulic fluids and other petroleum fluids in containers for disposal off the
site.
2. Prevent sediment, debris or other substances from entering sanitary sewers, storm drains and
culverts.
1.04 Erosion Control
A. Take such measures as are necessary to prevent erosion of soil that might result from construction
activities.
1. Measures in general will include: _
a. Control of runoff.
b. Trapping of sediment.
c. Minimizing area and duration of soil exposure.
d. Temporary materials such as hay bales, sandbags, plastic sheets, riprap or culverts to prevent
the erosion of banks and beds of watercourses or drainage swales where runoff will be
increased due to construction activities.
B. Preserve natural vegetation to the greatest extent possible.
C. Locate temporary storage and route construction traffic so as to preserve vegetation and minimize
erosion.
D. Comply with the City of Fort Collins' Storm Drainage Erosion Control Manual. r
END OF SECTION
City of Fort Collins SECTION 01500 — TEMPORARY CONTROLS
Park Planning & Development Division Page 1 of 1
14.1. Bids may be modified or withdrawn by an appropriate document duly
executed (in a manner that a Bid must be executed) and delivered to the
place where Bids are to be submitted at any time prior to the opening of
Bids.
14.2. Bids may also be modified or withdrawn in person by the Bidder or an
authorized representative provided he can prove his identity and authority
at any time prior to the opening of Bids.
14.3 Withdrawn Bids may be resubmitted up to the time designated for the
receipt of Bids provided that they are then fully in conformance with these
Instructions to Bidders.
15.0 OPENINGS OF BIDS.
Bids will be opened and (unless obviously non -responsive) read aloud
publicly as indicated in the Invitation to Bid. An abstract of the amounts
of the Base Bids and major alternates (if any) will be made available after
the opening of Bids.
16.0 BIDS TO REMAIN OPEN SUBJECT TO ACCEPTANCE.
All Bids shall remain open for forty-five (45) days after the day of the
Bid Opening, but OWNER may, in his sole discretion, release any Bid and
return the Bid Security prior to that date. '
17.0 AWARD OF CONTRACT.
17.1. OWNER reserves the right to reject any and all Bids, to waive any
and all informalities not involving price, time or changes in the Work, to
negotiate contract terms with the Successful Bidder, and the right to
disregard all nonconforming, nonresponsive, unbalanced or conditional Bids.
Also, OWNER reserves the right to reject the Bid of any Bidder if OWNER
believes that it would not be in the best interest of the Project to make
an award to that Bidder, whether because the Bid is not responsive or the r
Bidder is unqualified or of doubtful financial ability or fails to meet any
other pertinent standard or criteria established by OWNER. Discrepancies
between the indicated sum of any column of figures and the correct sum
thereof will be resolved in favor of the correct sum.
17.2. In evaluating Bids, OWNER will consider the qualifications of the
Bidders, whether or not the Bids comply with the prescribed requirements, ,
and such alternates, unit prices and other data, as may be requested in the
Bid Form or prior to the Notice of Award.
17.3. OWNER may consider the qualification and experience of
Subcontractors, Suppliers, and other persons and organizations proposed for
those portions of the Work as to which the identity of Subcontractors,
Suppliers, and other persons and organizations is submitted as requested by
OWNER. OWNER also may consider the operating costs, maintenance
requirements, performance data and guarantees of major items of materials
12/03 Section 00100 Page 6
DIVISION 1
SECTION 01510 - TEMPORARY UTILITIES
PART 1 - GENERAL
1.01 Utilities
A. Furnish all utilities necessary for constriction including, but not limited to temporary electric power
and pay all cost associated with utilities during and used for the contract period. All temporary utilities
installation shall meet the construction safety requirements of OSHA, State and local governing
agencies.
1.02 Water
A. Contractor is responsible for obtaining water for construction and shall pay all costs associated with
establishing a temporary meter used during construction.
1.03 Sanitary Facilities
A. Finnish temporary sanitary facilities at the site in the vicinity of the construction for the needs of
construction workers and others performing work or furnishing services on the Project.
B. Properly maintain sanitary facilities of reasonable capacity throughout construction periods.
C. Enforce the use of such sanitary facilities by all personnel at the site.
D. Obscure sanitary facilities from public view to the greatest extent practical.
PART 2 - MATERIALS (Not Used)
PART 3 - EXECUTION (Not Used)
PART 4 - MEASUREMENT & PAYMENT (Not Used)
END OF SECTION
City of Fort Collins SECTION 01510 - TEMPORARY UTILITIES
Park Planning & Development Division Page 1 of 1
DIVISION 1
SECTION 01570 - TRAFFIC CONTROL
PART 1-GENERAL
1.01 General
A. Traffic Control necessary to complete the project as depicted in the plans and specifications will be
provided by the Contractor and will not be paid for separately.
B. The Contractor must submit traffic control plans and coordinate all traffic control with the City's
Traffic Control Coordinator. The traffic control plans must he submitted and approved 72 hours prior
to starting construction and before making each modification.
C. Conformance: City of Fort Collins Work Area Traffic Control Handbook, Manual of Uniform Traffic
Control Devices (U.S. Dept. of Transportation), or applicable statutory requirements of authority
having jurisdiction.
D. Limited closures may be permitted for short periods up to three days to allow installation of concrete
pavement. Closures must be requested and approved 72 hours prior to anticipated closure.
E. Limited alternating one-way traffic operation may be permitted during the hours from 9:00 A.M. to
3:30 P.M. One-way traffic operation must be requested and approved 72 hours prior to anticipated
operation.
F. At all times, Contractor must maintain two-way traffic with a minimum of one lane of traffic in each
direction. Limited closures may be allowed.
G. The Contractor must coordinate with adjacent residents to provide and maintain them sufficient access T
during the duration of the project. It will be the Contractor's responsibility to coordinate and
cormnunicate with the residents during construction.
H. Keep traffic areas free of excavated material, construction equipment, pipe, and other materials and
equipment.
I. Keep fire hydrants and utility control devices free from obstruction and available for use at all times.
J. Conduct operations in a manner to avoid unnecessary interference with public and private roads and
drives.
K. Provide and maintain temporary approaches or crossings at streets, businesses, and residences.
L. Keep roads open and in acceptable condition, unless closure or detour has been approved by City's
Traffic Control Coordinator 72 hours prior to closure or detour.
M. Define a temporary pedestrian access route for children coming from the surrounding neighborhoods.
This pedestrian access route shall be located outside of the project limits. The pedestrian access route
shall be kept free of excavated material, construction equipment, pipe, and other materials.
1.02 Traffic Control Plan
A. Submit a detailed traffic control plan to Traffic Control Coordinator for review and acceptance. Plan _
must be accepted 72 hours prior to work commencing at the site. Maintain the accepted plan
throughout all phases of construction. Provide copy to Owner prior to submittal.
1. Notify parks dept, police, sheriff, ambulance services, and fire authorities of traffic control plan
and the schedule of it. Distribute copies if requested.
City of Fort Collins SECTION 01570 - TRAFFIC CONTROL
Park Planning & Development Division Page 1 of 2
1.03 Flagmen
A. Required where necessary to provide for public safety, or the regulation of traffic, or by jurisdictional
authorities.
B. Shall be properly equipped and licensed.
1.04 Warning Signs and Lights
A. Provide suitable barricades and warning signs for:
1. Open trenches and other excavations.
2. Obstructions, such as material piles, equipment, piled embankment.
B. Illuminate by means of warning lights all barricades and obstructions from sunset to sunrise.
C. Protect roads and driveways by effective barricades on which are placed acceptable warning signs.
1.05 Parking
A. Provide suitable parking areas for the use of all construction workers and others performing work or
furnishing services in connection with the Project so as to avoid interference with private property,
public traffic, City's operations, or constriction activities. Such parking shall occur on the project site
or another suitable location, approved by the City.
1.06 Roadway Usage between Operations
A. At all times when Work is not actually in progress, Contractor shall make passable and shall open to
traffic such portions of the Project and temporary roadways or portions thereof as may be agreed upon
between Contractor and City and all authorities having jurisdiction over any properties involved.
PART 2 - MATERIALS (Not Used)
PART 3 - EXECUTION (Not Used)
PART 4 - MEASUREMENT & PAYMENT (Not Used)
END OF SECTION
City of Fort Collins SECTION 01570 - TRAFFIC CONTROL
Park Planning & Development Division Page 2 of 2
A
DIVISION 1
SECTION 01600 — MATERIALS AND EQUIPMENT
PART 1 -GENERAL
1.01 Related Documents
A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and
other Division 1 Specification Sections, apply to this Section.
1.02 Summary
A. This Section includes administrative and procedural requirements governing the Contractor's selection
of products for use in the Project.
1.03 Definitions
A. Definitions used in this Article are not intended to change the meaning of other terns used in the
Contract Documents, such as "specialties," "systems," "structure," "finishes," "accessories," and
similar terns. Such terms are self-explanatory and have well -recognized meanings in the construction
industry.
1. "Products" are items purchased for incorporation in the Work, whether purchased for the Project
or taken from previously purchased stock. The term "product" includes the terms "material,"
"equipment," "systems," and terms of similar intent.
2. "Materials" are products substantially shaped, cut, worked, mixed, finished, refined, or otherwise
fabricated, processed, or installed to form a part of the Work.
3. "Equipment" is a product with operational parts, whether motorized or manually operated, that
requires service connections, such as wiring or piping.
1.04 Submittals
A. Product List: Prepare a list showing products specified in tabular form acceptable to the Owner.
Include generic names of products required. Include the manufacturer's name and proprietary product
names for each item listed.
1. Coordinate product list with the Contractor's Construction Schedule and the Schedule of
Submittals.
2. Form: Prepare product list with information on each item tabulated under the following column
headings:
a. Related Specifications Section number.
b. Generic name used in Contract Documents.
C. Proprietary name, model number, and similar designations.
d. Manufacturer's name and address.
e. Supplier's name and address. —
f. Installer's name and address.
g. Projected delivery date or time span of delivery period.
3. Initial Submittal: Within 30 days of date conunencement of the Work, submit 3 copies of an initial
product list. Provide a written explanation of omissions of data and for known variations from
Contract requirements.
City of Fort Collins SECTION 01600 - MATERIALS AND EQUIPMENT
Park Planning & Development Division Page 1 of 3
4. Complete List: Within 60 days after date of coimnencement of the Work, submit 3 copies of the
completed product list. Provide a written explanation for omissions of data and for known
variations from Contract requirements.
5. Owner's Action: The Owner will respond in writing to Contractor within 2 weeks of receipt of the
completed product list. No response within this period constitutes no objection to listed
manufacturers or products, but does not constitute a waiver of the requirement that products
comply with Contract Documents. The Owner's response will include a list of unacceptable
product selections, containing a brief explanation of reasons for this action.
1.05 Quality Assurance
A. Source Limitations: To the fullest extent possible, provide products of the same kind from a single
source.
B. Compatibility of Options: When the Contractor is given the option of seeking between 2 or more
products for use on the Project, the product selected shall be compatible with products previously
selected, even if previously selected products were also options.
C. Foreign Product Limitations: Except under one or more of the following conditions provide domestic
products, not foreign products, for inclusion in the Work:
1. Not available domestic product complies with the Contract Documents.
2. Domestic products that comply with the Contract Documents are available only at prices or terms
substantially higher than foreign products that comply with the Contract Documents.
1.06 Product Delivery, Storage and Handling
A. Delivery, store, and handle products according to the manufacturer's reconnmendations, using means
and methods that will prevent damage, deterioration, and loss, including theft.
1. Schedule delivery to minimize long-term storage at the site and to prevent overcrowding of
construction spaces.
2. Coordinate delivery with installation time to assure minimum holding time for items that are
flammable, hazardous, easily damaged, or sensitive to deterioration, theft, and other losses.
3. Delivery products to the site in an undamaged condition in the manufacturer's original sealed
container or other packaging system, complete with labels and instructions for handling, storing,
unpacking, protecting, and installing.
4. Inspect products upon delivery to ensure compliance with the Contract Documents and to ensure
that products are undamaged and properly protected.
5. Store products at the site in a mammr that will facilitate inspection and measurement of quantity or
counting of units.
6. Store heavy materials away from the Project structure in a manner that will not endanger the
supporting construction.
7. Store products subject to damage by the elements above ground, under cover in a weather -tight
enclosure, with ventilation adequate to prevent condensation.
PART 2-PRODUCTS
2.01 Product Selection
A. General Product Requirements: Provide products that comply with the Contract Documents, that are
undamaged and, unless otherwise indicated, new at the time of installation.
B. Product Selection procedures: The Contract Documents and governing regulations govern product
selection. Procedures governing product selection include the following:
City of Fort Collins SECTION 01600 —MATERIALS AND EQUIPMENT
Park Planning & Development Division Page 2 of 3
1. Proprietary Specification Requirements: Where Specifications name only a single product or
manufacturer, provide the product indicated. No substitutions will be permitted.
2. Sc.mipropi ie%iry Specification Requirements: Where Specifications name 2 or more products or
manufacturers or where Specifications specify products or manufacturers by name, accompanied
by the tern "or equal" or "or approved equal," provide one of the products listed or comply with
the Contract Document provisions concerning "substitutions" or obtain approval for use of an
unnamed product.
3. Nonproprietary Specification Requirements: When Specifications list products or manufacturers
that are available and may be incorporated in the Work, but do not restrict the Contractor to use
these products only, the Contractor may propose any available product that complies with Contract
requirements. Comply with Contract Document provisions concerning "substitutions" to obtain
approval for use of an unnamed product.
4. Descriptive Specification Requirements: Where Specifications describe a product or name, provide
a product or assembly that provides the characteristics and otherwise complies with Contract
requirements.
5. Compliance with Standards, Codes, and Regulations: Where Specifications only require
compliance with an imposed code, standard, or regulation, select a product that complies with the
standards, codes, or regulations specified.
6. Visual Matching: Where Specifications require matching an established Sample, the Owner's
decision will be final on whether a proposed product matches satisfactorily.
7. Visual Selection: Where specified product requirements include the phrase "... as selected from
manufacturer's standard colors, patterns, textures..." or a similar please, select a product and
manufacturer that complies with other specified requirements. The Owner will select the color,
pattern, and texture from the product line selected.
PART 3 - EXECUTION
3.01 Installation of Products
A. Comply with manufacturer's instructions and recornmendations for installation of products in the
applications indicated. Anchor each product securely in place, accurately located and aligned with
other Work.
END OF SECTION
City of Fort Collins SECTION 01600 — MATERIALS AND EQUIPMENT
Park Planning & Development Division Page 3 of 3
FfF�iRM�r"Ali�ifRE3 f'PM"1671f��P.. ,.... - ia�
DIVISION 1
SECTION 01700 —CONTRACT CLOSEOUT
PART 1 — GENERAL
1.01 Related Documents
A. Drawings and general provisions of the Contract, including general and supplementary conditions and
other Division 1 specification sections, apply to this section.
1.02 Summary
A. This Section includes administrative and procedural requirements for contract closeout including, but
not limited to, the following:
1. Inspection procedures.
2. Project record document submittal.
3. Operation and maintenance manual submittal.
4. Submittal of warranties.
5. Final cleaning.
B. Closeout requirements for specific construction activities are included in the appropriate Sections in
Divisions 2 through 16.
1.03 Substantial Completion
A. Preliminary Procedures: Before requesting inspection for certification of Substantial Completion,
complete the following. List exceptions in the request.
1. In the Application for Payment that coincides with, or first follows, the date Substantial
Completion is claimed, show 100 percent completion for the portion of the Work claimed as
substantially complete.
2. Advise the Owner of pending insurance changeover requirements.
3. Submit specific warranties, workmanship bonds, maintenance agreements, final certifications, and
similar documents.
4. Obtain and submit releases enabling the Owner unrestricted use of the Work and access to services
and utilities. Include occupancy permits, operating certificates, and similar releases.
5. Submit record drawings, maintenance manuals, final project photographs, damage or settlement
surveys, property surveys, and similar final record information.
6. Deliver tools, spare parts, extra stock, and similar items.
7. Make final changeover of permanent locks and transmit keys to the Owner. Advise the Owner's
personnel of changeover in security provisions.
8. Complete startup testing of systems and instruction of the Owner's operation and maintenance
personnel. Discontinue and remove temporary facilities from the site, along with mockups,
construction tools, and similar elements.
9. Complete final cleanup requirements, including touchup painting.
10. Touch up and otherwise repair and restore marred, exposed finishes.
B. Inspection Procedures: On receipt of a request for inspection, the Owner will either proceed with
City of Fort Collins SECTION 01700 — CONTRACT CLOSEOUT
Park Planning & Development Division Page 1 of 6
inspection or advise the Contractor of unfilled requirements. The Owner will prepare the Certificate of
Substantial Completion following inspection or advise the Contractor of constriction that must be
completed or corrected before the certificate will be issued.
1. If the Owner's Representative determines that the work is not substantially complete at the time of
review or that deficiencies remain at time of compliance review, the Contractor shall pay for the
additional review(s) by Owner's Representative.
2. Results of the completed inspection will form the basis of requirements for final acceptance.
1.04 Status after Substantial Completion
A. The date of substantial completion marks the beginning of the maintenance period defined in Section
02970 — Planting Maintenance.
B. During maintenance period, the following conditions hold:
1. Insurance: Same as during construction.
2. Electricity and Irrigation Water: Supplied by Owner, as installed by Contractor under this contract.
3. Bonds: Remain in effect.
4. Retainage: Same as during construction.
1.05 Final Acceptance
A. Preliminary Procedures: Before requesting final inspection for certification of final acceptance and
final payment, complete the following. List exceptions in the request.
1. Submit the final payment request with releases and supporting documentation not previously
submitted and accepted. Include insurance certificates for products and completed operations
where required.
2. Submit an updated final statement, accounting for final additional changes to the Contract Sum.
3. Submit a certified copy of the Owner's final inspection list of items to be completed or corrected,
endorsed and dated by the Owner. The certified copy of the list shall state that each item has been
completed or otherwise resolved for acceptance and shall be endorsed and dated by the Owner.
4. Submit final meter readings for utilities, a measured record of stored fuel, and similar data as of the
date of Substantial Completion or when the Owner took possession of and assumed responsibility
for corresponding elements of the Work.
5. Submit consent of surety to final payment.
6. Submit a final liquidated damages settlement statement.
7. Submit evidence of final, continuing insurance coverage complying with insurance requirements.
B. Reinspection Procedure: The Owner will reinspect the Work upon receipt of notice that the Work,
including inspection list items from earlier inspections, has been completed, except for items whose
completion is delayed under circumstances acceptable to the Owner.
1. Upon completion of reinspection, the Owner will prepare a certificate of final acceptance. If the
Work is incomplete, the Owner will advise the Contractor of Work that is incomplete or of
obligations that have not been fulfilled but are required for final acceptance.
2. If necessary, reinspection will be repeated.
City of Fort Collins SECTION 01700 - CONTRACT CLOSEOUT
Park Planning & Development Division Page 2 of 6
1.06 Record Document Submittals
A. General: Do not use record documents for construction purposes. Protect record documents from
deterioration and loss in a secure, fire-resistant location. Provide access to record documents for the
Owner's reference during normal working hours.
B. Record Drawings: Maintain a clean, undamaged set of blue or black line white -prints of Contract
Drawings and Shop Drawings. Mark the set to show the actual installation where the installation varies
substantially from the Work as originally shown. Mark which drawing is most capable of showing
conditions fully and accurately. Where Shop Drawings are used, record a cross-reference at the
corresponding location on the Contract Drawings. Give particular attention to concealed elements that
would be difficult to measure and record at a later date.
1. Mark record sets with red erasable pencil. Use other colors to distinguish between variations in
separate categories of the Work.
2. Mark new information that is important to the Owner but was not shown on Contract Drawings or
Shop Drawings.
3. Note related change -order numbers where applicable.
4. Organize record drawing sheets into manageable sets. Bind sets with durable -paper cover sheets;
print suitable titles, dates, and other identification on the cover of each set.
5. Prior to Contract Closeout, obtain from the Owner a reproducible mylar copy of the Drawings.
Using technical drafting pen, duplicate information contained on the Record Drawings maintained
on site.
Label each sheet "Record Drawing." On the first sheet, the Contractor or resident
Superintendent shall execute the following statement:
Having reviewed this document and all attaclunents, I affirm that, to the best of my knowledge, the
information presented here is true and accurate.
Signed: Date:
Position:
C. Record Specifications: Maintain one complete copy of the Project Manual, including addenda. Include
with the Project Manual one copy of other written construction documents, such as Change Orders and
modifications issued in printed form during construction.
1. Mark these documents to show substantial variations in actual Work performed in comparison with
the text of the Specifications and modifications.
2. Give particular attention to substitutions and selection of options and information on concealed
construction that cannot otherwise be readily discerned later by direct observation.
3. Note related record drawing information and Product Data.
4. Upon completion of the Work, submit record Specifications to the Owner.
D. Record Product Data: Maintain one copy of each Product Data submittal. Note related Change Orders
and markup of record drawings and Specifications.
1. Mark these documents to show significant variations in actual Work performed in comparison with
City of Fort Collins SECTION 01700 — CONTRACT CLOSEOUT
Park Planning & Development Division Page 3 of 6
information submitted. Include variations in products delivered to the site and from the
manufacturer's installation instructions and recommendations. --
2. Give particular attention to concealed products and portions of the Work that caimot otherwise be
readily discerned later by direct observation.
3. Upon completion of markup, submit complete set of record Product Data to the Owner. _
E. Miscellaneous Record Submittals: Refer to other Specification Sections for requirements of
miscellaneous record keeping and submittals in cormection with actual performance of Work.
Immediately prior to the date or dates of Substantial Completion, complete miscellaneous records and
place in good order. Identify miscellaneous records properly and bind or file, ready for continued use
and reference. Submit to the Owner.
F. Maintenance Manuals: Organize operation and maintenance data into suitable sets of manageable size.
Bind property indexed data in individual, heavy-duty, 2-inch (51-mm), 3-ring, vinyl -covered binders,
with pocket folders for folded sheet information. Mark appropriate identification on front and spine of
each binder. Include the following types of information:
1. Emergency instructions.
2. Spare parts list.
3. Copies of warranties.
4. Wiring diagrams.
5. Recommended "turn -around" cycles.
6. Inspection procedures.
7. Shop Drawings and Product Data.
8. Fixture lamping schedule.
1.07 Warranties and Bonds
A. Provide duplicate notarized copies. Maintain copies of all Contractor's submittals and assemble
documents executed by subcontractors, suppliers, and manufacturers. Provide table of contents and
assemble in binder with durable plastic cover.
B. Submit material prior to final application for payment. For items of Work delayed materially beyond
date of substantial completion, provide updated submittal within ten days after acceptance, listing date
of acceptance as start of warranty period.
1.08 Final Payment
A. At the end of maintenance period, submit written certification that Contract Documents Work has been
reviewed and that Work is complete in accordance with Contract Documents and ready for Owner
Representative's review.
B. In addition to submittals required by the conditions of the Contract provide submittals required by
governing authorities, and submit a final statement of accounting giving total adjusted Contract Sum,
previous payments and sum remaining due. _
C. Owner's Representative will issue a final Change Order reflecting approved adjustments to Contract
Sum not previously made by Change Order.
D. Retainage will be held until advertisement for liens and encumbrances is completed.
PART 2 — PRODUCTS (Not Applicable)
City of Fort Collins SECTION 01700 — CONTRACT CLOSEOUT
Park Planning & Development Division Page 4 of 6
and equipment proposed for incorporation in the Work when such data
is
required to be submitted prior to the Notice of Award.
17.4. OWNER may conduct such investigations as
OWNER deems necessary to
assist in the evaluation of any Bid and to establish the responsibility,
qualifications and financial
proposed
Subcontractors, Su ability of the Bidder's
p otherWork in accordance with sthe dContractersons Doccumentsd togOWNER'so satisfaoctith
onwithin the prescribed time.
17.5. If the Contract is to be awarded, it will be awarded to the lowest
responsive and responsible Bidder whose evaluation b
OWNER that the award will be in the best
shall be Y OWNER indicates to
made on the evaluated lowest interest of the OWNER. Award
basis for award shall be the base bid excluding
case of lowest Bid total for g alternates. The
more than one schedule the Schedule or, in the
contract will be awarded. for sum of all schedules.
Only one
17.6. If the Contract is to be awarded, OWNER will
Bidder a Notice of Award within forty-five (45) days after ytheedateCofsthe
Bid opening.
18.0 CONTRACT SECURITY.
The General Conditions and the Supplementary Conditions set forth OWNER'
requirements as to performance and other Bonds. When the Successful Bidder
delivers the executed Agreement to the s
the required Contract Security. OWNER, it shall
be accompanied by
19.0 SIGNING OF AGREEMENT.
When OWNER gives a Notice of Award to the Successful Bidder,
accompanied by the required number of unsi unsigned Agreement with all it will be
other written g counterparts of the
fifteen (15) days thereafter Contract Documents attached.
he
required number of counterparts of the
shall Within
OWNER with the required Bonds. the Agreement and attached documentsdeliver toshall deliver one full Within ten (10) days thereafter,
is to be Y signed counterpart to CONTRACTOR. OWNER
accompanied by a complete set of the Drawings with counterpart
identification.
appropriate
20.0 TAXES.
OWNER is exempt from Colorado State Sales and Use Taxes on
materials equipment to be incorporated in the Work. Said taxes shall not be included
in the Contract Price. Reference is made to the General and Supplementary
Conditions.
21.0 RETAINAGE.
Provisions concerning retainage are set forth in the Agreement.
12/03
Section 00100 Page 7
PART 3 — EXECUTION
3.01 Closeout Procedures
A. Operation and Maintenance Instructions: Arrange for each Installer of equipment that requires regular
maintenance to meet with the Owner's personnel to provide instruction in proper operation and
maintenance. Provide instruction by manufacturer's representatives if installers are not experienced in
operation and maintenance procedures. Include a detailed review of the following items:
1. Maintenance manuals.
2. Record documents.
3. Spare parts and materials.
4. Tools.
5. Lubricants.
6. Fuels.
7. Identification systems.
8. Control sequences.
9. Hazards.
10. Cleaning.
11. Warranties and bonds.
12. Maintenance agreements and similar continuing commitments.
B. As part of instruction for operating equipment, demonstrate the following procedures:
1. Startup.
2. Shutdown,
3. Emergency operations.
4. Noise and vibration adjustments.
5. Safety procedures.
6. Economy and efficiency adjustments.
7. Effective energy utilization.
., 3.02 Final Cleaning
A. General: The General Conditions require general cleaning during construction. Regular site cleaning
is included in Division 1.
B. Cleaning: Employ experienced workers or professional cleaners for final cleaning. Clean each surface
or unit to the condition expected in a normal, commercial building cleaning and maintenance program.
Comply with manufacturer's instructions.
1. Complete the following cleaning operations before requesting inspection for certification of
Substantial Completion.
C. Removal of Protection: Remove temporary protection and facilities installed for protection of the Work
during construction.
1. Remove labels that are not pernnanent labels.
2. Clean transparent materials, including mirrors and glass in doors and windows.
3. Clean exposed exterior and interior hard -surfaced finishes to a dust -free condition, free of stains,
films, and similar foreign substances. Restore reflective surfaces to their original condition. Leave
concrete floors broom clean.
4. Wipe surfaces of mechanical and electrical equipment. Remove excess lubrication and other
substances. Clean plumbing fixtures to a sanitary condition. Clean light fixtures and lamps.
5. Clean the site, including landscape development areas, of rubbish, litter, and other foreign
substances. Sweep paved areas broom clean; remove stains, spills, and other foreign deposits.
Rake grounds that are neither paved nor planted to a smooth, even -textured surface.
City of Fort Collins SECTION 01700 — CONTRACT CLOSEOUT
Park Planning & Development Division Page 5 of 6
D. Compliance: Comply with regulations of authorities having jurisdiction and safety standards for
cleaning. Do not bum waste materials. Do not bury debris or excess materials on the Owner's
property. Do not discharge volatile, harmful, or dangerous materials into drainage systems. Remove
waste materials from the site and dispose of lawfully.
1. Where extra materials of value remain after completion of associated Work, they become the
Owner's property. Dispose of these materials as directed by the Owner.
END OF SECTION 01700
City of Fort Collins SECTION 01700 - CONTRACT CLOSEOUT
Park Planning 6 Development Division Page 6 of 6
DIVISION 1
SECTION 01800 — DEFINITION OF BID ITEMS
The following items describe the scope of work for this contract and are further clarified through limit -of -work
boundary notes on the drawings and specifications. The work described in each Bid Item may contain work from
one or several technical specification sections. Contractor shall refer to the techmical specifications that apply to the
individual components.
Bid Item 1 - Mobilization
Contractor shall furnish all labor, materials and equipment for mobilization of personnel, equipment and supplies at
the project site in preparation for work on this project.
Bid Item 2 - Traffic Control
Contractor shall furnish all labor, materials and equipment for approved traffic control plan by a City of Fort Collins
approved Traffic Control Company. This includes furnishing, installing, and maintaining traffic control for the
duration of the trail project.
Bid Item 3 - Demolition
Contractor shall provide all labor and equipment for demolition and removal of existing 5' and 8' wide concrete trail
(as shown on drawings). Work includes all hauling and fees.
Bid Item 4 - Stump& Tree/Shrub Removal
Contractor shall provide all labor and equipment for removal of tree stumps and several small trees and shrubs.
Work includes all hauling and fees.
Bid Item 5 -Topsoil Removal/Replacement
Contractor shall furnish all labor, materials and equipment to remove, stockpile and replace topsoil (4" thick) from
construction areas.
Bid Item 6 - ABC Class 5
The bid price for this item shall include supplying, placing, and compacting aggregate base course in accordance
with the Drawings and Specifications or as otherwise directed by the ENGINEER. Measurement and payment for
this item will be by the actual number of tons in place (by scale tickets), complete at proper moisture. Quantities will
be adjusted accordingly if the moisture content is too high. The method to bring mixture to optimum moisture will
not be measured or paid for separately, but shall be included in the unit price for this item.
Bid Item 7 - 5" Colored Concrete Paving
Contractor shall furnish all labor, materials and equipment to install 8' wide concrete trail. Bid amount includes
.. installation of 5" thick standard concrete (3,500 psi) with fiber mesh reinforcement. All concrete paving to be
Yosemite Brown Colored Concrete.
r;
Bid Item 8 — Earthwork Cut
Contractor shall provide all labor and equipment for site earthwork including excavation; stockpiling; distributing;
filling; rough grading; grading for pavement; foundation(s) and all related work as noted on the plans and
specifications. Work includes placement of fill at 90% in non-structural areas and 95% in structural areas.
Bid Item 9 - 8' Wide Pedestrian Bridge (32')
Contractor shall furnish all labor, materials and equipment to construct cast in place bridge abutments and install an
8' wide pedestrian bridge in accordance to the drawings and specifications.
Bid Item 10 - Raise Manhole
Contractor shall furnish all labor, materials and equipment to raise an existing storm sewer manhole (as shown on
drawings).
City of Fort Collins Section 01800 - Definition of Bid Items
"' Park Planning & Development Division Page 1 of 2
Bid Item 11 - Hydro Seeding
Contractor shall provide all materials, labor and equipment to seed areas disturbed by construction. This work
includes hydro mulching disturbed areas.
END OF SECTION
END OF DIVISION 1
City of Fort Collins Section 01800 - Definition of Bid Items
Park Planning & Development Division Page 2 of 2
DIVISION 2
SECTION 02000 - MOBILIZATION
PART 1-GENERAL
0111mhrfam'41iRIF1 [0:1
A. Prepare the site for construction.
B. Move in and move out personnel and equipment.
C. Set up and remove temporary offices, buildings, facilities and utilities.
1.02 Site Conditions
A. The City has provided the right-of-way, easement or project site for all permanent access or
pernanent constriction for the project. Any additional access, access right-of-way, construction
areas, or additional needed land which may be involved in the construction of this project shall be
the responsibility of the Contractor.
B. The land owned by the City may be used as site headquarters, storage yard, or base of operations
provided that the use of said land meets with all of the requirements and restrictions imposed by
the City at the time of usage.
1.03 Site Preparation for Contractor Occupancy
A. The Contractor shall provide all temporary facilities as required for performing the work. The
Contractor shall secure and maintain proper storage areas for equipment and materials in locations
she/he may deem necessary for the proper execution of the job as approved by the City
Representative. No storage yard or project headquarters site may be utilized in conflict with
objections from the adjacent property owners unless the Contractor obtains from the City specific
written permission for such objectionable use. No objectionable material will be allowed to blow
from, wash off or drain off of any storage yard on to adjacent property.
B. The Contractor shall maintain all storage yards in as neat and orderly a manner as possible,
allowing no accumulation of waste materials or disposal piles. The Contractor may construct a
temporary security fence for the protection of materials, tools, and equipment. The fence shall be
maintained during the construction period. Upon completion of work, the security fence shall be
removed from the site. The Contractor shall provide adequate parking facilities within the
designated area for personnel working on the project.
C. The Contractor shall obtain the necessary per nits for connection to necessary services provided by
utility companies serving the project area.
D. Materials, equipment, and work required for temporary storm water management during the
construction period shall be provided by the Contractor as required to ensure public safety and to
protect the work in progress and materials stored on site.
1.04 Damage or Use -Fee Claims
A. Any damage or use -fee claims filed against the Contractor may become a part of the final
settlement of this project and may be cause for delay of final acceptance or delay of final payment.
City of Fort Collins Section 02000 — Mobilization
Park Planning and Development Division Page 1 of 2
PART 2 - NOT USED
PART 3 - EXECUTION
3.01 Obstructions
A. The location of some utilities and obstructions may not be shown. Bidders are advised to carefully
inspect the existing facilities before preparing their proposals. The removal and replacement of
minor obstructions such as electrical conduits, air, water, and waste piping and similar items shall
be anticipated and accomplished, even though not shown or specifically mentioned. Major
obstructions encountered that are not shown on the Contract Drawings or could not have been —
foreseen by visual inspection of the site prior to bidding should immediately be brought to the
attention of the City Representative. The City Representative will make a determination for
proceeding with the work. If the City Representative finds that the obstruction adversely affects
the Contractor's costs or schedule for completion, a proper adjustment to the Contract will be made
in accordance with the General Conditions.
3.02 Demolition
A. Any pipes or existing structures encountered during construction shall be preserved until accepted
for removal by the City Representative. The Contractor shall be required to repair pipes or
structures in use that are damaged during construction at no cost to the City. The removal of
abandoned pipes shall be reviewed by the City Representative.
3.03 Removal and Salvage of Materials
A. The Contractor shall carefully remove materials specified to be reused or salvaged so as not to
damage the material. Reuse by the Contractor of salvaged material will not be permitted, except as
specifically shown or specified herein. Existing materials to be removed or replaced and not —
specifically designated for salvage shall become the property of the Contractor. Provide and
maintain dust tight temporary partitions, bulkheads, or other protective devices during the
constriction to permit normal operation of the existing facilities. Construct partitions of plywood, _
insulating board, plastic sheets, or similar material.
END OF SECTION
City of Fort Collins Section 02000 — Mobilization
Park Planning and Development Division Page 2 of 2
DIVISION 2
m
SECTION 02050 - DEMOLITION
PART1-GENERAL
1.01 Description of Work
A. Demolition or salvage and removal of boulders (if found) for re -use in landscape; and remove
fencing, other plant material, and debris or other items on the site necessary for the construction of
the project.
1.02 Quality Assurance
A. Standards listed hereunder and referenced elsewhere in these specifications shall become a part of
this specification and are incorporated herein by reference. The latest edition, amendment or
supplements thereto in effect thirty (30) days before date of invitation shall apply.
1. City of Fort Collins, Street Cut and Excavation Repair Standards
2. City of Fort Collins, Stormwater Drainage Design and Construction Standards
PART 2 - MATERIALS - Not Used
PART 3 - EXECUTION
3.01 Inspection and Reviews
A. Schedule site meeting with Owner's Representative to verify and mark limits of demolition.
3.02 Protection
- A. Refer to the General Requirements for site protection and temporary controls.
B. Erect barriers and warning signs as necessary to prevent injury to the public and construction
personnel.
C. Protect features and areas not marked for demolition. Limit use of site to the delineated areas.
D. Use of explosives is prohibited.
3.03 Demolition and Removal
A. Items listed for salvage remain the property of the City. Items listed for demolition become the
property of the Contractor.
B. Remove from site items shown on demolition plan.
C. Arrange for and pay costs associated with off -site disposal.
3.04 Hidden Conditions
A. A hidden condition is any feature that could not be discovered or reasonably inferred from a
carefid inspection of the site prior to demolition.
B. Promptly report hidden conditions to the Owner's Representative.
C. Hidden conditions may cause damage to features that are to remain in a finished work if demolition
operations continue. Stop demolition operations affected by hidden conditions until a
determination is made by the Engineer.
D. Hidden conditions may cause a change in contract time or price; refer to the General Conditions.
END OF SECTION
City of Fort Collins Section 02050 - Demolition
Park Planning & Development Division Page 1 of 1
DIVISION 2
SECTION 02110 — CLEARING AND GRUBBING
PART 1 — GENERAL
1.01 Description of work
A. This work shall consist of clearing, grubbing, removing, and disposing of all vegetation and debris
within the limits of the project and such other areas as may be SHOWN ON THE DRAWINGS.
This work shall also include preservation of vegetation and objects designated to remain from
injury or defacement.
B. The Contractor shall be responsible for the procurement of all applicable licenses, permits, and
fees related to Forestry work in the City of Fort Collins as required for the specified work.
PART 2 — MATERIALS — Not used
PART 3 — EXECUTION
3.01 Protection of Existing Improvements
A. Provide protection necessary to prevent damage to existing improvements indicated to remain in
place.
B. Protect improvements on adjoining properties and on City's property.
C. Restore damaged improvements to their original condition, acceptable to parties having _
jurisdiction.
D. Protect existing trees and other vegetation indicated to remain in place, against unnecessary
cutting, breaking or skinning of roots, skinning and bruising of bark, smothering of trees by
stockpiling construction material or excavated material within drip line, excess foot or vehicular
traffic, or parking of vehicles within drip line. Provide temporary guards to protect trees and
vegetation to be left standing.
E. Water trees and other vegetation to remain within limits of contract work as required to maintain
their health during course of constriction operations.
F. Provide protection for roots over 1-1/2" diameter cut during construction operations. Coat cut
faces with emulsified asphalt, or other acceptable coating, formulated for use on damaged plant
tissues. Temporarily cover exposed roots with wet burlap to prevent roots from drying out; cover
with earth as soon as possible.
G. Repair or replace trees and vegetation indicated to remain which are damaged by construction
operations, in a manner acceptable to parties having jurisdiction. Employ qualified tree surgeon to
repair damages to trees and shrubs. Replace trees which cannot be repaired and restored to full
growth status, as determined by the City. —
3.02 Site Clearing
A. Site clearing consists of removing and properly disposing of ground vegetation, shrubs, bushes,
downed trees, and debris within the project area.
B. Branches on remaining trees and bushes in the way of construction shall be trimmed outside the
collar and branch bark ridge of the limb.
C. Cultured shrubs, bushes, and other vegetation to remain shall be protected.
D. Use only hand methods for grubbing inside drip line of trees indicated to be left standing.
City of Fort Collins Section 02110 — Clearing and Grubbing
Park Planning & Development Division Page 1 of 2
E. Fill depressions caused by clearing and grubbing operations with satisfactory soil material, unless
further excavation or earthwork is indicated.
