Loading...
HomeMy WebLinkAbout278055 COMPUTER CONSULTING SERVICES OF AMERICA - CONTRACT - RFP - 3304901 P857 VANGO DATABASE SERVICESPROFESSIONAL SERVICES AGREEMENT THIS AGREEMENT made and entered into the day and year set forth below, by and between THE NORTH FRONT RANGE TRANSPORTATION AND AIR QUALITY PLANNING COUNCIL (MPO) hereinafter referred to as the "MPO" and COMPUTER CONSULTING SERVICES OF AMERICA INC., a corporation, hereinafter referred to as "Professional". WITNESSETH: In consideration of the mutual covenants and obligations herein expressed, it is agreed by and between the parties hereto as follows: 1. The Work Schedule. The services to be performed pursuant to this Agreement shall be performed in accordance with the Work Schedule stated on each Work Order. 2. Time of Commencement and Completion of Services. The services to be performed pursuant to this Agreement shall be initiated as specified on each Work Order. Time is of the essence. Any extensions of any time limit must be agreed upon in writing by the parties hereto. 3. Contract Period. This Agreement shall commence October 20, 2002, and shall continue in full force and effect until December 31, 2003, unless sooner terminated as herein provided. In addition, at the option of the MPO, the Agreement may be extended for additional one year periods not to exceed four (4) additional one year periods. Pricing changes shall be negotiated by and agreed to by both parties and may not exceed the Denver - Boulder CPI-U as published by the Colorado State Planning and Budget Office. Written notice of renewal shall be provided to the Service Provider and mailed no later than ninety (90) days prior to contract end. 4. Early Termination by MPO. Notwithstanding the time periods contained herein, the MPO may terminate this Agreement at any time without cause by providing written notice of termination to the Professional. Such notice shall be delivered at least fifteen (15) days prior to the termination date contained in said notice unless otherwise agreed in writing by the parties. All notices provided under this Agreement shall be effective when mailed, postage prepaid and sent should the proposed covered transaction be entered into, it shall not knowingly enter into any lower tier covered transaction with a person who is debarred, suspended, declared ineligible, or voluntarily excluded from participation in this covered transaction, unless authorized in writing by the City of Fort Collins. 6. The prospective lower tier participant further agrees by submitting this proposal that it will include the clause titled "Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion - Lower Tier Covered Transaction", without modification, in all lower tier covered transactions and in all solicitations for lower tier covered transactions. 7. A participant in a covered transaction may rely upon a certification of a prospective participant in a lower tier covered transaction that it is not debarred, suspended, ineligible, or voluntarily excluded from the covered transaction, unless it knows that the certification is erroneous, A participant may decide the method and frequency by which it determines the eligibility of its principals. Each participant may, but is not required to, check the Nonprocurement List issued by U.S. General Service Administration. 8. Nothing contained in the foregoing shall be construed to require establishment of system of records in order to render in good faith the certification required by this clause. The knowledge and information of a participant is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings. 9. Except for transactions authorized under Paragraph 5 of these instructions, if a participant in a covered transaction knowingly enters into a lower tier covered transaction with a person who is suspended, debarred, ineligible, or voluntarily excluded from participation in this transaction, in addition to all remedies available to the Federal Government, the City of Fort Collins may pursue available remedies including suspension and/or debarment. "Certification Regarding Debarment, Suspension Ineligibility and Voluntary Exclusion - Lower Tier Covered Transaction" (1) The prospective lower tier participant certifies, by submission of this bid or proposal, that neither it nor its "principals" [as defined at 49 C.F.R. 29.105(p)] is presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in this transaction by any Federal department or agency. (2) When the prospective lower tier participant is unable to certify to the statements in this certification, such prospective participant shall attach an explanation to this proposal. PRIVACY ACT 5 U.S.C. 552 When a grantee maintains files on drug and alcohol enforcement activities for FTA, and those files are organized so that information could be retrieved by personal identifier, the Privacy Act requirements apply to all contracts. The