Loading...
HomeMy WebLinkAbout732 Fairbourne Way - Applications/Reroof - 02/10/2020City of F6rt Collins College Fort Collins, O 80524 buildingservices@fcgov.com ALL information is REQUIRED. Incomplete applications will not be accepted. Job Site Address T32 -r -I bUP-Mll� WI City/State/Zip IVIG I Property Owner Information (n Name , �/ ��� Y HEgMilh, Jh' Rd [.L k Phone Number Caro) Address-1'52 Pawbo UVV\- City/State/Zip 1L✓ ( r)11 I RIQ Single Family Detached Q Townhome (attached) Q Duplex OApartment/Condo O Garage/Other p Bank Q Bar p Church Q Hotel/Motel Q Medical Office Q Office Q Retail Q Restaurant COMMERCIAL STRUCTURES Are you tearing off existing roofing materials to the decking? 0 Yes O No If keeping existing layers, how many layers are there?_ What kind of material are they? Iq / A What new roofing materials are you using? (7 --L,6bKf`lIl�lC� ( � T ��' I�Q�-✓�`�tUt�� Is there existing insulation? (J(es 0 No Will any insulation be removed/replaced? 0 Yes (/-JNo Construction _I Residentiaf . $ o o c) Materials Manufacturer A U) � � 1 � C # of Squares # of Stories FLAT ROOF (less than 2:12 pitch) O Yes OJ No . • • Q Roof Repair 49% of roof area max. Class 4 shingle is not required. Note location(s) of areas to be repaired in space • Roof Repair 50% or more of roof area. Class 4 shingle is required, provided below. Additional Information (if applicable) ContractorinfoTmatilonl r n b I _ �/ Name MNK- GIiI�/F��92✓��`71�a7 L�.�.• P-10 l wu. r ) ct" f� �1 Address ZZ G)' lb,!2 C. PW el City/State/Zi`p ,,4 ll) rVy4III VL, tO - X(�I Phone Number l U3) Z&O %-3�9 Email �'6�4V �� j �W-k' '(jL • l.0 W License Certificate 0 License/Certificate Holder Q Payroll Employees p Exempt Roofer (1099): EX- WORK PERFORMED BY 0 Homeowner Company Name: Nr` K U05MC2 Print Name i5V--btj-9- (WSignature Date RESIDENTIAL• ROOFING CONTRA'C�T A M N R CONTRACTORS, LLC 2260 Oak Place Owner's Name: Owner's Address: Thornton, CO 80229 3 C i � 1 1, ? 3 a� c c� v �- � Office.....303.260.8358 Owner's City: Owner's Zip Code: O�oscer's Phone: Owner's Work Phone: Fax........ 720.541.7286 0--.1 n_1S- _e o . � �, er �5-)^ -1QLI fIJ4� Project Name & Address: I/WE, the Owner(s) of the premises described above authorize MNR Contractors, LLC, hereinafter referred to as "Contractor", to furnish all materials and labor necessary to roof and/or improve these premises according to the following terms, specifications and l provisions: rl i I Q lko v I:. I k O y eC O`S 05P9 J a. Sco a of roofing services and materials to be provided: 4 s a r, e to �V V 1-Sk Uvoat'l� S--��P �``YS\ \��,r� ��,r�erti. ��1{ ©ffF �e, �\k etf��r•a ��,s ��tne-tcc 9e$koie, o v� � 1�P- 0- - PE � , Cte0.� (oJ��ei S �a ��oe lCAL b. Description of any Areas hat will IVUT be worked on: nE } c� i ti o ` T %UC This list of specifications may be continued on subsequent pages (see page number below).c. Approximate Costs of the Services for Damage Known at This Time: ntractor ill pgfj� the above, (subject to any additions a pursuant to authorized change orders), for the Approximate Sum of $ ' Down Payment (if any) $ V INSURANCE: THIS AGREEMENT IS NULL AND VOID AND DOES NC)f OBLIGATE ANY PARTY TO IT SHOULD THE INSURANCE COMPANY REFUSE COVERAGE UNDER THIS CLAIM OR SHOULD THE COVERAGE OFFERED BE INSUFFICIENT FOR CONTRACTOR TO PROPERLY DO THE WORK. THE ONLY COST TO THE PROPERTY OWNER IS THEIR DEDUCTIBLE, PLUS ANY UPGRADES CHOSEN OR ANY NON COVERED ITEMS THAT MUST BE REPLACED TO COMPLETE THE REPAIRS. THE CONTRACT BALANCE (ACTUAL CASH VALUE OF THE WORK) IS PAID BY YOUR INSURANCE COMPANY PER FINAL LOSS INVOICE. ALL PROCEEDS FROM THE INSURANCE COMPANY INCLUDING, BUT NOT LIMITED TO, PROCEEDS FOR SUPPLEMENTAL CLAIMS MADE BY CONTRACTOR ON BEHALF OF OWNER, PROCEEDS FOR PROFIT & OVERHEAD, AND PROCEEDS FOR RECOVERABLE DEPRECIATION, ARE GIVEN IN PAYMENT FOR THE WORK OF CONTRACTOR AND OWNER AGREES TO TIMELY, (WITHIN 24 HOURS OF RECEIPT BY OWNER), REMIT ALL SUCH PROCEEDS TO CONTRACTOR. PER COLORADO SB38, CONTRACTOR SHALL HOLD IN TRUST ANY PAYMENT FROM THE PROPERTY OWNER UNTIL CONTRACTOR HAS DELIVERED ROOFING MATERIALS AT THE RESIDENTIAL PROPERTY SITE OR HAS PERFORMED A MAJORITY OF THE ROOFING WORK ON THE RESIDENTIAL PROPERTY. d. Approximate Dates of Service: Substantial commencement of work shall mean either the physical delivery of materials onto the premises or the performance of any labor and shall be subject toanymE�ys ajny per sible delays as per provision (5) on the reverse side. J Approximate Start Date: ! 0 - 6 ( Approximate Completion Date: ®� r e. Acceptance: This contract is approved and accepted. I (we) understand there are no oral agreements or understandings between the parties of this agreement. The written terms, provisions, plans (if any) and specifications in this contract is the entire agreement between the parties. Changes in this agreement shall be done by written change order only and with the express approval of both parties. Changes may incur additional charges. Additional Provisions Of This Contract Are On The Reverse Side And May Be Continued On Subsequent Pages (see page number below). Read "Arbitration of Disputes" provision on page two (2), provision 12 and the NOTICE following this provision. If you agree to arbitration, initial on the line below the NOTICE where indicated. Also, initial in the same place on EACH COPY of this contract. —Q� %/as/i9 CANCELLATION POLICY: Your right to cancel this contract is limited to the following: approved a to (owner) date You, the Buyer, may cancel this transaction at any time prior approved and a pted (owner) v approved (contractor) date to midnight of the third business day after the date of this transaction. See the attached Notice of Cancellation form for an explanation of this right. 