F. Place fill material in horizontal layers not exceeding 12" loose depth, and thoroughly compact to a
density equal to adjacent ground.
3.03 Individual Stump Removal
A. Removal of stumps will require the removal of all roots over three inches in diameter to a
minimum depth of six inches below subgrade. Roots over three inches in diameter protruding
from an excavated slope shall be cut flush with the excavated slope surface.
3.04 Disposal
A. Disposal of clearing debris, waste materials and unsuitable or excess topsoil shall be off site at an
area provided by the Contractor, at Contractor's expense, unless otherwise SHOWN ON THE
DRAWINGS.
B. Burning of debris on City property is not allowed.
C. Remove debris from site in a timely manner.
END OF SECTION
City of Fort Collins Section 02110 - Clearing and Grubbing
Park Planning & Development Division Page 2 of 2
DIVISION 2
SECTION 02200 - EARTHWORK AND GRADING
PART 1 — GENERAL
1.01 Description of Work
A. The Contractor shall provide all labor, materials and equipment necessary to perform the work
items called for on the bid schedule.
B. The Contractor shall perform all excavation regardless of the type, nature, or condition of material
encountered, as specified or required in order to accomplish the construction.
1.02 City Furnished Materials
A. None, unless otherwise noted on the Bid Schedule.
1.03 Site Conditions
A. A geotechnical investigation may have been performed for the City in order to obtain relative data
concerning the character of material in and upon which the project is to be built. If an
investigation has been performed, the information will be available to the Contractor for
information purposes only, and is not to be considered a part of the Contract Documents. The
Contractor shall satisfy himself as to the kind and type of soil to be encountered and any water
conditions that might affect the construction of the project.
B. The locations of existing utilities are shown in an approximate way only and not all utilities may be
shown. The Contractor shall determine the exact location of all existing utilities prior to
conunencing work. The Contractor shall be fully responsible for any and all damages that might
be occasioned by his failure to exactly locate and preserve any and all utilities. If utilities are to
remain in place, the Contractor shall provide adequate means of support and protection during
construction.
C. Should drawn, or incorrectly drawn, piping or other utilities be encountered during excavation, the
Contractor shall advise the City within thirty (30) minutes of encountering the utility. The
Contractor shall cooperate with the City and utility companies in keeping respective services and
facilities in operation to the satisfaction of the respective owners. The City reserves the right to
perfornn any and all work required should the Contractor fail to cooperate with the respective
companies, and back charge the Contractor for any and all expenses.
D. The Contractor shall provide barricades and signs in accordance with the Uniform Manual of
Traffic Control Devices where applicable. The Contractor shall maintain all devices in a working
manner.
1.04 Fill Material
A. Excess fill material, including rock, gravel, sod, broken concrete or asphalt, plaster, etc., shall be
hauled off the site and disposed of in accordance with applicable State and local regulations.
City of Fort Collins Section 02200 — Earthwork and Grading
Park Planning & Development Division Page 1 of 5
22.0 PURCHASING RESTRICTIONS.
Purchasing restrictions: The Bidder's authorized signature of this Bid _
assures the Bidder's compliance with the City's purchasing restrictions. A
copy of the resolutions are available for review in the Purchasing and Risk
Management Division or the City Clerk's office.
A. Cement Restrictions: City of Fort Collins Resolution 91-121 requires
that suppliers and producers of cement or products containing cement
to certify that the cement was not made in cement kilns that burn
hazardous waste as a fuel.
23.0 COLLUSIVE OR SHAM BIDS.
Any Bid deemed by the City in its sole discretion to be a collusive or sham
Bid will be rejected and reported to authorities as such. Your authorized
signature of this Bid assures that such Bid is genuine and is not a
collusive or sham Bid.
24.0 BID RESULTS.
For information regarding results for individual Bids send a self-
addressed, self -stamped envelope and a Bid tally will be mailed to you.
Bid results will be posted in the Purchasing office seven (7) days after
the Bid Opening. w
END OF SECTION
.e
12/03 Section 00100 Page 8
B. Additional fill material, if required, shall be hauled to the site from off the site as a necessary part
of the work. Material composition shall be subject to the requirements of the specifications.
1.05 Testing and Inspections
Coordinate and schedule testing with City Representative.
PART 2 - MATERIALS
2.01 Soil Materials
A. Coarse -grained soils free from debris, roots, organic material, and non -mineral matter containing
v no particles larger than 4-inch size and classified as either:
1. Sands with fines (SM, SC) and less than 25 percent of the soil particles passing the No. 200
sieve, or
2. Clean sands (SW, SP)
3. Native soils as determined acceptable by the Engineer
2.02 Filter Fabric
A. Filter Fabric shall be Typar 3451 W, Mirafi 70OX or approved equal.
PART 3 - EXECUTION
3.01 Preparation
A. Field measurements: Before commencing work, locate all baselines and coordinates required for
control of the work, establish required grade staking for control of excavation, fill and
embankment construction. Filed verify by excavation the location all utility crossings, service
connections, and connections to existing lines before proceeding with earthwork.
B. Layout Lines and Levels:
1. The drawings indicate existing elevations and proposed elevations. The existing elevations
and proposed are given for the convenience of the Contractor to assist him in arriving at the
quantities of excavation, grading, backfilling etc.
2. Before earthwork operations are started, all construction items shall be completely staked out
+* for the Owner's approval. For any area with a two- percent slope or flatter, the Contractor
shall lay out a 50-foot on -center grid and calculate the exact elevation at every intersection of
the grid lines. These calculations will be approved by the Owner's Representative.
C. Removal of TopSoil: Strip existing earthen material (topsoil) to a depth of 4 inches over the entire
site. Stockpile on site in area approved by Owner's Representative. Keep topsoil segregated.
, - Place, grade, and shape stockpile for proper drainage.
3.02 Excavation
A. Prior to beginning excavation operations, accomplish all site preparation in accordance with these
specifications. Perform excavation of every description to the lines and grades indicated on the
drawings.
City of Fort Collins Section 02200 — Earthwork and Grading
Park Planning & Development Division Page 2 of 5
B. Complete excavation work to the grade elevations shown on the drawings for all areas to be paved.
3.03 Clearing the Site
A. All areas underlying new structures, paved areas, site fills and embankments shall be cleared of
stumps, shrubs, brush, and other vegetative growth.
B. Any material containing roots, grasses and other deleterious or organic matter generally found in
the top six inches of undisturbed natural terrain shall be stripped from all areas requiring
excavation, grading, trenching, subgrade preparation for foundations and embankment work. The
City will require stripped top soil deemed suitable for spreading over the finished grades to be
stockpiled and preserved until the finished grading operation, at which time it shall be spread
uniformly over areas to be seeded or sodded.
C. Upon completion of the project, completion of a particular phase of the project, or termination of
the use of any particular area, site, storage yard right-of-way or easement, the Contractor shall
promptly and neatly clean up the area and re-establish the ground to the contours required by the
project or conditions prior to project commencement.
3.04 Earth Fill Construction
A. The Contractor shall perform all grading to the lines and grades specified and/or established by the
Engineer, with an appropriate allowance for topsoil. All slopes shall be free of all exposed roots
and stones exceeding 3-inch diameter, which are loose and liable to fall. Tops of banks shall be
rounded to circular curves not less than 6-feet in radius.
B. Rounded surfaces shall be neatly and smoothly trimmed. Topsoil shall be replaced to a depth of
4-inclies in areas to be revegetated.
C. The Contractor shall protect the fill against freezing when atmospheric temperature is less than 35
degrees F (1 degree C).
3.05 Compaction
A. The Contractor shall meet minimum percentage density specified for each area classification as
follows. Percentage of Maximum Density Requirements: Compact soil to not less than the
indicated percentages of maximum density relationship determined in accordance with ASTM D
698.
Foundations, Paved Areas, Utilities and Sidewalks - 95 percent
2. Unpaved Areas - 90 percent
B. Control moisture content within 2% of optimum moisture content as determined by ASTM D 698.
Where subgrade or layer of soil material is too dry to permit compaction to the specified density,
uniformly apply water to surface of cut area, subgrade, or loosely placed layer of soil material.
Mix soil and applied water by blading, disking, or other methods to achieve uniform moisture
content throughout the soil mass to be compacted.
C. Remove and replace, or scarify and air dry, soil material that is too wet to permit compaction to
specified density. Soil material that has been removed because it is too wet to permit compaction
City of Fort Collins Section 02200 — Earthwork and Grading
Park Planning & Development Division Page 3 of 5
may be stockpiled or spread and allowed to dry. Assist drying by disking, harrowing or
pulverizing until moisture content is reduced to a satisfactory value.
D. Puddling is not an acceptable method of compaction.
3.06 Grading
A. Paved Areas: Iuunediately prior to placing structural pavements, shape area to the required
lines, grades, and limits to provide the finished elevations indicated and roll with an approved
heavy vibratory roller until compacted to the specified density. Maintain moisture content within
2% of optimum during final rolling and until subgrade is covered by subsequent construction.
Remove loose material and protect subgrade until covered. The subgrade under all paved areas
and the play area shall conform to the elevations shown on the drawings.
B. Landscape Area and Remainder of Site:
1. Rough grade areas as indicated on grading plan to 4 inches below finish grade.
After rough grading is finished, compacted and approved, scarify area to a depth of at
least 6 inches.
2. Place previously stockpiled topsoil in all areas within the limits of the project not
indicated to receive subsequent foundations, slabs on grade, walks, safety surfacing
or other similar materials.
3. Uniformly distribute topsoil on the disturbed area and evenly spread to a thickness of
4 inches deep after light compaction. Perforni spreading so that planting can proceed
with little additional soil preparation or tillage. Do not place topsoil when subgrade
is frozen, excessively wet, extremely dry or in a condition otherwise detrimental to
specified grading, seeding and planting specifications.
C. Finish Grading:
1. Grade all excavated sections, filled sections, construction disturbed areas and
adjacent transition areas to finish elevation. Make finished surfaces smooth,
compacted and free from irregular surface changes.
2. Unless indicated otherwise on drawings, finish grade area adjacent to sidewalks and
pavements to '/2 inch below finish elevation of sidewalk and pavement.
�^ 3. Remove all construction debris. Grades not otherwise indicated shall be uniform
levels or slopes between such points and existing finish grade. Abrupt change in
slopes shall be rounded.
3.07 Settlement
A. Where completed compacted areas are disturbed by subsequent construction operations or adverse
weather, the Contractor shall scarify the ground surface, re -shape, and compact to required density
prior to further construction.
' B. Any settlement in backfill, fill, or in structures built over the backfill or fill, which may occur
within the guarantee period in the General Conditions will be considered to be caused by improper
compaction methods and shall be corrected at no cost to the City. Any structure damaged by
settlement shall be restored to their original condition by the Contractor at no cost to the City.
City of Fort Collins Section 02200 — Earthwork and Grading
Park Planning & Development Division Page 4 of 5
3.08 Disposal of Excess Excavation and Waste Materials and Special Requirements
A. The Contractor shall dispose of all excess excavated material not required for fill on -site, as
directed by the Engineer.
B. The Contractor shall remove and be responsible for legally disposing of excess fill material not
placed on -site, waste materials, trash and debris.
C. The Contractor shall conduct all site grading operations and other construction activities to
minimize erosion of site soil materials. He/she shall be responsible to maintain streets/public
ROW daily by removing any spillage of dirt, rocks or debris from equipment entering or leaving
the site.
END OF SECTION
City of Fort Collins Section 02200 — Earthwork and Grading
Park Planning & Development Division Page 5 of 5
DIVISION 2
SECTION 02304 - AGGREGATE BASE COURSE
I2_10 �C];I0I:1:L11
1.1 Description of work
A. The current edition of the Colorado Department of Transportation Standard Specification Booklet
is referenced into these specifications.
PART 2— REVISIONS
A. Subsection 304.01 is revised to include the following:
This work shall consist of placing Aggregate Base (Class 5) over previously prepared subgrade
approved by the Engineer. Aggregate Base will be used as fill under the curb, gutter, and
sidewalks if there is not any acceptable material onsite.
The proposed material shall meet the following minimum requirements:
LL Maximum: 30
PI Maximum: 6
"R" Value Minimum: 78
The minimum strength coefficient of the Class 5 Aggregate Base shall be 0.12.
B. Subsection 304.07 is revised to include the following:
Aggregate Base Course will be measured by the ton at proper moisture. Quality will be adjusted
accordingly if moisture is too high. Haul and water necessary to bring mixture to optimum
moisture will not be measured paid for separately, but shall be included in the price for Aggregate
Base.
C. Subsection 304/08 is revised to include the following:
The accepted qualities of Aggregate Base Course will be paid for at the contract price per ton.
D. Payment will be made under:
Pay Item Pay Unit
304-01 A.B.C.(C-5) Tons
The above prices and payments shall include full compensation for furnishing all labor, materials,
tools, equipment, and incidentals and for doing all work involved in placing Aggregate Base
Course including haul and water, complete -in -place, as shown on the plans, as specified in the
specifications, and as directed by the Engineer.
END OF SECTION
7
City of Fort Collins Section 02304 — Aggregate Base Course
Park Planning & Development Division Page 1 of 1
-1
DIVISION 2
SECTION 02520 — PORTLAND CEMENT CONCRETE PAVING
PART 1 -GENERAL
Scope
A. Furnish all labor, materials, supplies, equipment, transportation, and perform all operations in
connection with and reasonably incidental to complete installation of concrete paving as shown on
the drawings and as specified herein. Items of work specifically included are:
B. Subgrade preparation for plazas, walks, ramps, playground curbs and headers.
C. Form work.
D. Reinforcement.
E. Surface finish.
F. Construction, expansion and control joints.
G. Curing.
H. Concrete plazas, sidewalks, ramps, playground curbs and headers.
I. Interior slabs -on -grade in restroom, etc.
Work Not Included
J. Items of work specifically excluded or covered under other sections:
K. Excavation and backfill.
L. Earthwork and grading.
M. Cast -in -place structural concrete or precast concrete, such as foundations, drainage appurtenances,
and pad and building.
N. Joint sealers.
Related Work
A. Division 2 — Site Work:
a. Section 02050— Demolition.
b. Section 02200 — Earthwork/Grading.
c. Section 02220 — Trenching, Backfilling, and Compaction.
B. Not Used
C. Division 7 — Thermal and Moisture Protection:
I . Section 07000 — Joint S<<.ilers.
References
A. ACI 301 — Specifications for Structural Concrete for Buildings.
B. ASTM C33 — Concrete Aggregate.
C. ASTM C150 —Portland Cement.
City of Fort Collins SECTION 02520 — Portland Cement Concrete Paving
Park Planning & Development Division Page 1 of 1
D. ASTM C260 — Air Entraining Admixtures for Concrete.
E. ASTM C309 — Liquid Membrane — Forming Compounds for Curing Concrete.
F. ACI 304 — Recommended Practice for Measuring, Mixing, Transporting, and Placing Concrete.
G. ACT 305R— Hot Weather Concreting.
H. ACI 306R — Cold Weather Concreting.
I. ACI 308 — Standard Practice for Curing Concrete.
J. ACI 309 — Reconnnended Practice for Consolidation of Concrete.
K. ACI 318-89 — Building Code Requirements for Reinforced Concrete.
Regulatory Requirements
A. Conform to applicable code of governing authority for paving work within public right-of-way.
Tests
A. Submit proposed mix design to testing laboratory for review prior to commencement of work. For
standard premix concrete mixes, the supplier's quality control records may be substituted for job
mix testing.
B. Concrete Testing Service: Contractor will engage a testing laboratory to perform materials
evaluation, testing and design of concrete mixes as approved by Owner. All testing costs will be
borne by the Contractor. Should any test(s) fail to meet the specifications, the cost of the failed
test and all subsequent testing shall be borne by the Contractor.
C. Coordinate and schedule sampling testing during concrete placement with City Representative.
Submittals
A. Submit product data under provisions of Section 01600 — Materials and Equipment.
B. Submit data on admixtures and curing compounds.
C. Submit a ten pound sample of aggregate, for exposed aggregate finish.
D. Submit manufacturer's data on leave -in -place construction joint form.
E. Submit sample chips of specified colors indicating pigment number and required dosage rate.
Submittals are for general verification of color and may vary somewhat from concrete finished in
field according to Specifications.
F. Submit samples of colored sealers.
Test Panels
A. Provide a 3' x 3' test panel for finish and tooling of joints for Owner approval. Provide one panel
for each pavement type specified. In casting the panels, use personnel and methods to be
employed on the work.
B. If sample disapproved, cast additional samples until approval is obtained. Maintain test panel on
site until finished work is accepted. Test panel will represent minimum workmanship standard.
C. Work completed prior to text panel approval shall be subject to removal and replacement at
Owner's request.
City of Fort Collins SECTION 02520 — Portland Cement Concrete Paving
Park Planning & Development Division Page 2 of 2
PART 2 MATERIALS
2.01 Concrete Materials
A. General: Provide materials of same brand and source throughout the project unless otherwise
noted.
B. Portland Cement: ASTM C150, Type I or Type I/II, gray color.
C. Aggregates: ASTM C33, nomial weight. In addition, the combined aggregate shall comply with
the following gradation, shown in percent passing.
Sieve Size /-Inch Nominal Maximum Size
'/ Inch 90 — 100
3/8 Inch 60 — 80
No. 4 40 — 60
No. 8 30 — 45
No. 16 20 — 35
No. 30 13 — 23
No. 50 5 — 15
No. 100 0-5
D. Coarse Aggregate for Exposed Aggregate Finish: 5/8-inch maximum size; rounded shape, ratio of
maximum to minimum dimensions not to exceed 2.5:1; color to be tan to brown, no more than 2%
white or black combined, no pink, no red, no green.
E. Water: Clean and not detrimental to concrete.
2.02 Pigments for Integrally Colored Concrete
A. Manufacturer
1. Davis Colors manufactured by Davis Colors: phone (213) 269-7311.
2. Substitutions: Comply with Section 01600 for substitution request procedures.
B. Materials: Pigments shall contain pure, concentrated mineral pigments especially processed for
mixing into concrete and complying with ASTM C979.
C. Packaging: If pigments are to be added to mix at Site, furnish pigments in pre -measured Mix -
Ready disintegrating bags to minimize job site waste.
D. Colors: Concrete mix shall contain the dosage rate of pigments indicated in this specification.
Dosage rate shall be based on weight of Portland cement, fly ash, silica fume, lime and other
cementitious materials but not aggregate or sand. Refer to the site plans for locations of the
various colors of concrete.
2.03 Form Materials
A. Slab Edges: Two by lumber permitted for surfaces not exposed to view in the final work. Use
concrete -form grade hardboard, "plyform" grade plywood, or metal for forming surfaces exposed
to view. Forms shall be straight and sufficiently stiff and well braced to meet line tolerances
specified in Part 3.
B. Keyed Joint Form: Wooden key or leave -in -place metal construction joint form.
C. Form Coatings: Commercial form -coating compounds that will not bond with, stain, or adversely
affect concrete surfaces, and will not impair subsequent treatments of concrete surfaces.
City of Fort Collins SECTION 02520 - Portland Cement Concrete Paving
Park Planning & Development Division Page 3 of 3
�,..,d..........�...�,..� _.> ..�..__,... +wss' sw: _ • -ms '�"aka' ".' "��. .�.. •n4 aan..,x..n».. ,.�ri+.a`a`�"xr ...tz
2.04 Reinforcement
A. Reinforcing Steel: ASTM A615; 60 ksi yield grade; deformed billet -steel bars, uncoated finish.
B. Fibermesh: Bundled, fibrillated, virgin polypropylene fibers manufactured for use in premix
concrete and having the following characteristics:
1. Special Gravity: 0.91.
2. Tensile Strength: 70 to 100 ksi.
3. Fiber Lengths: 1/2 inch,'/ inch.
4. Accepted Materials: "Fibermesh" by Fibermesh Company of Chattanooga, TN; or "Forta
CR" by Forta Corporation of Groove City, PA.
C. Dowels: ASTM A615; 40 or 60 ksi yield grade, plain steel, uncoated finish; matched sleeve and
cap one end. Provide dowel basket to hold dowels in parallel alignment.
2.05 Admixtures
A. General: Unless specified in the mix or directed in Part 3, no admixtures shall be used without
approval of the Owner's Representative. Do not use admixtures that world result in mixing water
with a concentration of more than 150 ppm of chloride ion.
B. Air Entraining: ASTM C260.
C. Water Reducing: ASTM C494, Type A.
D. Accelerator: Nonchloride, ASTM C494, Type C or E.
E. Retarder: ASTM C494, Type B or D.
F. Color Agent: Davis Colors of Los Angeles, California.
2.06 Related Materials
A. Expansion Joint Filler: ASTM D1752, closed cell polyethylene, '/2 inch thickness.
B. Joint Sealant: See Section 07900,
C. Surface Retardant: Surface retarding agent intended for exposed aggregate. Retardx-SRO" by
•• Prokrete of Denver, Colorado, or approved equal.
- D. Curing Compound for Standard Non -Colored Walks, Curbs, Gutters, Etc: White pigmented, wax -
resin based compound, ASTM C309, Type I, Class A. Recorrimended by manufacturer for use on
exterior sidewalks and driveways.
E. Curing Compound for Concrete with Coloring Agent: Davis Seal Color to match colored
concrete.
F. Curing Compound and Sealer for Exposed Aggregate Concrete: Acryseal by Prokete Industries of
Denver, Colorado.
G. Curing Compound for Interior Slabs: Protex Promulsion 100 or equal.
H. Interior Floor Sealer: Protex Triple Seal or equal.
st. 2.07 Concrete Mix
A. Mix concrete in accordance with ASTM C94.
1. Provide non -colored concrete for exterior slabs on grade, sidewalks, curb and ¢utter,
walls, aprons and ramps (except panel inserts) with the following characteristics:
City of Fort Collins SECTION 02520 - Portland Cement Concrete Paving
Park Planning & Development Division Page 4 of 4
Unit
Measurement
a. Compressive Strength
3,500 psi
at 28 days
b. Minimum Cement
564 Ib./cy
c. Maximum Aggregate Size
1 '/z inches
d. Fibrous Reinforcement
'/ lb./cy
e. Air Entrainment
4% to 6%
f. Maximum Water/Cement Ratio
0.46
g. Maximum Slump
4 inches
2. Provide colored concrete for plazas,
ramps and other flatwork with the following
characteristics:
Unit
Measurement
a.
Compressive Strength
3,500 psi
at 28 days
b.
Minimum Cement
564 lb./cy
c.
Maximum Aggregate Size
1 %z inches
d.
Fibrous Reinforcement
/a Ib./cy
e.
Air Entrainment
4% to 6%
f.
Maximum Water/Cement Ratio
0.46
g.
Coloring Agent
Per manufacturer's recommendations
(refer to Definition of Bid Items and/or Drawings for
designated colors)
h.
Maximum Slump
4 inches
3. Provide non -colored concrete for plavground curb with the following characteristics
Unit
Measurement
a.
Compressive Strength
3,500 psi
at 28 days
b.
Minimum Cement
564 lb./cy
c.
Maximum Aggregate Size
5/8 inches
d.
Air Entraimnent
5% to 8%
e.
Maximum Water/Cement Ratio
0.46
f.
Maximum Slump
2.5 inches
4. Provide non colored concrete for interior slabs -on -grade with the following characteristics
Unit
Measurement
a. Compressive Strength
3,500 psi
at 28 days
b. Type I or II Cement
564 lb./cy
c. Maximum Aggregate Size
/ inches
d. Maximum Air
3%
e. Water reducing agent
3 oz. Minimum to 4 oz maximum
per 100 pounds.; or as recommended
by manufacturer to obtain
desired air content
5. Provide concrete for colored trail flatwork and paving with the following characteristics:
Unit Measurement
a. Compressive Strength 3.500 psi
at 28 days
b. Minimum Cement 564 lb./cy
City of Fort Collins SECTION 02520 — Portland Cement Concrete Paving
Park Planning & Development Division Page 5 of 5
SECTION 00300
BID FORM
PROJECT: PLEASANT VALLEY LAKE AND CANAL TRAIL; BID No. 5908,
Place c,c 4 6, I�i. s Co
Date u. H- aS
1. In compliance with your Invitation to Bid dated `1 N•o5
and subjectto all conditions thereof, the undersigned
CDA-% rU4,Xxs 4nc a ** Corporation L r r r; , ; j r mw 1,
P. J.cu.ui-ire, or )** authorized to do business
in the State of Colorado hereby proposes to furnish and do everything
required by the Contract Documents to which this refers for the
construction of all items listed on the following Bid Schedule or Bid
Schedules.
2. The undersigned Bidder does hereby declare and stipulate that this proposal
is made in good faith, without collusion or connection with any other
person or persons Bidding for the same Work, and that it is made in
pursuance of and subject to all the terms and conditions of the Invitation
to Bid and Instructions to Bidders, the Agreement, the detailed
Specifications, and the Drawings pertaining to the Work to be done, all of
which have been examined by the undersigned.
3. Accompanying this Bid is a certified or cashier's check or standard Bid
bond in the sum of 5U% oT 4a4al -6,4 ($
in accordance with the Invitation To Bid and
Instructions to Bidders.
F=
A. The undersigned Bidder agrees to execute the Agreement and a Performance
Bond and a Payment Bond for the amount of the total of this Bid within
fifteen (15) calendar days from the date when the written notice of the
award of the contract is delivered to him at the address given on this Bid.
The name and address of the corporate surety with which the Bidder
proposes to furnish the specified performance and payment bonds is as
follows: /J
f 1��.rel�coers red-, �i 1e-�vn� � u
5. All the various phases of Work enumerated in the Contract Documents with
their individual jobs and overhead, whether specifically mentioned,
included by implication or appurtenant thereto, are to be performed by the
CONTRACTOR under one of the items listed in the Bid Schedule, irrespective
of whether it is named in said list.
6. Payment for Work performed will be in accordance with the Bid Schedule or
Bid Schedules subject to changes as provided in the Contract Documents.
7. The undersigned Bidder hereby acknowledges receipt of Addenda No. ,
through _I .
7/96 Section 00300 Page 1
==Aawn. ,�'.�y., ` .,,a �e,..
c. Maximum Aggregate Size
1 '/2 inches
d. Fibrous Reinforcement
/ lb./cy
e. Air Entrairmlent
4% to 6%
f. Maximum Water/Cement Ratio
0.46
g. Coloring Agent
2 lbs. per sack of Yosemite Brown Color
h. Maximum Slump
4 inches
B. Pozzolanic mineral admixture is not permitted.
C. Use accelerating admixtures in cold weather as directed in Part 3.
D. Use set -retarding admixture during hot weather as directed in Part 3.
E. Water reducing agent is permitted.
2.08 Selection of Proportions
A. Mix Design: Cost of concrete mix design is responsibility of Contractor.
B. Selection of Proportions: Use method of ACI 301 3.9. Proportioning base on method of ACI 301
3.10 not allowed.
I . Field test records used for documentation of the average strength produced by a propos mix in
accordance with ACI 301 3.9.3.2 shall, in addition to the requirements listed, comply with the
following:
a. The test record shall represent production concrete from a single design mix produced
during the past year.
b. The test record shall represent concrete proportioned to produce the maximum slur
allowed by these specifications, and for air -entrained concrete, within a +0.5% of t
maximum air content allowed.
2. Mixes proportioned on the basis of trial mixtures shall meet the provisions of ACI 301 3.9.3.3.
PART 3 EXECUTION
3.01 Supgrade Preparation
A. Shape and compact subgrade to match appropriate detail. Compact to 95% density as measured by
ASTM D698. Coordinate with Section 02200 — Earthwork, Article 3.05, Compaction.
B. Where subgrade cannot be compacted, remove subgrade. Replace with bed course. Compact to
95% density as measured by ASTM D698.
C. Moisten subgrade to minimize absorption of water from fresh concrete. Subgrade shall not be
muddy, soft, frozen, or covered with standing water when concrete is placed.
3.02 Form Work
A. General: Design, construct, and brace forms in accordance with ACI 301 and ACI 347. In
addition to those requirements, forms shall be placed and braced so the finished edges and joints
meet the tolerances listed later in this section.
B. Preparation of Form Surfaces:
I . Clean reused forms of concrete matrix residue; repair and patch as required to return forms to
acceptable surface condition.
2. Coat contact surfaces of forms with specified form -coating compound before reinforcement is
placed. Apply form -coating compound according to manufacturer's instructions. Do not
City of Fort Collins SECTION 02520 — Portland Cement Concrete Paving
Park Planning & Development Division Page 6 of 6
r. �vnT ... ...ti. L . �e.�a .. .x :ie ... , e..- s .w eq` v.!. .. '.... ....t .. n. t.._ r
allow excess form -coating material to accumulate in forms or to come in contact with concrete
surfaces against which fresh concrete will be placed.
C. Slipforning: Slipforming of vertical curb and gutter sidewalks is permitted.
D. For Surfaces Exposed To View: Form faces shall be free from raised grain, tears, worn edges,
patches, dents, or other defects which would impair texture of the concrete surfaces. Minimize
number of seams in form material, and arrange seams in an orderly manner.
3.03 Reinforcement and Embedments
A. General:
1. Fabricate, position, and secure reinforcement and embedded items according to ACI 301 and
ACI 315. Coordinate with other sections for locations, instructions, or equipment for
embedded items.
2. Shop drawings are not required.
3. Welding reinforcement is not permitted.
4. In the event of discrepancy, immediately notify the Owner's Representative. Do not proceed
with installation in areas of discrepancy until all such discrepancies have been fully resolved.
B. Field -Bending of Reinforcement: Reinforcement partially embedded in concrete shall not be
field -bent, except as noted on the drawings or specifically permitted by the Owner's
Representative.
C. Inspection of Reinforcement: Completed installation of concrete reinforcement must be reviewed
by the Owner's Representative before depositing concrete.
D. Unless otherwise indicated, place reinforcement where required at top of slabs on grade. Provide
%a -inch minimum cover over reinforcement.
E. Dowels: Grease sleeves, insert dowels and through form, secure dowel basket against movement.
F. Notches for Sleeving: Notch both vertical sides of walk or slab where sleeving occurs.
G. Welded wire fabric shall be overlapped one full mesh and tied.
H. Fibrous Reinforcement:
1. Add fibrous concrete reinforcement to concrete materials at the time concrete is batched in
amounts in accordance with approved submittals for each type of concrete required.
2. Mix batched concrete in accordance with manufacturer's reconmiendations for uniform and
complete dispersion.
3.04 Joints
A. General: Place joints in accordance with ACI 301. Conform to the tolerances listed later in Part
3.
B. Isolation/Expansion Joints: Isolation joint and expansion joint are synonymous for concrete
paving.
1. Place isolation joints where work abuts existing walls, curbs and structures, and where shown
on the drawings.
2. Interrupt reinforcement at isolation joint. Install dowels only where indicated on drawings.
3. Joint filler shall extend full depth of the slab. Hold back filler from top of slab as required for
sealant. Attach joint filler to first placement.
4. Seal all expansion joints per Section 07900.
City of Fort Collins SECTION 02520 — Portland Cement Concrete Paving
Park Planning & Development Division Page 7 of 7
. ...:tr„a °XuAixmr =
C. Keyed/Construction Joints: Keyed joint and construction joint are synonymous for concrete
paving.
1. Reinforcement, if required, shall continue through the joint.
2. Install where indicated on drawings, or where required by concrete delivery or finishing rate.
3. Key first placement. Key shall be 1'/2 inches wide and inches deep.
4. After first placement has hardened, clean and roughen face. Install control joint form at top of
slab.
5. Subject to Owner's Representative approval; manufactured leave -in -place cold joint form may
be used.
D. Control/Score Joint: Control joint and score joint are synonymous for concrete paving.
1. Control joints shall penetrate 1/3 of slab thickness.
2. Sawn Joints: Control joints on play area curb shall be sawn. Kerf shall be 3/16-inch wide.
Start cutting as soon as concrete is able to be sawn without dislodging aggregate. Complete
cutting before shrinkage cracks occur. Joints perpendicular to walls may be less than required
depth within 6 inches of the wall, and may stop 2 inches from the wall. Wash slung from
concrete to avoid staining of slab.
3. Tooled Joints: Control joints may be cut into the plastic concrete during finishing operations.
Tooled joints shall have '/ radius, and shall not incorporate a troweled edge unless
specifically noted on the drawings.
4. Formed control joints are permitted only in conjunction with keyed joints.
5. Unless otherwise indicated, provide control joints at the following intervals:
Use Type Maximum Spacing
Uncolored Exterior & Tooled broom Symmetrically placed:
Interior Slabs, Sidewalks over joint 10' maximum or 1 %2
times width of walk,
whichever is smaller
Curb and Gutter Tooled joints 10' maximum
Pans Tooled joints 15' maximum
Play Area Curb & Header Tooled joints 10' maximum
Concrete Tooled joints 10' maximum
3.05 Concrete
A. Preplacement hrspection: Form work installation, reinforcing steel placement, and installation of
all items to be embedded or cast in, to be verified by the Owner's Representative prior to
placement.
B. General: Comply with ACI 301, ACI 304, and as herein specified.
C. Added Water: Concrete mix has been designed to a specific water cement ratio in order to
enhance durability of the final product. Do not add water at the job site or concrete will not be
accepted.
D. Cold Weather Placement: When depositing concrete after the first frost or when the mean daily
temperatures area below 40 degrees, follow recommendations of ACI 306 as modified herein. Use
specified accelerator. Maintain concrete temperature at a minimum of 55 degrees for not less than
City of Fort Collins SECTION 02520 — Portland Cement Concrete Paving
'I Park Planning & Development Division Page 8 of 8
72 hours after depositing. Do not place concrete without approval of the Owner's Representative
on days when temperature at 9:00 a.m. is below 30 degrees. Job -cured cylinders for verification of
strength and/or the adequacy of the Contractor's protective methods will be required.
E. Hot Weather Placement: When depositing concrete in hot weather, follow recommendations of
ACI 305 as modified herein. When the air temperature is expected to exceed 90 degrees, the
Contractor shall obtain acceptance from the Civil Engineer or Owner's Representative of the
procedures to be used in protecting, depositing, finishing, and curing the concrete. The
temperature of concrete at the time of placement shall not exceed 90 degrees. Protect to prevent
rapid drying. Start finishing and curing as soon as possible. Specified water reducing retarding
admixture may be used. The use of continuous wetting or fog sprays may be required by the
Owner's Representative for 24 hours after depositing.
F. Placing: Deposit and consolidate concrete slabs in a continuous operation, within the limits of
construction joints, until the placing of a panel or section is completed. Deposit concrete as nearly
as practicable in its final location to avoid segregation.
G. Consolidation: Consolidate concrete with internal vibrators with a minimum frequency of 7,000
rpm. Maintain one standby vibrator for every three vibrators used. Consolidate according to ACI
309. Do not transport concrete with vibrators. Work concrete into comers and around
embedments and reinforcement.
H. Surface Leveling: Strike off and level surface with screed of sufficient length to span the slab.
On slabs greater than 15 feet wide, use intermediate screed strips.
I. Integral colored concrete: Add color by weight directly into the mixer along with the aggregate,
cement. and water while the mixer is operating at mixing speed. Continue mixing for 5-10 minutes
or from 50 — 100 revolutions.
3.06 Finishes
A. Float Finish: After surface stiffens enough to support the operation, float with hand floats or
powered disc floater. Use magnesium float; do not use wood float on air entrained concrete.
Check surface planeness with a 10-foot straight edge, applied at not less than two different angles.
Cut down high spots and fill low spots to produce a surface with Class B tolerance. Refloat the
slab to a uniform sandy texture.
B. Broom Finish: Concrete flatwork shall receive a heavy broom finish applied at a right angle to the
direction of travel. The plaza area shall have smooth troweled joints, 1 %2 inches from the
centerline of the joint, to result in a total trowel width of 3 inches. All other flatwork shall have
broom finish over joints.
C. Exposed Aggregate Finish: Irnrnediately after floating, apply surface retardant. Apply retardant
uniformly. Cover with polyethylene sheet to retain moisture. When mortar is hard enough to
retain aggregate but soft enough to be removed by brushing, wash the surface with water and
remove mortar from surface aggregate by brushing. Do not dislodge aggregate.
D. Coordinate rate of concrete placement with pace of washing crew.
E. Formed Finishes:
1. Surfaces Not Exposed to View: Patch tie holes and defects. Chip off fins greater than % inch
in height.
2. Surfaces Exposed to View: Patch tie holes and defects. Completely remove fins.
F. Schedule of Finishes:
1. Curbs, gutters, ramps within ROW — per City Specifications.
2. Sidewalk— heavy broom finish.
City of Fort Collins SECTION 02520 — Portland Cement Concrete Paving
Park Planning & Development Division Page 9 of 9
_.n..e.J.e®®...,...�.±.ws.-. •�—^—�. �••—* %L`t. �Ak<. _unzr�nd •<. ;ti't�41.1'`.�� � Su`r:FfYWS$..�". ••••me: �xvearobwa_ wez� _ E isi�?.14c1<Siww4nliro'1`�R;:.4':•
3. Plaza paving — as shown on plans.
4. Playground curbs and header — exposed aggregate finish.
5. Interior slabs at restroom — medium broom finish.
G. Notch both vertical sides of concrete flatwork to indicate location of irrigation sleeves.
3.07 Curing/Sealing
A. Apply curing compound within 30 minutes of completing finish. Follow manufacturer's
recommendations for applying compound. Reapply in areas exposed to rain within 3 hours of
initial application. Maintain continuity of coating and repair damage during 7-day curing period.
Follow manufacturer's instructions for sealing interior slabs.
B. Integral colored concrete is to be cured with the matching Davis Color Seal (if called for in section
01800 Definition of Bid Items). Follow manufacturer's recommendations for application.
3.08 Tolerances
A. Surface Planeness: Unless otherwise specified, produce slabs with a Class B tolerance.
1. Finishes with Class B tolerances shall be true planes within '/a inch in 10 feet, as determined
by a 10-foot straight edge placed anywhere on the slab in any direction.
2. Slope interior slabs to drains as indicated.
B. Formed Surfaces, Joints, and Embedments: Unless otherwise specified, the finished work shall
meet the following tolerances:
Variations of formed, or cut or tooled linear element
a. In 20 feet: '/2 inch.
b. For entire length: 1 inch.
3.09 Field Quality Control
A. Field inspection and testing will be performed under provisions of Paragraph 1.06, Tests, and as
specified below.
B. Concrete Tests:
I . Shall be provided by the Contractor and shall be accordance with requirements of ACI 301,
�- Chapter 16 — Testing, except as noted or modified in this section.
a. Strength test.
i. Mold and cure four cylinders from each sample.
ii. Test one at 7 days and one at 14 days for information and one at 28 days for
acceptance. Keep the remaining one as a spare to be tested as directed by the Owner.
b. Minimum samples.
i. Collect the following minimum samples for each 28-day strength concrete used in the
work for each day's placing:
r-
uantit Number of Samples
50 cubic yards or less one
50 to 100 cubic yards two
100 cubic yards or more two plus one sample for each
additional 100 cubic yards
c. Sample marking.
i. Mark or tag each sample of compression test cylinders with date and time of day
cylinders were made.