Federal Privacy Act requirements flow down to each third party contractor and their contracts at every tier. (1) The Contractor agrees to comply with, and assures the compliance of its employees with, the information restrictions and other applicable requirements of the Privacy Act of 1974, 5 U.S.C. 552a. Among other things, the Contractor agrees to obtain the express consent of the Federal Government before the Contractor or its employees operate a system of records on behalf of the Federal Government. The Contractor understands that the requirements of the 13 persons with disabilities. In addition, the Contractor agrees to comply with any implementing requirements FTA may issue. (3) The Contractor also agrees to include these requirements in each subcontract financed in whole or in part with Federal assistance provided by FTA, modified only if necessary to identify the affected parties. PATENT AND RIGHTS IN DATA 37 CFR Part 401 49 CFR Parts 18 and 19 The FTA patent clause is substantially similar to the text of 49 C.F.R. Part 19, Appendix A, Section 5, but the rights in data clause reflects FTA objectives. For patent rights, FT/k is governed by Federal law and regulation. For data rights, the text on copyrights is insufficient to meet FTA's purposes for awarding research grants. This model clause, with larger rights ,as a standard, is proposed with the understanding that this standard could be modified to FTA's needs. CONTRACTS INVOLVING EXPERIMENTAL, DEVELOPMENTAL, OR RESEARCH WORK. A. Rights in Data - This following requirements apply to each contract involving experimental, developmental or research work: (1) The term "subject data" used in this clause means recorded information, whether or not copyrighted, that is delivered or specified to be delivered under the contract. The term includes graphic or pictorial delineation in media such as drawings or photographs; text in specifications or related performance or design -type documents; machine forms such as punched cards, magnetic tape, or computer memory printouts; and information retained in computer memory. Examples include, but are not limited to: computer software, engineering drawings and associated lists, specifications, standards, process sheets, manuals, technical reports, catalog item identifications, and related information. The term "subject data" does not include financial reports, cost analyses, and similar information incidental to contract administration. (2) The following restrictions apply to all subject data first produced in the performance of the contract to which this Attachment has been added: (a) Except for its own internal use, the Purchaser or Contractor may not publish or reproduce subject data in whole or in part, or in any manner or form, nor may the Purchaser or Contractor authorize others to do so, without the written consent of the Federal Government, until such time as the Federal Government may have either released or approved the release of such data to the public; this restriction on publication, however, does not apply to any contract with an academic institution. (b) In accordance with 49 C.F.R. 18.34 and 49 C.F.R. 19.36, the Federal Government reserves a royalty -free, non-exclusive and irrevocable license to reproduce, publish, or otherwise use, and to authorize others to use, for "Federal Government purposes," any subject data or copyright described in subsections (2)(b)I and (2)(b)2 of this clause below. As used in the previous sentence, "for Federal Government purposes," means use only for the direct purposes of the Federal Government. Without the copyright owner's consent, the Federal Government may not extend its Federal license to any other party. 1. Any subject data developed under that contract, whether or not a copyright has been obtained; and 2. Any rights of copyright purchased by the Purchaser or Contractor using Federal assistance 15 with federal funds under this Agreement. Consequently, the DBE requirements of 49 CFR Part 23 and Section 106(c) of the STURAA of 1987, apply to this Contract. The Contractor agrees to ensure that DBEs as defined in 49 CFR Part 23 and Section 106(c) of the STURAA of 1987, have the maximum opportunity to participate in the whole or in part with federal funds provided under this Agreement. In this regard, the Contractor shall take all necessary and reasonable steps in accordance with the regulations to ensure that DBEs have the maximum opportunity to compete for and perform subcontracts. The Contractor shall not discriminate on the basis of race, color, national origin, religion, sex, age or physical handicap in the award and performance of subcontracts. It is further the policy of the City of Fort Collins to promote the development and increase the participation of businesses owned and controlled by disadvantaged. DBE involvement in all phases of the City of Fort Collins procurement activities is encouraged. (b) DBE