2 NOTE: Thi ontract may be withdrawn or renegotiated after 3 days from "� if not approved and signed by BOTH parties. Form RC31-C Copyright © 1996-2012 ACT Contractors Forms (800}8 0-5656 www�om ^/ y ! Page ONE of 2 Total Pages / — J 8 9:5� I ADDITIONAL PROVISIONS- Unless otherwise specified herein, the following additional provisions are expressly incorporated into this contract: 1. Contract, Plans, Specifications, Permits and Fees. The work described in this contract shall be done according to the plans and the plan specifica- tions (if any) except in the case of conflict when the Provisions of this contract shall have control over both the plans and the plan specifications. All required building permits will be paid for by owner and obtained by Contractor. All other charges, taxes, assessments, fees etc., of any kind whatsoever, required by any government body, telephone or utility compa- ny or the like shall be paid for by Owner. 2.Installation. Contractor has the right to subcontract any part of, or all of, the work herein 3.Change Orders. Should Owner, construction lender, or any government body or inspector require any modification to the work covered under this contract, any cost incurred by Contractor shall be added to the contract price as extra work and Owner agrees to pay Contractor his normal selling price for such extra work. All extra work as well as any other modifications to the original contract shall be specified and approved by both parties in a written change order. All change orders as well as all insurance supple- ments, shall become a part of this contract and shall be incorporated herein. 4.Owner's Responsibility: Insurance etc. Owner is responsible for the fol- lowing: (1) to see that all necessary water, electrical power, access to premises, and toilet facilities are provided on the premises. (2) to provide a storage area on the premises for equipment and materials. (3) to relocate and protect any item that prevents Contractor from having free access to the work areas such as but not limited to TV or radio antennas, vehicles, tools or garden equipment. In the event that Owner fails to relocate such items, Contractor may relocate these items as required but in no way is Contractor responsible for damage to these items during their relocation and during the performance of the work. (4) to obtain permission from the owner(s) of adjacent property(ies) that Contractor must use to gain access to the work areas. Owner agrees to be responsible and to hold Contractor harmless and accept any risks resulting from the use of adjacent property(ies) by Contractor. (5) to correct any existing defects which are recognized during the course of the work. Contractor shall have no liability for correcting any existing defects such as, but not limited to, dry rot, structural defects, or code violations. (6), to maintain property insurance with Fire, Course of Construction, all Physical Loss with Vandalism and Malicious Mischief clauses attached, in a sum at least equal to the contract price, prior to and during performance of this contract. If the project is destroyed or damaged by an accident, disaster or calamity, or by theft or vandalism, any work or materials supplied by Contractor in reroofing or restoring the project shall be paid for by Owner as extra work. (7) to timely fill out and submit any documentation required by the insurance company. S.DelaY. Contractor shall not be held responsible for any damage occa- sioned by delays resulting from: work one by Owner's subcontractors, extra work, acts of owner or owner's agent including failure of owner to make timely progress payments or payments for extra work, shortages of material and/or labor, bad weather, fire, strike, war, governmental regula- tions, or any other contingencies unforeseen by Contractor or beyond Contractor's reasonable control. 6.Surplus Materials and Salvage. Any surplus materials left over after this contract has been completed are the property of Contractor and will be removed by same. No credit is due Owner on returns for any surplus materials because this contract is based upon a complete job. All salvage resulting from work under this contract is the property of Contractor. \ 7.Cleanup & Advertising. Upon completion, and after removing all debris and surplus materials, wherever possible, Contractor will leave premises in a neat, broom clean condition. Any debris consisting of dust, dirt, asphalt, or small bits of materials that settle into attics, garage areas, or any other area being worked over with open beam ceilings or no attic, is unavoidable and Contractor shall not be responsible for this cleanup. Contractor recom- mends that Owner lay out drop cloths to protect such areas wherever owner discovers debris infiltration. Owner hereby grants to Contractor the right to display signs and advertise at the job site for the period of time starting at the date of signing of this contract and continuing uninterrupted until fourteen (14) days past the date the job is completed and payment in full has been made. Owner grants Contractor the right to publish the project street address on a "references" list given to prospective customers. 