City of Fort Collins SECTION 02520 — Portland Cement Concrete Paving
Park Planning & Development Division Page 10 of 10
ii. Identify location in work where concrete represented by cylinders was placed.
iii. Identify delivery truck or batch number, air content, and slump.
d. Slump test.
Conduct test for each strength test sample and whenever consistency of concrete appears
to vary.
e. Air content.
Conduct test from one of first three batches mixed each day and for each strength test
sample.
C. Acceptance of Concrete:
1. If the average of three consecutive 7-day tests falls below the specified 7-day strength, the
Owner shall have the right to require conditions of temperature and moisture necessary to
secure the required strength and may require core tests in accordance with ASTM C-42.
2. Strength level of concrete will be considered satisfactory so long as average of all sets of three
consecutive strength test results equals or exceeds specified 28-day strength and no individual
strength test result falls below specified strength by more than 500 psi.
D. Failure of Test Cylinder Results:
1. Upon failure of the 28-day test cylinder results, Owner may require Contractor, at his expense,
to obtain and test at least three cored samples from area in question.
2. Concrete will be considered adequate if average of three core tests is at least 85 percent of,
and if no single core is less than 75 percent of the specified 28-day strength.
3. Upon failure of core test results, Owner may require Contractor, at his expense, to perform
load tests as specified in ACI 318, Chapter 2.
4. In the event an area is found to be structurally unsound, the Owner may order removal and
replacement of concrete as required. The costs of the core tests, the load test and the
structural evaluation shall be borne by the Contractor.
5. Fill all core holes with a non -shrink grout as Master Builders Masterflo 713 or approved
equal.
E. Maintain records of placed concrete items. Record date, location of pour, quantity, air
temperature, and test samples taken.
3.10 Integral Color Schedule
LOCATION
DAVIS COLOR
DOSAGE/PIGMENT
FINISH
Poudre Trail
Yosemite Brown
21bs 641
Heavy Broom
END OF SECTION
City of Fort Collins SECTION 02520 - Portland Cement Concrete Paving
Park Planning & Development Division Page 11 of 11
zta:' xir': ae&:r :.. .. � i. • .:h.3 :�`'u�v` i.. .._ � .� . $... sa�ti'r�t i u..�...sir��« � � .�,..
DIVISION 2
SECTION 02850 - PEDESTRIAN AND LIGHT VEHICLE BRIDGE - IPE DECKING
PART 1-GENERAL
1.01 SECTION INCLUDES
A. This section contains requirements for a fully engineered clear span bridge and shall be the
minimum standards for design and construction.
B. Clear span length and width of the bridge shall be 32 feet and 8 feet respectively.
1.02 RELATED SECTIONS
Section 02210 Earthwork and grading
Section 02221 Trenching, backfilling, and Compaction
1.03 QUALITY ASSURANCE
A. Bridge shall meet the referenced standards as called for in the following paragraphs.
B. Bridge design shall be certified by a Registered Colorado Professional Engineer.
1.04 SUBMITTALS
A. _Submit complete shop Drawings to the ENGINEER for review.
B. Submit manufacturer's certification of compliance with referenced standards.
1.05 PRODUCT DELIVERY AND HANDLING
A. Coordinate delivery requirements with manufacturer.
B. Comply with manufacturer's requirements for unloading, lifting, and placement.
1.06 DESIGN REQUIREMENTS
A. Railing: Minimum height of 54" (top of truss top chord).
B. Maximum horizontal opening in railing of nine inches.
C. Loading Design: Uniform live load of 60 psf. Concentrated live load of 10,000 pounds vehicle
weight on bridge plus thirty percent (30%) impact. Minimum wind load of 25 psf. Horizontal
pressure as if enclosed surface. Railing load of 50 pounds per lineal foot of horizontal load.
D. Mounting plates shall allow for thermal expansion.
E. All allowable design stresses shall be in compliance with the specifications of the design,
fabrication, and erection of structural steel for buildings by the American Institute of Steel
Construction AISCF and UBC.
City of Fort Collins Section 02850 - Pedestrian and Light Vehicle Bridge - IPE Decking
�. Park Planning & Development Division Page 1 of 4
F. Sizes:
Length: 32 feet.
Clear unobstructed inside width: 8' minimum.
Vertical members shall be spaced 48" on center with odd panel dimensions divided between
each end of the truss.
Railings: Install for full length of bridge.
Camber: Five percent (5%) of %a of span (if required).
Nominal 2"x 6" wood rub rails on inside of bridge shall be placed 42" above the top of the
bridge deck.
PART PRODUCTS
`XiS M y_1-1 1.7 lNe\ i ld k
A. General
1. Workmanship, fabrication, and shop connections shall be in accordance with AWS and AISC
specifications.
2. All welding shall be done by welders certified for AWS, D.I structural welding requirements.
3. Welding electrodes for self -weathering, corrosion -resistant steel shall have the same weathering
characteristics such as E5018 or equivalent.
4. All boldly exposed members shall have mill scale removed according to steel strictures
preparation specifications 96 Conunercial Blast Cleaning SSPC-SP6-63.
A. Materials
Metal Fabrication: Bridge to be fabricated from high strength tow -alloy atmospheric corrosion -
resistance ASTM A606 type 4 steel, self -weathering, (U.S.S. Cor Ten) ASTM A242 or ASTM
A588 structural steel shapes and tubing (FY=50,000 psi.). Bolts and nuts shall be in accordance
with specifications for structural joints using ASTM A325 or A490 bolts. Anchor bolts A307
or A36. E8018 series electrodes of equivalent for welding. Material thickness and design of
member shall be frilly engineered for the length and style of each bridge requirement specified.
2. Hardwood Decking: All decking shall be frill thickness planks unless approved otherwise.
Wood decking shall be naturally durable hardwood Ipe (Tabebuia Spp Lapacho Group).
All planks shall be partially air dried to a moisture content of 15% to 20%, and shall be
supplied S4S (surfaced four sides), E4E (eased four edges), with the edges eased to a
radius of 1/8". Measured at 30% moisture content, the width and thickness shall not vary
from specified dimensions by more than ± 0.04 inches. All planks shall be supplied with
the end sealed with "Anchorseal" Mobil CER-M or an equal aquious wax log sealer.
All plariks shall be graded as FEQ-CAH (First Export Quality -Clear All Heart) grading
roes, defined as follows:
Lumber shall be graded both faces and both edges.
Lumber shall be straight grained, maximum slope of grain to be 1:10.
City of Fort Collins Section 02850 - Pedestrian and Light Vehicle Bridge - IPE Decking
Park Planning & Development Division Page 2 of 4
Lumber shall be parallel cut without heart centers or sapwood.
Lumber shall be in sound condition, free from wormholes or knots.
Allowable Imperfections are:
All faces: Natural drying checks, Discoloration caused by weathering or
chemical reaction, Bow or Spring which can be removed using normal
installation methods and tools.
Imperfections Not Allowed:
Longitudinal heart cracks, Internal cracks, Firm or Soft sap wood, Splits, End
splits, Ring shades, Fungi affects (blue to gray, brown to red, white to yellow, or
incipient decay), Deformation (twisting or cupping) which cannot be removed
using normal installation methods and toots.
All planks shall meet or exceed the following mechanical properties (based on the 2"
standard) as defined by the U.S. Forest Products Laboratory publications and testing data:
MC% Modulus of Rupture Modulus of Elasticity Max. Crush Strength
12% 22,360 psi 3,140,000 psi
13,010 psi
Janka side hardness is 3680 lbs. at 12% moisture content
Average air-dry density is 66 to 75 pcf.
Basic specific gravity is 0.85 - 0.97.
All planks shall be naturally fire resistant without the use of any fire resistant
preservatives to meet NFPA Class A and UBC Class 1.
Planks shall be supplied that meet or exceed the Static Coefficient of Friction for both
neolite and leather shoes in accordance with ASTM Test Method C 1028-89.
SHOE MATERIAL
Neolite
Leather
FORCE IN POUNDS
DRY WET
0.73 0.69
0.55 0.79
For transverse wood decking, wheel loads shall be assumed to act on one plank only. The
wheel loads shall be distributed on the plank along a length equal to the tire print width.
The plank shall be designed for shear and bending in accordance with the support
conditions and spacing. For design, the following unfactored allowable stresses shall be
used:
Allowable Bending = 3700 psi
Allowable Shear = 320 psi
a.
Modulus of Elasticity = 3,000,000 psi
At time of installation, planks are to be placed tight together with no gaps.
-� Every plank must be attached with at least one fastener at each end.
City of Fort Collins Section 02850 - Pedestrian and Light Vehicle Bridge - IPE Decking
Park Planning & Development Division Page 3 of 4
All fasteners to be zinc plated. Self -tapping screws or hex -head bolts, with a steel plank
hold down, are to be used at the ends of planks. Self -tapping screws or carriage bolts are
to be used as interior connection fasteners when required. Power actuated fasteners will
not be allowed.
Planks are to be drilled prior to installation of bolts and/or screws.
In addition to at least one fastener at each end of every plank (typical for all installations),
planks for bridges with widths of 72" to 143" shall be attached with a minimum of two
fasteners at a location approximately near the center of the bridge width. Bridges wider
than 143" are to have two fasteners located at a minimum of two interior stringer
locations, approximately at the third points of the bridge width.
Attachments at the ends of the planks may be modified as required when
obstructions, such as interior safety system elements, prevent installation of the specified
hold down system.
END OF SECTION
City of Fort Collins Section 02850 - Pedestrian and Light Vehicle Bridge - IPE Decking
Park Planning & Development Division Page 4 of 4
J
CQNTRACTQ
BY:
ADDRESS: 19&3 2t-'
Edek', CD 80&31
8. BID SCHEDULE (Base Bid)
Bid items are described in Section 01800
BID
EST.
UNIT
ITEM
ITEM #
DESCRIPTION
QTY.
UNIT
PRICE
TOTAL
1
Mobilization
1
LS
t o, o
2
Traffic Control
1
LS.e
3
Demo of Existing 5' & 8' Wide Trail
_ 561
SF
4
Stump & Tree/Shrub Removal
1
LS
sc�o,°°
1r6aa
5
4" Topsoil Removal/Replacement
120
Cy
[a.
T `°
6
Class 5 ABC
100
TON
°=
7
5" Colored Concrete Paving
9,910
SF
3.40
?23do
4.
8
Earthwork Cut
100
CY
tq'b
,0
00
i�9co,
9
B' Wide Pedestrian Bridge
1
LS
2s,000
1800--�
�- 10
Raise Manhole
1
LS
Soo,°O
560.e?
11
Hydro Seeding
7,000
SF
.IS
1.26o.�
TOTAL OF BASE
BID
.!r
n°Iwc
$ 92 515. ao
(written
9. PRICES
The
foregoing prices shall include all
labor, materials,
transportation,
shoring, removal, dewatering, overhead,
profit,
insurance,
etc.,
to cover
the
complete Work in place of the several
kinds
called
for.
7/96
Section
00300
Page 2
...�,.. --.:.ua.:...�...ua��s�—___....... .:usm�uvasv.+anfa"t _:., u�'�.:. ... _. .,�'^' .°='�;s�°';,�a a•rr�new.a.>.ws.� :,'yy�'avmt�7`. '"" az5r u..a :E'vm"n..,�"'�8:u �. fe.a
DIVISION 2
SECTION 02900 - SITE REVEGETATION
PART 1 - GENERAL
1.01 Description of Work
A. The work covered by this specification includes the furnishing of all materials and application of
fertilizer, seed and mulch to areas defined in the plans or required by field condition. The work
shall be completed in accordance with these specifications, accepted horticultural practice, and
with the plans.
1.02 Related Work
A. See appropriate sections for site work needed prior to work required in this section. Obtain
approval from the Engineer prior to starting work required in this section.
1.03 Submittals
A. Submit manufacturer's specifications and literature on all products.
B. Submit materials list including quantities and description of materials.
1.04 Quality Assurance
A.
Source Quality Control: Manufacturer's test for purity and germination of seed, dated within six
`
months of seeding.
B.
Certificates: Manufacturer's certification that fertilizer meets specification requirements.
PART 2 - MATERIALS
2.01 Grass Seed
A.
Grass seed shall be of the latest crop available. Seed shall meet Colorado Department of
Agriculture Seed Laws, Chapter 35, Article 27.
B.
The seeding mixture shall be applied at a pure live seed (PLS) rate per acre AS SHOWN ON
SHEET 4 OF 4.
C.
Do not use seed which has become wet, moldy, or otherwise damaged in transit or in storage.
D.
The Contractor shall compensate for percentage of purity and germination by furnishing sufficient
additional seed to equal the specified pure live seed product. The formula for determining the
quantity of pure live seed (PLS) shall be: Pounds of Seed (Bulk) x Purity x Germination =
E.
Pounds of Pure Live Seed (PLS)
^' F.
The Contractor shall present to the Engineer a certificate of the PLS test of the grass seed which he
intends to use. All grass furnished shall be delivered in sealed bags showing the weight, analysis
and vendor's name.
2.02 Fertilizer
A. Commercial fertilizer type and application rate shall be AS SHOWN ON SHEET 4 OF 4.
City of Fort Collins Section 02900 — Site Revegetation
Park Planning & Development Division Page 1 of 4
.rvn.::e ....a "Z-; ,..a C..ar.. .......h.. G.': tie.. ....+wa- .., .. ..> ti!.:.ix ' -,a.:..s — .a
2.03 Mulch
A. Hydraulically spray or approved equal.
2.04 Topsoil
A. Topsoil shall be select earth material of loose friable loam reasonably free of admixtures of
subsoil, refuse stumps, roots, rocks, brush, weeds or other material which can be detrimental to the
proper development of ground cover.
PART 3 - EXECUTION
3.01 General
A. The pattern of seeding and mulching, and fertilization if required, shall be as detailed or as
required by field conditions to provide a uniform stand of grass acceptable to the City. In no case
shall revegetation occur within 30 days of the application of a chemical weed control substance.
B. Warranty excludes replacement of plants after final acceptance because of injury by storm,
drought, drowning, hail, freeze, insects or diseases.
3.02 Preparation
A. Verify that soil preparation has been completed prior to seeding.
B. Seed areas damaged by construction activities as directed by the Engineer.
C. Apply by broadcasting or drillings at the rate specified herein.
D. Selection of the time of seeding shall be Contractor's responsibility, consistent with erosion
control.
E. Rework previously prepared areas that have become compacted or damaged by rains or traffic.
F. Do not drill or sow during windy weather or when ground is frozen or untillable.
G. Cover seed to depth between '/a to %z inch by raking or harrowing.
H. Firm seed areas with roller weighing maximum of 100 lbs. per foot to width.
3.03 Hydraulic Seeding and Mulching
A. Seed and fertilize in the amounts per acre designated. Wood cellulose fiber mulch at 2,000 lbs/
acre.
B. Combine with water to provide a slurry. Perform hydraulic application in such a manner that the
liquid carrier will uniformly distribute the material over the entire area to be seeded at rates not
less than indicated herein. Do not compact. Double the amount of seed per acre if seed and mulch
are applied in a single application.
3.04 Drill Seeding
A. Seed shall be applied in a minimum of two passes at 90 degrees two each other.
3.05 Reseeding and Repair
A. Reseed and mulch areas where there is not a satisfactory stand of grass at the end of 60 days after
seeding.
B. Minimum satisfactory stand: 4 plants per square foot.
City of Fort Collins Section 02900 — Site Revegetation
Park Planning & Development Division Page 2 of 4
w
I
3.06 Areas to be Seeded
A. All areas that have been damaged or disturbed by the Contractor's operation shall be reseeded
according to these specifications and as indicated on the plans.
3.07 Maintenance
A. No maintenance is required, UNLESS NOTED ON THE BID SCHEDULE.
City of Fort Collins
Park Planning & Development Division
Section 02900 — Site Revegetation
Page 3 of 4
Fertilizer and Seed Mix
Commercial Fertilizer (18-46-0)
Nitrogen
Phosphorus
Potassium
Application rate of 250 lbs per acre
Percent available by weight
18
46
0
Seed Mix Pure Live Seed Lbs./Acre Seed
Buffalo Grass 20%
25
Blue Gramma 30%
25
Sheep's Fescue 50%
20
100
70
END OF SECTION
City of Fort Collins
Park Planning & Development Division
Section 02900 — Site Revegetation
Page 4 of 4
SECTION 07900
JOINT SEALERS
PARTI-GENERAL
1.01 WORK INCLUDED
A. Furnish and Install: Provide all caulking and sealant indicated on the Drawings, specified herein, and not
specified under other sections. In general, seal all openings indicated on the Drawings and at other locations
requiring caulking to seal visually and against infiltration from air and water, including but not limited to the
following:
I . Expansion joints in concrete walks
2. Exterior wall joints
3. Masonry control joints
4. Isolation joints, between structure and other elements
S. Joints at penetrations of walls, decks and floors by piping and other service equipment
6. Joints between items of equipment and other construction
7. Joints between door and window frames and adjacent materials, exterior and interior
8. Bedding for door thresholds
9. Open joints between dissimilar materials as required to close and conceal jointing of the work
10. Construction and expansion joints, joints between dissimilar materials; joints around windows, door
frames, louvers, and other penetrations and openings
I I. Other joints as indicated
1.02 SUBMITTALS
A. Color Samples: Submit color chart for each type of sealant in accordance with Division I.-
B. Product Data: Submit for each material intended for use and location of application in accordance with
Division 1.
1.03 DELIVERY, STORAGE AND HA14DLING
A. General: Complywith Section01600. Deliver in original unopened containers and store in an area not subject
to extreme heat or cold.
1.04 PROJECT CONDITIONS
A. Environmental Conditions: Do not apply exterior sealants during wet weather or when the outside temperature
is below 40°F. Do not apply interior sealants when the inside temperature is below 60°F.
1.05 WARRANTY
A. Provide a written three year warranty in writing covering materials and workmanship in accordance with
Section 01700. Warranty shall require installer, at no cost to Owner, to repair or replace sealants which fail
to perform as air -tight and water -tight joints; or fail in joint adhesion, cohesion, abrasion resistance, weather
resistance, extrusion resistance, migration resistance, stain resistance, or general durability; or appear to
deteriorate in any other manner not clearly specified as an inherent quality of the material by submitted
manufacturer's data.
Section 07900
Joint Sealers - 1
PART 3 - EXECUTION
3.01 INSPECTION
A. Inspection: Inspect work of others prior to application of any work under this section.
to receive this work is not according to detail and cannot be put into proper condition to receive the work If any joint or space
unsatisfactory caulking and sealing•resulting. space
specified methods; notify the General Contractor in writing or assume responsibility for and rectify anby
y
B. Acceptance: Beginning of installation means acceptance of existing conditions.
3.02 PREPARATION
A. Preparation of Surfaces:
I • Clean surfaces in accordance with manufacturer's recommendations.
2. Mask edges, if required, to protect adjoining surfaces and produce a
3• Clean joint surfaces immediately before installation of sealant straight finish line,
moisture and other substances which would interfere with frond of sealant move dirt, insecure coatings,
4 • Do not proceed with installation of sealant over joint surfaces which have been painted, iacgq�red,
waterproofed or treated with water repellent or other treatment of coating. Remove coating d,
treatment joint surfaces before installing sealant.
5. Etch concrete masonryjointsurfaces toremove e
instruction indicates that alkalinity does not xcess alkalinity unless sealant manufacturers printed
interfere with sealant bond and performance. Etch with
5%solution of muriatic acid, neutralize with diluted ammonia solution, rinse thoroughly with water
and allow to dry before sealant installation. •
B. Priming: If required, prime surfaces which are to be caulked with manufacturer's recommended or standard
primer, after the surfaces have been prepared as specified. Before use, check primers for discoloration and dirt
pick-up on adjacent surfaces. If staining occurs, after exposure, take adequate measures to prevent the primer
from being applied over the face of adjacent porous materials by masking or other suitable measures.
C. Joint Backing:
' 1 • Joints shall be of depth necessary to provide for the specified all thickness of sealant and also
the required backing where and as specified. Provide backing of extent and We as specified and
required to provide for the allowable depth of the sealant
2. Back-up Materials for Sealants: Non -staining, compatible with the sealant and resilient nature acid as recommended by the manufacturer of the sealant. Size and shape of the
backing shatl be as required by the width of thejoint and specified. Do not use materials impregnated
with il, solvents, or bituminous materials.
3. Compress backing material a minimum of 30% when inserted in the joint. Backing material for the
upper portion of joints shall be a round rod or semi -circular in cross-section with the arc in contact
with the sealanL
D. Bond BreakerTape: Install where indicated and as required by manufacturer's recommendations to ensure that
sealants will perform properly.
3.03 APPLICATION
A. Exterior Metal Sills: Set in full bed of polyurethane sealant.
B. Thresholds: Set in full bed of latex acrylic sealant.
Section 07900
Joint Sealers - 3
Cleaning:
I. Protect surfaces from damage. Clean soiled surfaces immediately. Replace with new material any
damaged material which cannot be cleaned with near material.
END OF SECTION
r.'
s_.
Section 07900
Joint Sealers - 5
Project Location Map
NFPL
_ORD DR �Z
7W;-HORSETOOTH:RD—_9
CARME_LACT a
X
Q
zj o—BROOK-DR o 0
W Y , o �o
Pre- id M X E
Location at the
IMPERIAL -DR u u o
Parkin F]o
P�URy AGE CT Sanctuary Apts. ��o Ll
El
m WINDCREEK'CT
m INP�
O
z WESTFIELD DR OO��FI�ip
0
GRES/
WESTFIELD PARK
SAILCR STE CT LAKE- EST CT
W TROUT M _ N_PK1NY
Legend m
New Trail U)
2.
Location ,i
W
Pre -Bid W
IG
O
m
0
X
City of Fort Collins
Administrative Services
Purchasing Division
CITY OF FORT COLLINS
ADDENDUM No. 1
BID #5908
PLEASANT VALLEY LAKE & CANAL TRAIL
SPECIFICATIONS AND CONTRACT DOCUMENTS
Description of Bid #5908 Pleasant Valley Lake and Canal Trail
OPENING DATE: April 4, 2005, 3:00p.m. (Our Clock)
To all prospective bidders under the specifications and contract documents described above, the
following changes are hereby made.
GENERAL CLARIFICATION
1. Clearing for trail through area with small trees and shrubs to be 3 foot off the edge of the
proposed trail. Contractor may scatter debris (small trees & shrubs) from the clearing
throughout the wooded area for wildlife habitat.
2. Contractor can access west side of ditch for construction, south along ditch from Troutman
Pkwy. and west from Westfield Dr. along existing sidewalk. Any damaged or disturbed area
is to be replaced by contractor (refer to GENERAL CONDITIONS, ARTICLE 6--
CONTRACTOR'S RESPONSIBILITIES, Use of Premises: 6.16.).
DRAWINGS
Replace note 1, first sentence, on drawing sheet 1 OF 4, PROJECT NOTES with:
1. PEDESTRIAN BRIDGE SHALL BE SUPPLIED BY CONTRACTOR.
SPECIFICATIONS
NIA
ATTACHMENTS
NIA
If you have questions please contact John Stephen, CPPO, Senior Buyer, at 970-221-6777.
RECEIPT OF THIS ADDENDUM MUST BE ACKNOWLEDGED BY A WRITTEN STATEMENT
ENCLOSED WITH THE BID/QUOTE STATING THAT THIS ADDENDUM HAS BEEN RECEIVED.
215 North Mason Street • 2nd Floor • P.O. Box 580 • Fort Collins, CO 80522-0580 • (970) 221-6775 • FAX (970) 221-6707
Bidder acknowledges that the OWNER has the right to delete items in the Bid
or change quantities at his sole discretion without affecting the Agreement
or prices of any item so long as the deletion or change does not exceed
.e
twenty-five percent (25%) of the total Agreement Price,
RESPECTFULLY SUBMITTED:
' 1f - 0 5
Si aD r Date
" T
Title
�►� P
License Number (If Applicable)
(Seal - if Bid is by corporation)
i
Attest: _ (YM. W4..-
Address if�63 a EKG
Telephone 00c)-3X'10.-mog
7/96
Section 00300 Page 3
SECTION 00400
SUPPLEMENTS TO BID FORMS
00410Bid Bond
00420Statement of Bidder's Qualifications
00430Schedule of Subcontractors
5
7/96
f-
Section 00410 Page 1
0
SECTION 0091.0
BID BOND
KNOW ALL MEN BY THESE PRESENTS,; that we, the undersigned
* as Pxincipa. , and Dev ouer_�rety & J„d_ emnj���mp_n3i as
Surety, are hereby held and firmly bound unto the City of Fort Collins, Colorado,
as OWNER, in the si.tm of $ . 5% of Amnnnr u;A for the payment of.which, well and
truly to be made, we hereby jointly and severally bind ourselves,,successors, and
assigns.
THE CONDITION of this obligation is such that whereas the Principal has
submitted to the City o=_Fort _ Collins, Colorado the accompanying Bid and hereby
made a part hereof to enter into a Construction Agreement for the construction of
Fort Collins Project, 'LEASANT;VALLEY LAKE AND CANAL TRAIL; BID NO. 5908.
NOW THEREFORE,
(a) If said Bid shall be rejected, or
(b) If said Bid shall be accepted and the Principal shall execute and ;deliver a
Contract in the form of Contract attached hereto (properly completed in
accordance with said Bid) and sha'1 furnish a 801\11) for his faithful
performance of sa-d Contract, and for payment of all persons performing
labor or furnishing materials in connection therewith, and shall in all
other respects perform the Agreement created by the acceptance of said Bid,
than .this obligation shall be void; otherwise the same shallremain in
force and effec�, it being expressly understood and agreed that the
liability of the Surety for any and all claims hereunder shall, in no
event, exceed the penal amount of this obligation as herein stated,
The Surety, for value received, hereby st.1pulates and agrees that the obligations
of said Surety and its BOND shall be In no way impaired or affected by any
extension of the time wwth'in which the OWNER may accept such Sid; and said Surety
does hereby waive notice of any such extension.
Surety Companies executing bonds must be authorized to transact business in the
State of Colorado and be accepted by the,' OWNER.
* Naranjo Civil Constructors, Inc.
7/96 Section 00410 Page 2
IN WITNESS WHEREOC, the Principal and tale Surety have hereunto set their hands
and seals this 4th day of April _, 2005, and such of them as are
corporations have caused their ccrporare seals to be hereto affixed and these
presents to be signed by their proper officers, the day and year first set forth
above.
PRINCIPAL
Name: Naranjo Civil Constructors, Inc
Address: 1863 2nd Ave.
Greeley, CO 80631-5901
BY:__ 5 j
ATTEST;
8 ;
(SEAL)
SURETY
Developers Surety & Indemnity Company
7211 S. Peoria St. Ste. 290
Englewood, C 8 12
By:
Jeffrey L. Broyles
Title: orne In -Fact
(SEAL)
7/96 Section 00410 Page 3
.r POWER OF ATTORNEY FOR
DEVELOPERS SURETY AND INDEMNITY COMPANY
PO BOX 19725, IRVINE, CA 92623 (9491 263-3300
www.InscoDico.com
KNOW ALL MEN BY THESE PRESENTS, that except as expressly limited. DEVELOPERS SURETY AND INDEMNITY COMPANY does hereby make,
constitute and appoint:
***D.N. Broyles, Kathryn D. Broyles, Todd D. Bengford, Thomas D. Berry, Susan Howard, Jeffrey L. Broyles,
Don R. Broyles, Marie E. Reinoehl, Derek Grewatz, Kelly L. Tenold, Spencer Fred Thomas, Kristin A. Poling,
jointly or severally***
as its if and lawful Attorncy(s)-in-Fact, to make, execute. deliver and acknowledge, for and on behalf of said corporation as Surety, bonds. Undertakings and
contracts of suretyship giving and granting unto said Attorncy(s)-in-Fact full Power and authority to do and to perform every act necessary, requisite or proper to
be done in connection therewith as the corporation could do. but reserving to the corporation full power of substitution and revocation- and all of the acts of said
Attorncy(s)-in-Fact, pursuant to these presents, are heichy ratified and confirmed.
This Power of Attorney is granted and is signed by facsimile under and by authority of the following resolution adopted by the Board of Directors of DEVELOPERS
SURETY AND INDEMNITY COMPANY effective as of November 1. 2000:
RESOLVED, that the Chairman of the Board, the President and any Vice President of the corporation be, and that each of them hereby is. tntthcn-ized to
execute Powers of Attorney, qualifying the Attorney(s)-in-Fact named in the Provers of Attorney to execute. on behalf of the corporation. bonds, undertakings and
contracts of suretyship; and that the Secretary or any Assistant Senrtory of the corporation he. and each of them hereby IS, authorized to attest the execution of
any such Power of Attorney:
RESOLVED. FURTI IER, that the signatures of such officers may he affixed to any such Power of Attorney or to any certificate relating thereto by
facsimile, and any such Power of Attorney or certificate bearing such facsimile signatures shall be valid and binding upon the corporation when so affixed ancf in
the future with respect to any bond, undertaking or contract of suretyship to which it is attached.
IN WITNESS WHEREOF. DEVELOPERS SURETY AND INDEMNITY COMPANY has caused these Presents to be signed by its respective Executive Vice
President and attested by its Secretary this Is[ day of October, 1003. ,
AND
By:
David H. Rhodes. Executive Vice -President — yJ;�`pPpDR,t
czr OCT.
-W.
1936
Walter A. Crowell. Secretary '•••,,,,*,,,
STATE OF CALIFORNIA
)SS.
COUNTY OF ORANGE )
On October I. 2003, before me, Diane.[. Kawata, personally appeared David H. Rhodes and Walter A. Crowell, personally known to me (or proved to
me on the basis of satisfactory evidence) to be the pc1'sons whose names arc subscribed to the within instrument and acknowledged to nu that they executed the
Same in their authorized capacities. and that by their signatures un the instrument the entity Upon bchelf of which the persons acted, exeaUcd the instrument.
WITNESS my hand and official seal �e
NE
C_. l Dy Publi RAWATA
COMM. 91334746
,(�, � '9�`.-;= Notary Public -California O
Signature ""' � 3: ORANGE COUNTY _
My Comm. Expires JAN. 6, 2006
CERTIFICATE
The undersigncCI, as Senior Vice -President. Underwriting. of DEVELOPERS SURETY AND INDEMNITY COMPANY. does hereby certify that file
foregoing Power of Anorncy remains in full force anti has not been revoked, and furthermore, that file Imovisions of the resolution of the respective Boards of
Directors of said corporntion set forth in the Power of Attorney. is in fierce as of tile dme of this Certificate.
This Certificate is executed in the City of Irvine. Calitbrma, the 1+'th day of April 2005
Wesley W. Cowl ill "JAenfor Vicc-President. Uncfciwi i g
ID-1439 (DSI) (Rev. 10/03)
SECTION 00420
STATEMENT OF BIDDER'S QUALIFICATIONS
All questions must be answered and the data given must be clear and
comprehensive. This statement must be notarized. If necessary, questions may be
answered on separate attached sheets. The Bidder may submit any additional
information he desires. ",,
1. Name of Bidder: K1arLin%o r:V:I cons-lfoc Isr_;ne
2. Permanent main office address: lB 2'dAst. Ere le.,. Coto f304P31
3. When organized: Fr6roc:c-:) 19 6?
4. If a corporation, where incorporated:
5. How many, years have you been engaged in the contracting business under your
present firm or trade name? Z `'Z !IPncS
6. Contracts on hand: (Schedule these, showing the amount of each contract and
the appropriate anticipated dates of completion.)
Gvlcl, — Pant-e 2Gor,r n. 06 - Abrd Is* ?ao<
llaiop (s,.� �n - Castleroc� - r 2on,Qoo, 3t 260<
(;&)I,d Gncic-{s Qrm:r - Sco boo! - S,4. 26tl5
'A re' - —Si. ACYa:��e;'e �O 000.E - }.111a.11 154,. ;Zoos
SH 34 - s 1-15, 000 Tarim 30yoo 3
7. General character of Work performed by your company:
8. Have you ever failed to complete any Work awarded to you?
If so, where and why? ?1 0
9. Have your ever defaulted on a contract?
If so, where and why?
10. Are you debarred by any government agency?
If yes list agency name.
r 7/96
Section 00420 Page 1
11. List the more important projects recently completed by your company,
stating the approximate cost of each, and the month and year completed,
location and type of construction.
12
List your major equipment available for this contract.
13. Experience in construction Work similar in importance to this
project:
TnSialled Qedes%t±a gC rI_ aG � Tra' ( -� Soo4c, SU6Nl,o., Po�y�_ ��s�__
Jo.s�allGd Pedes �'da_�t �.�_I�FG(.. �'ieGIL �nol�' �'ohrs• �l ilbJ�.we..�
cc
14. Background and experience of the principal members of your organization,
including officers: I1 11
4 Sew Ai�at�c�% �1
f B 0
15. Credit available: $ Z So o0o
r 16. Bank reference: QQT Vi bocr _ Weds �a�r_]o__&n-V uJPC i - '70 33b- b23(o
17. Will you, upon request, fill out a detailed financial statement and furnish
any other information that may be required by the OWNER?
18. Are you licensed as a General CONTRACTOR? �e5
If yes, in what' city, county and state? GceelejCweldi Goldentje%fw,�What
r class, license and numbers? a,,o4e
Cnn-kc nLr _—_-_T
19. Do you anticipate subcontracting Work under this Contract.) SIPS
If yes, what percent of total contract? o?
and to whom?_,Ma-k e ✓Cee�{ers - S eJ, -i
w 20. Are any lawsuits pending against you or your firm at this time? �o
If yes,
DETAIL
M
-U96 Section 00420 Page 2
21. What are the limits of your public liability? DETAIL
I n l l •on oe r oee.,re.^ c e 2- M:11:on Aqq regain
What company? Lj,.d-ems __ reels d Floe T —
22. What are your company's bonding limitations? yi;il;o„ F aeG� i
2 5 ft (I o., Ao— I .
23. The undersigned hereby authorizes and requests any person, firm or
corporation to furnish any information requested by the OWNER in
verification of the recital comprising this Statement of Bidder's
Qualifications.
•w+
Dated at 101-30Arn this 14 day of Qvril 1 2006•
Name of 7Bi er �]
s B y :
Title:y Ce rrs'ckn+!
State of COLD an
County of Welt{
C '
Serra ►iQra�10 being duly sworn deposes and says that he is
Vick - PreS, J _-1 of �ara,.�o C'��) �o��frae rS� S.,c. and that
(name of organization)
the answers to the foregoing questions and all statements therein contained are
true and correct.
g Subscribed and sworn to before me this y day of
20o5 • (�NE•M.,Wq
r-
TA
Notary Notary�I Public
/�J
L�iS4iyie k r,rngfBO _
N� ; A •
CO�-O�
My commission expires Zoo to
My Commission Expires 07/05I2008
P
P,
�/96 Section 00420 Page 3
.£
emmmmmaia
di lllllp�
C O N S T R lJ C T O M S
PROPOSAL
City of Fort Collins
Pleasant Valley Lake and Canal Trail
About Us
Naranjo Civil Constructors, Inc. is the continuation of a small company started in 1982 as H & L
Construction Co. with two ownerlemployees. Today, Naranjo Civil Constructors, Inc. employs
over thirty-five people from project superintendents to tradesmen to in-house civil engineers.
Herman Naranjo, President & Founder, remains with the company to this day. With over thirty
years of total experience, Mr. Naranjo is involved in the daily management of the company's
operations. Jerry Naranjo, Vice -President and Corporate General Manager looks after customer
service, strategic planning and business development. Mr. Naranjo is a graduate of Colorado
School of Mines with a B.Sc. Degree in Engineering - Civil Specialty.
A family business, Naranjo Civil is rooted in the belief that hard work carries the day. Naranjo Civil
focuses on diligent attention to customer service and jobsite safety. Construction quality and
jobsite productivity are the principles upon which the company was founded and continue to drive
the daily operations. Naranjo Civil has built a diversified project portfolio based on technically
complex structural concrete, flatwork concrete, drainageway construction, stormwater
construction, road reconstruction, irrigation, and minor utility projects.
Customer Service Pledge
It is our sincere commitment to provide an elite level of customer service to The City of Fort
Collins for the Golden 2005 Storm Sewer Projects. Our company culture is to continually put
forward our very best effort with regard to Customer Service. As a local civil contractor we pledge
to offer The City of Fort Collins fair pricing, qualified staff, excellent job quality - all on the
shoulders of a relentless customer service mission.
Equipment
We currently own, at a minimum, every piece of equipment needed to perform the construction of
this project. Most importantly, we have an experienced construction management team that
knows how to fit the right piece of equipment into the right construction situation to maximize
productivity and safety, as well as minimizing disturbance to sensitive drainage environments. We
also perform 90% of all repairs on our equipment by employing a full-time equipment mechanic.
Availability
We currently have over six crews with over 35 employees at any one time working on projects
throughout the Front Range and Denver Metro Area. With our recent growth we have become
more adept at retooling and responding quicker to "Rapid Response" situations. We currently
serve as a standby contractor for several municipalities and ditch companies to respond to flood
damage or emergency construction repairs. We have used our growth to better serve our core
customers and offer a larger, more responsive suite of services. In the Spring of 2003, we
responded to over eight different emergency repair situations that were not on our original
construction schedule. In addition, all of our crew superintendents have drainageway experience
which gives us a great amount of flexibility in making our resources rapidly available to our
customers.
Construction Services
Drainageway Construction - Our initial experience in drainageway construction was related to
building technically complex concrete structures in the most difficult of job conditions. Over the
years we have added several key staff members that have built their careers on constructing
drainageway projects from start to finish. Our ability to handle the ever -changing environment of
natural and civil drainageways lies with our people and all of the unique experiences they have
encountered along the way.
Structural Concrete - Cast -in -place concrete structures served as the foundation for our
company's growth for many years. Our knowledge in this particular area of construction is known
throughout Colorado with signature projects built from as far south as Pueblo through the entire
Front Range of Colorado. With our extensive knowledge in this field we have even completed
several design -build projects for some of our most important clients. Structural concrete is at our
core and we will always strive to maintain our status in this industry sector.
Flatwork Concrete - Flatwork concrete has also been a staple of continued success for our
company. Our flatwork crews focus primarily on public works projects where major demolition and
reconstruction are required. Our flatwork experience covers the full realm of projects including but
not limited to curb, gutter, sidewalk, road paving, ditch lining, slab on grade, bike path, pedestrian
trails, as well as stamped, colored and exposed finishes. Our crews have recently completed a
faux finish sandstone style shore lining project utilizing colored concrete and an almost artistic
styling of the upper bank cap to mimic a weathered and striated sandstone outcrop.
Stormwater Construction - With our beginnings in structural concrete and construction of over one
thousand stormwater related structures we now employ at least one full-time crew tasked with
pipe installation and construction of all of the associated appurtenances. Our crews have built
several pipeline projects ranging in complexity and size. Our most challenging projects include
the crossing of SH85 at night in three phases with HERCP as well as the crossing of a local bank
entrance with a double barrel 30" RCP irrigation siphon at night, and over the weekend. Our
crews are well versed in the use of pipe laser, trench shoring, and confined space technology.
Road Construction - Our combined crews are able to merge to form a very competent road
construction operation. Our target projects in this field are small to mid -size reconstruction
projects for municipalities. Oftentimes we are able to self -perform the entire project including the
tasks of demolition, grading, concrete, stormwater, compaction, and asphalt prep.