obligation - The Contractor and its subcontractors agree to ensure that disadvantaged businesses have the maximum opportunity to participate in the performance of contracts and subcontracts financed in whole or in part with federal funds provided under the Agreement. In that regard, all Contractors and subcontractors shall take all necessary and reasonable steps in accordance with 49 CFR Part 23 as amended, to ensure that minority business enterprises have the maximum opportunity to compete for and perform contracts. (c) Where the Contractor is found to have failed to exert sufficient reasonable and good faith efforts to involve DBE's in the work provided, the City of Fort Collins may declare the contractor noncompliant and in breach of contract. (d) The Contractor will keep records and documents for a reasonable time following performance of this contract to indicate compliance with the City of Fort Collins DBE program. These records and documents will be made available at reasonable times and places for inspection by any authorized representative of the City of Fort Collins and will be submitted to the City of Fort Collins upon request. (e) The City of Fort Collins will provide affirmative assistance as may be reasonable and necessary to assist the prime contractor in implementing their programs for DBE participation. The assistance may include the following upon request: 19 No member of or delegate to the Congress of the United States shall be admitted to any share or part of this Agreement or to any benefit arising therefrom. PROHIBITED INTEREST No employee, officer, or agent of the grantee shall participate in selection, or in the award or administration of a contract if a conflict of interest, real or apparent, would be involved. Such conflict would arise when: The employee, officer or agent; any member of his immediate family; his or her partner; or an organization which employs, or is about to employ, has a financial or other interest in the firm selected for award. The grantee's officers, employees, or agents shall neither solicit nor accept gratuities, favors or anything of monetary value from contractors, potential contractors, or parties of subagreements. INCORPORATION OF FEDERAL TRANSIT ADMINISTRATION (FTA) TERMS FTA Circular 4220.I1D Incorporation of Federal Transit Administration (FTA) Terms - The preceding provisions include, in part, certain Standard Terms and Conditions required by DOT, whether or not expressly set forth in the preceding contract provisions. All contractual provisions required by DOT, as set forth in FTA Circular 4220.1 D, dated April 15, 1996, are hereby incorporated by reference. Anything to the contrary herein notwithstanding, all FTA mandated terms shall be deemed to control in the event of a conflictwith other provisions contained in this Agreement. The Contractor shall not perform any act, fail to perform any act, or refuse to comply with any the City of Fort Collins requests which would cause the City of Fort Collins to be in violation of the FTA terms and conditions. 21 negotiated by the parties hereto for each such Work Order. Monthly partial payments based upon the Professional's billings and itemized statements are permissible. The amounts of all such partial payments shall be based upon the Professional's MPO-verified progress in completing the services to be performed pursuant to the Work Order and upon approval of the Professional's direct reimbursable expenses. Final payment shall be made following acceptance of the work by the MPO. Upon final payment, all designs, plans, reports, specifications, drawings, and other services rendered by the Professional shall become the sole property of the MPO. 7. MPO Representative. The MPO will designate, prior to commencement of work, its project representative who shall make, within the scope of his or her authority, all necessary and proper decisions with reference to the project. All requests for contract interpretations, change orders, and other clarification or instruction shall be directed to the MPO Representative. 8. Project Drawings. Upon conclusion of the project and before final payment, the Professional shall provide the MPO with reproducible drawings of the project containing accurate information on the project as constructed. Drawings shall be of archival quality, prepared on stable mylar base material using a non -fading process to prove for long storage and high quality reproduction. 9. Monthly Report. Commencing thirty (30) days after the date of execution of this Agreement and every thirty (30) days thereafter, Professional is required to provide the MPO Representative with a written report of the status of the work with respect to the Scope of Services, Work Schedule, and other material information. Failure to provide any required monthly report may, at the option of the MPO, suspend the processing of any partial payment request. 