Utilities - While not a stand-alone division, our company has the ability to handle a full variety of
utility projects including but not limited to waterline lowering, sanitary sewer rehabilitation, sanitary
sewer bypass pumping, water and sanitary sewer service tie-ins, water valve installations, and
conduit installation. Our most recent project involved upsizing a four -inch sanitary sewer line to an
eight -inch line as part of a larger stormwater reconstruction project.
Landscape Reclamation - With the numerous projects we have under construction at any one
time, we have developed a crew to focus primarily on landscape reclamation, project cleanup,
and punchlist management. This crew is able to perform minor sprinkler repair, major sod
installation, landscaping, and to deliver a project to its final closeout stage.
Project Management - Several companies and municipalities use our services to solve
construction problems they are not equipped to handle due to time or expertise constraints. For
example, one of our core customers recently called and asked if we would install over 2,000 linear
feet of double barrel 30" RCP with an integrated siphon. While this company is a major pipeline
company in the Northern Colorado area, they did not want to deal with the intense testing and
quality control requirements of this particular run of pipe. The run of pipe also crossed the
entrance to one of the major banks in the area requiring some of the construction to be done after
Saturday noon and to final completion by Monday morning 5:00 a.m.
MARCH 23, 2005
CITY OF FORT COLLINS
PLANHOLDERS LIST FOR
BID #5908
PLEASANT VALLEY LAKE AND CANAL TRAIL
STORMY PEAKS CONSTRUCTION
246 STORMY PEAKS DR.
BELLVUE, CO 80512
PH 970-221-9244
FAX 970-498-9477
G. L. HOFF
P.O. BOX 7448
LOVELAND, CO 80537
PH 970-669-3255
FAX 970-663-1566
MOUNTAIN CONSTRUCTORS
P.O. BOX 405
PLATTEVILLE, CO 80651
PH 970-785-6161
FAX 970-785-2515
STEADFAST BRIDGES
4021 GAULT AVE. SOUTH
FORT PAYNE, AL 35967
PH 256-845-0154
FAX 256-845-4106
WHEELER LUMBER, LLC
9330 JAMES AVE. SOUTH
BLOOMINGTON, MN 55431
PH 952-929-7854
FAX 952-929-2909
FLATIRON CONSTRUCTORS
P.O. BOX 2239
LONGMONT, CO 80502-2239
PH 303-485-4050
FAX
NARANJO CIVIL CONSTRUCTORS
1863 2ND AVE.
GREELEY, CO 80631
PH 970-356-7909
FAX 970-356-0887
LEISURE TIME ASSOCIATES
10298 W. LAYTON PL.
LITTLETON, CO 80127-1328
PH 303-979-1101
FAX 303-933-4166
JAG'S ENTERPRISES, INC.
661 INNOVATION DR.
WINDSOR, CO 80550
PH 970-674-1957
FAX 970-674-1985
CARNES SERVICE
P.O. BOX 1258
WINDSOR, CO 80550
PH 970-568-3632
FAX 970-568-3165
NORTHSTAR CONCRETE
P.O. BOX Y
BERTHOUD, CO 80513
PH 970-532-0805
FAX 970-532-4687
Manaaement Personnel
Our management philosophy is to have our management team highly involved in the day-to-day
field operations of all of our crews. Our management personnel can thereby influence a culture of
productivity, quality, jobsite safety and diligent attention to customer service. All of our
management personnel have extensive field experience and can contribute on a daily basis to the
problem solving effort required in the field. Our management team can always be considered as a
first point of contact for all customer service related issues. We are diligent in our efforts to keep
our customers happy and continually strive to improve our operation.
Herman Naranjo - With regard to this contract, Mr. Naranjo will handle management issues
related to quality control, jobsite productivity and operations problem -solving. Mr. Naranjo has
over 33 years of diverse experience in civil construction in Colorado. Mr. Naranjo has been
building concrete structures associated with channel reconstruction and restoration for many of
his 33 years of experience. Mr. Naranjo has built signature projects from Pueblo to Breckenridge,
Denver Metro to Northern Colorado. Mr. Naranjo, a Company founder, was the original motivator
to build an organization that specializes in civil concrete structures through urban and rural
waterways. Mr. Naranjo has been part of a team that has operated Naranjo Civil for over 21
years and has built a solid reputation throughout the industry.
Jerry Naranjo - With regard to this contract, Mr. Naranjo will serve as the contract administrator,
estimator, technical advisor, overall project management - first contact, and customer service
representative. Mr. Naranjo has over 11 years of experience as a Manager for Naranjo Civil and
the former Morrison Knudsen Corporation. Mr. Naranjo currently serves as the Vice President
and General Manager for Naranjo Civil in Greeley, Colorado. Mr. Naranjo also holds a Bachelor of
Science (B.Sc.) Degree from the Colorado School of Mines in Engineering - Civil Specialty.
Moreover, Mr. Naranjo has served most of his career as a troubleshooting engineer, often tasked
with assembling a team of professionals across several engineering and management disciplines
to solve problems in both construction and mining operations. Mr. Naranjo, as a consultant, also
participated in the management reorganization of several large mining operations designed to
trim overhead, better allocate personnel, and subsequently increase efficiency.
Christine Warner - With regard to this contract, Ms. Warner will assist with project management,
utility locates, traffic control supervision, job cost tracking for "time and materials" projects, and
the full suite of administrative support issues. Ms. Warner has over nine years of experience in
the construction field and is a Colorado Contractors Association certified Traffic Control
Supervisor as well as a certified Erosion Control Supervisor. Ms. Warner has been very involved
in the administration of City of Fort Collins projects over the last two years primarily handling
engineering takeoffs with regard to estimating and job costing during construction.
Gail Racine - With regard to this contract, Mr. Racine will serve as the on -call equipment
maintenance superintendent. Mr. Racine has over 35 years of experience working on all types of
construction equipment both large and small. Working in the sensitive environs of waterways,
quick response and immediate repair are paramount to protecting the environment and
minimizing downtime. Minimizing downtime minimizes the amount of time we must spend in a
waterway and thereby lowers the chances of contamination. Minimizing downtime also means we
can lower production costs and pass on significant savings to our customers.
Operations Kev Personnel
Glen Helzer - With regard to this contract, Mr. Helzer will most often fill the role of project
superintendent. Mr. Helzer has over 22 years of civil construction experience. Mr. Helzer is a very
skilled large equipment operator but moreover has become especially skilled at managing
channel projects with major diversion and dewatering challenges. Mr. Helzer has run several
projects from start to finish with experience in all facets of channel and concrete construction
including, but not limited to, grouted boulder drop structures, sub -grade excavation, sub -grade
stabilization, riprap placement, seeding, natural site conservation and overall project
management. Mr. Helzer is known in the industry as an excellent large equipment operator, a
knowledgeable and respected source of experience in channel construction and restoration, and
a conscientious constructor within the sensitive environs of civil and natural waterways. Mr.
Helzer is also certified as an OSHA Competent Person in Trench Safety.
Anthony Naranjo - With regard to this contract, Mr. Naranjo will most often fill the role of structural
concrete superintendent. Mr. Naranjo has over seven years of civil construction experience, most
of which has been related to structural concrete. Mr. Naranjo has built several major structures in
urban and natural waterways including but not limited to reinforced concrete box culverts, cutoff
walls, retaining walls, flow -energy dissipators, irrigation siphons, inlets, manholes, and flow
diversion structures. Mr. Naranjo recently supervised the construction of the Chappelow Shore
Lining Project in the City of Evans, implementing a colored concrete bulkhead with a striated
"faux -sandstone outcrop" finish.
Joel Velazco - With regard to this contract, Mr. Velazco will most often fill the role of flatwork
concrete superintendent. Mr. Velazco has over 20 years of civil construction experience, most of
which has been related to flatwork concrete. Mr. Velazco has worked around drainageway
construction throughout his career building bicycle and pedestrian trails as part of several overall
channel reconstruction projects. Mr. Velazco recently supervised the construction of 880 linear
feet of reinforced concrete drainage channel as part of the Montbello Channel Improvements
Project.
Leonard Rios - With regard to this contract, Mr. Rios will most often serve as either a flatwork or
structural concrete superintendent. Mr. Rios is also a very skilled equipment operator with several
years of pipeline and utilities experience. Mr. Rios can supervise all of the different types of
services we offer, from drainageway construction to utility work. Overall, Mr. Rios has over 30
years of civil construction experience. Mr. Rios recently supervised the construction of over 30
ADA ramp reconstruction projects in the City of Fort Collins.
"Mundo" Perez - With regard to this contract, Mr. Perez will most often serve as an excavation
and rockwork superintendent. Mr. Perez has over 18 years of civil construction experience, with at
least ten of those years spent exclusively on drainageway construction projects. Mr. Perez is a
highly skilled large equipment operator and is well versed in the tasks of detailed boulder
placement, grouting, dewatering, and sediment control. Mr. Perez recently completed the
construction of a grouted boulder bank stabilization project at the Lakewood Gulch Confluence of
the South Platte River. Mr. Perez is also certified as an OSHA Competent Person in Trench
Safety.
Protect Portfolio
In the last 24 months we have completed over 100 different construction projects along the
Colorado Front Range. Our major clients are highlighted below:
City of Brighton
City of Greeley
Urban Drainage
Fulton Ditch Company
City of Evans
Town of Frederick
Weld County Public Works
Defalco Lee Construction
City of Commerce City
Town of Frederick
Pierce Lateral Ditch Company
Hall - Irwin Corporation
Our resume of projects is filled with technically complex structures built in the most difficult of job
conditions. Our ability to restore natural and civil drainageways to an aesthetically pleasing and
functionally operational state requires a precise blend of people, equipment, and persistence.
Highlighted below are a couple of projects that we believe spoken to the quality of our work and
our perseverance in tough site conditions.
Project: Big Dry Creek Low Flow Pedestrian
Trail Crossings and Improvements
Owner: South Suburban Parks and Recreation
District
Engineer: John M. Pflaum, P.E. McLaughlin
Water Engineers, Ltd.
Contract Value: Approx. $250,000
Scope Synopsis: The scope of work for this
project was the reconstruction of four failing low
water crossings and an upgrade to the
incorporated bank protection and pedestrian
trail segments. The project carried an additional
level of complexity due to the flash flows in Big
Dry Creek and the need to put the trail system
back in service as quickly as possible. Especially challenging was the tight working conditions
created by several large trees that had to be protected to maintain the integrity of natural setting.
Completed Summer 2001.
Project: Chappelow Detention Pond
Owner: City of Evans
Engineer: Martin Howell, P.E. City of Evans
Public Works Department
Contract Value: Approx. $100,000
Scope Synopsis: The scope of work for this
project was the installation of over 1,000 linear
feet of pond shorelining. The shorelining is the
first of its type in the Greeley - Evans area.
The structure utilizes colored concrete to
replicate an eroded sandstone outcrop
shoreline. The project was built by pouring a
15' slab up the pond slope and then "free -
handing" a 5 ' bulkhead with a striated "faux -
sandstone" finish. Completed Spring 2003
References
As part of our diligent customer service effort we aim to maintain a core customer base that will
generate repeat business. As a Contractor over the last few years we have worked with a large
majority of municipalities. We feel that we have enjoyed a great relationship with all of the
inspectors and project engineers and encourage the selection committee to verify these
experiences. Please find below a comprehensive list of references outside of The City of Fort
Collins for your review:
Owners / Customers
Earl Smith, P.E.
City of Evans - Public Works Department
(970) 339 -5344
Jeff Fisher
Urban Drainage & Flood Control District - Project Manager
(303) 455 - 6277
Cindy Thrush
Urban Drainage & Flood Control District - Project Administrator
(303) 455 - 6277
Mark Heidt
City of Brighton
(303) 655 - 2170
Bill Woodcock
South Suburban Parks & Recreation District
(303) 795 - 6531
John M. Pflaum
McLaughlin Water Engineers, Ltd.
(720) 855-6900
Bruce A. Behrer
Muller Engineering
(303) 988 4939
Bonding
Jeff Broyles
Western States Insurance Agency
301 Edelweiss Drive
Bozeman, MT. 59771
(406)586-5151
Material Suppliers
Bestway Concrete Inc.
(970) 351 - 7550
Contact: Tim Hughey
PMC Construction Rentals
(303) 944 - 3062
Contact: Brent Niedringhaus
Foothills Concrete Pipe Products
(970) 785 - 60¢6
Contact: Mike Hoganson
z
NARANJO
C t7 N S T R U C T U R S
EQUIPMENT
VIN/SERIAL #
2004 Bobcat Skidsteer 5300
S/N 525911086
2002 Koamtsu PC200LC - 71.
A86173
1998 Komatsu PC200 LC-6
A83877
1996 Case 621 B Loader
JEE0041490
1996 Case Loader Backhoe 580L
JIG0197278
1999 Komatsu PC60
56132
2001 CAT 246 Skid Loader
055Z03021
DUMP TRUCKS
1993 Kenworth Tractor
1996 GMC Utility Dump Truck
I
I
PICK UPS/SMALL VEHICLES
2004 Ford F 150 Pickup
1 FTPW 14524KD85676
2003 Toyota SR5 4x4 Pickup
5TBBT441 13541 1279
2003 Dodge D2500 Pickup
3D7KU26673G752305
2003 Chevy Cl 500 #43
2GCEC19X431237294
2003 Chevy CI 500 #9
2GCEC19X331379877
2003 Chevy 2500 HD 4x4
I GCHK29GX3E 111090
2002 GMC 2500 Utility Truck 4x4
1 GDHK24UX2E149149
2001 Chevrolet Crew Cab 4x4
I GBIK33GO I F 144708
2001 Chevrolet Crew Cab 4X2
IGBJC33GI 1F146786
2000 GMC Utility Fuel Truck 4X2
1 GDGC24R8YR224615
2000 Chevrolet 1500 Extended Cab 4X4
IGCEK19T9YE150044
1999 Dodge Turbo Diesel 2500 Extended Cab 4X4
I B7KF2363X)544774
1999 Ford Explorer XLT
1 FMZU34E7XZB30376
1999 Ford F350 Crew Cab 4X4
1 FDWW37S3XED96290
1990 Dodge Diesel Pickup Utility
187KE2685LS686435
TRAILERS
1999 Ingersoll Rand Generator Trailer
29677UAJ221
1999 Fontaine Lowboy Trailer
4LF4S5134X3508570
1995 Gold Star Trailer
4HLCH1621ST080982
1995 Maxey Trailer
1 M9FT24T7S 1 104053
1991 Strick Van Trailer
IS i I S8286ME336559
1991 Strick Van Trailer
IS 1 I S8288ME336594
1972 Fruehauf Van Trailer
BLP899218
2001 SUP TRAILER
1 S9TP 14291 C243596
2001 HMD Trailer
ID0319299CO
1981 HMD Trailer
ID61058I COLO
LE CONSTRUCTION
2003 3" Gas Trash Pump
Serial # 18606 Model # QP301 TH
2003 Honda GX120 4.0 HP Joint Saw
n/a
2004 Partner K950 14" Demo Saw
n/a
2003 Partner K950 14" Demo Saw
n/a
2002 Partner K950 14" Demo Saw
n/a
2002 Wylie Water Trailer
n/a
2002 Laser Level Spectra Precision
n/a
2002 Topcon Pipe Laser
n/a
2001 Partner K950 16" Concrete Demo Saw w/blade
n/a
2001 Munro 3" Submersible Pump
n/a
2001 Munro 3" Submersible Pump
n/a
2001 Georgia buggy - Concrete transport
n/a
2001 Georgia buggy - Concrete transport
n/a
2001 Bosch Rotary Hammer Drill 11227E
n/a
2001 Asphalt Cutting tool attachment
n/a
2000 Stanley Hydraulic Plate Compactor for CASE 580
n/a
2000 Partner K950 14" Concrete Demo Saw w/Blade
n/a
2000 Honda Generator 5.5 hP
n/a
2000 Honda Generator 5.5 hP
n/a
1999 Honda Generator 6.5 hP
n/a
1998 Hydraulic Thumb Attachment for Komatsu PC200
n/a
1998 Wacker Jumping Jack
SN-755104405
1998 Hotsy 550C
n/a
1997 Cat Forklift 5000 LB.
05AM05128
1996 Multi - Quip Rammer MT-85H
n/a
1995 Multi - Quip Generator 6.5 hP
n/a
1995 Ground Pounder Plate Compactor (Honda)
N/A
1995 Ground Pounder Plate Compactor (Honda)
n/a
1995 Gar-Bro Concrete Bucket
n/a
1993 Ground Pounder Plate Compactor (Honda)
n/a
1988 Dayton Industrial Generator 1 1 hP
n/a
Bomag BW605 Walk Behind Roller
n/a
1985 Lincoln Arc Welder (Portable)
n/a
1985 Clipper Concrete 14" Floor Saw w/ Diamond Blade
n/a
�' NARAN.JO
C O N S T R U C T O R S
PROJECTS COMPLETED OR UNDER CONSTRUCTION BY OUR FIRM WITHIN, THE LAST 48 MONTHS
NAME & TYPE OF PROJECT
LOCATION
NAME & ADDRESS
ESTIMATED
PERCENT
COMPLETED
OF OWNER
CONSTR. COST
7TH AVE BRIDGE
Greeley, Colo.
City of Greeley
$140,000.00
100%
17-May-01
Bride & Utilies
EAGLE CREST: INLETS,
Del Camino, Colo.
Hall Invin
$30,000,00
100%
25-Jul-01
Excavation, Structural
Greeley, Colo.
BIG DRY CREEK:
Centennial, Colo.
South Suburban
$246,996.80
100%
27-Jul-01
General Contractor
WEST MEADOWS:INLETS,
Denver, Colo.
L&M Enterprises
$3,750.00
100%
31-Aug-01
Box Culverts, Excavation
Berthoud, Colo.
SEVERANCE: INLETS
Severance, Colo.
Union Colony Excavating
$7,800.00
100%
18-Sep-01
Box Culverts, Excavation
Greeley, Colo.
2001 IMPAC PROGRAM:
Greeley, Colo.
City of Greeley
$500,000.00
100%
28-Sep-01
Concrete Flatwork
Greeley, Colo.
DOW LOWELL: INLETS
Denver, Colo.
Walsh Construction
$2,580.50
100%
28-Sep-01
Box Culverts, Excavation
C & D ST. aQ 9TH AVE:
Greeley, Colo.
City of Greeley
$300,000.00
100°%
30-Sep-0t
Road Realignment
Greeley, Colo.
EATON-GOODELL'S
Eaton, Colo.
Goodell Machinery
$5,400.00
1000%
30-Sep-01
Concrete Flatwork
Eaton, Colo.
42ND STREET:
Greeley, Colo.
J-2 Contracting
$13,000,00
100%
31-Oct-01
Structural Concrete
Greeley, Colo.
47TH AVE: INLETS
Greeley, Colo.
Union Colony Excavating
$25,476.60
100°!
31-Oct-01
Box Culverts, Excavation
Greeley, Colo.
QUINCY WALL:
Aurora, Colo.
Urban Drainage & Flood Control
$11,995,D0
100%
14-Nov-01
Structural Concrete
District, Denver, Colo.
BALSAM: INLETS, CULVERTS
Greeley, Colo.
Hall Irwin Corporation
$47,000.00
100%
25-Nov-01
Structural, Excavation
Greeley, Colo.
WESTERLY LAKE:
Aurora, Colo.
Urban Drainage & Flood Control
$70,411,19
100%
27-Nov-01
Structural Concrete
District, Denver, Colo.
NORTHPOINT:
Greeley, Colo.
J-2 Contracting
$28,000.00
100%
30-Nov-01
Inlets
Greeley, Colo.
49TH AVE DRAINAGE:
Greeley, Colo.
J-2 Contracting
$36,000.00
100%
31-Dec-01
Inlets, Storm Sewer Manholes
Greeley, Colo.
2001 BRIDGE REHAB:
Weld County
Weld County Public Works
$99,300.00
100%
31-Jan-02
Bridge Replacement, Structural Concrete
HUNTERS COVE: INLETS,
Greeley, Colo.
Hall Irwin Corporation
$36,000.00
100%
31-Jan-02
Box Culverts, Excavation, Inlets
Greeley, Colo.
OXBOW: INLETS, BOX CULVERT
Greeley, Colo.
Hall Irwin Corporation
$23,000.00
100%
23-Feb-02
Excavation, Structural Concrete, Inlets
Greeley, Colo.
BRIGHTON PHEASANT RIDGE:
Brighton, Colo.
Hall Invin Corporation
$20,000.00
100%
25-Mar-02
Box Culverts, Structural Concrete, Inlets
Greeley, Colo.
FIRESTONE:
Firestone, Colo.
Lefthand Excavating
$2,600.00
100%
22-Apr-02
Structural Concrete
Longmont, Colo.
COAL CREEK:
Lafayette, Colo.
Lefthand Excavating
$9,802.87
100%
9-May-02
Structural Concrete
Longmont, Colo.
COYOTE RUN:
Greeley, Colo.
Greeley Parks - N - Recreation
$40,000.00
100%
13-May-02
Concrete Flatwork
LONGMONT-LYONS:
Longmont, Colo.
Lefthand Excavating
$7,550,00
100%
21-May-02
Structural Concrete
Longmont, Colo.
WEST COOK CREEK:
Lonetree, Colo.
Urban Drainage & Flood Control
$67,924.50
100%
24-May-02
Concrete Flatwork
District, Denver, Colo.
2001 CONCRETE REPAIR
Greeley, Colo.
City of Greeley
$135.000.00
100%
31-May-02
Concrete Flatwork
ACCESS RAMPS:
Greeley, Colo.
City of Greeley
$123,000.00
100%
31-May-02
Concrete Flatwork
NORTHVIEW:
Greeley, Colo.
City of Greeley
$400,000.00
100%
31-May-02
Concrete Flatwork
GRANT STREET:
Littleton, Colo.
Urban Drainage &Flood Control
$12,859.00
100%
7-Jun-02
Storm Sewer Drainageways
IlDistrict,
Denver, Colo.
2012 68TH AVE:
Greeley, Colo.
Classic Builders
$5,000.00
100%
18-Jun-02
Storm Sewer Inlets
Greeley, Colo.
FISH CREEK:
Estes Park, Colo.
Defalco Lee Construction
$108,000.00
100%
30-Jun-02
Concrete Bridge Structure
Longmont, Colo.
RINGWALL:
Brighton, Colo.
Walsh Construction
$12,528.00
100%
30-Jun-02
Structural Concrete
CHERRY HILLS BRIDGE:
Centennial, Colo.
South Suburban
$59,607.75
100%
24-Jul-02
General Contractor
Denver, Colo.
HENDERSON GAUGE:
Henderson, Colo.
Urban Drainage & Flood Control
$186,646.40
100%
26-Jul-02
River Flow Channel
District, Denver, Colo.
PROMONTORY:INLETS,
Greeley, Colo
Hall Irwin Corporation
$62,000.00
100%
30-Jul-02
Box Culverts, Structural Concrete, Inlets
Greeley, Colo.
WEST LAKE:
Broomfield, Colo.
Urban Drainage & Flood Control
$61,368.17
100%
30-Jul-02
Concrete Flatwork
District, Denver, Colo.
2002 CONCRETE REPAIR:
Evans, Colo.
City of Evans
$71,000.00
100%
31-Jul-02
Concrete Flatwork
ALLEN PARK:
Greeley, Colo.
Greeley Parks - N - Recreation
$2,500.00
100%
19-Aug-02
Concrete Flatwork
35TH AVE & 20TH ST:
Greeley, Colo.
J-2 Contracting
$41,000.00
100%
20-Aug-02
Turn Lane Construction, Storm Sewer
Greeley, Colo.
DIAMOND VALLEY:
Windsor, Colo.
Environmental Concerns
$15,000.00
100%
21-Aug-02
Storm Sewer Inlets
11 TH AVE TRAFFIC:
Greeley, Colo.
City of Greeley
$5,600.00
100%
28-Aug-02
Concrete Flatwork
DAYSPRING SCHOOL:
Greeley, Colo.
Dayspring Christian School
$5,000.00
100%
28-Aug-02
Concrete Flatwork
Greeley, Colo.
MONTBELLO CHANNEL:
CITY & COUNTY
URBAN DRAINAGE FLOOD
$100,000.00
100%
30-Sep-02
DRAINAGE CHANNEL REPLACE
OF DENVER
CONTROL DISTRICT
HARVARD GULCH:
CITY & COUNTY
L & M ENTERPRISES
$40,000.00
100%
22-Aug-02
CONCRETE FLATWORK
OF DENVER
BERTHOUD,COLO.
2002 SHARE PROGRAM
CITY OF
CITY OF GREELEY
$90,000.00
100%
23-Aug-02
FLATWORK
GREELEY
2002 DRAINAGE IMPROVE.
Evans, Colo.
City of Evans
$380,000.00
100%
30-Jun-03
Storm Sewer Pipe, Inlets, Manholes
SCHOOL DISTRICT 6:
Greeley, Colo.
School District 6
$35,000.00
100%
7-Oct-02
Concrete Flatwork
Greeley, Colo.
UNC FACULTY APTS.
Greeley, Colo.
FCI Constructors, Inc.
$120,000.00
95%
IN PROGRESS
Concrete Flatwork, Structural Concrete
Longmont, Colo.
37TH ST DRAINAGE:
Evans, Colo.
City of Evans
$230,000.00
100%
21-Feb-03
Storm Sewer Pipe, Inlets, Manholes
ASHCROFT HEIGHTS:
Evans, Colo.
City of Evans
$30,000.00
100%
4-Oct-02
Storm Inlets, Chase Drains
GRAPEVINE HOLLOW
Evans, Colo.
Union Colony Excavating
$122,000.00
100%
30-Jun-03
Headwalls, Inlets, Drop Structures
Greeley, Colo.
2002 INTEGRATION PROJECT
Golden, Colo.
City of Golden
$100,000.00
100%
1-Jun-03
Concrete Flatwork
47TH AVE 24" STORM LINE
Greeley, Colo.
City of Greeley
$50,000.00
100%
30-Jul-03
Storm Sewer Pipe, Inlets, Manholes
FULTON DITCH TRAIL
Brighton, Colo.
City of Brighton
$115, 000.00
100%
05/30/2003
Concrete Flatwork, Structural Concrete
8TH AVE CORRIDOR
Greeley, Colo.
City of Greeley
$430,000.00
100%
25-Jun-03
Storm Sewer Pipe, Inlets, Manholes
PEACHTREE SUBDIVISION
Greeley, Colo.
Union Colony Excavating
$3,000,00
100%
25-Dec-03
Storm Sewer Inlets
Greeley, Colo.
2002 ACCESS PROGRAM -
Greeley, Colo.
City of Concrete
$144,000.00
100%
15-Jul-03
Concrete Flatwork, Handicap Rams
Greeley, Colo.
FREDERICK BOX CULVERTS
Frederick, Colo.
Town of Frederick
$210,000.00
100%
05/16/2003
Box Culverts, Structural Concrete, Inlets
CENTERPLACE
Greeley, Colo.
Hall Irwin Corporation
$156,000.00
100%
1-Aug-03
Structural Concrete, Boulder Placement
Greeley, Colo.
MONTBELLO CHANNEL -PHASE 2
Denver, Colo.
Urban Drainage & Flood Control
$170,000.00
100%
05/30/2003
Concrete Drainage Channel Replacement
District, Denver, Colo.
LAKEWOOD GULCH
Denver, Colo.
Urban Drainage & Flood Control
$40,000.00
100%
05/23/2003
Grouted Boulder Drop Structures
District, Denver, Colo.
CHAPPELOW
Greeley, Colo,
Defalco Lee Construction
$20,000.00
100%
05/23/2003
Structural Concrete
Longmont, Colo.
S. PLATTE RIVER RUNDOWNS
Denver, Colo.
Urban Drainage & Flood Control
$40,000.00
100%
05/16/2003
Grouted Boulder Drop Structures
District, Denver, Colo.
GOLDSMITH GULCH
Denver, Colo
Urban Drainage & Flood Control
$40,000.00
100%15-Sep-03
Drop Structure Replacement
District, Denver, Colo.
2003 ACCESS RAMP PROJECT
Greeley, Colo.
City of Greeley
$60,000.00
Installing Handicap Rams
Greeley, Colo.
SULPHUR GULCH
Parker, Colo.
Town of Parker
$700,000.00
100%
26-Sep-03
Grouted Boulder Drop Structures, Flatwork
2003 SCHOOL SIDEWALK PROJECT
Greeley, Colo.
City of Greeley
$30,000.00
100%
25-Aug-03
Concrete Flatwork
2003 CONCRETE REPAIR PROGRAM
Evans, Colo.
City of Evans
$60,000.00
100%
31-Oct-03
Concrete Flatwork
LITTLE DRY CREEK AT UINTA STREET
Littleton, Colo.
Urban Drainage & Flood Control
$166,000.00
100%
15-Oct-03
Drop Structure Replacement
District, Denver, Colo,
IDAHO CREEK
Longmont, Colo.
Hall Irwin Corporation
$15,D00.00
100%
31-Jan-04
Box Culvert Installation
Greeley, Colo.
2003 CONCRETE MAINTENANCE
Greeley, Co.
City of Greeley
$145,000.00
100%
30-Nov-03
Concrete Flatwork
SKUNK CREEK
Boulder, Colo.
Lefthand Excavating
$30,000.00
100%
30-Sep-03
Installing Retaining Wall
Longmont, Colo.
RALSTON CREEK
Denver, Colo.
Urban Drainage & Flood Control
$80,000.00
100%
25-Feb-04
Structural - Drainage
District, Denver, Colo.
BALDWIN GULCH
Parker, Colo.
Douglas County
$280,000.00
100%
30-May-04
Structural - Drainage
Castle Rock, Colo.
DUTCH CREEK
Denver, Colo.
Urban Drainage & Flood Control
$135,000.00
100%
25-Apr-04
Structural - Drainage
District, Denver, Colo.
SJCD 6200
Littleton, Colo.
Urban Drainage & Flood Control
$28,000.00
100%
30-Nov-03
Structural - Drainage
District Denver, Colo.
LEFTHAND CREEK
Longmont, Colo.
Defalco Lee Construction
$130,000,00
100%
15-May-04
Flatwork - Structural
Longmont, Colo.
ADA HIGHLAND HILLS-MAINT. CENTER
Greeley, Colo.
City of Greeley
$85,000.00
100%
10-Sep-04
Flatwork
EVANS DITCH DIVERSION
Evans, Colo.
City of Evans
$450,000.00
100%
8-15-204
Structural - Drainage
2004 EVANS CONCRETE REPAIR
Evans, Colo.
City of Evans
$80,000.00
100%
15-Aug-04
Concrete Flatwork - Pi a Installation
MONTBELLO PHASE III
Denver, Colo.
Urban Drainage & Flood Control
$120,000.00
100%
5-May-04
Drainage Channel Replacement
District, Denver, Colo.
THE PINERY - WINDLAWN WAY
Parker, Colo.
Douglas County
$260,000.00
100%
27-Aug-04
Structural - Drainage
Parker, Colo.
MOUNT VERNON CREEK
Morrison, Colo.
Urban Drainage & Flood Control
$240,000.00
100%
31-Aug-04
Structural - Drainage - Flatwork
District, Denver, Colo.
SULPHUR PHASE 5
Parker, Colo.
Town of Parker
$70,000.00
100%
3-Sep-04
Grouted Boulder Drop Structure
Parker, Colo.
TWENTY MILE
Parker, Colo,
Urban Drainage & Flood Control
$70,000.00
100%
20-Jun-04
Grouted Boulder Drop Structure
Denver, Colo.
AURORA DAIRY
Platteville, Colo.
Hall Irwin Corporation
$180,000.00
100%
15-Dec-04
Structural - Drainage - RipTap
Greeley, Colo.
PREBLE CREEK
Broomfield, Colo.
Hall Irwin Corporation
$215,000.00
80%
In Progress
Structural Concrete - Box Culvert
Greeley, Colo.
Est. 4-15-05
CLEAR CREEK
Wheatridge, Colo.
Urban Drainage & Flood Control
$25,000.00
100%
15-Sep-04
Drainage Channel Improvements
Denver, Colo.
NIVER CREEK
Northglenn, Colo.
Urban Drainage & Flood Control
$9,000.00
100%
31-Aug-04
Cleaning Drainage Channel
Denver, Colo.
112TH AVE & IRMA
Northglenn, Colo.
Urban Drainage & Flood Control
$20,000.00
100%
27-Aug-a
Cleaning Drainage Channel
Denver, Colo.
GOLDEN 2004 CONCRETE REPAIR
Golden, Colo.
City of Golden
$680,000,00
95%
Contract Renewal
Concrete Flatwork Replacement
Golden, Colo.
Est. 9-30-2005
2004 Concrete Repair
Greeley, Colo.
Weld County School District
$90,000.00
100%
1-Jan-OS
Concrete Flatwork
88TH AVE BOX CULVERT
Commerce City, Co.
City of Commerce City
$120,000.00
100%
3-Sep-04
Replacement of Box Culvert Structure
Commerce City, Colo.
CENTENNIAL VILLAGE
Greeley, Colo.
City of Greeley
$10,000.00
100%
31-Jul-04
Structural Concrete
Greeley, Colo.
Brook Valley
Littleton, Colo.
Urban Drainage & Flood Control
$88,072.00
60%
In Progress
Drainage Im rovements
Denver, Colo.
Est. 4-15-2005
WCR 13 & WCR 18
Frederick, Colo.
Town of Frederick
$533,501.00
99%
25-Mar-05
Structural Box Culvert
Frederick, Colo.
Westerly Creek
Denver, Colo.
Urban Drainage & Flood Control
$35,000.00
100%
15-Dec-04
Concrete Flatwork-Drainage Channel
Denver, Colo.
So. Platte River Trail Improvements
Denver, Colo.
Urban Drainage & Flood Control
$27,000,00
50%
1-Apr-05
Concrete Flatwork
Denver, Colo.
West Harvard Gulch
Denver, Colo.
Urban Drainage & Flood Control
$60,000,00
100%
1-Dec-04
Concrete Flatwork
Denver, Colo.
Coon Creek
Denver, Colo.
Urban Drainage & Flood Control
$188,335,00
80%
In Progress
Drainage Improvements
Denver, Colo.
Est, 4-8-2005
Stone Canyon
Lyons, Colo.
Crow Creek Construction
$165,000.00
60 %
In Progress
Stuctural Concrete
Greeley, Colo.
Est. 4-29-2005
SECTION 00430
r^
SCHEDULE OF SUBCONTRACTORS
List all subcontractors for the work items listed below and all subcontractors
performing over 150 of the contract.
ITEM SUBCONTRACTOR
H dco [�j a-�; V e Sete! , c
r:
r-
d=
r
r-
r=.
e _
r
7/96 Section 00430 Page 1
ATTENDANCE RECORD
PRE CONFERENCE
Project: Bid #5908 PLEASANT VALLEY LAKE AND CANAL TRAIL
Time: 10:OOA.M.
Date: MARCH 21, 2005
Location: 1401 W. HORSETOOTH ROAD, PARKING LOT
NAME
FIRM NAME
ADDRESS
TELEPHONE
FAX #
E-MAIL ADDRESS
I -TV -J \
CO ,� �i , .�J' 1
(574o1
f
9tQA
- I i
k�T tTl. iT `'Ci G:k+1
a ` Warm/
-W s
18b3 a^� A e
Kcl Cot,, %to3)
q-iu-
. S,- RoR
35''-ogg-7
C.Ar%e
IO
c�
Ul c vU
S ��s� s�
G6/ Tr4ot 4jox M
o. b
-t
(0
lA,4,-,NJ
uG MIKkurit
uV-1
VoW � Amv'o
Pla yl le ZD(051
� s-(O«,
*72 - 256
jDevll-y\@ ear-rM14.ne-r
t J
p
;t7e l S'
3�3
33 W66
J nl(`f CEictoL: •�
3D{F� 57-t ��if
r, e
tf
SECTION 00500
AGREEMENT FORMS
00510Notice of Award
00520Agreement
00530Notice to Proceed
SECTION 00510
NOTICE OF AWARD
Date: April 20, 2005
TO: NARANJO CIVIL CONSTRUCTORS, INC.
PROJECT: PLEASANT VALLEY LAKE AND CANAL TRAIL; BID NO. 5908
OWNER: CITY OF FORT COLLINS
(hereinafter referred to as "the OWNER")
You are hereby notified that your Bid dated April 4, 2005 for the above project
has been considered. You are the apparent successful Bidder and have been
awarded an Agreement for PLEASANT VALLEY LAKE AND CANAL TRAIL; BID NO. 5908.
The Price of your Agreement is Seventy-two Thousand Five Hundred -fifteen
Dollars ($72,515.00).
Three (3) copies of each of the proposed Contract Documents (except Drawings)
accompany this Notice of Award. Three (3) sets of the Drawings will be
delivered separately or otherwise made available to you immediately.
You must comply with the following conditions precedent within fifteen (15)
days of the date of this Notice of Award, that is by May 5, 2005.
1. You must deliver to the OWNER three (3) fully executed counterparts of
the Agreement including all the Contract Documents. Each of the Contract
Documents must bear your signature on the cover of the page.
2. You must deliver with the executed Agreement the Contract Security
(Bonds) as specified in the Instructions to Bidders, General Conditions
(Article 5.1) and Supplementary Conditions.
Failure to comply with these conditions within the time specified will entitle
OWNER to consider your Bid abandoned, to annul this Notice of Award and to
declare your Bid Security forfeited.
Within ten (10) days after you comply with those conditions, OWNER will return
to you one (1) fully -signed counterpart of the Agreement with the Contract
Documents attached.
City of Fort Collins
OWNER
By:
Ja es B. O'Neil II, CPPO, FNIGP
Direc o of Purchasing and Risk Management
Title
9/12/01 Section 00510 Page 1
SECTION 00520
AGREEMENT
THIS AGREEMENT is dated as of the 20th day of April in the year of
2005 and shall be effective on the date this AGREEMENT is signed by
the City.
The City of Fort Collins (hereinafter called OWNER) and
Naranjo Civil Constructors, Inc. (hereinafter called CONTRACTOR)
OWNER and CONTRACTOR, in consideration of the mutual covenants
hereinafter set forth, agree as follows:
ARTICLE 1. WORK
CONTRACTOR shall complete all Work as specified or indicated in the
Contract Documents. The Project for which the Work under the Contract
Documents may be the whole or only a part is defined as the
construction including 8 foot wide concrete trail, 8 foot wide
pedestrian bridge, stump and tree/shrub removal, and seeding.
ARTICLE 2. ENGINEER
The Project has been designed by City of Fort Collins Park Planning,
who is hereinafter called ENGINEER and who will assume all duties and
responsibilities and will have the rights and authority assigned to
ENGINEER in the Contract Documents in connection with completion of
the Work in accordance with the Contract Documents.
ARTICLE 3. CONTRACT TIMES
3.1 The Work shall be Substantially Complete within 80 calendar
days after the date when the Contract Times commence to run as
provided in the General Conditions and completed and ready for Final
Payment and Acceptance in accordance with the General Conditions
within 90 calendar days after the date when the Contract Times
commence to run.
3.2. Liquidated Damages. OWNER and CONTRACTOR recognize that
time is of the essence of this Agreement and that OWNER will suffer
financial loss if the Work is not completed within the times specified
in paragraph 3.1. above, plus any extensions thereof allowed in
accordance with Article 12 of the General Conditions.
They also recognize the delays, expenses and difficulties involved in
proving in a legal proceeding the actual loss suffered by OWNER if the
Work is not completed on time. Accordingly, instead of requiring any
such proof, OWNER and CONTRACTOR agree that as liquidated damages for
delay (but not as penalty) CONTRACTOR shall pay OWNER the amounts set
forth hereafter.
1) Substantial Completion:
Three Hundred ($300.00) for each calendar day or fraction
thereof that expires after the Eighty (80) calendar day
period for Substantial Completion of the Work until the
Work is Substantially Complete.
2) Final Acceptance:
After Substantial Completion, One Hundred Fifty Dollars
($150.00) for each calendar day or fraction thereof that
expires after the Ten (10) calendar day period for Final
Payment and Acceptance until the Work is ready for Final
Payment and Acceptance.
ARTICLE 4. CONTRACT PRICE
4.1. OWNER shall pay CONTRACTOR for performance of the Work in
accordance with the Contract Documents in current funds as
follows:($72,515.00), Seventy-two Thousand Five Hundred Fifteen
Dollars, in accordance with Section 00300, attached and incorporated
herein by this reference.
ARTICLE 5. PAYMENT PROCEDURES
CONTRACTOR shall submit Applications for Payment in accordance
with Article 14 of the General Conditions. Applications for Payment
will be processed by ENGINEER as provided in the General Conditions.
5.1. PROGRESS PAYMENTS. OWNER shall make progress payments on
account of the Contract Price on the basis of CONTRACTOR's Application
for Payment as recommended by ENGINEER, once each month during
construction as provided below. All progress payments will be on the
basis of the progress of the Work measured by the schedule of values
established in paragraph 2.6 of the General Conditions and in the case
of Unit Price Work based on the number of units completed, and in
accordance with the General Requirements concerning Unit Price Work.
5.1.1. Prior to Substantial Completion, progress payments will
be in the amount equal to the percentage indicated below, but, in each
case, less the aggregate of payments previously made and less such
amounts as ENGINEER shall determine, or OWNER may withhold, in
accordance with paragraph 14.7 of the General Conditions. 90% of the
value of Work completed until the Work has been 50% completed as
determined by ENGINEER, when the retainage equals 5% of the Contract
Price, and if the character and progress of the Work have been
satisfactory to OWNER and ENGINEER, OWNER on recommendation of
ENGINEER, may determine that as long as the character and progress of
the Work remain satisfactory to them, there will be no additional
retainage on account of Work completed in which case the remaining
progress payments prior to Substantial Completion will be in an amount
equal to 100% of the Work completed. 90% of materials and equipment
not incorporated in the Work (but delivered, suitably stored and
accompanied by documentation satisfactory to OWNER as provided in
paragraph 14.2 of the General Conditions) may be included in the
application for payment.
5.1.2. Upon Substantial Completion payment will be made in an
amount sufficient to increase total payments to CONTRACTOR to 950 of
the Contract Price, less such amounts as ENGINEER shall determine or
OWNER may withhold in accordance with paragraph 14.7 of the General
Conditions or as provided by law.
5.2. FINAL PAYMENT. Upon Final Completion and Acceptance of the
Work in accordance with paragraph 14.13 of the General Conditions,
OWNER shall pay the remainder of the Contract Price as recommended by
ENGINEER as provided in said paragraph 14.13.
ARTICLE 6. CONTRACTOR'S REPRESENTATION
In order to induce OWNER to enter into this Agreement, CONTRACTOR
makes the following representations:
6.1. CONTRACTOR has familiarized himself with the nature and
extent of the Contract Documents, Work, site, locality, and with all
local conditions and Laws and Regulations that in any manner may
affect cost, progress, performance or furnishing of the Work.
6.2. CONTRACTOR has studied carefully all reports of
explorations and tests of subsurface conditions and drawings of
physical conditions which are identified in the Supplementary
Conditions as provided in paragraph 4.2 of the General Conditions.
6.3. CONTRACTOR has obtained and carefully studied (or assumes
responsibility for obtaining and carefully studying) all such
examinations, investigations, explorations, tests, reports, and
studies (in addition to or to supplement those referred to in
paragraph 6.2 above) which pertain to the subsurface or physical
condition at or contiguous to the site or otherwise may affect the
cost, progress, performance or furnishing of the Work as CONTRACTOR
considers necessary for the performance or furnishing of the Work at
the Contract Price, within the Contract Times and in accordance with
the other terms and conditions of the Contract Documents, including
specifically the provisions of paragraph 4.2 of the General
Conditions; and no additional examinations, investigations,
explorations, tests, reports, studies or similar information or data
are or will be required by CONTRACTOR for such purposes.
6.4. CONTRACTOR has reviewed and checked all information and
data shown or indicated on the Contract Documents with respect to
existing Underground Facilities at or contiguous to the site and
assumes responsibility for the accurate location of said Underground
Facilities. No additional examinations, investigations, explorations,
tests, reports, studies or similar information or data in respect of
said Underground Facilities are or will be required by CONTRACTOR in
order to perform and furnish the Work at the Contract Price, within
the Contract Times and in accordance with the other terms and
conditions of the Contract Documents, including specifically the
provision of paragraph 4.3. of the General Conditions.
6.5. CONTRACTOR has correlated the results of all such
observations, examinations, investigations, tests, reports and data
with the terms and conditions of the Contract Documents.
6.6. CONTRACTOR has given ENGINEER written notice of all
conflicts, errors or discrepancies that he has discovered in the
Contract Documents and the written resolution thereof by ENGINEER is
acceptable to CONTRACTOR.
ARTICLE 7. CONTRACT DOCUMENTS
7.1 The Contract Documents which comprise the entire Agreement
between OWNER and CONTRACTOR concerning the Work consist of the
General Conditions, Supplementary Conditions, those items included in
the definition of "Contract Documents" in Article 1.10 of the General
Conditions, and such other items as are referenced in this Article 7,
all of which are incorporated herein by this reference.
7.2 Forms for use by CONTRACTOR in performing the Work and
related actions in carrying out the terms of this Agreement are deemed
Contract Documents and incorporated herein by this reference, and
include, but are not limited to, the following:
7.2.1Certificate of Substantial Completion
7.2.2 Certificate of Final Acceptance
7.2.3 Lien Waiver Releases
7.2.4Consent of Surety
7.2. 5 Application for Exemption Certificate
7.2.6Application for Payment
7.3 Drawings, consisting of a cover sheet and sheets as
follows:
1-Cover Sheet, 2-Location Map, 3-Bridge Plan and Profile 1
of 4, 4-Trail Plan and Profiles 2 of 4, 5-Trail Plan and
Profiles 3 of 4, 6-Trail Plan and Profiles 4 of 4
The Contract Drawings shall be stamped "Final for Construction" and
dated. Any revisions made shall be clearly identified and dated.
7.4. Addenda Numbers 1 to 1, inclusive.
7.5. The Contract Documents also include all written amendments
and other documents amending, modifying, or supplementing the Contract
Documents pursuant to paragraphs 3.5 and 3.6 of the General
Conditions.
7.6. There are no Contract Documents other than those listed or
incorporated by reference in this Article 7. The Contract Documents
may only be amended, modified or supplemented as provided in
paragraphs 3.5 and 3.6 of the General Conditions.
ARTICLE 8. MISCELLANEOUS
8.1. Terms used in this Agreement which are defined in Article I
of the General Conditions shall have the meanings indicated in the
General Conditions.
8.2. No assignment by a party hereto of any rights under or
interests in the Contract Documents will be binding on another party
hereto without the written consent of the party sought to be bound;
and specifically but not without limitations, moneys that may become
due and moneys that are due may not be assigned without such consent
(except to the extent that the effect of this restriction may be
limited by law), and unless specifically stated to the contrary in any
written consent to an assignment no assignment will release or
discharge that assignor from any duty or responsibility under the
Contract Document.
8.3. OWNER and CONTRACTOR each binds itself, its partners,
successors, assigns and legal representatives to the other party
hereto, its partners, successors, assigns and legal representatives in
respect to all covenants, Agreement and obligations contained in the
Contract Document.
OWNER: CITY OF FORT COLLINS
DAME$ B/. O'NEILL II, CPPO, FNIGP
RECTOR OF PURCHASING
AND R�J MAN GEM^E�T
Date: tlb
CONTRACTOR: Naranjo Civil
Constructors, Inc.
Date: 5-4. 2'n=g
(CORPORATE SEAL)
Ant/tes I / *" (4t� Attest:
NMJ�
Ad zes fo V A n notices: Address for giving notices:
P. O.•'pBox 580
Fort vpl1, 80522 �ce/eye Glo kb63/
LICENSE NO.:
Approved as to Form
Assistan City ttorney
{ L
r! a fAA
SECTION 00530
NOTICE TO PROCEED
Description of Work: PLEASANT VALLEY LAKE AND CANAL TRAIL; BID NO. 5908
To
This notice is to advise you:
That the contract covering the above described Work has been fully executed by
the CONTRACTOR and the OWNER.
That the required CONTRACTOR's Performance Bond and Payment Bond have been
received by the OWNER.
That the OWNER has approved the said Contract Documents.
Therefore, as the CONTRACTOR for the above described Work, you are hereby
authorized and directed to proceed within ( ) calendar days from
receipt of this notice as required by the Agreement.
Dated this day of 20
The dates for Substantial Completion and Final Acceptance shall_ be
and , 20_, respectively.
City of Fort Collins
OWNER
By:
Title:
ACKNOWLEDGMENT OF NOTICE
Receipt of the above Notice to Proceed is hereby acknowledged this day
of , 20 .
CONTRACTOR
By:
Title:
7/96 Section 00530 Page 1
SECTION 00600
BONDS AND CERTIFICATES
00610Performance Bond
00615Payment Bond
00630Certificate of Insurance
00635Certificate of Substantial Completion
00640Certificate of Final Acceptance
00650Lien Waiver Release (CONTRACTOR)
00660Consent of Surety
006'?0Application for Exemption Certificate
CONTRACT DOCUMENTS TABLE OF CONTENTS
Section
BID INFORMATION
00020 Notice Inviting Bids
00100 Instruction to Bidders
00300 Bid Form
00400 Supplements to Bid Forms
00410 Bid Bond
00420 Statements of Bidders Qualifications
00430 Schedule of Major Subcontractors
CONTRACT DOCUMENTS
00500 Agreement Forms
00510 Notice of Award
00520 Agreement
00530 Notice to Proceed
11
00600 Bonds and Certificates
00610 Performance Bond
00615 Payment'Bond
00630 Certificate of Insurance
00635 Certificate of Substantial Completion
00640 Certificate of Final Acceptance
00650 Lien Waiver Release(Contractor)
00660 Consent of Surety
00670 Application for Exemption Certificate
CONDITIONS OF THE CONTRACT
00700 General Conditions
Exhibit GC -A
00800 Supplementary Conditions
00900 Addenda, Modifications, and Payment
00950 Contract Change Order
00960 Application for Payment
SPECIFICATIONS
Pages
00020-1 - 00020-2
00100-1 - 00100-9
00300-1 - 00300-2
00400-1
00410-1 - 00410-2
00420-1 - 00420-3
00430-1
00500-1
00510-0
00520-1 - 00520-6
00530-1
00600-1
00610-1 - 00610-2
00615-1 - 00615-2
00630-1
00635-1
00640-1
00650-1 - 00650-2
00660-1
00670-1 - 00670-2
00700-1 - 00700-34
GC -Al - GC-A2
00800-1 - 00800-2
00900-1
00950-1 - 00950-2
00960-1 - 00960-2
:;ECTION 00610
PERFORMANCE BOND
Dond No.882210P
KNOW A(1 MEN BY THESE PRESENTS: that.
(Finn) Naranjo Civil Constructors, Inc.
(Add_ess)1863 2nd Ave., Greeley, Co 80631-5901
(an Indivi.dual), (,a Partnership), (a Corporation), here. i.naftc.r referred t:o ,a* tho
"Principal" and
W i.rcr) Developers Surety and Indemnity Company
(Addr(-.r;r;)7211 S. Peoria St. Ste. 290, Englewood, CO 80112
hereinaftor roforrod to a:; "t:he Surety", are held and firmly bound unto C;i.ty of
Fort Collins, 300 Laporto Ave, Fort Collins Colorado 80522 a (Municipal
Corporation) hereinafter reforred to Ns l.he. "OWNER", in the. pcna.l sum of
im lawful money of the United States, foz the
p rytnc nt cif. whirh arum well and truly LO be made, we bind Ourr:elveS, SucceSSOrs , rid
assigns, jointly and seve-rally, firmly by these presanL:;.
THE CONDITIONS OF THIS OnT,rGATION are ::uch that. wher.oa., thn Principal ontered
into a certain Agreement with the OWNER, dated t:hn 2p4day of '�a.I ,
2005, a• copy of which is hcret.o attached and made a part heroof for the
performance of 'r•he City of Fort Collins projnct, PLEASANT VALLEY LAKE AND CANAL
TRATL; 8X0 NO. .9908.
NOW, THEREFORE, if the Principal shall well, truly and f,3 i thf:ully perform i.t.s
duLies, all the undertnkingm, uovenant�;, Lernls, C:Onditions and cs9reement:i of, said
'Agreement during the oricli.na.l term tho•re;of, and any cxtensions thc.roof which may
be gr rrLed by the OWNER, with or without Not:Lc:e: to the Surety and during the life
of the gr,ar•ant.y period, and if the Principal shill satisfy all claims and demands
i.ncurl:od under ,;u0L agreement, and shall fully inctemniLy and save harmless the
OWNER from all co^t and damages which it may surfer by 1:0a:;on or Lailure to c%o
so, and shall reimbur!;e: and repay the. OWNER all outlay and cn-xpense: which the
OWNER may incur in making good any defaulL then thin obligation ,hall. be void;
otherwise. La' remain in. full force and cf.feci:.
*-Seventy-two Thousand Five Hundred -fifteen Dollars ($72,515.00)
7/90 Section 00610 Page I
Kzovll.)P;(), FURTHER, Lhal. I.he said Surely, for va.L,,c rec_ivc,d, horoby stipulates
and agrees that no change, extension of time, al,toration or addition to r.hc term;;
OF t:hr. AgrLlement or LO the Work to be perrormed rh(t rounder or- the Specifications
accompanying the same shall in any way affect. its obligation on this bond; and 11
doeeFr hereby waive notice of any such chartcic, extension of t.iare., all .oration or
addition to I.he. t:e.rms, of the Agreement: or to the Work or to t.hc Specificat.i.ons,
t-YM t l)ED, FURTHER, L•hat. no final ue.ttlement betwer.n the OWNER 'inci the- CONTRACTOR
shall a1Dr.idc7e the right of any hencficiary hereunder, whose claim niny be
unsatisfied.
PROVIDED, F1jRTKF.':R, that. the Surely Company must be aut..horizrd to transact
business in the State of Coiorado and be arc_e.ptable Lo the OWNER.
IN"WTTNr;:,S WHEREOF, thl.s Lnst•rument is exr•,cuted in three (3) counl.erpurt5, each.
one of which �;hall he dr:cmr_d an original., this 44- day of. PAa,
20DS, " "t .
IN PRESENCE OF:
,a1)
IN
PF. SBN31-j(1,':
r
�
.,
� a
J"
Principal
Naranjo Civil Constructors, Inc.
f V !ce - Rtes:,Aas
1862 2nd Ave., Greeley, CO 80631-5901
(Address) _
Other Partners
By-.- _.. --
I ,`'' G f•;NCh: C>1 : Surety 1;, t y Developers urety and Indemnity Company
9 p / AM—
JeffBroyles, Attorney -In -Fact
By:_ .2211 S. PPoria St. Ste. 290, Englewood, CO
(Address) 80112
(:iur(-et.y Seai)
NOTE: Date of Bonet must not be prior to date of Agreement,
it CONTRACTOR is ParLnrr.ship, al.l partners :,hould execute Bong.
t
��96 Sec:tion 00610 Pace 2
SECTION 00615
PAYMENT BOND
Bond No. 882210P
KNOW Aa ,I, M'..,N BY THESE PRESENTS: that
(Firm) Naranjo Civil Constructors, Inc.
(Address) 1863 2nd Ave., Greeley, CO 80631-5901
(an Individual.), (,s PmrL•ner5hip), (a Corporation), hereiruiLt.er referred to as the
"Principal" and
(Firm, Developers Surety and Indemnity Company
(Addres,$) 7211 S. Peoria St. Ste. 290, Englewood, CO 80112
hereinafter
referred
to as "the Surrtty",
arc held and firmly bound
unto the Cif
of Tort Collin:.,
309
Laporte Avo.,
Fort. Collins, Colorado 80522
11
a (Mun.Lci.pal
Corporation)
1Zr..re i.naLl.er referred
to as "the OWNER", in the
penal sum of
in lawful money of the United States, for
the payment
of which
sum well find truly
Lo be made, we bind ourselves,
successors
and :is.-i.gns,
jointly
and sevorally,
firmly by thesc pr.osont:,.
THE CONDITION.'.; Or' THIS OBLIGATION aro such that whereas the Prinr..i.pxl enl:ered
into a certain AgreemenL with the OWNER, dated the Zp'K day of pc�� 200s, a Copy of which is hereto attached and made a part hezoo.7 for_thc
performance of The Ci.ty of FurL Collins projec.L, PLEASANT VALLEY LAKE AND CANAL
't'ttl1IL; BID NO. 6908,
NOW, Tf1T.'.Kh.1h'C71tJ, it the Principal e.;ha1.1 make: payment t'p all persons, firms,
subcont.ractore, n:id 'corporations furnishi.nq materials for or performing labor in
the prosecution of Lhe Work provided -for in such Agreement and any aut_hor.i.zed
extension or modi.f.i.cat:ion thereof, including all amounts clue for mrateri.,als,
lubricants, repairs on rnac:hinery, equipnienL• and tools, consumed, rented or used
in ConneCLion with the con:-,,t_ruc: Lion of Such Work, and ;ill in:;urance premiums on
said Work, anti for all labor, prr.formed in such Work whothcr by subcontractor or
otherwisse, then Lhis obligation shall. bo void; otherwise to .rcm,ain in full force
and effect.
* Seventy-two Thousand Five Hundred -fifteen Dollars ($72,515.00)
+
7/96 :iection 00615 Put}c: 1
PROVIDED, FURTHER, that 01e ,aid Surety, for, value received, hereby stipu.letc,
and agt'ee6 that• no change, extension of 11J.me, alt.-ration or nddiI -ion l:<) the terlTi£
of the Agreement or to the Work Lo he pertormed thr..rcundcr or the Specifications
accompanying t:he snmc shall in any way afEect its obligation on this, tx>rid; and it
does hereby waive notice of any such change, exterislorr of time,., alteration or
addition to the term. OE t.hr. Agreeemrnt or 1:o the Work or to the Speciticaticiriz.
PROVIDED, FURTHER, that no final set.t.l.ement between the OWNt•:h and t.hc CONTRACTOR
shall abridge the right: of any beneficiary hereondr_.r, whose claim may be:
unsat:i:;fied.
PROVIDED, FURTHER, Lhat. l.he Surety Company must_ b,^ authorized to transact:
business in the :Stmt..e of Colorado and be acceptable. to the OWNER.
1N WITNESS WHEREOF, this instrument is executed in three (3) r".ounterpnr.ts;, each
ono of which shall be deemed an original., this �! dny of.
20f.
IN PRESENCE 0r': Principal
By: Naranjo Civil Constructors Inc.
r _Jlce Pnsc6.1
U
.{Corppra't* Weal)
:IN PRESEN�"®F:
S; y
,i
IN .PRESENCE OF:
J
j § ,
(Suret:y PSea1 )
1862 2nd Ave., Greeley, CO 80631-5901
.......------
Other Partners
Surety DZZ
lope'Ss Surety and Indemnity Company
Jey L. Broyles, Attorney -In -Fact
By._..Z211.. S. Peoria St. $te. 290,•.Englewood, CO 80112
(Address)
NOTE: Date of Bond roust not be prior to date of Agreement..
If CONTRACTOR i.s NHrt.ne.r.ship, all partner,; t,hoitld execute 11ond.
'7/9n". 1Section 00615 Page 2
POWER OF ATTORNEY FOR
DEVELOPERS SURETY AND INDEMNITY COMPANY
PO BOX 19725,IRVINE.C'A92623 (949)263-3300
www. hiscoDiai.coni
KNOW ALL MEN BY THESE PRESENTS. that except as expressly limited. DEVELOPERS SURETY AND INDEMNITY COMPANY does hereby make,
constitute and appoint:
***D.N. Broyles, Kathryn D. Broyles, Todd D. Bengford, Thomas D. Berry, Susan Howard, Jeffrey L. Broyles,
Don R. Broyles, Marie E. Reinoehl, Derek Grewatz, Kelly L. Tenold, Spencer Fred Thomas, Kristin A. Poling,
jointly or severally***
as its true and lawful Attorneys) -in -Fact, to make, execute, deliver and acknowledge, for and on behalf of said corporation as surety, bonds, undertakings and
contracts of suretyship giving and granting unto said Attorney(s)-in-Fact full power and authority to do and to perform every act necessary, requisite or proper to
be done in connection therewith as the corporation could do, but reserving to the corporation full power of Substitution and revocation, and all of the acts of said
Attomcy(s)-in-Fact, pursuant to these presents. are hereby ratified and confirined.
This Power of Attorney is granted and is signed by facsimile under and by authority of the following resolution adopted by the Board of Directors of DEVELOPERS
SURETY AND INDEMNITY COMPANY effective as of November 1. 2000:
RESOLVED, that the Chairman of the Board, the President and any Vice President of the corporation be, and that each of them hereby is, authorized to
execute Powers of Attorney. qualifying the Attorney(s)-in-Fact named in the Powers of Attorney to execute. on behalf of the corporation, bonds, undertakings and
contracts of suretyship; and that file Secretary or any Assistant Secretary of the corporation be, and each of them hereby is, authorized to attest the execution of
any such Power of Attorney:
RESOLVED. FURTI IER, that the signatures of such officers may he affixed to any such Power of Attorney or to any certificate relating thereto by
facsimile, and any such Powcr of Attorney or certificate hearing such facsimile signatures shall be valid :md binding upon the corporation when so affixed and in
the future with respect to any band. undertaking or contract of suretyship to which it is attached.
IN WITNESS WHEREOF. DEVELOPERS SURETY AND INDEMNITY COMPANY has caused these presents to be signed by its respective Executive Vice
President and attested by its Secretary this I st day of October. 2003.
. AND
By
.JQrc ,,,,POR.
: 5 VOR q
David H. Rhode%. Executive Vice -President
y e
z
a 10
1936
,/0 W P;,
By: _A1Zw—Walter
,��"'".........
A. Crowell. Secretary
STATE OF CALIFORNIA )
)SS.
COUNTY OF ORANGE )
On October I, 2003, before file. Diane .I. Knwata. personally appeared David H. Rhodes and Walter A. Crowell, personally known tome (or proved to
fire on the basis of satisfactory evidence) to be the persons whose names are subscribed to the within instrument mid acknowledged to me that they executed the
same in their authorized capacities, and that by their signatures on the instrument the entity upon behalf of which the persons acted, executed the instrument.
WITNESS my hand and official seal
DIANE J. =ATA
G@My
COMMif 1334746
��y �Notary Pudic - CaliforniaA�� �iORANGE COUNTY
Signature L PC.S""� Comm. Expires JAN. 8. 20061
CERTIFICATE
The undersigned, as Senior Vitt -President. Underwriting, of DEVELOPERS SURETY AND INDEMNITY COMPANY, does hereby certify that the
foregoing Powcr of Attorney remains in fill] force and has not been revoked, and furthermore, flint the provisions of the resolution of the respective Boards of
Directors of said corporntion set forth in the Power of Attorney, is in force as of the date of this Certificate.
This Certificate is executed in, the City of Irvine. California, the day of
By
Weslcy W. Cowling• enior Vice-Pi-esideni. Undcfuri r a—
ID-1438 (DSI) (Rev. 10103)
SECTION 00630
CERTIFICATE OF INSURANCE
CONTRACTOR shall insert his own standard form for Certificate of Insurance.
7/96 Section 00630 Page 1
CERTIFICATE OF LIABILITY INSURANCE OP ID D OnrE(Mnnoonrr5)
rORD
�y^-„� H&LCO-1 04/25/0
PRODUCER THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION
ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
LBN Insurance Agency, LLC GR HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
3459 W 20th Street Suite 224 ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
Greeley CO 80634
Phone:970-356-1133 Fax:970-356-4088 INSURERS AFFORDING COVERAGE NAIC#
INSURED INSURER A: EMC Insurance Companies
Naranjo Civil Constructors Inc INSURERS: Pinnacol Assurance
H&L Concrete, Inc & Naranjo INSURERC:
Investments, LLC
1863 2nd Avenue INSURER D:
Greeley, CO 80631 INSURER E:
GUVtKAUrb
THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING
ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR
MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH
POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
LTR
NSR
TYPE OF INSURANCE
POLICY NUMBER
DATE MM/DD/YY
POLICY EXPIRATION
DATE MM/DD1YY
LIMTOUCYIFFECTW BS
A
GENERAL LIABILITY
PXCOMMERCIAL GENERAL LIABILITY
CLAIMS MADE XI OCCUR
2D4436205
BLANKET ADDITIONAL
02/18/05
02/18/06
EACH OCCURRENCE
$1,000,000
PREMISESEeoOouence)
$100,000
MED EXP (Any one person)
s5,000
PERSONAL& ADV INJURY
S1,000,000
GENERAL AGGREGATE
s2,000,000
WSD a C07497 (12-00)
PRODUCTS - COMP/OP AGG
$ 2 , 000 , 0 00
GEN'L AGGREGATE LIMIT APPLIES PER:
POLICY X PROJECT LOC
A
AUTOMOBILE
LIABILITY
ANY AUTO
2E4436205
02/18/05
02/18/06
COMBINED SINGLE LIMIT
(Ea eooiderd)
$1,000,000
X
ALL OWNED AUTOS
SCHEDULED AUTOS
( INCLUDES HIRED &
NON —OWNED AUTOS)
BODILY INJURY
(Per person)
$
INJ
(Per BODILYIN URY JURY
$
HIRED AUTOS
NON -OWNED AUTOS
PROPERTY DAMAGE
(Per accident)
$
GARAGE LIABILITY
AUTO ONLY- EA ACCIDENT
$
OTHER THAN E4ACC
AUTO ONLY: AGG
$
ANY AUTO
N/A
$
EXCESS/UMBRELLALIABILITY
EACH OCCURRENCE
$1,000,000
AGGREGATE
$ 1, 000,000
A
X OCCUR CLAIMSMADE
2J4436205
02/18/05
02/18/06
$
$
DEDUCTIBLE
$
RETENTION $10,000
WORKERS COMPENSATION AND
701 _
X TORY LIMITS I I ER
E.L. EACH ACCIDENT
$100,000
B
EMPLOYERS' LIABILITY
ANY PROPRIETOR/PARTNER/EXECUTIVE
OFFICER/MEMBER EXCLUDED?
1452910
06/01/04
06/01/05
E.L. DISEASE - EA EMPLOYE
$100, 000
E.L. DISEASE -POLICY LIMIT
1 $500,000
If yes, descnbs under
SPECIAL PROVISIONS below
OTHER
Installation
$150,000 Special
A
Floater
12C4436205
02/18/05
02/181/06
Perils, $250. Ded
DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES / EXCLUSIONS ADDED BY ENDORSEMENT / SPECIAL PROVISIONS
CITY OF FORT COLLINS, ENGINEER, ENGINEERS CONSULTANTS AND OTHERS AS REQUIRED
BY CONTRACT ARE ADDITIONAL INSUREDS UNDER THE GENERAL LIABILITY - PRIMARY
AND COVERAGE CARRIED BY THE ADDITIONAL INSURED SHALL BE EXCESS, BUT ONLY
WITH RESPECTS TO LIABILITY ARISING OUT OF THE INSUREDS OPERATIONS ON THE
PLEASANT VALLEY LAKE AND CANAL TRAIL PROJECT, BID #5908
l =n 111-1,M I" n V LwCn
FT COLL SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATK
DATE THEREOF, THE ISSUING INSURER WILL QVVlEXn==MA1L 3 0 DAYS WRITTEN
NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT
City of Fort Collins
Attn: Purchasing Division 1
281 North College Avenue
Fort Collins, CO 80522
Armor, ee Mnnq, a% / 1 0 ACO614 CORPORAT17JN 1988
IMPORTANT
If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. A statement
on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s).
If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may
require an endorsement. A statement on this certificate does not confer rights to the certificate
holder in lieu of such endorsement(s).
DISCLAIMER
The Certificate of Insurance on the reverse side of this form does not constitute a contract between
the issuing insurer(s), authorized representative or producer, and the certificate holder, nor does it
affirmatively or negatively amend, extend or alter the coverage afforded by the policies listed thereon.
ACORD 25 (2001/08)
SECTION 00635
CERTIFICATE OF SUBSTANTIAL COMPLETION
T0: CITY OF FORT COLLINS
(OWNER)
DATE OF SUBSTANTIAL COMPLETION: PROJECT TITLE:
PLEASANT VALLEY LAKE AND CANAL TRAIL;
BID NO. 5908
PROJECT OR SPECIFIED PART SHALL LOCATION: Fort Collins, Colorado
INCLUDE:
OWNER: City of Fort Collins
CONTRACTOR:
CONTRACT DATE:
The Work performed under this contract has been inspected by authorized
representatives of the OWNER, CONTRACTOR, and the ENGINEER and the project (or
specified part of the project, as indicated above) is hereby declared to be
substantially completed on the above date.
A tentative list of items to be completed or corrected is appended hereto. This
list may not be exhaustive, and the failure to include an item on it does not
alter the responsibility of the CONTRACTOR to complete all the Work in accordance
with the Contract Documents.
ENGINEER AUTHORIZED REPRESENTATIVE DATE
The CONTRACTOR accepts the above Certificate of Substantial Completion and agrees
to complete and correct the items on the tentative list within the time
indicated.
By:
CONTRACTOR AUTHORIZED REPRESENTATIVE DATE
The OWNER accepts the project or specified area of the project as substan-
tially complete and will assume full possession of the project or specified area
of the project at 12:01 a.m., on The responsibility for
heat, utilities, security, and insurance under the Contract Documents shall be as
set forth under "Remarks" below.
CITY OF FORT COLLINS, COLORADO By:
OWNER
REMARKS:
AUTHORIZED REPRESENTATIVE DATE
7/96 Section 00635 Page 1
SECTION 00640
CERTIFICATE OF FINAL ACCEPTANCE
TO
Gentlemen:
20
You are hereby notified that on
the
day of
, 20_, the City of
Fort Collins, Colorado,
has
_
accepted the
Work completed by
for
the
City of Fort
Collins project,
PLEASANT VALLEY LAKE AND CANAL
TRAIL;
BID NO. 5908.
A check is attached hereto in the amount of $ as Final Payment for
all Work done, subject to the terms of the Contract Documents which are dated
In conformance with the Contract Documents for this project, your obligations and
guarantees will continue for the specified time from the following date:
Sincerely,
OWNER: Citv of Fort Collins
By:
Title:
ATTEST:
Title:
7/96 Section 00640 Page 1
SECTION 00020
INVITATION TO BID
SECTION 00650
LIEN WAIVER RELEASE
(CONTRACTOR)
TO: City of Fort Collins, Colorado (OWNER)
FROM: (CONTRACTOR)
PROJECT: PLEASANT VALLEY LAKE AND CANAL TRAIL; BID NO. 5908
1. The CONTRACTOR acknowledges having received payment, except retainage from
the OWNER for all work, labor, skill and material furnished, delivered and
performed by the CONTRACTOR for the OWNER or for anyone in the
construction, design, improvement, alteration, addition or repair of the
above described project.
2. In consideration of such payment and other good and valuable consideration,
the receipt and adequacy of which are hereby acknowledged, the CONTRACTOR
voluntarily waives all rights, claims and liens, including but not limited
to, mechanic's liens, Miller Act claims (40 U.S.C.A. 270 a and b), stop
notices, equitable liens and labor and material bond rights which the
CONTRACTOR may now or may afterward have, claim or assert for all and any
work, labor, skill or materials furnished, delivered or performed for the
construction, design, improvement, alteration, addition or repair of the
above described project, against the OWNER or its officers, agents,
employees or assigns, against any fund of or in the possession or control
of the OWNER, against the project or against all land and the buildings on
and appurtenances to the land improved by the project.
3. The CONTRACTOR affirms that all work, labor and materials, furnished,
delivered or performed to or for the construction, design, improvement,
alteration, addition or repair of the project were furnished, delivered or
performed by the CONTRACTOR or its agents, employees, and servants, or by
and through the CONTRACTOR by various Subcontractors or materialmen or
their agents, employees and servants and further affirms the same have been
paid in full and have released in full any and all existing or possible
future mechanic's liens or rights or claims against the project or any
funds in the OWNER'S possession or control concerning the project or
against the OWNER or its officers, agents, employees or assigns arising out
of the project.
4. The CONTRACTOR agrees to defend and hold harmless the OWNER, the lender, if
any, and the Surety on the project against and from any claim hereinafter
made by the CONTRACTOR'S Subcontractors, materialmen, employees, servants,
agents or assigns against the project or against the OWNER or its officers,
employees, agents or assigns arising out of the project for all loss,
damage and costs, including reasonable attorneys fees, incurred as a result
of such claims.
7/96 Section 00650 Page 1
5. The parties acknowledge that the description of the project set forth above
constitutes and adequate description of the property and improvements to
which this Lien Waiver Release pertains. It is further acknowledged that
this Lien Waiver Release is for the benefit of and may be relied upon by
the OWNER, the lender, if any, and Surety on any labor and material bonds
for the project.
Signed this day of , 20
CONTRACTOR
Title:
ATTEST:
Secretary
STATE OF COLORADO
)ss.
COUNTY OF LARIMER )
Subscribed and sworn to before me this day of
20 , by
Witness my hand and official seal.
My Commission Expires:
Notary Public
7/96 Section 00650 Page 2
SECTION 00660
CONSENT OF SURETY
TO: City of Fort Collins, Colorado
(hereinafter referred to as the "OWNER")
CONTRACTOR:
PROJECT: PLEASANT VALLEY LAKE AND CANAL TRAIL; BID NO. 5908
CONTRACT DATE:
In accordance with the provisions of the Contract between the OWNER and the
CONTRACTOR as indicated above, for
on bond of
(Surety)
hereby approves of the Final Payment to the CONTRACTOR, and agrees that Final
Payment to the CONTRACTOR shall not relieve the Surety Company of any of its
obligations to the OWNER, as set forth in the said Surety Company's Bond.
IN WITNESS WHEREOF, the Surety Company has hereunto set its hand this day
of ,
(Surety Company)
M
ATTACH: Power of Attorney and Certificate of Authority of Attorney(s)-in-Fact.
7/96 Section 00660 Page 1
SECTION 00670
APPLICATION FOR EXEMPTION CERTIFICATE
Insert State certificate here.
OR 0172 (01103)
COLORADO DEPARTMENT OF REVENUE
( 03)23BSOERV(7378) CONTRACTOR APPLICATION
FOR
EXEMPTION CERTIFICATE
Pursuant to Statute
Section 39-26.114(1)(a)(M)
M
DO NOT WRITE IN.THIS SPACE
.The exemption certificate for which you are applying must be used only for the purpose of purchasing construction and building
materials for the exempt project described below. This exemption does not include or apply to the purchase or rental of equipment,
supplies, and materials which are purchased, rented, or consumed by the contractor and which do not become a part of the
structure, highway, road, street, or other public works owned and used by the exempt organization.
Any unauthorized use of the exemption certificate will result in revocation ofyour exemption certificate and other penalties provided
by law.
A separate certificate is required for each contract.
Subcontractors will not be issued Certificates of Exemption by the Department of Revenue. It is the responsibility of the prime
contractor to issue certificates to each of the subcontractors. (See reverse side.)
FAILURE TO ACCURATELY COMPLETEALL BOXES WILL CAUSE THE APPLICATION TO BE DENIED.
Reglstration/Account No. (to be assigned by DOR)
Period
7070-750 (9cc
89 -
v. .
t�tiMAV N
Trade namelDBA:
Owner, partner, or corporate name:
-Mailing address (City, State, Zip):
Contact Person
E-Mail address.
Federal Employer's Identification Number: Bid amount for your contract:
Fax number:
( )
Business telephone number: Colorado withholding tax account number:
Copies of'oo traot 0 ogreerfl. In pages:(1)yd@n;ifymg the contracting parties, (2) b.id
=f hil�'7tQN I�1F RMATION amDunt and (3) cAntatr(tng signatures of pontraottng artles MUST be attached.
Name of exempt organization (as shown on contract):
Exempt organizafion's number:
98 -
Address of exempt organization (City, State, Zip):
cipal contact at exempt organization:
Principal contact's telephone number:
sical location of project site (give actual address when applicable and Cities andlor County lies) where project is located)
F
eduledMonth Day Year=crsnt1imp1aetteon
Month Day Year
struction start date:
:
I declare under penalty of perjury in the second degree that the statements made in this application are true and
complete to the best of my knowledge.
Signature of owner, partner or corporate officer
Title of corporate officer:
Date:
DO NOT WRITE 6ELUVV I HIS LINt
Special Notice
Contractors who have completed this application in the past, please note the following changes in procedure:
The Department will no longer issue individual Certificates of exemption to subcontractors. Only prime contrac-
tors will receive a Contractor's Exemption Certificate on exempt projects.
Upon receipt of the Certificate, the prime contractor should make a copy.for each subcontractor involved in the
project and complete it by filling in the subcontractor's name and address and signing it.
The original Certificate should always be retained by the prime contractor. Copies of all Certificates that the
prime contractor issued to subcontractors should be kept at the prime contractor's place of business for a
minimum of three years and be available for inspection in the event of an audit.
Once an 89# has been assigned to you, please use the next five numbers following it for any applications
submitted for future projects. This should be your permanent number. For instance, if you were assigned 89- _
12345-0001, every application submitted thereafter should contain 89-12345 on the application. The succeed-
ing numbers will be issued by the Department of Revenue. QO NOT enter what you believe to be the next in
sequence as this may delay processing of your application.
SECTION 00700
GENERAL CONDITIONS
No Text
GENERAL CONDITIONS
OF THE
CONSTRUCTION CONTRACT
These GENERAL CONDITIONS have been developed by using the
STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION
CONTRACT prepared by the Engineers Joint Contract Documents
Committee, EJCDC No. 1910-8 (1990 Edition), as a base. Changes to
that document are shown by underlining text that has been added and
striking through text that has been deleted.
EJCDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
WITH CITY OF FORT COLLINS MODIFICATIONS (REV 9/99)
No Text
SECTION 00020
INVITATION TO BID
Date: March 9, 2005
Sealed Bids will be received by the City of Fort Collins (hereinafter referred to
as OWNER), at the office of the Purchasing Division, 3:00 P.M., our clock, on
April 4, 2005 for the PLEASANT VALLEY LAKE AND CANAL TRAIL; Bid No. 5908. If
delivered, they are to be delivered to 215 North Mason Street, 2Id Floor, Fort
Collins, Colorado, 80524. If mailed, the mailing address is P. O. Box 580, Fort
Collins, CO 80522-0580.
At said place and time, and promptly thereafter, all Bids that have been duly
received will be publicly opened and read aloud.