10. Independent Contractor. The services to be performed by Professional are those of an independent contractor and not of an employee of the MPO of Fort Collins. The MPO shall not be responsible for withholding any portion of Professional's compensation hereunder for the payment of FICA, Workers' Compensation, other taxes or benefits or for any other purpose. interpretation, execution and enforcement of this Agreement. In the event any provision of this Agreement shall be held invalid or unenforceable by any court of competent jurisdiction, such holding shall not invalidate or render unenforceable any other provision of this Agreement. 17. Special Provisions. Special provisions or conditions relating to the services to be performed pursuant to this Agreement are set forth in Exhibit "B", consisting of Nineteen (19) pages, attached hereto and incorporated herein by this reference. CITY OF FORT COW NS, COLORADO� By: J es B. 'Neill II, CPPO Dire o f Purchasing & Risk Management DATE: —to / Z� THE NORTH FRONT RANGE TRANSPORTATION AND AIR QUALITY PLANNING COUNCIL (MPO) By: 0V Executive Director COmPufler Co sulting Services of America, Inc. y By:awrh¢v\ i Title: _ Lee posrd" a� Co li CORPORATE PRESIDENT OR VICE PRESIDENT Date: (o I ;-0 k pL ATTEST: (Corporate Sea]) Corporate Secretary A EXHIBIT "B" - FEDERAL REQUIREMENTS TABLE OF CONTENTS Lobbying Access to Records and Reports Federal Changes Contract Works Hours and Safety Standards No Government Obligation to Third Parties Program Fraud and False or Fraudulent Statements Termination Governmentwide Debarment and Suspension (Nonprocurement) Privacy Act Civil Rights Requirements Patent and Rights in Data Disadvantaged Business Enterprise (DBE) Interests of Members of or Delegates to Congress Incorporation of Federal Transit Administration (FTA) Terms Page 8 Page 2 Page 2-3 Page 3 Page 3-7 Page 7 Page 8-12 Page 12 Page 13 Page 13 Page 14-17 Page 17-18 Page 19 Page 19 E LOBBYING 31 U.S.C. 135249 CFR Part 1949 CFR Part 20 Byrd Anti -Lobbying Amendment, 31 U.S.C. 1352, as amended by the Lobbying Disclosure Act of 1995, P.L. 104-65 [to be codified at 2 U.S.C. 1601, et seq.] - Contractors who apply or bid for an award of $100,000 or more shall file the certification required by 49 CFR part 20, "New Restrictions on Lobbying." Each tier certifies to the tier above that it will not and has not used Federal appropriated funds to pay any person or organization for influencing or attempting to influence an officer or employee of any agency, a member of Congress, officer or employee of Congress, or an employee of a member of Congress in connection with obtaining any Federal contract, grant or any other award covered by 31 U.S.C. 1352. Each tier shall also disclose the name of any registrant under the Lobbying Disclosure Act of 1995 who has made lobbying contacts on its behalf with non -Federal funds with respect to that Federal contract, grant or award covered by 31 U.S.C. 1352. Such disclosures are forwarded from tier to tier up to the recipient. ACCESS TO RECORDS AND REPORTS 49 U.S.C. 5325 18 CFR 18.36 49 CFR.633.17Access to Records - The following access to records requirements apply to this Contract: 1. Where the Purchaser is not a State but a local government and is the FTA Recipient or a subgrantee of the FTA Recipient in accordance with 49 C. F. R. 18.36(i), the Contractor agrees to provide the Purchaser, the FTA Administrator, the Comptroller General of the Unites States or any of their authorized representatives access to any books, documents, papers and records of the Contractor which are directly pertinent to this contract for the purposes of making audits, examinations, excerpts and transcriptions. Contractor also agrees, pursuant to 49 C. F. R. 633.17 to provide the FTA Administrator or his authorized representatives including any PMO Contractor access to Contractor's records and construction sites pertaining to a major capital project, defined at 49 U.S.C. 5302(a)1, which is receiving federal financial assistance through the programs described at 49 U.S.C. 5307, 5309 or 5311. 2. Where the Purchaser enters into a negotiated contract for other than a small purchase or under the simplified acquisition threshold and is an institution of higher education, a hospital or other non-profit organization and is the FTA Recipient or a subgrantee of the FTA Recipient in accordance with 49 C.F.R. 19.48, Contractor agrees to provide the Purchaser, FTA Administrator, the Comptroller General of the Unites States or any of their duly authorized representatives with access to any books, documents, papers and record of the Contractor which are directly pertinent to this contract for the purposes of making audits, examinations, excerpts and transcriptions. 