The Contract Documents provide for the construction including 8 foot wide
concrete trail, 8 foot wide pedestrian bridge, stump and tree/shrub removal, and
seeding.
All Bids must be in accordance with the Contract Documents on file with The City
of Fort Collins, 215 North Mason St., 2nd floor, Fort Collins, Colorado 80524.
Contract Documents will be available March 11, 2005.
Copies of the Contract Documents, complete with Construction Specifications and
Drawings, may be obtained from Purchasing Division at 215 North Mason St., 2nd
floor, Fort Collins, Colorado, 80521 upon payment of a refundable fee of Fifty
Dollars ($50.00) per set. No partial sets will be issued.
The Contract Documents and Construction Drawings may be examined at:
1. City of Fort Collins, Purchasing Division.
2. Dodge Plan Room, 1114 W. 7th Ave., Suite 100, Denver, Colorado.
3. Reed Construction Data, 8878 Barrons Blvd., Highlands. Ranch, Colorado
4. Builders Exchange, 223 South Link Lane, Fort Collins, Colorado.
5. Construction News Service, 3630 Sinton Road, Suite 210, Colorado Springs,
Colorado.
A prebid conference and job walk with representatives of prospective Bidders will
be held at 10:OOA.M., on March 21, 2005, at Sanctuary Apartments, 1401 W.
Horsetooth Road, at the Clubhouse Parking Lot, Corner of Kuntz Court and Booker l
Drive. J
t
Prospective Bidders are invited to present their questions relative to this Bid
proposal at this meeting.
Bids will be received as set forth in the Bidding Documents.
The Work is expected to be commenced within the time as required by Section 2.3
of General Conditions. Substantial Completion of the Work is required as
specified in the Agreement.
07/2001 Section 00020 Page 1
Article or Paragraph
Number & Title
DEFINITIONS
TABLE OF CONTENTS OF GENERAL CONDITIONS
Page Article or Paragraph Page
Number Number & Title Number
1.1
Addenda....................................I........1
1.2
Agreement..........................................1
1.3
Application for Payment.......................I
1.4
Asbestos.............................................1
1.5
Bid.....................................................1
1.6
Bidding Documents .............................1.
1.7
Bidding Requirements .........................1
1.8
Bonds.................................................1
1.9
Change Order......................................I
1.10
Contract Documents .............*. ...........1
1.11
Contract Price ..................
1.12
Contract Times....................................1
1.13
CONTRACTOR..................................1
1.14
defective.............................................1
1.15
Drawings............................................1
1.16
Effective Date of the Agreement .........,1
1.17
ENGINEER........................................1
1.18
ENGINEERS Consultant ......................I
1.19
Field Orde..............................
1
1.20
General Requirements .........................2
1.21
Hazardous Waste.................................2
1.22.a
Laws and Regulations; Laws or
Regulations......................................2
1.22.b
Legal Holidays.....................................2
1.23
Liens.................................................2
1.24
Milestone............................................2
1.25
Notice of Award..................................2
1.26
Notice to Proceed.................................2
1.27
OWNER.............................................2
1.28
Partial Utilization................................2
1.29
PCBs.................................................2
1.30
Petroleum...........................................2
1.31
Project.........................................I......2
1.32.a
Radioactive Material........ 4...................2
1.32.b
Regular Working Hours ........ ............
*..2
1.33
Resident Project Representative............
2
1.34
Samples..............................................2
1.35
Shop Drawings ...................................?
1.36
Specifications ............. 44............ .....
.....?
1.37
Subcontractor .....................................?
1.38
Substantial Completion.......*...............2
1.39
Supplementary Conditions... I................2
1.40
Supplierr..............................................2
1.41
Underground Facilities ................ ...**2-3
1.42
Unit Price Work. . ...............................
3
1.43
Work.................................................3
1.44
Work Change Directive ................
*.......3
1.45
Written Amendment ...........................3
2. PRELIMINARY MATTERS ................................
3
2.1
Delivery of Bonds .............................3
2.2
Copies of Documents...... I.................3
2.3
Commencement of Contract
Times; Notice to Proceed... ..... I ......
3
2.4
Starting the Work ............................
3
2.5-2.7
Before Starting Construction;
CONTRACTORS Responsibility
to Report; Preliminary Schedales;
Delivery of Certificates of
Insurance ...................................
3-4
2.8
Preconstruction Conference .............
4
2.9
Initially Acceptable Schedules.........,
4
3. CONTRACT DOCUMENTS: INTENT,
AMENDING, REUSE...........................I..............4
3.1-3.2
Intent ...................................... I.......
3.3
Reference to Standards and Speci-
fications of Technical Societies;
Reporting and Resolving Dis-
crepancies .................................
4-5
3.4
Intent of Certain Terms or
Adjectives .....................................
5
3.5
Amending Contract Docunents.........
5
3.6
Supplementing Contract
Documents ........................ I..........
5
3.7
Reuse of Documents .........................5
4. AVAILABILITY OF LANDS;
SUBSURFACE AND PHYSICAL CONDITIONS;
REFERENCE POINTS ........................ I................5
4.1
Availability of Lands ........... ........5-6
4.2
Subsurface and Physical
Conditions ..................... I..............
6
4.2.1
Reports and Drawings......................6
4.2.2
Limited Reliance by CONTRAC-
TOR Authorized; Technical
Data.............................................6
4.2.3
Notice of Differing Subsurface
or Physical Conditions„................6
4.2.4
ENGINEERS Review.......................0
4.2.5
Possible Contract Documents
Change.........................................6
4.2.6
Possible Price and Times
Adjustments ..............................
6-7
4.3
Physical Conditions --Underground
Facilities.......................................7
4.3.1
Shown or Indicated ..........................7
4.3.2
Not Shown or Indicated..... I..............7
4.4
Reference Points...............................7
E.ICDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9/99)
Article or Paragraph Page Article or Paragraph Page
Number & Title Number Number & Title Number
4.5
Asbestos, PCBs, Petroleum,
6.25
Submittal Proceedures; CON -
Hazardous Waste or
TRACTOR's Review Prior
Radioactive Material ,,,,,,,,,,,,,,,,,,„7-8
to Shop Drawing or Sample
Submittal
16
5. BONDS AND INSURANCE .................................
8
6.26
Shop Drawing & Sample Submit-
5.1-5.2
Performance, Payment and Other
tals Review by ENGINEER ... ,.,16-17
Bonds ................................ ...........8
6.27
Responsibility for Variations
5.3
Licensed Sureties and Insurers;
From Contract Documents ............
17
Certificates of Insurance
8
6.28
Related Work Performed Prior
5.4
CONTRACTOR's Liability
to ENGINEER's Review and
Insurance..........................................9
Approval of Required
5.5
OWNER's Liability Insurance ..............
9
Submittals.........,
17
5.6
Property Insurance ..........................9-10
6.29
Continuing the Work...,.,,
17
5.7
Boiler and Machinery or Addi-
6.30
CONTRACTOR's General
tional Property Insurance..................10
Warranty and Guarantee....,,....,...
17 -�
5.8
Notice of Cancellation Prolvision.........
10
6.31-6.33
Indemnification .........................17-18
5.9
CONTRACTOR's Responsibility
6.34
Survival of Obligations ..................
j8
for Deductible Amounts ....................
10
5.10
Other Special Insurance .....................
10
7. OTHER WORK....... ...... ...................... ..............18
5.11
Waiver of Rights................................11
7.1-7.3
Related Work at Site .......................
18
5.12-5.13
Receipt and Application of
7.4
Coordination,,..... I..........................18
Insurance Proceeds............. ........
10-11
5.14
Acceptance of Bonds and Insu-
8. OWNER'S
RESPONSIBILITIES .........................18
ance; Option to Replace ....................
11
8.1
Communications to CON-
5.15
Partial Utilization --Property
TRACTOR.................................18
Insurance........................................11
8.2
Replacement of ENGINEER ............
18
8.3
Furnish Data and Pay Promptly
6. CONTRACTOR'S RESPONSIBILITIES ...............11
When Due ...,,,.,..,,,...,,,....,,,._,..19
6.1-6.2
Supervision and Superintendence,,,,.,,
11
8.4
Lands and Easements; Reports
6.3-6.5
Labor, Materials and Equipment,,.
11-12
and Tests...............................18-19
6.6
Progress Schedule..............................12
8.5
Insurance,.,,,,,,, ..........................
....19
6.7
Substitutes and "Or -Equal" Items;
8.6
Change Orclers...............................19
CONTRACTOR's Expense;
8.7
Inspections, Tests and
Substitute Construction
Approvals...................................19
Methods or Procedures;
8.8
Stop or Suspend Work;
ENGINEER's Evaluation .............
12-13
Terminate CONTRACTOR's
--
6.8-6.11
Concerning Subcontractors,
Services......................................19
Suppliers and Others;
8.9
Limitations on OWNER'S
Waiver of Rights .........................13-14
Responsibilities
19
6.12
Patent Fees and Royalties ..................14
8.10
............................
Asbestos, PCBs, Petroleum,
6.13
Permits ............................
1.14
Hazardous Waste or
6.14
Laws and Regulations... ..... I ..........
I ..... 14
Radioactive Material ....................
j9
6.15
Taxes ........ ................... ................
14-15
8.11
Evidence ofFinancal
6.16
Use of Premises.................................15
Arrangements.............................19
6.17
Site Cleanliness .................................
15
6.18
Safe Structural Loading,,,,,,,,,,,,,,,,,,,„
15
9. ENGINEER'S STATUS DURING
6.19
Record Documents .............................15
CONSTRUCTION.,,,..,.,,,,.,....,.,.,,..,,,.-...,...,,.,,,.19
6.20
Safety and Protection„ .............15-16
9.1
OWNER's Representative ..........
19
6.21
Safety Representative .........................16
9.2
Visits to Site,,,..,,,,.........................19
6.22
Hazard Communication Programs..,,..
16
9.3
Project Representative ..... ........
19-21 --
6.23
Emergencies ................... I .......... ......
16
9.4
Clarifications and Interpre-
6.24
Shop Drawings and Samples..............16
tations,,.,.,.,,,......,,.....................
21
9.5
Authorized Variations in Wrk
21
........
ul
E.ICDC GENERAL CONDITIONS 1910-9 (1990
EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9(99) �^
li.e.
Article or Paragraph Page Article or Paragraph Page
Number & Title Number Number & Title Number
9.6
Rejecting Defective Work...................21
9.7-9.9
Shop Drawings, Change Orders
and Payments....................................21
9.10
Determinations for Unit Prices.,...,
21-22
9.11-9.12
Decisions on Disputes; ENGI-
NEER as Initial Interprete................
22
9.13
Limitations on ENGINEER'S
Authority and Responsibilities....
22-23
CHANGES IN
THE WORK .......................................
23
10.1
OWNEKs Ordered Change.,.........**,,
3
10.2
Claim for Adjustment ........................23
10.3
Work Not Required by Contract
Documents......................................23
10.4
Change Orders..................................23
10.5
Notification of Surety ..........................23
CHANGE OF
CONTRACT PRICE .............................23
11.1-11.3
Contract Price; Claim for
Adjustment; Value of
the Work ...................................
23-24
11.4
Cost of the Work ................. ..... .....24-25
11.5
Exclusions to Cost of the Work„
......25
11.6
CONTRACTOR'S Fee ........................
25
11.7
Cost Records ............................. I
... 25-26
11.8
Cash Allowances...............................26
11.9
Unit Price Work.................................26
CHANGE OF
CONTRACT TIMES ............................26
12.1
Claim for Adjustment ........................26
12.2
Time of the Essence ..........................26
12.3
Delays Beyond CONTRACTOR'S
Control ......................................
26-27
12.4
Delays Beyond OWNER'S and
CONTRACTOR'S Control................27
TESTS AND INSPECTIONS; CORRECTION,
REMOVAL OR ACCEPTANCE OF
DEFECTIVE WORK..................................................27
13.1
Notice of Defects...............................27
13.2
Access to the Work ...........................27
13.3
Tests and Inspections;
CONTRACTOR'S Cooperation.........
27
13.4
OWNER's Responsibilities;
Independent Testing Laboratory.....,
27
13.5
CONTRACTOR'S
Responsibilities...............................27
13.6-13.7
Covering Work Prior to Inspec-
tion, Testing or Approval.................27
13.8-13.9 Uncovering Work at ENGI
NEER's Request........... I ..........
27-28
13.10
OWNER May Stop the Work ...........
28
13.11
Correction or Removal of
Defective Work .........I.................28
13.12
Correction Period ...........................28
13.13
Acceptance ofDefective Work .........
28
13.14
OWNER May Correct Defective
Work .....................................
28-29
14. PAYMENTS TO CONTRACTOR AND
COMPLETION .................................................
29
14.1
Schedule of Values........... I.............29
14.2
Application for Progress
Payment..................... I...............
29
14.3
CONTRACTOR's Warranty of
Title...........................................29
14.4-14.7
Review of Applications for
Progress Payments..................29-30
14.8-14.9
Substantial Completion ..................
30
14.10
Partial Utilization ....... .................
30-31
14.11
Final Inspection ............................31
14.12
Final Application for Payment ........
31
14.13-14.14
Final Payment and Acceptance .......
31
14.15
Waiver of Claims........... I ............
31-32
15. SUSPENSION OF WORK AND
TERMINATION ...............................................
32
15.1 OWNER May Suspend Work ..........
32
15.2-15.4 OWNER May Terminate ................
32
15.5 CONTRACTOR May Stop
Work or Terminate .................
32-33
16. DISPUTE RESOLUTION ... 33
17. MISCELLANEOUS...........................................33
17.1
Giving Notice................................33
17.2
Computation of Times....................33
17.3
Notice of Claim..............................33
17.4
Cumulative Remedies.....................33
17.5
Professional Fees and Court
Costs Included .............................33
17.6
Applicable State Laws ...............
33-34
Intentionally left blank.......................................35
EXHIBIT GC -A:
(Optional)
Dispute Resolution Agreement ........ I ............
GC -AI
16.1-16.6
Arbitration.............................GC-A1
16.7
Mediation ................................
GC -AI
iv
E.ICDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9/99)
INDEX TO GENERAL CONDITIONS
City of Fort Collins modifications to the General Conditions of the Construction Contract are not shown in this index
Article or Paragraph
Number
Acceptance of --
Bonds and Insurance...5.14
.......................................
defective Work............................10.4.1, 13.5, 13.13
final payment.,, „....... ................... 9.12, 14.15
insurance......... ......... .......... ..............5.14
other Work, by CONTRACTOR...._...................7.3
Substitutes and "Or -Equal" Items ......................6.7.1
Work by OWNER ................... ..... ...2.5, 6.30, 6.34
Access to the --
Lands, OWNER and CONTRACTOR
responsibilities ............................................ 4.1
site, related Work .......................... I ...... .............. 7.2
Work...........................................13.2, 13.14, 14.9
Acts or Omissions--, Acts and Omissions--
CONTRACTOR6.9.1, 9.13.3
ENGINEER..........................................6.20, 9.13.3
OWNER ................................................... 6.20, 8.9
Addenda --definition of (also see
definition of Specifications) ....... (1.6, 1.10, 6.19), 1.1
Additional Property Insurances ................................. 5.7
Adjustments --
Contract Price or Contract
Times ...........................1.5, 3.5, 4.1, 4.3.2, 4.5.2,
.......I.....................4.5.3, 9A, 9.5, 10.2-10.4,
.........................................11, 12, 14.8, 15.1
progress schedule .............................................. 6.6
Agreement --
definition of ; 1.2
..................................
"All -Risk" Insurance, policy form............................5.6.2
Allowances, Cash ................................................... 11.8
Amending Contract Documents ................................ 3.5
Amendment, Written --
in general................1.10, 1.45, 3.5, 5.10, 5.12, 6.6.2
.............. I ....... b.8.2, 6.19, 10.1, 10.4, 11.2
..................... I ......... 12.1, 13,12.2, 14.7.2
Appeal, OWNER or CONTRACTOR
intent to ..........................9.10, 9.11, 10.4, 16.2, 16.5
Application for Payment --
definition of......................................................1.3
ENGINEER's Responsibility................................9.9
final payment,.,.,,,,. .......... 9.13.4, 9.13.5, 14.12-14.15
in general, ......................... . 2.8, 2.9, 5.6.4, 9.10, 15.5
progress payment ...................................... 14.1-14.7
review of 14.4-14.7
...................................................
Arbitration 16.1-16.6
Asbestos --
claims pursuant thereto..........................4.5.2, 4.53
CONTRACTOR authorized to stop Work .......... 4.5.2
definition of.......................................................1,.4
Article or Paragraph
Number
OWNER responsibility for.........*....* ..............
4.5.1, 8.10
possible price and times change
................... .4 5.2
Authorized Variations in Work.....,,,,,
3.6, b 25, 6.27, 9.5
Availability of Lands .........................................
4.1, 8.4
Award, Notice of--defined,,,,,,,,,,,,,I............
I ... ,........ 1.25
Before Starting Construction,.,,,,.,
......... ......2.5-2.8
Bid --definition of........................1.5
(1.1, 1.10, 2.3, 3.3,
_ 4.2.6.4, 6.13, 11.4.3, 11.9.1)
Bidding Documents --definition
of...................................................1.6
(6.8.2)
Bidding Requirements --definition
of..........................................1.7
(1.1, 4.2.6.2)
Bonds --
acceptance of....................................................5.14
additional bonds
4 „10.5, 11..5.9
Cost of the Work.............................................11.5.4
definitionof.......................................................1.8
delivery of...................................................7.1,
5.1
final Application for Payment .................14.12-14.14
general..................................I...1.10,
5.1-5.3, 5.13,
........................................
9.13, 10.5, 14.7.6
Performance, Payment and Other...................5.1-5.2
Bonds and Insurance --in general ................
....... *......._.5
Builder's risk "all-risk" policy form ........................5.6.2
Cancellation Provisions, Insurance,,,,,,,,
5.4,11, 5.8, 5.15
Cash Allowances ....................................
11.8
Certificate of Substantial CompletioR
........ 1.38, 6.30.2.3,
14.8, 14.10
Certificates of Inspection ...................9.13.4,
13.5, 14.12
Certificates of Insurance ..........2.7,
5.3, 5.4.11, 5.4.13,
......I................5.6.5, 5.8,
5.14, 9.13.4, 14.12
Change in Contract Price --
Cash Allowances
IL8
claim for price
adjustment.,,....,,... 4.1, 4.2.6,
4.5, 5.15, 6.8.2, 9.4
...................9.5, 9.11, 10.2,
10.5, 11.2, 13.9,
..................13.13, 13.14,
14.7, 15.1, 15.5
CONTRACTOR's fee.........................................11.6
Cost of the Work
general ...............................................
11.4-11.7
Exclusions to...............................................11.5
Cost Records.....................................................11.7
in general „....„.....1,19, 1.44, 9.11,
10.4.2, 10.4.3, 11
Lump Sum Pricing..........................................11.3.2
Notification of Surety ...................
I.....................10.5
Scope of ................ .........
..............10.3-10.4
Testing and Inspection,
Uncovering the Work ..................................
13.9
E.ICDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
vd CITY OF FORT COLLINS MODIFICATIONS (REV 9199)
Unit Price Work .......................................... 11.9
Article or Paragraph
Number
Value of Work..................................................11.3
Change in Contract Times --
Claim for times adjustment .........
4.1, 4.2.6, 4.5, 5.15,
..... 6.8.2, 9.4, 9.5, 9.11,
10.2, 10.5, 12.1,
.... ,,.,,," '13.9, 13.13, 13.14, 14.7, 15.1, 15.5
Contractual time limits.....................................12.2
Delays beyond CONTRACTOR's
control........................................................12.3
Delays beyond OWNER's and
CONTRACTOR's control............................1.2.4
Notification of surety.........................................10.5
Scope of change........................................10.3-10.4
Change Orders --
Acceptance of Defective Work ..........................13.13
Amending Contract Documents
..,.,..3.5
Cash Allowances..............................................11.8
Change of Contract Price . ............
*... .... ............... .11
Change of Contract Times...............................1.1.12
Changes in the Work..........................................10
CONTRACTOR's fee ............. ..............
.. .. .........11.6
Cost of the Work ................................
I ...... 11.4-11.7
Cost Records....................................................11.7
definition of......................................................1.9
emergencies....................................................
6.23
ENGINEER's responsibility .......
9.8, 10.4, 11.2, 12.1
execution of.....................................................10.4
Indemnifiction .........................6.12,
6.16, 6.31-6.33
Insurance, Bonds and.......................5.10,
5.13, 10.5
OWNER may terminate .....................
........ 15.2-15.4
OWNER's Responsibility .............................8.6,
10.4
Physical Conditions --
Subsurface and..............................................4.2
Underground Facilities--..........................I..4.3.2
Record Documents...........................................6.19
Scope of Change ....... .........
.............10.3-10.4
Substitutes.............................................6.7.3,
6.8.2
Unit Price Work...............................................11.9
value of Work, covered by.....................I...........11.3
Changes in the Work..................................................10
Notification of surety.........................................10.5
OWNER's and CONTRACTOR's
responsibi I i ties ............................................
10.4
Right to an adjustment.................................
... .10.2
Scope of change ...................................
..... 10.3-10.4
Claims --
against CONTRACTOR....................................6.16
against ENGINEER .........................................
6.32
against OWNER...............................................6.32
Change of Contract Price ...........................9.4,
11.2
Change of Contract Times ..........................
9.4, 12.1
CONTRACTOR's.............4, 7.1,
9.4, 9.5, 9.11, 10.2,
...................11.2,
11.9, 12.1, 13.9, 14.8,
............................................15.1,
15.5, 17.3
CONTRACTOR's Fee.......................................11.6
Article or Paragraph
Number
CONTRACTOR's liability ........... 5.4, 6.12, 6.16, 6.31
Cost of the Work.......................................11.4,
11.5
Decisions on Disputes.......... I....................9.11,
9.12
Dispute Resolution............................................16.1
Dispute Resolution Agreement ....................16.1-16.6
ENGINEER as initial interpretol,'.......................9.11
Lump Sum Pricing., ...................... ................
11.3.2
Noticeof..........................................................17.3
OWNER's................... 9.4, 9.5, 9.11, 10.2,
11.2, 11.9
........................12.1, 13.9, 13.13,
13.14, 17.3
OWNER's liability...............................................5.5
OWNER may refuse to make payment.................14.7
Professional Fees and Court Costs
Included .....................................................
17.5
request for formal decision on............................9..11
Substitute Items.............................................0.7.1.2
Time Extension.................................................12.1
'Time requirements....................................9.11,
12.1
Unit Price Work.............................................11.9.3
Valueof...........................................................1.1.3
Waiver of --on Final Payment .................
j4.14, 14.15
Work Change Directive ................................
I ..... 10.2
written notice required ........ I.............9.11, 11.2, 12.1
Clarifications and Interpretations. ...........
3.6.3, 9.4, 9.11
CleanSite............................................................6.17
Codes of Technical Society, Organization
or Association .................................................
3.3.3
Commencement of Contract Times ...........................2.3
Communications--
general..............................................6.2,
6.9.2, 8.1
Hazard Communication Programs .....................6.22
Completion --
Final Application for Payment ..........................14.12
Final Inspection ............................ I..................14.11
Final Payment and Acceptance ... .............
14.13-14.14
Partial Utilization............................................14.10
Substantial Completion ......................1.38,
14.8-14.9
Waiver of Claims............................................14.15
Computation of Times...............................17.2.1-17.2.2
Concerning Subcontractors, Suppliers
andOthers ...............................................
.... 6.8-6.11
Conferences --
initially acceptable schedules ..............................
2.9
precOtis Iructioil ...................................................
2.8
Conflict, Error, Ambiguity, Discrepancy--
CONTRACTOR to Report ..........................
2.5, 3.3.2
Construction, before starting by
CONTRACTOR ............................................
2.5-2.7
Construction Machinery, Equipment, etc,
... .............6.4
Continuing the Work......................................6.29,
10.4
Contract Documents --
Amending..........................................................3.5
Bonds.........................................:....................5.1
V1
E.ICDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9199)
Cash Allowances11.8
Article or Paragraph
Number
Change of Contract Price ....................................
11
Change of Contract Times,..,,......* .......................
12
Changes in the Work.................................10.4-10.5
check and verify ............................ ................
2.5
Clarifications and
Interpretations ......................... 3.2, 3.6, 9.4, 9.11
definition of....................................................1.10
ENGINEER as initial interpreter of ..................
9.11
ENGINEER as OWNER's representative..............9.1
general3
Insurance...........................................................5.3
Intent........................................................3.1-3.4
Work
minor variations in the ..........
......................
3.6
OWNER's responsibility to furnish data...............8.3
OWNER's responsibility to make
prompt payment ......................... 8.3, 14.4,
14.13
precedence ....... ......... ......................3.1,
3.3.3
Record Documents............................................6.19
Reference to Standards and Specifications
of Technical Societies ...................................
3.3
Related Work:'
7.2
Reporting and Resolving Discrepancies... ....
.2.5, 3.3
Reuseof ...........................................................
3.7
Supplementing..................................................
3.6
Termination of ENGINEER's Employment...
....... 8.2
Unit Price Work...............................I................11.9
variations.........................................3.6,
6.23, 6.27
Visits to Site, ENGINEER's................................
9.2
Contract Price --
adjustment of ............... 3.5, 4.1, 9.4, 10.3,
11.2-11.3
Changeof...........................................................11
Decision on Disputes........................................9.11
definition of
1.11
Contract Times --
adjustment of ..........................3.5, 4.1, 9.4, 10.3, 12
Change of.,,,,.. ., .......................................12.1-12.4
Commencement of ............................................
2.3
of
definition ...
....................................................
1.12
CONTRACTOR --
Acceptance of Insurance ......... . .. . ............. .
. ....... 5.14
Communications,....,,... „ ......... ........
6.2, 6.9.2
Continue Work ........................................
6.29, 10.4
coordination and scheduling., ..........................
6.9.2
of
definition .....
..................................................
1.13
Limited Reliance on Technical
Data Authorized
4.2.2
May Stop Work or Terminate............................1.5.5
provide site access to others .......................7.2,
13.2
Safety and Protection ...................4.3.1.2, 6.16, 6.18,
......... ........... I ..... I ........... 6.21-6.23,
7.2, 13.2
Shop Drawing and Sample Review
Prior to Submittal .........................................
6.25
Stop Work requirements..................................4.5.2
CONTRACTOR's-
Article or Paragraph
Number
Compensation............................................11.1-11.2
Continuing Obligation.....................................14.15
T
Defective Work...........................I....9.6, 13.10-13.14
Duty to correct defective Work ..........................13.11
Duty to Report--
-
Changes in the Work caused by
Emergency ... ........................................
6.23
Defects in Work of Others7,3
Differing conditions ................. I.................4.2.3
Discrepancy in Documents,,,..,,, 2.5, 3.3.2, 6.142
Underground Facilities not indicated...,,....,
4.3.2
Emergencies.....................................................6.23
Equipment and Machinery Rental, Cost
of the Work ..........................................
11.4.5.3
Fee --Cost Plus..........................11.4.5.6, 11.5.1, 11.6 _
General Warranty and Guarantee .......................6.30
Hazard Communication Programs,,,,,,,,,,,,,,,,,,,,,
6.22
Indemnification._..,..........
„,_..,.6 .._...,,.12, 6.16,
6.31-6.33
Inspection of the Work.......................I.......7.3,
13.4 -.
Labor, Materials and Equipment ....................
b 3-6.5
Laws and Regulations, Compliance by .............
6.14.1
Liability Insurance..............................................5A
Notice of Intent to Appeal ..........................9.10,
10.4
obligation to perform and complete
the Work ....................................................
6.30
.
Patent Fees and Royalties, paid for by ................
6.12 --
Performance and Other Bonds ....... . ... .
.........5.1
Permits, obtained and paid for by.......................6.13
"
Progress Schedule ...........................2.6, 2.8, 2.9, 6.6,
........................................ 6.29, 10.4, 15.2.1 1'
Request for formal decisionon disputes ..............
9.11
Responsibilities --
Changes in the Work ........ ........ *........
.,...... ,10.1 --
Concerning Subcontractors, Suppliers
and Others......................................6.8-6.11
Continuing the Work...........................6.29,
10.4
CONTRACTOR's expense ..........................
6.7.1
CONTRACTOR's General Warranty
and Guarantee.......................................6.30
CONTRACTOR's review prior to Shop
Drawing or Sample submittal.................6.25
Coordination of Work.................................6.9.2
Emergencies ...............................................
6.23
ENGINEER's evaluation, Substitutes
or "Or -Equal" Items......... I...................6.7.3
For Acts and Omissions
of Others.................:...........6.9.1-6.9.2, 9.13
for deductible amounts, insurance...................5.9
general........................................6, 7.2,
7.3, 8.9
Hazardous Communication Programs ...........
6.22
Indemnification
6.31-6.33
vii
E.ICDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9199) •"
Labor, Materials and Equipment..............6.3-6.5
Laws and Regulations.............................I....6.14
Liability Insurance ......... ................... 5.4
Article or Paragraph
Number
Notice of variation from Contract
Documents ...........................................
6.27
Patent Fees and Royalties.............................6.12
Permits.......................................................6.13
Progress Schedule.........................................6.6
Record Documents ..................................
I.... 6.19
related Work performed prior to
ENGINEER's approval of required
submittals.............................................0.28
safe structural loading..........................*......6.18
Safety and Protection ....................6.20,
7.2, 13.2
Safety Representative...................................6.21
Scheduling the Work..................................6.9.2
Shop Drawings and Samples .......................
6.24
Shop Drawings and Samples Review
by ENGINEER......................................6.26
Site Cleanliness..........................................6.17
Submittal Procedures...................................6.25
Substitute Construction Methods
and Procedures ...............................
....6.7.2
Substitutes and "Or -Equal" Items.................6.7.1
Superintendence ...........................................
6.2
Supervision...................................................6.1
Survival of Obligations................................6.34
Taxes................. ... ....... ... .....
......6.15
Tests and Inspections...................................13.5
ToReport ................ ...............................
2.5
Use of Premises......................6.16-6.18, 6.30.2.4
Review Prior to Shop Drawing or
Sample Submittal ........................................
6.25
Right to adjustment for changes in the Work,,...10.2
right to claim ............. 4, 7.1, 9.4, 9.5, 9.11,
10.2,11.2,
..........11.9, 12.1, 13.9, 14.8, 15.1,
15.5, 17.3
Safety and Protection .................. 6.20-6,22,
7.2, 13.2
Safety Representative ..,._ ........ ............
*...... 6.21
Shop Drawings and Samples Submittals.„..6.24-6.28
Special Consultants. . . . . .. ...... .................
11.4.4
Substitute Constructioneos ad Procedures,.6.7
Substitutes and "Or -Equal" Items,
Expense...........................................6.7.1, 6.7.2
Subcontractors, Suppliers and Others,.,,,,,,.,
6.8-6.11
Supervision and Superintendence .......... 6.1,
6.2, 6.21
Taxes, Payment by ............................................6.15
Use of Premises .......................................
6.16-6.18
Warranties and guarantees ..........................6.5,
6.30
Warranty of Title ..............................................
14.3
Written Notice Required --
CONTRACTOR stop Work or terminate ........ 15.5
Reports of Differing Subsurface
and Physical Conditions .......................4.2.3
Substantial Completion................................14.8
CONTRACTORS --other .............................................. 7
Contractual Liability Insurance,,,,,,.... I...................5.4.10
Contractual Time Limits... ..IJ2.2
Article or Paragraph
Number
Coordination
CONTRACTOR's responsibility ...................I...6.9.2
Copies of Documents ...............................................
2.2
Correction Period..................................................13.12
Correction, Removal or Acceptance
of Defective Work--
in general.................................10.4.1,
13.10-13.14
Acceptance ofDefective Work ..........................1.3.13
Correction or Removal of
Defective Work ........................ .......6.30,
13.11
Correction Period............................................13.12
OWNER May Correct Defective Work ..............13.14
OWNER May Stop Work ....... ............ I .............
13.10
Cost --
of Tests and Inspections.....................................13.4
Records]1.7
Cost of the Work --
Bonds and insurance, additional ..................11.4.5.9
Cash Discounts...............................................11.4.2
CONTRACTOR's Fee .......................................
11.6
Employee Expenses......................................11.4.5.1
Exclusions to ......................................................
11.5
General11.4-11.5
Home office and overhead expenses ...................
11.5
Losses and damages........ ........
.......11.4.5.6
Materials and equipment................................11.4.2
Minor expenses ............... ......._ ....1...11.4.5.8
Payroll costs on changes..................................11.4.1
performed by Subcontractors .........
..........11.4.3
Records 11.7
Rentals of construction equipment
and machinery ............ ....„,,,,;,,,,,,.,,,,,,,,,11.4.5.3
Royalty payments, permits and
license fees......................„..,,,.,,,..........,11.4.5.5
Site office and temporary facilities.. ..............11.4.5.2
Special Consultants, CONTRACTOR'S
..........11.4.4
Supplemental.................................................11.4.5
Taxes related to the Work............................11.4.5.4
Tests and Inspection..........................................13.4
Trade Discounts ..............................................
11.4.2
Utilities, fuel and sanitary facilities ...............11.4.5.7
Work after regular hours.................................11.4.1
Covering Work ....... ........................................
13.6-13.7
Cumulative Remedies ......................................
17.4-17.5
Cutting, fitting and patching...................................7.2
Data, to be furnished by OWNER..............................8.3
Day --definition of................................................17.2.2
Decisions on Disputes.....................................9.11,
9.12
defective --definition of...........................................1.14
defective Work --
Acceptance of.......................................10.4.1,
13.13
viii
E.ICDC GENERALCONDITIONS 1910-8 (1990 EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9/99)
Correction or Removal of .....................10.4.1, 13.11
Correction Period .......... ................... .....13.12
in general........................................13, 14,7, 14.11
Article or Paragraph
Number
Observation by ENGINEER ................................
9.2
OWNER May Stop Work.................................13.10
Prompt Notice of Defects,_„_._, ...... _.... _.,,_.,_-__„13.1
Rejecting...........................................................9.6
Uncovering the Work,,,,,,,,,,,,,,,,,, ..................,
13.8
Definitions................................................................I
Delays......................................4.1, 6.29, 12.3-12.4
Delivery of Bonds.....................................................2.1
Delivery of certificates of insurance ............................2.7
Determinations for Unit Prices .......... ... .". ........
,.,,. 9.10
Differing Subsurface or Physical Conditions--
Noticeof.........................................................4.2.3
ENGINEER's Review., .................. I ..................
4.2.4
Possible Contract Documents Change,,,,,,,,,,,,,,
4.2.5
Possible Price and Times Adjustments .... ,.........
4.2.6
Discrepancies -Reporting
and Resolving................................2.5, 3.3.2,
6.14.2
Dispute Resolution --
Agreement ......... ................................ :......
16.1-16.6
Arbitration,,,,,..,,,........................ ..............16.1-16.5
.
general 16
Mediation........................................................1.6.6
Dispute Resolution Agreement.........................16,1-16.6
Disputes, Decisions by ENGINEER,,,,,,,,,,,,,,,,,, ...................
Documents --
Copiesof...........................................................2.2
Record 6.19
Reuseof............................................................
3.7
Drawings --definition of..........................................1.15
Easements.............................................................4.1
Effective date of Agreement -- definition of .............I.16
Emergencies ...................................... I....................6.23
ENGINEER --
as initial interpreter on disputes,,,,,,,,,,,,,,,, .................
definition of ......................................................
1.17
.
Limitations on authority and responsibilities.....9.13
Replacement of ......... ................... ..... I .................
.2
Resident Project Representative ...........................9.3
ENGINEER's Consultant -- definition of
.....................
1.18
ENGINEER's--
authority and responsibility, limitations orI
......... 9.13
Authorized Variations in the Work
.......................
9.5
Change Orders, responsibility fo)........ 9.7,
10, 11, 12
Clarifications and Interpretations ...............3.6.3,
9.4
Decisions on Disputes ...............................
9.11-9.12
defective Work, notice of..................................13.1
Evaluation of Substitute Items .............................
6.7.3
Liability...................................................6.32,
9.12
Notice Work is Acceptable..............................J4.13
Observations ....................
6.30.2, 9.2
OWNER'S Representative....................................9.1
Payments to the CONTRACTOR,
Responsibility for„...................................9.9, 14
Recommendation of Payment ....................14.4, 14.13
Article or Paragraph
Number
Responsibilities --Limitations on,,,,,,,,,,,,,,,,,
9.11-9.13
Review of Reports on Differing Subsurface
and Physical Conditions.............................4.2.4
Shop Drawings and Samples, review
responsibility ..............................................
6.26
Status During Construction --
authorized variations in the Work..................9.5
Clarifications and Interpretations ...
..........9.4
Decisions on Disputes .........................
9.11-9.12
Determinations on Unit Price .......................9.10
ENGINEER as Initial Interpreter ..........
9.11-9.12
ENGINEER's Responsibilities ................9.1-9.12
Limitations on ENGINEER's Authority
and Responsibilities..............................9.13
OWNER's Representative..............................9.1
Project Representative...................................9.3
Rejecting Defective Work ............................
9.6
Shop Drawings, Change Orders
and Payments....................................9.7-9.9
Visits to Site— ......... .................
I ..... 9.2
Unit Price determinations ..................................
9.10
Visits to Site .......... ......................... I ...................
.2
Written consent required..............................7.2,
9.1
Equipment, Labor, Materials and.........................6.3-6.5
Equipment rental, Cost of the Work,,,,,,,,,,,,,,,,,,
11.4.5.3
Equivalent Materials and Equipment .......................
_6.7
error or omissions..................................................6.33
Evidence of Financial Arrangements .......................8.11
Explorations of physical conditions .......................
4.2.1
Fee, CONTRACTOR's--Costs Plus ...........................11.6
Field Order --
definition of
1.19
issued by ENGINEER ................................
3.6.1, 9.5
Final Application for Payment... ..... .... ..................
14.12
Final Inspection..............................................I.....14.1
1
Final Payment --
and Acceptance .................... ..................
14.13-14.14
Prior to, for cash al lovances .......................
I ..... , 11.8
General Provisions ..........................................
17.3-17.4
General Requirements --
definition of......................................................1.20
principal references to..............2.6, 6.4,
6.6-6.7, 6.24
GivingNotice .......... ................ ....... ........................17.1
Guarantee of Work --by CONTRACTOR ........
6 30, 14.12
Hazard Communication Programs ..........................
6.22
Hazardous Waste --
definition of
1.21
general.............................................................4.5
OWNER's responsibility fo................................
8AO
ix
E.1CDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9/99)
Indemnification . ..........................6.12, 6.16, 6.31-6.33
Initially Acceptable Schedules...................................2.9
Inspection --
Certificates of..............................9.13.4, 13.5, 14.12
Final ................................... 14.11
Article or Paragraph
Number
Special, required byENGINEER ................I........9.6
Tests and Approval .............................$ 7, 13.3-13.4
Insurance --
Acceptance of, by OWNER...............................5,14
Additional, required by changes
in the Work............................................11.4.5.9
Before starting the Work.....................................2.7
Bonds and --in general.....................................I.....5
Cancellation Provisions ......................................
5.8
Certificates of...................2.7, 5, 5.3, 5.4.11,
5.4.13,
................. 5.6.5,5.8,5.14,9.13.4, 14.12
completed operations......................................5.4.13
CONTRACTOR's Liability..................................5.4
CONTRACTOR's objection to coverage .............