3. Where any Purchaser which is the FTA Recipient or a subgrantee of the FTA Recipient in accordance with 49 U.S.C. 5325(a) enters into a contract for a capital project or improvement (defined at 49 U.S.C. 5302(a)(1) through other than competitive bidding, the Contractorshall make available records related to the contract to the Purchaser, the Secretary of Transportation and the Comptroller General or any authorized officer or employee of any of them for the purposes of conducting an audit and inspection. 4. The Contractor agrees to permit any of the foregoing parties to reproduce by any means whatsoever or to copy excerpts and transcriptions as reasonably needed. 5. The Contractor agrees to maintain all books, records, accounts and reports required under this contract for a period of not less than three years after the date of termination or expiration of this contract, except in the event of litigation or settlement of claims arising from the performance of this contract, in which case Contractor agrees to maintain same until the Purchaser, the FTA 3 years thereafter for all laborers and mechanics working at the site of the work (or under the United States Housing Act of 1937, or under the Housing Act of 1949, in the construction or development of the project). Such records shall contain the name, address, and social security number of each such worker, his or her correct classification, hourly rates of wages paid (including rates of contributions or costs anticipated for bona fide fringe benefits or cash equivalents thereof of the types described in section 1 (b)(2)(B) of the Davis -Bacon Act), daily and weekly number of hours worked, deductions made and actual wages paid. Whenever the Secretary of Labor has found under 29 CFR 5.5(a)(1)(iv) that the wages of any laborer or mechanic include the amount of any costs reasonably anticipated in providing benefits under a plan or program described in section 1 (b)(2)(B) of the Davis -Bacon Act, the contractor shall maintain records which show that the commitment to provide such benefits is enforceable, that the plan or program is financially responsible, and that the plan or program has been communicated in writing to the laborers or mechanics affected, and records which show the costs anticipated or the actual cost incurred in providing such benefits. Contractors employing apprentices or trainees under approved programs shall maintain written evidence of the registration of apprenticeship programs and certification of trainee programs, the registration of the apprentices and trainees, and the ratios and wage rates prescribed in the applicable programs. Section 107 (OSHA): Contract Work Hours and Safety Standards Act (i) The Contractor agrees to comply with section 107 of the Contract t Work Hours and Safety Standards Act, 40 U.S.C. section 333, and applicable DOL regulations, " Safety and Health Regulations for Construction " 29 C.F.R. Part 1926. Among other things, the Contractor agrees that it will not require any laborer or mechanic to work in unsanitary, hazardous, or dangerous surroundings or working conditions. (ii) Subcontracts - The Contractor also agrees to include the requirements of this section in each subcontract. The term "subcontract" under this section is considered to refer to a person who agrees to perform any part of the labor or material requirements of a contract for construction, alteration or repair. A person who undertakes to perform a portion of a contract involving the furnishing of supplies or materials will be considered a "subcontractor" underthis section if the work in question involves the performance of construction work and is to be performed: (1) directly on or near the construction site, or (2) by the employer for the specific project on a customized basis. Thus, a supplier of materials which will become an integral part of the construction is a "subcontractor' if the supplier fabricates or assembles the goods or materials in question specifically for the construction project and the work involved may be said to be construction activity. If the goods or materials in question are ordinarily sold to other customers from regular inventory, the supplier is not a "subcontractor." The requirements of this section do not apply to contracts or subcontracts for the purchase of supplies or materials or articles normally available on the open market. If it is later determined by the City of Fort Collins that the Contractor had an excusable reason for not performing, such as a strike, fire, or flood, events which are not the fault of or are beyond the control of the Contractor, the City of Fort Collins, after setting up a new delivery of performance schedule, may allow the Contractor to continue work, or treat the termination as a termination for convenience. C. Opportunity to Cure (General Provision) The City of Fort Collins in its sole discretion may, in the case of a termination for breach or default, allow the Contractor [an appropriately short period of time] in which to cure the defect. In such case, the notice of termination will state the time 5 appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the Recipient resulting from the Contractor's refusal or failure to complete the work within specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the Recipient in completing the work. The Contractor's right to proceed shall not be terminated nor the Contractor changed with damages under this clause if- 1. the delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include: acts of God, acts of the Recipient, acts of another Contractor in the performance of a contract with the Recipient, epidemics, quarantine restrictions, strikes, freight embargoes; and 2. the contractor, within [1 0] days from the beginning of any delay, notifies the City of Fort Collins in writing of the causes of delay. If in the judgment of the City of Fort Collins, the delay is excusable, the time for completing the work shall be extended. The judgment of the City of Fort Collins shall be final and conclusive on the parties, but subject to appeal under the Disputes clauses. If, after termination of the Contractor's right to proceed, it is determined that the Contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if the termination had been issued for the convenience of the Recipient. h. Termination for Convenience or Default (Architect and Engineering) The City of Fort Collins may terminate this contract in whole or in part, for the Recipient's convenience or because of the failure of the Contractor to fulfill the contract obligations. The City of Fort Collins shall terminate by delivering to the Contractor a Notice of Termination specifying the nature, extent, and effective date of the termination. Upon receipt of the notice, the Contractor shall (1) immediately discontinue all services affected (unless -the notice directs otherwise), and deliver to the Contracting Officer all data, drawings, specifications, reports, estimates, summaries, and other information and materials accumulated in performing this contract, whether completed or in process. If the termination is for the convenience of the Recipient, the Contracting Officer shall make an equitable adjustment in the contract price but shall allow no anticipated profit on unperformed services. If the termination is for failure of the Contractor to fulfill the contract obligations, the Recipient may complete the work by contact or otherwise and the Contractor shall be liable for any additional cost incurred by the Recipient. If, after termination for failure to fulfill contract obligations, it is determined that the Contractor was not in default, the rights and obligations of the parties shall be the same as if the termination had been issued for the convenience of the Recipient. Termination for Convenience of Default (Cost -Type Contracts) The City of Fort Collins may terminate this contract, or any portion of it, by serving a notice or termination on the Contractor. The notice shall state whether the termination is for convenience of the City of Fort Collins or for the default of the Contractor. If the termination is for default, the notice shall state the manner in which the contractor has failed to perform the requirements of the contract. The Contractor shall account for any property in its possession paid for from funds received from the City of Fort Collins, or property supplied to the Contractor by the City of Fort Collins. If the termination is for default, the 7 PROGRAM FRAUD AND FALSE OR FRAUDULENT STATEMENTS AND RELATED ACTS 31 U.S.C. 3801 et seq. 49 CFR Part 31 18 U.S.C. 1001 49 U.S.C. 5307 Program Fraud and False or Fraudulent Statements or Related Acts. (1) The Contractor acknowledges that the provisions of the Program Fraud Civil Remedies Act of 1986, as amended, 31 U.S.C. 3801 et seq. and U.S. DOT regulations, "Program Fraud Civil Remedies," 49 C.F.R. Part 31, apply to its actions pertaining to this Project. Upon execution of the underlying contract, the Contractor certifies or affirms the truthfulness and accuracy of any statement it has made, it makes, it may make, or causes to be made, pertaining to the underlying contract or the FTA assisted project for which this contract work is being performed. In addition to other penalties that may be applicable, the Contractor further acknowledges that if it makes, or causes to be made, a false, fictitious, or fraudulent claim, statement, submission, or certification, the Federal Government reserves the right to impose the penalties of the Program Fraud Civil Remedies Act of 1986 on the Contractor to the extent the Federal Government deems appropriate. (2) The Contractor also acknowledges that if it makes, or causes to be made, a false, fictitious, or fraudulent claim, statement, submission, or certification to the Federal Government under a contract connected with a project that is financed in whole or in part with Federal assistance originally awarded by FTA under the authority of 