5.14
Contractual Liability.....................................5.4.10
AC
deductible amounts, CONTRTOR's
responsibility................................................5.9
Final Application for Payment ..........................14.12
Licensed Insurers ............................................
... 5.3
Notice requirements, material changes.......5.8,
10.5
.
Option to Replace ....... ... ..:....... .......... ......
..... ....5.14
other special insurances....................................5.10
OWNER as fiduciary for insureds...............5.12-5.13
OWNER's Liability ......... ................................5.5
...
OWNER's Responsibility.....................................8.5
Partial Utilization, Property Insurance...............5.15
Property.................................................... ........................
Receipt and Application of Insurance
Proceeds. . _ ......................................
5.12-5.13
Special Insurance .............................................
5.10
Waiver of Rights..............................................5.11
Intent of Contract Documents ... ...........................
3.1-3.4
Interpretations and Clarifications .....................
3.6.3, 9.4
Investigations of physical conditions ..........................4.2
Labor, Materials and Equipment..........................6.3-6.5
Lands --
and Easements... ................................................
8.4
Availability of.............................................4.1,
8.4
Reports and Tests...............................................8.4
Laws and Regulations --Laws or Regulations --
Bonds.................................................
........5.1-5.2
Changes in the Work.......................................10.4
..
Contract Documents...........................................3.1
CONTRACTOR's Responsibilities .....................6.14
Correction Period,defective Work....................13.12
Cost of the Work, taxes ..............................
11.4.5.4
definition of ................................
1.22
general6.14
Indemnification ........................................
6.31-6.33
Insurance...........................................................5.3
Precedence ...............3.11 3.3.3
.................................
Reference to....................................................3.3.1
Safety and Protection................................6.20, 13.2
Subcontractors, Suppliers and Others„.......,.6.8-6.11
Article or Paragraph
Number
Tests and Inspections...................................13.5
Use of Premises.................................................6.16
Visits to Site.......................................................9.2
Liability Insurance--
CONTRACTOR's ...............................................
5.4
OWNER's...........................................................5.5
Licensed Sureties and Insurers .................................
5.3
Liens --
Application for Progress Payment ......................1.4.2
CONTRACTOR's Warranty of Title....................14.3
Final Application for Payment .........................1.4.12
definition of.....................................................1.23
Waiver of Claims............................................14.15
Limitations on ENGINEER's authority and
responsibilities ............................................I
.... 9.13
Limited Reliance by CONTRACTOR
Authorized ........................................................
4.2.2
Maintenance and Operating Manuals --
Final Application for Payment .........................1.4.12
Manuals (of others) --
Precedence ............................
3.3.3.1
Reference to in Contract Documents .................
3.3.1
Materials and equipment --
furnished by CONTRACTOR...............................6.3
not incorporated in Work...................................14.2
Materials or equipment --equivalent ...........................6.7
Mediation (Optional)..............................................16.7
Milestones --definition of......................I.................1.24
Miscellaneous --
Computation of Times......................................17.2
Cumulative Remedies ........................................
17.4
Giving Notice....................................................17.1
Notice of Claim.................................................17.3
Professional Fees and Court Costs Included........
17.5
Multi -prime contracts.................................................7
Not Shown or Indicated.........................................4.3.2
Notice of --
Acceptability of Project.....................................14.13
Award, definition of.........................................1.25
Claim.............................................................1.7
1
Defects,13.1
Differing Subsurface or Physical Conditions ......
4.2.:
Giving ............................................................
17.1
.
Tests and Inspections....................................I...13.3
Variation, Shop Drawing and Sample.................6.27
Notice to Proceed --
definition of.....................................................1.26
givingof ........................................................... 2.3
x
E.ICDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9/99)
Notification to Surety..............................................JO.5
Observations, by ENGINEER...........................6.30,
9.2
Occupancy of the Work ...................
5.15, 6.30.2.4, 14.10
Omissions or acts by CONTRACTOR...............6.9, 9.13
Open Peril policy form, Insurance..........................5.6.2,
Option to Replace.-- .... I ........................................
5.14
Article or Paragraph
Number
"Or Equal" Items......................................................6.7
Other work 7
Overtime Work --prohibition of .................................
6.3
OWNER --
Acceptance ofclefective Work ..........................13.13
appoint an ENGINEER.......................................8.2
as fiduciary .................... ...........................
5.12-5.13
Availability of Lands, responsibility ....................4.1
definition of .......................................................
1.27
data, furnish......................................................8.3
May Correct Defective Work...........................1.3.14
May refuse to make payment ......... ...........I......14.7
May Stop the Work,,., .........
.13.10
May Suspend Work,
Terminate ........................... 8.8, 13.10,
15.1-15.4
Payment, make prompt.....................8.3, 14.4,
14.13
performance of other work ..................................
7.1
permits and licenses, requirements ....................6.13
purchased insurance requirements ..............
OWNER's--
Acceptance of the Work...............................6.30.2.5
Change Orders, obligation to execute..........
8.6, 10.4
Communications .................................................
8.1
Coordination of the Work
7.4
Disputes, request for decision... 6.......................
9..11
Inspections, tests and approvals..................8.7,
13.4
Liability Insurance..............................................565
Notice of Defects..............................................13.1
Representative --During Construction,
ENGINEER's Status ......................................
9.1
Responsibilities --
Asbestos, PCBs, Petroleum, Hazardous
Waste or Radioactive Material .................
8.10
Change Orders.............................I................8.6
Changes in the Work...................................10.1
communications............................................
8.1
CONTRACTOR's responsibilities ...................
8.9.
evidence of financial arrangements.............8.11
inspections, tests and approval$.....................8.7
insurance......................................................
8.5
lands and easements.....................................8.4
prompt payment by, ..... 6 ................. ...............
8.3
replacement of ENGINEER ...............6..........6.8.2
reports and tests............................................8.4
stop or suspend Work..................8.8, 13.10,
15.1
terminate CONTRACTOR'S
services..........................................8.8,
15.2
separate representative at site ........................6...,
9.3
testing, independent.........................................13.4
use or occupancy
of the Wo1k......................... 5,15, 6.30.2.4, 14.10
written consent or approval
required.........................................9.1, 6.3, 11.4
E.ICDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9/99) .�
{.w
The successful Bidder will be required to furnish a Performance Bond and a
Payment Bond guaranteeing faithful performance and the payment of all bills and
obligations arising from the performance of the Contract.
No Bid may be withdrawn within a period of forty-five (45) days after the date
fixed for opening Bids.
The OWNER reserves the right to reject any and all Bids, and to waive any
informalities and irregularities therein.
Bid security in the amount of not less than 5% of the total Bid must accompany
each Bid in the form specified in the Instructions to Bidders.
Sales Prohibited/Conflict of Interest: No officer, employee, or member of City
Council, shall have a financial interest in the sale to the City of any real or
personal property, equipment, material, supplies or services where such officer
or employee exercises directly or indirectly any decision -making authority
concerning such sale or any supervisory authority over the services to be
rendered. This rule also applies to subcontracts with the City. Soliciting or.
accepting any gift, gratuity favor,, entertainment, kickback or any items of
monetary value from any person who has or is seeking to do business with the City
of Fort Collins is prohibited
City of Fort Collins
By f" t—
am s B. O'N�ill, II, CPPO, FNIGP
sinhag/Risk Management Director
07/2001 Section 00020 Page 2
Article or Paragraph
Number
written notice required .........................7.1,
9.4, 9.11,
11.2,
11.9, 14.7, 15.4
PCBs --
definition of......................................................1.29
general .......................................
4.5
OWNER's responsibility for...............................8.10
Partial Utilization --
definition of. .....................................................J
1.28
general 6.30.2.4, 14.10
Property Insurance ............................................
5.15
Patent Fees and Royalties .......................................
6.12
Payment Bonds...................................................5.1-5.2
Payments, Recommendation of..............14.4-14.7,
14.13
Payments to CONTRACTOR and Completion
--
Application for ProgressPayments ......................14.2
CONTRACTOR's Warranty of Title ..........
*........14.3
Final Application for Payment ..........................14.12
Final Inspection ..............................................
14.11
Final Payment and Acceptance ................14.13-14.14
general.........................................................$.3,
14
Partial Utilization............................................14.10
Retainage..........................................................14.2
Review of Applications for
Progress Payments...............................14.4-14.7
prompt payment..................................................8.3
Schedule of Values............................................14.1
Substantial Completion ........ ......................
14.8-14.9
Waiver of Claims.............................................14.15
when payments due .................................
14.4, 14.13
withholding payment.........................................14.7
Performance Bonds .......... ...................................
5.1-5.2
Permits............................................................6.13
Petroleum --
definition of......................................................1.30
general.............. ..................................
I .............4.5
OWNER's responsibility for...............................8.10
Physical Conditions --
Drawings of, in or relating to ........................4.2.1.2
ENGINEER's review ....................... I................
4.2.4
existing structures............................................4.2.2
general4.2.1.2..........................................................
Notice of Differing Subsurface or.......................4.2.3
Possible Contract Documents Change...............4.2.5
Possible Price and Times Adjustments ...........
I .... 4.2.6
Reports and Drawings......................................4.2.1
Subsurface and....................................................4.2
Subsurface Conditions.................................4.2.1.1
Technical Data, Limited Reliance by
CONTRACTOR Authorized .......................
4.2.2
Underground Facilities--
general........................................................
4.3
Not Shown or Indicaed..............................4.3.2
Protection of ........................................
4.3, 6.20
Article or Paragraph
Number
Shown or Indicated................................................4.3.1
Technical Data.................................I.............4.2.2
Preconstrtiction Conference.......................................2.8
Preliminary Matters......................................................2
Preliminary Schedules ............. ............... I ........
I ......... 2.6
Premises, Use of ........................................
I..... 6.16-6.18
Price, Change of Contract .......... .................................
I I
Price, Contract --definition of ..................................
1.11
Progress Payment, Applications fo............................
14.2
Progress Payment--retainage...................................
14.2
Progress schedule, CONTRACTOR's............
2.6, 2.8, 2.9,
................. ... I............ 6.6, 6.29, 10.4, 15.2.1
Project --definition of...............................................1.31
Project Representative—
ENGINEER's Status During Construction...,
......... 9.3
Project Representative, Resident --definition
of ....... ,..1.33
prompt payment by OWNER................................I....8.3
Property Insurance --
Additional.........................................................5.7
general5.6-5.10
Partial Utilization................................5.15,
14.10.2
receipt and application of proceeds.............5,12-5.13
Protection, Safety and..............................6.20-6.21,
13.2
Punch list .............................................
............ 14.11
Radioactive Material--
defintion of......................................................1.32
general4.5
OWNER's responsibility for .............................
8.10
Recommendation of Payment ................. 14.4, 14.5, 14.13
Record Documents .......................................
6.19, 14.12
Records, procedures for maintaining... ..................
.... 2.8 -
Reference Points.........................................I.............4.4
Reference to Standards and Specifications
of Technical Societies.........................................3.3
Regulations, Laws and(or)......................................6.14
Rejecting Defective Work ..........................
I...............9.6
Related Work --
at Site........................................................7.
1-7.3
Performed prior to Shop Drawings
and Samples submittals review., ........
I ........... 6.28
Remedies, cumulative......................................17.4,
17.5
Removal or Correction ofDefective Work................13.11
rental agreements, OWNER approval required
..... 11.4.5.3
replacement of ENGINEER, by OWNER....................8.2
Reporting and Resolving
Discrepancies, ............................... 12.5, 3.3.2, 6.14.2
Reports --
and Drawings.................................................4.2.1
and Tests, OWNER's responsibility .....................8.4
Resident and Project Representative --
definition of....................................................1.33
provision for............................................................9.3
xu
E.ICDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9(99)
Article or Paragraph
Number
Resident Superintendent, CONTRACTOR's................6.2
Responsibilities—
CONTRACTOR's-in general .................................. 6
ENGINEER's-in general........................................9
Limitations on.............................................9.13
OWNER's-in general..............................................8
Retainage.............................................................I4.2
Reuse of Documents .................................................
3.7
Review by CONTRACTOR: Shop Drawings
and Samples Prior to Submittal ..........................6.25
Review of Applications for
Progress Payments.....................................14.4-14.7
Right to an adjustment .................... I.........__............10.2.
Rights of Way.,,....,
4.1
Royalties, Patent Fees and......................................6.12
Safe Structural Loading..........................................6.18
Safety --
and Protection................................4.3.2,
6.16, 6.18,
................... I., ................ 6.20-6.21,
7.2, 13.2
general ....................................................
6.20-6.23
Representative, CONTRACTOR's.......................6.21
Samples --
definition of.....................................................1.34
general ............... ....................... ...............
0.24-6.28
Review by CONTRACTOR................................6.25
Review by ENGINEER..............................6.26,
6.27
relatedWork.....................................................6.28
submittal of....................................................6.24.2
submittal procedures....................................I....6.25
Schedule of progress.............................2.6,
2.8-2.9, 6.6,
........... ......... ..........6,29,
10.4, 15.2.1,
Schedule of Shop Drawing and Sample
Submittals..............................2.6,
2.8-2.9, 6.24-6.28
Schedule of Values...............................2.6,
2.8-2.9, 14.1
Schedules --
Adherence to ...................................................
15.2.1
Adjusting...........................................................6.6
Change of Contract Times.................................10.4
Initially Acceptable..,,...,. ........
._...... 2.8, 2.9
Preliminary...................................
.....................2.6
Scope of Changes......................................10.3-10.4
Subsurface Conditions
4.2.1.1
Shop Drawings --
and Samples, general., .... I ..............
I ........... 6.24-6.28
Change Orders & Applications for
Payments, and .... .............................
........ 9.7-9.9
definition of......................................................1.35
ENGINEER'S approval of.................................3.6.2
ENGINEER's responsibility
for review .....................................
9.7, 6.24-6.28
related Work.....................................................6.28
review procedures................................2.8,
6.24-6,28
Article or Paragraph
Number
submittal required ...............................................
6.24.1
Submittal Procedures6.25
use to approve substitutions,,,,,,,,,,,,,,,,,,,,,,
5.7.3
Shown or Indicated ,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,4.3.1
Site Access........................................I.............7.2,
13.2
Site Cleanliness.......................................................0.17
Site, Visits to --
by ENGINEER...........................................9.2,
13.2
byothers ............................ ..... .........................13.2
"special causes of loss" policy form,
insurance ................................................
5.6.2
definition of.....................................................1.36
Specifications --
definition of ..............................................j.36
.
of Technical Societies, reference to...................3.3.1
precedence......................................................3.3.3
Standards and Specifications
of Technical Societies........................................3.3
Starting Construction, Before..............................2.5-2.8
Starting the Work .......................................................
2.4
Stop or Suspend Work--
by CONTRACTOR...........................................15.5
by OWNER ..................................... 8.8, 13.10,
15.1
Storage of materials and equipment ....................14.1,
7.2
Structural Loading, Safety........................................6.18
Subcontractor --
Concerning ................................................
6.8-6.1 1
definition of.....................................................1.37
delays............................................................12.3
waiver of rights................................................6.11
Subcontractors --in general6.8-6.11
Subcontracts --required provisions .......... 5 11, 6.11,
11.4.3
Submittals --
Applications for Payment ............... *.,....... ..,,,._.,
14.2
Maintenance and Operation Manuals,.. ........
14.12
Procedures ........................................................
6.25
Progress Schedules.......................................2.6,
2.9
Samples .......... ....... ......... ................... .......
6.24-6.28
Schedule of Values .......... .. ..... ....................2.6,
14.1
Schedule of Shop Drawings and Samples
Submissions......................................2.6,
2.8-2.9
Shop Drawings ........................ I................
6.24-6.28
Substantial Completion --
certification of............................6.30.2.3,
14.8-14.9
definition of.....................................................1.38
Substitute Construction Methods or Procedures ........
6.7.2
Substitutes and "Or Equal" Items .............. _....
.......... 6.7
CONTRACTOR's Expense............................6.7.1.3
ENGINEER's Evaluation6.7.3
"Or -Equal .....................................................
0.7.1.1
Substitute Construction Methods
EJCDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9/99)
Article or Paragraph
Number
or Procedures.............................................6.7.2
Substitute Items............................................6.7.1.2
Subsurface and Physical Conditions --
Drawings of, in or relatng to ........................
4.2.1.2
ENGINEER's Review ......................................
4.2.4
general..............................................................4.2
Limited Reliance by CONTRACTOR
Authorized ..................................................
4 2.2
Notice of Differing Subsurface or
Physical Conditions.........................................4.2.3
Physical Conditions ......................................
4.2.1.2
Possible Contract Documents Change................4.2.5
Possible Price and Times Adjustments ......
I ......... 4.2.6
Reports and Drawings ......................................
4.2.1
Subsurface and ...................................................
4.2
Subsurface Conditions at the Site....................4.2.1.1
Technical Data.................................................4.2.2
Supervision--
CONTRACTOR's responsibility ...........................6.1
OWNER shall not supervise.................................8.9
ENGINEER shall not supervise................9.2,
9.13.2
Superintendence.......................................................6.2
Superintendent, CONTRACTOR's resident
...............6.2
Supplemental costs ..............................................
11.4.5
Supplementary Conditions --
definition of .................1.39
.....................................
principal references to.................1.10,
1.18, 2.2, 2.7,
...........I...........4.2, 4.3, 5.1, 5.3, 5.4, 5.6-5.9,
.............. 5.11, 6.8, 6.13, 7.4,
8.11, 9.3, 9.10
Supplementing Contract Documents .........................
3.6
Supplier --
definition of......................................I...............1.40
principal references to ........... 3.7, 6.5, 6.8-6.11, 6.20,
..........................................6.24, 9.13, 14.12
Waiver of Rights...............................................6.11
Surety --
consent to final payment ........................14.12,
14.14
ENGINEER has no duty to.................................9.13
Notification of.................................110.1,
10.5, 15.2
qualification of . ........... ........... I .....................
5.1-5.3
Survival of Obligations...........................................6.34
Suspend Work, OWNER May .......................13.10,
15.1
Suspension of Work and Termination-- ......................15
CONTRACTOR May Stop Work
or Terminate...............................................15.5
OWNER May Suspend Work .............................
1.5.1
OWNER May Terminate ............................
15.2-15.4
Taxes --Payment by CONTRACTOR ............
I............ 6.15
Technical Data --
Limited Reliance by CONTRACTOR .................4.2.2
Possible Price and Times Adjustments....
I..........4.2.6
Reports of Differing Subsurface and
Physical Conditions....................................4.2.3
Temporary construction facilities 4.1
Article or Paragraph
Number
Termination --
by CONTRACTOR...........................................15.5
by OWNER........................................8.8,
15.1-15.4
of ENGINEER's employment.....................I........8.2
Suspension of Work-in general .............................15
Terms and Adjectives..............................................3.4
Tests and Inspections --
Access to the Work, by others............................13.2
CONTRACTOR's responsibilities ......................
13.5
cost of 13.4
covering Work prior to..............................13.6-13.7
Laws and Regulations(or)................................
13.5
Notice of Defects..............................................
13.1
OWNER May Stop Work ..................
I..............13.10
OWNER's independent testing ..........................13.4
special, required by ENGINEER ..........................9.6
timely notice required .......................................
13.4
Uncovering the Work, at ENGINEER's
request.................................................13.8-13.9
Times--
Adjusting...........................................................6.6
Change of Contract..............................................12
Computation of.................................................17.2
Contract Times --definition of ...........................1.12
day.........................................................17.2.2
Milestones ....................................
I........I............ 12
Requirements--
appeals.................................................9,10,
16
clarifications,
claims and disputes..................9.11,
11.2, 12
Commencement of Contract Times ................ 2.3
Preconstruction Conference......,
I ........ ............ Z-8
schedules.........................................2.6,
2.9, 6.6
Starting the Work..........................................2.4
Title, Warranty of..................................................14.3
Uncovering Work.............................................13.8-13.9
Underground Facilities, Physical Conditions
--
definition of .....................................................
1.41
Not Shown or Indicated .....................
.............4.3.2
protection of..............................................4.3,
6.20
Shown or Indicated ................................
...... ...,4.3.1
Unit Price Work--
claims.........................................................1.1.9.3
definition of....................................................1.42
general11.9, 14.1, 14.5
Unit Prices--
general11.3.1
Determination for ............................................
9.10
Use of Premises................................16.16,
6.18, 6.30.2.4
Utility owners.............................6.13,
6.20, 7.1-7.3, 13.2
Utilization, Partial...................1.28,
5.15, 6.30.2.4, 14.10
Value of the Work ...............................
..................... 11.3
Values, Schedule of..............................2.6,
2.8-2.9, 14.1
xiv
E.ICDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9/99)
Variations in Work --Minor
Authorized ........................................ 6.25, 6.27, 9.5
Article or Paragraph
Number
Visits to Site --by ENGINEER ............................
........9.2
Waiver of Claims --on Final Payment ,,,,,,,,,,,,,,,,,,,,,,14.15
Waiver of Rights by insured partig..................5.11,
6.11
Warranty and Guarantee, General --by
CONTRACTOR ....................... I ........................6.30
Warranty of Title, CONTRACTORs.......................
14.3
Work --
Accessto..........................................................13.2
byothers...............................................................
7
Changesin the ....................................................
10
Continuing the ...............................
CONTRACTOR May Stop Work
or Terminate ................................................
15.5
Coordination of. .............................
7.4
......................
Cost of the.................................................11.4-11.5
definition of
........................................................
1.43
neglected by CONTRACTOR ............................)
3.14
otherWork............................................................7
OWNER May Stop Work.................................13.10
OWNER May Suspend Work ...................
j3.10, 15.1
Related, Work at Site....................................7.1-7.3
Starting the........................................................2.4
Stopping by CONTRACTOR..............................15.5
Stopping by OWNER .......................
1......... 15.1-15.4
Variation and deviation authorized,
minor ........... 3.6
Work Change Directive --
claims pursuant to.............................................10.2
definition of......................................................1.44
principal references to.......................�.5.3,
10.1-10.2
Written Amendment --
definition of
1.45
principal references to..............1,10, 3.5, 5.10,15.12,
.........................6.6.2, 6.8.2,
6.19, 10.1, 10.4,
............................11.2, 12.1,
13.12.2, 14.7.2
Written Clarifications and
Interpretations....*............*..............-.3.6.3,
9.4, 9.11
Written Notice Required--
by CONTRACTOR............................7,1,
9.10-9.11,
............. I ..... I.......................
10.4, 11.2, 12.1
by OWNER ....................9.10-9.11,
10.4, 11.2, 13.14
n
xv
EJCDC GENERAL CONDITIONS 1910-8 (1990 EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9/99)
S.«
(This page left blank intentionally)
xvi E.ICDC GENERAL CONDITIONS 1910-9 (1990 EDITION)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 9/99)
No Text
GENERAL CONDITIONS
ARTICLE 1--DEFINITIONS
Wherever used in these General Conditions or in the other
Contract Documents the following terms have the
meanings indicated which are applicable to both the
singular and plural thereof:
1.1. Addenda --Written or graphic instruments issued
prior to the opening of Bids which clarify, correct or
change the Bidding Requirements or the Contract
Documents.
1.2. Agreement --The written contract between OWNER
and CONTRACTOR covering the Work to be performed;
other Contract Documents are attached to the Agreement
and made a part thereof as provided therein.
1.3. Application for Payment --The form accepted by
ENGINEER which is to be used by CONTRACTOR in
requesting progress or final payments and which is to be
accompanied by such supporting documentation as is
required by the Contract Documents.
1.4. Asbestos --Any material that contains more than one
percent asbestos and is hiable or is releasing asbestos fibers
into the air above current action levels established by the
United States Occupational Safety and Health
Administration.
1.5. Bid --The offer or proposal of the bidder submitted
on the prescribed form setting forth the prices for the Work
to be performed.
1.6. Bidding Documents --The advertisement or
invitation to Bid, instructions to bidders, the Bid form, and
the proposed Contract Documents (including all Addenda
issued prior to receipt of Bids).
1.7. Bidding Requirements --The advertisement or
invitation to Bid, instructions to bidders, and the Bid form.
1.8. Bonds --Performance and Payment bonds and other
instruments of security.
1.9. Change Order --A document recommended by
ENGBNEER, which is signed by CONTRACTOR and
OWNER and authorizes an addition, deletion or revision in
the Work, or an adjustment in the Contract Price or the
Contract Times, issued on or after the Effective Date of the
Agreement.
1.10. Contract Documents --The Agreement, Addenda
(which pertain to the Contract Documents),
CONTRACTOR's Bid (including documentation
accompanying the Bid and any post Bid documentation
submitted prior to the Notice of Award) when attached as
an exhibit to the Agreement, the Notice to Proceed, the
Bonds, these General Conditions, the Supplementary
Conditions, the Specifications and the Drawings as the
E1CDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
same are more specifically identified in the Agreement,
together with all Written Amendments, Change Orders,
Work Change Directives, Field Orders and ENGINEER's
written interpretations and clarifications issued pursuant to
paragraphs 3.5, 3.6.1 and 3.6.3 on or after the Effective
Date of the Agreement. Shop Drawing submittals
approved pursuant to paragraphs 6.26 and 6.27 and the
reports and drawings referred to in paragraphs 4.2.1 and
4.2.2 are not Contract Documents.
1.11. Contract Price --The moneys payable by
OWNER to CONTRACTOR for completion of the Work
in accordance with the Contract Documents as stated in
the Agreement (subject to the provisions of
paragraph 11.9.1 in the case of Unit Price Work).
1.12. Contract Times --The numbers of days or the
dates stated in the Agreement: (i) to achieve Substantial
Completion, and (ii) to complete the Work so that it is
ready for final payment as evidenced by ENGINEER's
written recommendation of final payment in accordance
with paragraph 14.13.
1.13. CONTRACTOR --The person, firm or corporation
with whom OWNER has entered into the Agreement.
1.14, defective --An adjective which when modifying
the word Work refers to Work that is unsatisfactory, faulty
or deficient in that it does not conform to the Contract
Documents, or does not meet the requirements of any
inspection, reference standard, test or approval referred to
in the Contract Documents, or has been damaged prior to
ENGINEER's recommendation of final payment (unless
responsibility for the protection thereof has been assumed
by OWNER at Substantial Completion in accordance with
paragraph 14.8 or 14.10).
1.15. Drawings --The drawings wlmich show the scope,
extent and character of the Work to be furnished and
performed by CONTRACTOR and which have been
prepared or approved by ENGINEER and are referred to
in the Contract Documents. Shop drawings are not
Drawings as so defined.
1.16. Effective Date of the Agreement --The date
indicated in the Agreement on which it becomes effective,
but if no such date is indicated it means the date on which
the Agreement is signed and delivered by the last of the
two parties to sign and deliver.
1.17. ENGINEER --The person, firm or corporation
named as such in the Agreement.
1.18. ENGINEER's Consultant --A person, firm or
corporation having a contract with ENGINEER to furnish
services as ENGINEER's independent professional
associate or consultant with respect to the Project and who
is identified as such in the Supplementary Conditions.
1.19. Field Order --A written order issued by
ENGINEER which orders minor changes in the Work in
accordance with paragraph 9.5 but which does not involve
a change in the Contract Price or the Contract Times.
1.20: General Requirements --Sections of Division 1 of
the Specifications.
1.21. Hazardous Waste --The term Hazardous Waste shall
have the meaning provided in Section 1004 of the Solid
Waste Disposal Act (42 USC Section 6903) as amended
from time to time.
1.22.a. Laws and Regulations; Laws or Regulations --Any
and all applicable laws, rules, regulations, ordinances,
codes and orders of any and all governmental bodies,
agencies, authorities and courts having jurisdiction.
1.22.b. Lezal Holidays --shall be those holidays observed
by the City of Fort Collins.
1.23. Liens —Liens, charges, security interests or
encumbrances upon real property or personal property.
1.24. Milestone --A principal event specified in the
Contract Documents relating to an intermediate completion
date or time prior to Substantial Completion of all the
Work.
1.25. Notice of Award --A written notice by OWNER to
the apparent successful bidder- stating that upon compliance
by the apparent successful bidder with the conditions
precedent enumerated therein, within the time specified,
OWNER will sign and deliver the Agreement.
1.26. Notice to Proceed --A written notice given by
OWNER to CONTRACTOR (with a copy to ENGINEER)
fixing the date on which the Contract Times will
commence to run and on which CONTRACTOR shall start
to perform CONTRACTOR'S obligations under the
Contract Documents.
1.27. OWNER —The public body or authority,
corporation, association, firm or person with whom
CONTRACTOR has entered into the Agreement and for
whom the Work is to be provided.
1.28. Partial Utilization --Use by OWNER of a
substantially completed part of the Work for the purpose
for which it is intended (or a related purpose) prior to
Substantial Completion of all the Work.
1.29. PCBs --Polychlorinated biphenyls.
1.30. Petroleum --Petroleum, including crude oil or any
fraction thereof which is liquid at standard conditions of
temperature and pressure (60 degrees Fahrenheit and
14.7 pounds per square inch absolute), such as oil,
petroleum, fuel oil, oil sludge, oil refuse, gasoline, kerosene
and oil mixed with other non -Hazardous Wastes and crude
oils.
1.31. Project --The total construction of which the Work
to be provided under the Contract Documents may be the
whole, or a part as indicated elsewhere in the Contract
Documents.
1.32.a. Radioactive Material --Source, special nuclear, or
byproduct material as defined by the Atomic Energy Act of
EJCDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
1954 (42 USC Section 2011 et seq.) as amended fi-orn
time to time.
1.32.b. Regular Working Hours --Regular working hours
are defined as 7:00am to 6:000M unless otherwise
specified in the General Requirements.
1.33. Resident Project Representative --The authorized
representative of ENGINEER who may be assigned to the
site or any part thereof.
1.34. Samples --Physical examples of materials,
equipment, or workmanship that are representative of
some portion of the Work and which establish the
standards by which such portion of the Work will be
judged.
1.35. Shop Drawings --All drawings, diagrams,
illustrations, schedules and other data or information
which are specifically prepared or assembled by or for
CONTRACTOR and submitted by CONTRACTOR to
illustrate some portion of the Work.
1.36. Specifications --Those portions of the Contract
Documents consisting of written technical descriptions of
materials, equipment, construction systems, standards and
workmanship as applied to the Work and certain
administrative details applicable thereto.
1.37. Subcontractor --An individual, firm or corporation
having a direct contract with CONTRACTOR or with any
other Subcontractor for the performance of a part of the
Work at the site.
1.38. Substantial Completion --The Work (or a
specified part thereof) has progressed to the point where,
in the opinion of ENGINEER as evidenced by
ENGINEER's definitive certificate of Substantial
Completion, it is sufficiently complete, in accordance with
the Contract Documents, so that the Work (or specified
part) can be utilized for the purposes for which it is
intended; or if no such certificate is issued, when the
Work is complete and ready for final payment as
evidenced by ENGINEER's written recommendation of
final payment in accordance with paragraph 14.13. The
terms "substantially complete" and "substantially
completed" as applied to all or part of the Work refer to
Substantial Completion thereof.
1.39. Supplementary Conditions --The part of the
Contract Documents which amends or supplements these
General Conditions.
1.40. Supplier --A manufacturer, fabricator, supplier,
distributor, materialman or vendor having a direct contract
with CONTRACTOR or with any Subcontractor to
furnish materials or equipment to be incorporated in the
Work by CONTRACTOR or any Subcontractor.
1.41. Underground Facilities --All pipelines, conduits,
ducts, cables, wires, manholes, vaults, tanks, tunnels or
other such facilities or attachments, and any encasements
containing such facilities which have been installed
underground to furnish any of the following services or
I
materials: electricity, gases, steam, liquid petroleum
products, telephone or other communications, cable
television, sewage and drainage removal, traffic or other
control systems or water.
1.42. Unit Price Work --Work to be paid for on the basis
of unit prices.
1.43. Work --The entire completed construction or the
various separately identifiable parts thereof required to be
furnished under the Contract Documents. Work includes
and is the result of performing or furnishing labor and
fiunishing and incorporating materials and equipment into
the construction, and performing or firrnishing services and
furnishing documents, all as required by the Contract
Documents.
1.44. Work Change Directive --A written directive to
CONTRACTOR, issued on or after the Effective Date of
the Agreement and signed by OWNER and recommended
by ENGINEER, ordering an addition, deletion or revision
in the Work, or responding to differing or unforeseen
physical conditions under which the Work is to be
performed as provided in paragraph 4.2 or 4.3 or to
emergencies under paragraph 6.23. A Work Change
Directive will not change the Contract Price or the Contract
Times, but is evidence that the parties expect that the
change directed or documented by a Work Change
Directive will be incorporated in a subsequently issued
Change Order following negotiations by the parties as to its
effect, if any, on the Contract Price or Contract Times as
provided in paragraph 10.2.
1.45. Written Amendment --A written amendment of the
Contract Documents, signed by OWNER and
CONTRACTOR on or after the Effective Date of the
Agreement and normally dealing with the nonengineering
or nontechnical rather than strictly construction -related
aspects of the Contract Documents.
ARTICLE 2--PRELIMINARY MATTERS
Delivery of Bonds:
2.1, When CONTRACTOR delivers the executed
Agreements to OWNER, CONTRACTOR shall also
deliver to OWNER such Bonds as CONTRACTOR may
be required to furnish in accordance with paragraph 5.1.
Copies of Documents:
2.2. OWNER shall furnish to CONTRACTOR up to ten
copies (unless otherwise specified in the Supplementary
Conditions) of the Contract Documents as are reasonably
necessary for the execution of the Work. Additional copies
will be famished, upon request, at the cost of reproduction.
Commencement of Contract Times; Notice to Proceed:
2.3. The Contract Times will commence to run on the
thirtieth day after the Effective Date of the Agreement, or,
E.I C DC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
if a Notice to Proceed is given, on the day indicated in the
Notice to Proceed. A Notice to Proceed may be given at
any time within thirty days after the Effective Date of the
Agreement. in _ event will the r,.nhtaet Tifnes
eeniffienee te run later than the sixtieth day aftff the day
of Bid epenifig er the thirtieth day after the Effaetk,e
„f the n gice,,„. .. ent hiehe ei- date : none.. - ,ten «
Starting the Work:
2.4. CONTRACTOR shall start to perform the Work
on the date when the Contract Times continence to run,
but no Work shall be done at the site prior to the date on
which the Contract Times continence to run.
Before Starting Construction:
2.5. Before undertaking each part of the Work,
CONTRACTOR shall carefully study and compare the
Contract Documents and check and verify pertinent
figures shown thereon and all applicable field
measurements. CONTRACTOR shall promptly report in
writing to ENGINEER any conflict, en -or, ambiguity or
discrepancy which CONTRACTOR may discover and
shall obtain a written interpretation or clarification fi-om
ENGINEER before proceeding with any Work affected
thereby; however, CONTRACTOR shall not be liable to
OWNER or ENGINEER for failure to report any conflict,
error, ambiguity or discrepancy in the Contract
Documents, unless CONTRACTOR knew or reasonably
should have known thereof.
2.6. Within ten days after the Effective Date of the
Agreement (unless otherwise specified in the General
Requirements), CONTRACTOR shall submit to
ENGINEER for review:
2.6.1. a preliminary progress schedule indicating
the times (numbers of days or dates) for starting and
completing the various stages of the Work, including
any Milestones specified in the Contract Documents;
2.6.2. a prelimmary schedule of Shop Drawing and
Sample submittals which will list each required
submittal and the times for submitting, reviewing and
processing such submittal;
2.6.2.1, In no case will a schedule be
acceptable which allows less than 21 calendar
days for each review by Enr?ineer.
2.6.3. A preliminary schedule of values for all of
the Work which will include quantities and prices of
items aggregating the Contract Price and will
subdivide the Work into component parts in sufficient
detail to serve as the basis for progress payments -..
during construction. Such prices will include an
appropriate amount of overhead and profit applicable
to each item of Work.
2.7. Before any Work at the site is started,
CONTRACTOR and " E shall eaeh deliver to the
ether OWNER with copies to each additional :n ed
identified in the Stipp leniGend:tien ENGINEER,
certificates of insurance (and other evidence of insurance
teasenably request requested by OWNER) which
CONTRACTOR is required
to purchase and maintain in accordance with
paragraphs 5.4, 5.6 and 5.7.
Preconstruction Conference:
2.8. Within twenty days after the Contract Times start to
run, but before any Work at the site is started, a conference
attended by CONTRACTOR, ENGINEER and others as
appropriate will be held to establish a working
understanding among the parties as to the Work and to
discuss the schedules referred to in paragraph 2.6,
procedures for handling Shop Drawings and other
submittals processing Applications for Payment and
maintaining required records.
Initially Acceptable Schedules:
2.9. Unless otherwise provided in the Contract
Documents, at react tan dFry., be fare ....4.«.ission e f the firs
"pplieatien r.._ u,.before any work at the site begins,
a conference attended by CONTRACTOR, ENGINEER
and others as apprepriate designated by OWNER will be
held to review for acceptability to ENGINEER as provided
below the schedules submitted in accordance with
paragraph 2.6. and Division 1 - General Requirements.
CONTRACTOR shall have an additional ten days to make
corrections and adjustments and to complete and resubmit
the schedules. No progress payment shall be made to
CONTRACTOR until the schedules are submitted to and
acceptable to ENGINEER as provided below. The
progress schedule will be acceptable to ENGINEER as
providing an orderly progression of the Work to
completion within any specified Milestones and the
Contract Times, but such acceptance will neither impose on
ENGINEER responsibility for the sequencing, scheduling
or progress of the Work nor interfere with or relieve
CONTRACTOR from CONTRACTOR's full
responsibility therefor. CONTRACTOR's schedule of
Shop Drawing and Sample submissions will be acceptable
to ENGINEER as providing a workable arrangement for
reviewing and processing the required submittals
CONTRACTOR's schedule of values will be acceptable to
ENGINEER as to form and substance.
ARTICLE 3--CONTRACT DOCUMENTS: INTENT,
AMENDING, REUSE
Intent:
3.1. The Contract Documents comprise the entire
agreement between OWNER and CONTRACTOR
concerning the Work. The Contract Documents are
complementary; what is called for by one is as binding as if
called for by all. The Contract Documents will be
construed in accordance with the law of the place of the
Project.
3.2. It is the intent of the Contract Documents to
E.ICDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
describe a functionally complete Project (or part thereof)
to be constructed in accordance with the Contract
Documents. Any Work, materials or equipment that may
reasonably be inferred from the Contract Documents or
from prevailing custom or trade usage as being required to
produce the intended result will be furnished and
performed whether or not specifically called for. When
words or phrases which have a well-known technical or
construction industry or trade meaning are used to
describe Work, materials or equipment, such words or
phrases shall be interpreted in accordance with that
meaning. Clarifications and interpretations of the Contract
Documents shall be issued by ENGINEER as provided in
paragraph 9.4.
3.3. Reference to Standards and Specifications of
Technical Societies; Reporting and Resolving
Discrepancies:
3.3.1. Reference to standards, specifications,
manuals or codes of any technical society, organization
or association, or to the Laws or Regulations of any
governmental authority, whether such reference be
specific or by implication, shall mean the latest
standard, specification, manual, code or Laws or
Regulations in effect at the time of opening of Bids (or,
on the Effective Date of the Agreement if there were
no Bids), except as may be otherwise specifically
stated in the Contract Documents.