49 U.S.C. 5307, the Government reserves the right to impose the penalties of 18 U.S.C. 1001 and 49 U.S.C. 5307(n)(1) on the Contractor, to the extent the Federal Government deems appropriate. (3) The Contractor agrees to include the above two clauses in each subcontract financed in whole or in part with Federal assistance provided by FTA. It is further agreed that the clauses shall not be modified, except to identify the subcontractor who will be subject to the provisions. TERMINATION 49 U.S.C.Part 18 FTA Circular 4220.1 D a. Termination for Convenience (General Provision) The City of Fort Collins may terminate this contract, in whole or in part, at any time by written notice to the Contractor when it is in the Government's best interest. The Contractor shall be paid its costs, including contract close-out costs, and profit on work performed up to the time of termination. The Contractor shall promptly submit its termination claim to the City of Fort Collins to be paid the Contractor. If the Contractor has any property in its possession belonging to the City of Fort Collins, the Contractor will account for the same, and dispose of it in the manner the City of Fort Collins directs. b. Termination for Default [Breach or Cause] (General Provision) If the Contractor does not deliver supplies in accordance with the contract delivery schedule, or, if the contract is for services, the Contractor fails to perform in the manner called for in the contract, or if the Contractor fails to comply with any other provisions of the contract, the City of Fort Collins may terminate this contract for default. Termination shall be effected by serving a notice of termination on the contractor setting forth the manner in which the Contractor is in default. The contractor will only be paid the contract price for supplies delivered and accepted, or services performed in accordance with the manner of performance set forth in the contract. termination had been issued for the convenience of the City of Fort Collins g. Termination for Default (Construction) If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract or any extension or fails to complete the work within this time, or if the Contractor fails to comply with any other provisions of this contract, the City of Fort Collins may terminate this contract for default. The City of Fort Collins shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. In this event, the Recipient may take over the work and compete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the Recipient resulting from the Contractor's refusal or failure to complete the work within specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the Recipient in completing the work. The Contractor's right to proceed shall not be terminated nor the Contractor changed with damages Under this clause if- 1. the delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include: acts of God, acts of the Recipient, acts of another Contractor in the performance of a contract with the Recipient, epidemics, quarantine restrictions, strikes, freight embargoes; and 2. the contractor, within [10] days from the beginning of any delay, notifies the City of Fort Collins in writing of the causes of delay. If in the judgment of the City of Fort Collins, the delay is excusable, the time for completing the work shall be extended. The judgment of the City of Fort Collins shall be final and conclusive on the parties, but subject to appeal under the Disputes clauses. If, after termination of the Contractor's right to proceed, it is determined that the Contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if the termination had been issued for the convenience of the Recipient. h. Termination for Convenience or Default (Architect and Engineering) The City of Fort Collins may terminate this contract in whole or in part, for the Recipient's convenience or because of the failure of the Contractor to fulfill the contract obligations. The City of Fort Collins shall terminate by delivering to the Contractor a Notice of Termination specifying the nature, extent, and effective date of the termination. Upon receipt of the notice, the Contractor shall (1) immediately discontinue all services affected (unless -the notice directs otherwise), and (2) deliver to the Contracting Officer all data, drawings, specifications, reports, estimates, summaries, and other information and materials accumulated in performing this contract, whether completed or in process. If the termination is for the convenience of the Recipient, the Contracting Officer shall make an Equitable adjustment in the contract price but shall allow no anticipated profit on unperformed services. If the termination is for failure of the Contractor to fulfill the contract obligations, the Recipient may complete the work by contact or otherwise and the Contractor shall be liable for any additional cost incurred by the Recipient. 11