3.3.2. If, during the performance of the Work,
CONTRACTOR discovers any conflict, error,
ambiguity or discrepancy within the Contract
Documents or between the Contract Documents and
any provision of any such Law or Regulation
applicable to the performance of the Work or of any
such standard, specification, manual or code or of any
instruction of any Supplier referred to in paragraph 6.5,
CONTRACTOR shall report it to ENGINEER in
writing at once, and, CONTRACTOR shall not
proceed with the Work affected thereby (except in an
emergency as authorized by paragraph 6.23) until an
amendment or supplement to the Contract Documents
has been issued by one of the methods indicated in
paragraph 3.5 or 3.6; provided, however, that
CONTRACTOR shall not be liable to OWNER or
ENGINEER for failure to report any such conflict,
error, ambiguity or discrepancy unless
CONTRACTOR knew or reasonably should have
known thereof.
3.3.3. Except as otherwise specifically stated in the
Contract Documents or as may be provided by
amendment or supplement thereto issued by one of the
methods indicated in paragraph 3.5 or 3.6, the
provisions of the Contract Documents shall take
precedence in resolving any conflict, error, ambiguity
or discrepancy between the provisions of the Contract
Documents and:
3.3.3.1. the provisions of any such standard,
specification, manual, code or instruction (whether
or not specifically incorporated by reference in the
Contract Documents); or
SECTION 00100
INSTRUCTIONS TO BIDDERS
3.3.3.2. the provisions of any such Laws or
Regulations applicable to the performance of the
Work (unless such an interpretation of the
provisions of the Contract Documents would result
in violation of such Law or Regulation).
No provision of any such standard, specification, manual,
code or instruction shall be effective to change the duties
and responsibilities of OWNER, CONTRACTOR or
ENGINEER, or any of their subcontractors, consultants,
agents or employees from those set forth in the Contract
Documents, not shall it be effective to assign to OWNER,
ENGINEER or any of ENGINEER's Consultants, agents or
employees any duty or authority to supervise or direct the
furnishing or performance of the Work or any duty or
authority to undertake responsibility inconsistent with the
provisions of paragraph 9.13 or any other provision of the
Contract Documents.
3.4. Whenever in the Contract Documents the terms "as
ordered", "as directed", "as required", "as allowed", "as
approved" or terms of like effect or import are used, or the
adjectives "reasonable", "suitable", "acceptable", "proper"
or "satisfactory" or adjectives of like effect or import are
used to describe a requirement, direction, review or
judgment of ENGINEER as to the Work, it is intended that
such requirement, direction, review or judgment will be
solely to evaluate, in general, the completed Work for
compliance with the requirements of and information in the
Contract Documents and conformance with the design
concept of the completed Project as a functioning whole as
shown or indicated in the Contract Documents (unless there
is a specific statement indicating otherwise). The use of
any such term or adjective shall not be effective to assign to
ENGINEER any duty or authority to supervise or direct the
furnishing or performance of the Work or any duty or
authority to undertake responsibility contrary to the
provisions of paragraph 9.13 or any other provision of the
Contract Documents.
Amending and Supplementing Contract Documents:
3.5. The Contract Documents may be amended to
provide for additions, deletions and revisions in the Work
or to modify the terms and conditions thereof in one or
more of the following ways:
3.5.1. a formal Written Amendment,
3.5.2. a Change Order (pursuant to paragraph 10.4),
or
E.ICDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
3.5.3. a Work Change Directive (pursuant to
paragraph 10.1).
3.6. In addition, the requirements of the Contract
Documents may be supplemented, and minor variations
and deviations in the Work may be authorized, in one or
more of the following ways:
3.6.1. A Field Order (pursuant to paragraph 9.5),
3.6.2. ENGINEER's approval of a Shop Drawing or
Sample (pursuant to paragraphs 6.26 and 6.27), or
3.6.3. ENGINEER's written interpretation or
clarification (pursuant to paragraph 9.4).
Reuse of Documents:
3.7. CONTRACTOR, and any Subcontractor or
Supplier or other person or organization performing or
furnishing any of the Work under a direct or indirect
contract with OWNER (i) shall not have or acquire any
title to or ownership rights in any of the Drawings,
Specifications or other documents (or copies of any
thereot) prepared by or bearing the seal of ENGINEER or
ENGINEER's Consultant, and (ii) shall not reuse any of
such Drawings, Specifications, other documents or copies
on extensions of the Project or any other project without
written consent of OWNER and ENGINEER and specific
written verification or adaptation by ENGINEER.
ARTICLE 4--AVAILABILITY OF LANDS;
SUBSURFACE AND PHYSICAL CONDITIONS;
REFERENCE POINTS
Availability of Lands:
4.1. OWNER shall funish, as indicated in the Contract
Documents, the lands upon which the Work is to be
performed, rights -of -way and easements for access
thereto, and such other lands which are designated for the
use of CONTRACTOR. r r__ _,.,.. est
ef ei- filing Et meehanie's lien against stleh lands, —in
OWNER shall identify any encumbrances or restrictions
not of general application but specifically related to use of
lands so furnished with which CONTRACTOR will have
to comply in performing the Work. Easements for
permanent structures or permanent changes in existing
facilities will be obtained and paid for by OWNER, unless
otherwise provided in the Contract Documents. If
CONTRACTOR and OWNER are unable to agree on
entitlement to or the amount or extent of any adjustments
in the Contract Price or the Contract Times as a result of
any delay in OWNER's furnishing these lands, rights -of -
way or easements, CONTRACTOR may make a claim
therefor as provided in Articles 11 and 12.
CONTRACTOR shall provide for all additional lands and
access thereto that may be required for temporary
construction facilities or storage of materials and
equipment.
4.2. Subsurface and Physical Conditions:
4.2.1. Reports and Drawings: Reference is made to
the Supplementary Conditions for identification of.
4.2.1.1, Subsurface Conditions: Those reports of
explorations and tests of subsurface conditions at or
contiguous to the site that have been utilized by
ENGINEER in preparing the Contract Documents;
and
4.2.1.2. Physical Conditions: Those drawings of
physical conditions in or relating to existing surface
or subsurface structures at or contiguous to the site
(except Underground Facilities) that have been
utilized by ENGINEER in preparing the Contract
Documents.
4.2.2. Limited Reliance by CONTRACTOR Authorized, -
Technical Data: CONTRACTOR may rely upon the
general accuracy of the "technical data" contained in such
reports and drawings, but such reports and drawings are not
Contract Documents. Such "technical data" is identified in
the Supplementary Conditions. Except for such reliance on
such "technical data", CONTRACTOR may not rely upon
or make any claim against OWNER, ENGINEER or any of
ENGINEER's Consultants with respect to:
4.2.2.1. the completeness of such reports and
drawings for CONTRACTOR's purposes,
including, but not limited to, any aspects of the
means, methods, techniques, sequences and
procedures of construction to be employed by
CONTRACTOR and safety precautions and
programs incident thereto, or
4.22.2. other data, interpretations, opinions
and information contained in such reports or shown
or indicated in such drawings, or
4.2.2.3. any CONTRACTOR interpretation of
or conclusion drawn from any "technical data" or
any such data, interpretations, opinions or
information.
4.2.3. Notice of Differing Subsurface or Physical
Conditions: If CONTRACTOR believes that any
subsurface or physical condition at or contiguous to the site
that is uncovered or revealed either:
4.2.3.1. is of such a nature as to establish that
any "technical data" on which CONTRACTOR is
entitled to rely as provided in paragraphs 4.2.1 and
4.2.2 is materially inaccurate, or
4.2.3.2. is of such a nature as to require a
change in the Contract Documents, or
4.2.3.3. differs materially from that shown or
E.IC DC GENERAL CONDITIONS 1910-9 (1990 Edition)
w/CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
indicated in the Contract Documents, or
4.2.3.4. is of an unusual nature, and differs
materially from conditions ordinarily encountered
and generally recognized as inherent in work of
the character provided for in the Contract
Documents; then
CONTRACTOR shall, Rremptly inuriediately after
becoming aware thereof and before further disturbing
conditions affected thereby or performing any Work in
connection therewith (except in an emergency as
permitted by paragraph 6.23), notify OWNER and
ENGINEER in writing about such condition.
CONTRACTOR shall not further disturb such conditions
or perform any Work in connection therewith (except as
aforesaid) until receipt of written order to do so.
4.2.4. ENGINEER's Review: ENGINEER will
promptly review the pertinent conditions, determine the
necessity of OWNER's obtaining additional exploration or
tests with respect thereto and advise OWNER in writing
(with a copy to CONTRACTOR) of ENGINEER's
findings and conclusions.
4.2.5. Possible Contract Documents Change: If
ENGINEER concludes that a change in the Contract
Documents is required as a result of a condition that meets
one or more of the categories in paragraph 4.2.3, a Work
Change Directive or a Change Order will be issued as
provided in Article 10 to reflect and document the
consequences of such change.
4.2.6. Possible Price and Times Adjustments: An
equitable adjustment in the Contract Price or in the
Contract Times, or both, will be allowed to the extent that
the existence of such uncovered or revealed condition
causes an increase or decrease in CONTRACTOR's cost
of, or time required for performance of, the Work; subject,
however, to the following: .
4.2.6.1. such condition must meet any one or
more of the categories described in
paragraphs 4.2.3.1 through 4.2.3.4, inclusive;
4.2.6.2. a change in the Contract Documents
pursuant to paragraph 4.2.5 will not be an
automatic authorization of nor a condition
precedent to entitlement to any such adjustment;
4.2.6.3. with respect to Work that is paid for
on a Unit Price Basis, any adjustment in Contract
Price will be subject to the provisions of
paragraphs 9.10 and 11.9; and
4.2.6.4. CONTRACTOR shall not be entitled
to any adjustment in the Contract Price or Times
if;
4.2.6.4.1. CONTRACTOR knew of
the existence of such conditions at the
time CONTRACTOR made a final
commitment to OWNER in respect of
Contract Price and Contract Times by the
submission of a bid or becoming bound
under a negotiated contract; or
4.2.6.4.2. the existence of such
condition could reasonably have been
discovered or revealed as a result of any
examination, investigation, exploration,
test or study of the site and contiguous
areas required by the Bidding
Requirements or Contract Documents to be
conducted by or for CONTRACTOR prior
to CONTRACTOR's making such final
commitment; or
4.2.6.4.3. CONTRACTOR failed to
give the written notice within the time and
as required by paragraph 4.2.3.
If OWNER and CONTRACTOR are unable to agree on
entitlement to or as to the amount or length of any such
equitable adjustment in the Contract Price or Contract
Times, a claim may be made therefor as provided in
Articles I I and 12. However, OWNER, ENGINEER and
ENGINEER's Consultants shall not be liable to
CONTRACTOR for any claims, costs, losses or damages
sustained by CONTRACTOR on or in connection with any
other project or anticipated project.
4.3. Physical Conditions --Underground Facilities:
4.3.1. Shown or Indicated: The information and data
shown or indicated in the Contract Documents with
respect to existing Underground Facilities at or
contiguous to the site is based on information and data
furnished to OWNER or ENGINEER by the owners of
such Underground Facilities or by others. Unless it is
otherwise expressly provided in the Supplementary
Conditions:
4.3.1.1. OWNER and ENGINEER shall not be
responsible for the accuracy or completeness of any
such information or data; and
4.3.1.2. The cost of all of the following will be
included in the Contract Price and CONTRACTOR
shall have full responsibility for: (i) reviewing and
checking all such information and data, (ii) locating
all Underground Facilities shown or indicated in the
Contract Documents,(iii) coordination of the Work
with the owners of such Underground Facilities
during construction, and (iv) the safety and
protection of all such Underground Facilities as
provided in paragraph 6.20 and repairing any
damage thereto resulting from the Work.
4.3.2. Not Shown or Indicated: If an Underground
Facility is uncovered or revealed at or contiguous to
the site which was not shown or indicated in the
Contract Documents, CONTRACTOR shall, prefflpdy
immediately after becoming aware thereof and before
further disturbing conditions affected thereby or
performing any Work in connection therewith (except
in an emergency as required by paragraph 6.23),
identify the owner of such Underground Facility and
E1CDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
give written notice to that owner and to OWNER and
ENGINEER. ENGINEER will promptly review the
Underground Facility and determine the extent, if
any, to which a change is required in the Contract
Documents to reflect and document the consequences
of the existence of the Underground Facility. If
ENGINEER concludes that a change in the Contract
Documents is required, a Work Change Directive or a
Change Order will be issued as provided in Article 10
to reflect and document such consequences. During
such time, CONTRACTOR shall be responsible for
the safety and protection of such Underground
Facility as provided in paragraph 6.20.
CONTRACTOR shall may be allowed an increase in
the Contract Price or an extension of the Contract
Times, or both, to the extent that they are attributable
to the existence of any Underground Facility that was
not shown or indicated in the Contract Documents
and that CONTRACTOR did not know of and could
not reasonably have been expected to be aware of or
to have anticipated. If OWNER and CONTRACTOR
are unable to agree on entitlement to or the amount or
length of any such adjustment in Contract Price or
Contract Times, CONTRACTOR may make a claim
therefor as provided in Articles I I and 12. However,
OWNER, ENGINEER and ENGINEER's
Consultants shall not be liable to CONTRACTOR for
any claims, costs, losses or damages incurred or
sustained by CONTRACTOR on or in connection
with any other project or anticipated project.
Reference Points:
4.4. OWNER shall provide engineering surveys to
establish reference points for construction which in
ENGINEER's judgment are necessary to enable
CONTRACTOR to proceed with the Work.
CONTRACTOR shall be responsible for laying out the
Work, shall protect and preserve the established reference
points and shall make no changes or relocations without
the prior written approval of OWNER. CONTRACTOR
shall report to ENGINEER whenever any reference point
is lost or destroyed or requires relocation because of
necessary changes in grades or locations, and shall be
responsible for the accurate replacement or relocation of
such reference points by professionally qualified
personnel.
4.5. Asbestos, PCBs, Petroleum, Hazardous Waste or
Radioactive Material:
4.5.1. OWNER shall be responsible for any
Asbestos, PCBs, Petroleum, Hazardous Waste or
Radioactive Material uncovered or revealed at the site
which was not shown or indicated in Drawings or
Specifications or identified in the Contract
Documents to be within the scope of the Work and
which may present a substantial danger to persons or
property exposed thereto in connection with the Work
at the site. OWNER shall not be responsible for any
such materials brought to the site by
CONTRACTOR, Subcontractors, Suppliers or
anyone else for whom CONTRACTOR is
responsible.
.. .. ..
., r '.MY-
VAINIM
1.0
■ ...
E.ICDC G EN ERAL CON DIT[ON S 1910-8 (1990 Edition)
w/ CITY 0F FORT COLLINS MODIFICATIONS (REV 4/2000)
ARTICLE 5--BONDS AND INSURANCE
Performance, Payment and Other Bonds:
5.1. CONTRACTOR shall furnish Performance and
Payment Bonds, each in an amount at least equal to the
Contract Rice as security for the faithful performance and
payment of all CONTRACTOR's obligations under the
Contract Documents. These Bonds shall remain in effect
at least until one year after the date when final payment
becomes due, except as provided otherwise by Laws or
Regulations or by the Contract Documents.
CONTRACTOR shall also fumish such other Bonds as
are required by the Supplementary Conditions. All Bonds
shall be in the form prescribed by the Contract Documents
except as provided otherwise by Laws or Regulations and
shall be executed by such sureties as are named in the
current list of "Companies Holding Certificates of
Authority as Acceptable Sureties on Federal Bonds and as
Acceptable Reinsuring Companies" as published in
Circular 570 (amended) by the Audit Staff, Bureau of
Government Financial Operations, U.S. Treasury
Department. All Bonds signed by an agent must be
accompanied by a certified copy of such agent's authority
to act.
5.2. If the surety on any Bond furnished by
CONTRACTOR is declared a bankrupt or becomes
insolvent or its right to do business is terminated in any
state where any part of the Project is located or it ceases to
meet the requirements of paragraph 5.1, CONTRACTOR
shall within ten days thereafter substitute another Bond
and surety, both of which must be acceptable to OWNER.
5.3. Licensed Sureties and Insurers; Certificates of
Insurance:
5.3.1. All Bonds and insurance required by the
Contract Documents to be purchased and maintained
by OWNER or CONTRACTOR shall be obtained
from surety or insurance companies that are duly
licensed or authorized in the jurisdiction in which the
Project is located to issue Bonds or insurance policies
for the limits and coverages so required. Such surety
and insurance companies shall also meet such
additional requirements and qualifications as may be
provided in the Supplementary Conditions.
5.3.2. CONTRACTOR shall deliver to OWNER,
with copies to each additional insured identified in the
Supplementary Conditions, certificates of insurance
(and other evidence of insurance requested by
OWNER or any other additional insured) which
CONTRACTOR is required to purchase and maintain
in accordance with paragraph 5.4. OlAqMR gall
� �. .•.. _
::: ..
CONTRACTOR's Liability Insurance:
5.4. CONTRACTOR shall purchase and maintain such
liability and other insurance as is appropriate for the Work
being performed and tumished and as will provide
protection from claims set forth below which may arise out
of or result fi-om CONTRACTOR's performance and
furnishing of the Work and CONTRACTOR's other
obligations under the Contract Documents, whether it is to
be performed or furnished by CONTRACTOR, any
Subcontractor or Supplier, or by anyone directly or -
indirectly employed by any of them to perform or furnish
any of the Work, or by anyone for whose acts any of them
may be liable:
5.4.1. claims under workers' compensation, disability
benefits and other similar employee benefit acts;
5.4.2. claims for damages because of bodily injury,
occupational sickness or disease, or death of
CONTRACTOR's employees;
5.4.3. claims for damages because of bodily injury,
sickness or disease, or death of any person other than
CONTRACTOR's employees;
5.4.5. claims for damages, other than to the Work
itself, because of injury to or destruction of tangible
property wherever located, including loss of use
resulting therefrom; and
5.4.6. claims for damages because of bodily injury or
death of any person or property damage arising out of
the ownership, maintenance or use of any motor
vehicle.
The policies of insurance so required by this paragraph 5.4
to be purchased and maintained shall:
5.4.7. with respect to insurance required by
paragraphs 5.4.3 through 5.4.6 inclusive and 5.4.9,
include as additional insureds (subject to any
customary exclusion in respect of professional
liability), OWNER, ENGINEER, ENGINEER's
Consultants and any other persons or entities identified
in the Supplementary Conditions, all of whom shall .be
listed as additional insureds, and include coverage for
the respective officers and employees of all such
additional insureds;
5.4.8. include the specific coverages and be written
for not less than the limits of liability provided in the
Supplementary Conditions or required by Laws or
Regulations, whichever is greater;
5.4.9. include completed operations insurance;
EICDCGENERAL CONDITIONS 1910-9 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
5.4.10. include contractual liability insurance
covering CONTRACTOR's indemnity obligations
under paragraphs 6.12, 6.16 and 6.31 through 6.33;
5.4.11. contain a provision or endorsement that the
coverage afforded will not be cancelled, materially
changed or renewal refused until at least thirty days'
prior written notice has been given to OWNER and
CONTRACTOR and to each other additional insured
identified in the Supplementary Conditions to whom
a certificate of insurance has been issued (and the
certificates of insurance ftumished by the
CONTRACTOR pursuant to paragraph 5.3.2 will so
provide);
5.4.12. remain in effect at least until final payment
and at all times thereafter when CONTRACTOR may
be correcting, removing or replacing defective Work
in accordance with paragraph 13.12; and
5.4.13. with respect to completed operations
insurance, and any insurance coverage written on a
claims -made basis, remain in effect for at least two
years after final payment (and CONTRACTOR shall
furnish OWNER and each other additional insured
identified in the Supplementary Conditions to whom
a certificate of insurance has been issued evidence
satisfactory to OWNER and any such additional
insured of continuation of such insurance at final
payment and one year thereafter).
OWNER's Liability Insurance:
5.5. In addition to insurance required to be provided
by CONTRACTOR under paragraph 5.4, OWNER, at
OWNER's option, may purchase and maintain at
OWNER's expense OWNER's own liability insurance as
will protect OWNER against claims which may arise fi-om
operations under the Contract Documents.
Property Insurance:
.. .,._ _ .
W-2.4
I
1 ited fe fees and e f
s
ffizc- eets '
5.9. OWNER shall not be responsible for purchasing
and maintaining any property insurance to protect the
interests of CONTRACTOR, Subcontractors or others Fn
the Werk to the .,tent of atiy , a bl
identified in the Supplementary Genditiens. TheFiskOf
less within sueh identified deduetible ameunt, will be beme
by CONTRACTOR, Subeefittzaetei, eF etheus suffering any
sueh less and if any of theffi wishes pl'epeFty insaFanee
oeverage the linlit,; v
pui-ehase and own expens
E.ICDC GENERAL CONDITIONS 1910-8 (1990 Edition)
10 W/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
LUM
Mow
.1
WN -_ . .. •_.
_
. ■.
_•.
Will
•",..'_.
NOW PINWORM—'
Receipt and Application oflnsurance Proceeds:
5.12. Any insured loss under the policies of insurance
required by paragraphs 5.6 and 5.7 will be adjusted with
OWNER and made payable to OWNER as fiduciary for the
insureds, as their interests may appear, subject to the
requirements of any applicable mortgage clause and of
paragraph 5.13. OWNER shall deposit in a separate
account any money so received, and shall distribute it in
accordance with such agreement as the parties in interest
may reach. If no other special agreement is reached the
damaged Work shall be repaired or replaced, the moneys so
received applied on account thereof and the Work and the
cost thereof covered by an appropriate Change Order or
Written Amendment.
5.13. OWNER as fiduciary shall have power to adjust
and settle any loss with the insurers unless one of the
parties in interest shall object in writing within fifteen days
after the occurrence of loss to OWNER's exercise of this
power. If such objection be made, OWNER as fiduciary
shall make settlement with the insurers in accordance with
such agreement as the parties in interest may reach. If no
such agreement among the parties in interest is reached,
OWNER as fiduciary shall adjust and settle the loss with
the insurers and, :f FeEluired in titing b any pa
:~te'est 03ANER as fidl to shall give bend f . the
Acceptance of Bonds and Insurance, Option to Replace:
5.14. If either pai4y (0V.qPn Rr Cnrrru ACTOR)
OWNER has any objection to the coverage afforded by or
other provisions of the Bends er insurance required to be
purchased and maintained by the ether party
CONTRACTOR in accordance with Article 5 on the basis
of non-conformance with the Contract Documents, the
OWNER will
notify CONTRACTOR in writing within ten fifteen days
after reeeip delivery of the certificates (e•- ether e,videnee
requested) to OWNER as required by paragraph 2.7.
03AW :D and CONTRACTOR shell eaeh p , :dJe tdl the
ethei- s t•,`,r,••'additidnal infermatieR : respeet of
pi-evided as the ether mayieasenably iequest. if cmcT
Daeunients, eh e.-t, shall nat:6, the ..tr,e,. pai=ty in
xx le.L e Of e el. C 'I e ....,., :....., «e any e0.ange :..
the required eeverage. With t _.., Udiee ,.the.Fight
Bends e e to p eet a el, ether ..,e..t, 's [_
tffasts at
,.et ' Cent..n..:ee., e.,,ingi.
Partial Utilization —Property Insurance:
5.15. If OWNER finds it necessary to occupy or use a
portion or portions of the Work prior to Substantial
E.ICDC GENERAL CONDITIONS 1910-8 (1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
Completion of all the Work, such use or occupancy may
be accomplished in accordance with paragraph 14.10;
provided that no such use or occupancy shall commence
before the insurers providing the property insurance have
acknowledged notice thereof and in writing effected any
changes in coverage necessitated thereby. The insurers
providing the property insurance shall consent by
endorsement on the policy or policies, but the property
insurance shall not be cancelled or permitted to lapse on
account of any such partial use or occupancy.
ARTICLE 6--CONTRACTOR'S
RESPONSIBILITIES
Supervision and Superintendence:
6.1. CONTRACTOR shall supervise, inspect and
direct the Work competently and efficiently, devoting
such attention thereto and applying such skills and
expertise as may be necessary to perform the Work in
accordance with the Contract Documents.
CONTRACTOR shall be solely responsible for the means,
methods, techniques, sequences and procedures of
construction, but CONTRACTOR shall not be responsible
for the negligence of others in the design or specification
of a specific means, method, technique, sequence or
procedure of construction which is shown or indicated in
and expressly required by the Contract Documents.
CONTRACTOR shall be responsible to see that the
completed Work complies accurately with the Contract
Documents.
6.2. CONTRACTOR shall keep on the Work at all
times during its progress a competent resident
superintendent, who shall not be replaced without written
notice to OWNER and ENGINEER except under
extraordinary circumstances. The superintendent will be
CONTRACTOR's representative at the site and shall have
authority to act on behalf of CONTRACTOR. All
communications to the superintendent shall be as binding
as if given to CONTRACTOR.
Labor, Materials and Equipment:
6.3. CONTRACTOR shall provide competent,
suitably qualified personnel to survey, lay out and
construct the Work as required by the Contract
Documents. CONTRACTOR shall at all times maintain
good discipline and order at the site. Except as otherwise
required for the safety or protection of persons or the
Work or property at the site or adjacent thereto, and
except as otherwise indicated in the Contract Documents,
all Work at the site shall be performed during regular
working hours and CONTRACTOR will not permit
overtime work or the performance of Work on Saturday,
Sunday or any legal holiday without OWNER's written
consent given after prior written notice to ENGINEER.
CONTRACTOR shall submit requests to the ENGINEER
no less than 48 hours in advance of any Work to be
performed on Saturday, Sunday. Holidays or outside the
Regular Working Hours
11
6.4. Unless otherwise specified in the General
Requirements, CONTRACTOR shall fumish and assume
full responsibility for all materials, equipment, labor,
transportation, construction equipment and machinery,
tools, appliances, fuel, power, light, heat, telephone, water,
sanitary facilities, temporary facilities and all other
facilities and incidentals necessary for the fumishing,
performance, testing, start-up and completion of the Work.
6.4.1. Purchasing Restrictions: CONTRACTOR
must comply with the Citv's purchasing restrictions A
copy of the resolutions are available for review in the
offices of the Purchasing and Risk Management
Division or the City Clerk's office
6.4.2. Cement Restrictions: City of Fort Collins
Resolution 91-121 requires that suppliers and producers
of cement or products containing cement to certify that
the cement was not made in cement kilns that bum
hazardous waste as a fuel.
6.5. All materials and equipment shall be of good
quality and new, except as otherwise provided in the
Contract Documents. All warranties and guarantees
specifically called for by the Specifications shall expressly
run to the benefit of OWNER. If required by ENGINEER,
CONTRACTOR shall furnish satisfactory evidence
(including reports of required tests) as to the kind and
quality of materials and equipment. All materials and
equipment shall be applied, installed, connected, erected,
used, cleaned and conditioned in accordance with
instructions of the applicable Supplier, except as otherwise
provided in the Contract Documents.
Progress Schedule:
6.6. CONTRACTOR shall adhere to the progress
schedule established in accordance with paragraph 2.9 as it
may be adjusted from time to time as provided below:
6.6.1. CONTRACTOR shall submit to ENGINEER
for acceptance (to the extent indicated in
paragraph 2.9) proposed adjustments in the progress
schedule that will not change the Contract Times (or
Milestones). Such adjustments will conform generally
to the progress schedule then in effect and additionally
will comply with any provisions of the General
Requirements applicable thereto.
6.6.2. Proposed adjustments in the progress schedule
that will change the Contract Times (or Milestones)
shall be submitted in accordance with the requirements
of paragraph 12.1. Such adjustments may only be
made by a Change Order or Written Amendment in
accordance with Article 12.
6.7. Substitutes and "Or-Equal"Items:
6.7.1. Whenever an item of material or equipment is
specified or described in the Contract Documents by
using the name of a proprietary item or the name of a
particular Supplier, the specification or description is
intended to establish the type, function and quality
required. Unless the specification or description
12 EJCDCGENERAL CONDITIONS 1910-8(1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
contains or is followed by words reading that no like,
equivalent or "or -equal" item or no substitution is
permitted, other items of material or equipment or
material or equipment of other Suppliers may be
accepted by ENGINEER under the following
circumstances:
6.7.1.1. "Or -Equal": If in ENGINEER's sole
discretion an item of material or equipment
proposed by CONTRACTOR is functionally
equal to that named and sufficiently similar so that
no change in related Work will be required, it may
be considered by ENGINEER as an "or -equal"
item, in which case review and approval of the
proposed item may, in ENGINEER's sole
discretion, be accomplished without compliance
with some or all of the requirements for
acceptance of proposed substitute items.
6.7.1.2. Substitute Items: If in ENGINEER's sole
discretion an item of material or equipment
proposed by CONTRACTOR does not qualify as
an "or -equal" item under subparagraph 6.7.1.1, it
will be considered a proposed substitute item.
CONTRACTOR shall submit sufficient
information as provided below to allow
ENGINEER to determine that the item of material
or equipment proposed is essentially equivalent to
that named and an acceptable substitute therefor.
The procedure for review by the ENGINEER will --
include the following as supplemented in the
General Requirements and as ENGINEER may
decide is appropriate under the circumstances.
Requests for review of proposed substitute items
of material or equipment will not be accepted by
ENGINEER fi-om anyone other than
CONTRACTOR. If CONTRACTOR wishes to
furnish or use a substitute item of material or .�
equipment, CONTRACTOR shall first make
written application to ENGINEER for acceptance
thereof, certifying that the proposed substitute will
perform adequately the functions and achieve the
results called for by the general design, be similar
in substance to that specified and be suited to the
same. use as that specified. The application will
state the extent, if any, to which the evaluation
and acceptance of the proposed substitute will
prejudice CONTRACTOR's achievement of
Substantial Completion on time, whether or not
acceptance of the substitute for use in the Work _
will require a change in any of the Contract
Documents (or in the provisions of any other
direct contract with OWNER for work on the
Project) to adapt the design to the proposed _
substitute and whether or not incorporation or use
of the substitute in connection with the Work is
subject to payment of any license fee or royalty.
All variations of the proposed substitute fi-om that
specified will be identified in the application and
available maintenance, repair and replacement
service will be indicated. The application will
also contain an itemized estimate of all costs or
credits that will result directly or indirectly from
acceptance of such substitute, including costs of
redesign and claims of other contractors affected
by the resulting change, all of which will be
considered by ENGINEER in evaluating the
proposed substitute. ENGINEER may require
CONTRACTOR to furnish additional data about
the proposed substitute.
6.7.1.3. COATRACTOR's Expense: All data to be
provided by CONTRACTOR in support of any
proposed "or -equal" or substitute item will be at
CONTRACTOR's expense.
6.7.2. Substitute Construction Methods or
Procedures: If a specific means, method, technique,
sequence or procedure of construction is shown or
indicated in and expressly required by the Contract
Documents, CONTRACTOR may furnish or utilize a
substitute means, method, technique, sequence or
procedure of construction acceptable to ENGINEER.
CONTRACTOR shall submit sufficient information to
allow ENGINEER, in ENGINEER's sole discretion, to
determine that the substitute proposed is equivalent to
that expressly called for by the Contract Documents.
The procedure for review by ENGINEER will be
similar to that provided in subparagraph 6.7.1.2.
6.7.3.Engineer's Evaluation: ENGINEER will be
allowed a reasonable time within which to evaluate
each proposal or submittal made pursuant to
paragraphs 6.7.1.2 and 6.7.2. ENGINEER will be the
sole judge of acceptability. No "or -equal" or
substitute will be ordered, installed or utilized without
ENGINEER's prior written acceptance which will be
evidenced by either a Change Order or an approved
Shop Drawing. OWNER may require
CONTRACTOR to furnish at CONTRACTORSs
expense a special performance guarantee or other
surety with respect to any "or -equal" or substitute.
ENGINEER will record time required by
ENGINEER and ENGINEER's Consultants in
evaluating substitutes proposed or submitted by
CONTRACTOR pursuant to paragraphs 6.7.1.2 and
6.7.2 and in making changes in the Contract
Documents (or in the provisions of any other direct
contract with OWNER for work on the Project)
occasioned thereby. Whether or not ENGINEER
accepts a substitute item so proposed or submitted by
CONTRACTOR, CONTRACTOR shall reimburse
OWNER for the charges of ENGINEER and
ENGINEER's Consultants for evaluating each such
proposed substitute item.
6_8. Concerning Subcontractors, Suppliers and
Others:
6.8.1. CONTRACTOR shall not employ any
Subcontractor, Supplier or other person or organization
(including those acceptable to OWNER and
ENGINEER as indicated in paragraph 6.8.2), whether
initially or as a substitute, against whom OWNER or
ENGINEER may have reasonable objection.
CONTRACTOR shall not be required to employ any
Subcontractor, Supplier or other person or organization
to furnish or perform any of the Work against whom
CONTRACTOR has reasonable objection.
EICDC GENERALCONDITIONS 1910-8 (1990 Edition)
w/CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
69.
CONTRACTOR shall perform not less than 20
percent of the Work with its own forces (that is,
without subcontracting). The 20 percent requirement
shall be understood to refer to the Work the value of
which totals not less than 20 percent of the Contract
Price.
6.8.2. if the SupplemeftiaFy Genditien Biddin
Documents require the identity of certain
Subcontractors, Suppliers or other persons or
organizations (including those who are to furnish the
principal items of materials or equipment) to be
submitted to OWNER is aa,.anee of the spea:aea
date prior to the Effective Date of the Agreement for
acceptance by OWNER and ENGINEER, —an"
CONTRACTOR A CTO h I. ,J list the..eef
aeeei-danee with the e pple aenta.. Gend:rens
OWNER's or ENGINEER's acceptance (either in
writing or by failing to make written objection thereto
by the date indicated for acceptance or objection in
the bidding documents or the Contract Documents) e€
F.va .« 6e ,.I, e.J the
o;g« e OR
basis of y in hiehease CONTRACTOR shall submit ini
aeeeptable substitute, the G,..,t..aat u„ee ,..:n he
adjusted by the difT pence in the eest e ned 6,
ah substitution and a .:ate Change 0Fde..
..ill be 4ssued er V.4tten Afnend-me t sigfied. will
constitute a condition of the Contract requiring the
use of the named subcontractors, suppliers or other
persons or organization on the Work unless prior
written approval is obtained fi-om OWNER and
ENGINEER. No acceptance by OWNER or
ENGINEER of any such Subcontractor, Supplier or
other person or organization shall constitute a waiver
of any right of OWNER or ENGINEER to reject
defective Work.
6.9.1. CONTRACTOR shall be fully responsible to
OWNER and ENGINEER for all acts and omissions
of the Subcontractors, Suppliers and other persons
and organizations performing or furnishing any of the
Work under a direct or indirect contract with
CONTRACTOR just as CONTRACTOR is
responsible for CONTRACTOR's own acts and
omissions. Nothing in the Contract Documents shall
create for the benefit of any such Subcontractor,
Supplier or other person or organization any
contractual relationship between OWNER or
ENGINEER and any such Subcontractor, Supplier or
other person or organization, nor shall it create any
obligation on the part of OWNER or ENGINEER to
pay or to see to the payment of any moneys due any
such Subcontractor, Supplier or other person or
organization except as may otherwise be required by
Laws and Regulations. OWNER or ENGINEER may
furnish to any subcontractor, supplier or other person
or organization evidence of amounts paid to
CONTRACTOR in accordance with
CONTRACTOR'S "Applications for Payment".
13
6.9.2. CONTRACTOR shall be solely responsible
for scheduling and coordinating the Work of
Subcontractors, Suppliers and other persons and
organizations performing or furnishing any of the
Work under a direct or indirect contract with
CONTRACTOR. CONTRACTOR shall require all
Subcontractors, Suppliers and such other persons and
organizations performing or furnishing any of the
Work to communicate with the ENGINEER through
CONTRACTOR.
6.10. The divisions and sections of the Specifications and
the identifications of any Drawings shall not control
CONTRACTOR in dividing the Work among
Subcontractors or Suppliers or delineating the Work to be
performed by any specific trade.
6.11. All Work performed for CONTRACTOR by a
Subcontractor or Supplier will be pursuant to an
appropriate agreement between CONTRACTOR and the
Subcontractor or Supplier which specifically binds the
Subcontractor or Supplier to the applicable terms and
conditions of the Contract Documents for the benefit of
OWNER and ENGINEER. ., hefte,v,e- aw., ,i eh ,..._...._..Rt
------------------------
Patent Fees and Royalties:
6.12. CONTRACTOR shall pay all license fees and
royalties and assume all cost'§ incident to the use in the
performance of the Work or the incorporation in the Work
of any invention, design, process, product or device which
is the subject of patent rights or copyrights held by others.
If a particular invention, design, process, product or device
is specified in the Contract Documents for use in the
performance of the Work and if to the actual knowledge of
OWNER or ENGINEER its use is subject to patent rights
or copyrights calling for the payment of any license fee or
royalty to others, the existence of such rights shall be
disclosed by OWNER in the Contract Documents. To the
fullest extent permitted by Laws and Regulations,
CONTRACTOR shall indemnify and hold harmless
OWNER, ENGINEER, ENGINEER's Consultants and the
officers, directors, employees, agents and other consultants
of each and any of them from and against all claims, costs,
losses and damages arising out of or resulting from any
infringement of patent rights or copyrights incident to the
use in the performance of the Work or resulting from the
incorporation in the Work of any invention, design,
process, product or device not specified in the Contract
Documents.
14 EJCDC GENERAL CONDITIONS 1910-8(1990 Edition)
w/ CITY OF FORT COLLINS MODIFICATIONS (REV 4/2000)
Permits:
6.13. Unless otherwise provided in the Supplementary
Conditions, CONTRACTOR shall obtain and pay for all
construction permits and licenses. OWNER shall assist
CONTRACTOR, when necessary, in obtaining such
permits and licenses. CONTRACTOR shall pay all
governmental charges and inspection fees necessary for
the prosecution of the Work, which are applicable at the
time of opening of Bids, or, if there are no Bids, on the
Effective Date of the Agreement. CONTRACTOR shall
pay all charges of utility owners for connections to the
Work, and OWNER shall pay all charges of such utility
owners for capital costs related thereto such as plant
investment fees.
6.14. Laws and Regulations:
6.14.1. CONTRACTOR shall give all notices and
comply with all Laws and Regulations applicable to
furnishing and performance of the Work. Except
where otherwise expressly required by applicable
Laws and Regulations, neither- OWNER nor
ENGINEER shall be responsible for monitoring
CONTRACTOR's compliance with any Laws or
Regulations.
6.14.2. If CONTRACTOR performs any Work
knowing or having reason to know that it is contrary
to Laws or Regulations, CONTRACTOR shall bear
all claims, costs, losses and damages caused by,
arising out of or resulting therefrom; however, it shall
not be CONTRACTOR's primary responsibility to
make certain that the Specifications and Drawings are
in accordance with Laws and Regulations, but this
shall not relieve CONTRACTOR of
CONTRACTOR's obligations under paragraph 3.3.2.
Taxes:
6.15. CONTRACTOR shall pay all sales, consumer,
use and other similar taxes required to be paid by
CONTRACTOR in accordance with the Laws and
Regulations of the place of the Project which are
applicable during the performance of the Work.
6.15.1. OWNER is exempt from Colorado State and
local sales and use taxes on materials to be
permanently incorporated into the project. Said taxes
shall not be included in the Contract Price,
Address:
Colorado Department of Revenue
State Capital Annex