8.Concealed Damage & Dry Rot. Contractor will inform Owner of any dry rot or other sub -roof deterioration which is concealed and is discovered during the course of the work. Contractor is not responsible to repair any such discovered deterioration and any work done by Contractor to remedy such discovered deterioration will only be done as extra work in a written change order. 9.Termites, Pests & Hazardous Substances. Owner understands that Con- tractor is not qualified or licensed as an inspector or abatement contractor for Hazardous Materials (as defined by the government), or for Pests (including Termites). Should any such hazardous substances or Pest be suspected to be present on the premises, it is the Owners' responsibility to arrange and pay for inspection and abatement. Contractor cannot certify or warrant your building as being free of hazardous substances or pests. 10. Collection. Owner agrees to pay all collection fees and charges including but not limited to all legal and attorney fees that result should Owner default in payment of this contract. Overdue accounts are subject to inter- est charged at 18% per annum or at the highest rate allowed by law. 11. Legal Fees. In the event litigation or arbitration arises out of this con- tract, prevailing party(ies) are entitled to all legal, arbitration, and attorney fees. The court or arbitrator shall not be bound to award fees based on any set, fee schedule but shall if it so chooses, award the true amount of all costs, expenses and attorney fees paid or incurred. 12. Arbitration of Disputes. Any controversy or claim arising out of or relating to this proposal/contract, or the breach thereof, shall be settled by arbitration in accordance with the applicable Construc- tion Industry Arbitration Rules of the American Arbitration Associa- tion which are in effect at the time the demand for arbitration is filed. Ajudgment upon the award rendered by the arbitrator(s) may be entered in any court having jurisdiction thereof. Any arbitration award shall be subject to correction and/or vacation for the reasons stated in the law. The arbitrator shall award reasonable attorneys fees and expenses to the prevailing party. After being given due notice, should any party fail to appear at or participate in the arbi- tration proceedings, the arbitrator shall make an award based upon the evidence presented by the party(ies) who do (does) appear and participate. Notwithstanding Contractor's right to arbitrate, Con- tractor does not waive any of its lien rights. NOTICE: By initialing in the space below you are agreeing to have any dispute arising out of the matters included in the "arbitration of disputes" provision decided by neutral arbitration as provided by law and you are giving up any rights you might possess to have the dispute litigated in a court or jury trial. By initialing in the space below you are giving up yourjudicial rights to discovery and appeal, unless those rights are specifically, included in the "arbitration of disputes" provision. If you refuse to submit to arbitration after agreeing to this provision, you may be compelled to arbitrate under the authority of the applicable laws. Your agreement to this arbitra- tion provision is voluntary. We have read and understand the foregoing and agree to submit disputes arising out of the matters included in the "arbitration of disputes" provision to neutral arbitration. I Agree to Arbitration: I Agree to Arbitration: (Initials of Owner) (Initials of Owner) NOTICES PER COLORADO SB38 1) If the client plans to use the proceeds of a property or casualty insurance policy to pay for the roofing work, the roofing contractor cannot pay, waive, rebate, or promise to pay, waive, or rebate all or part of any deductible applicable to the claim for payment for roofing work on the covered residential property. 2) Property owner is _Jis not intending to make payment from proceeds of a property and casualty insurance policy . 3) Owner may rescind this contract if the insurer denies the claim in whole or in part, as long as the person notifies Contractor within 72 hours after the claim is denied. Contractor will refund any moneys paid by the customer within 10 days after receipt of this notice of rescission. Owner may not rescind the contract when supplemental claims for additional roofing services not reasonably foreseen at the time of initial inspection for this contract, (concealed damage for example), are denied by the Insurance Company. See provision (8) in this contract for details about concealed damage. Owner may give notice of rescission in writing to Contractor at the address listed herein on page one or by email to Contractor at the email listed herein (if any). Email notice of rescission is effective on the date of the email. Standard mail notice of rescission is effective upon deposit in the United States Mail, postage pre -paid. Per- sonal delivery of notice of rescission is effective upon delivery. 4) If Owner rescinds this contract, Contractor may retain all or a portion of any payments or deposits made by Owner to compensate Contractor for roofing work actually performed on the residential property in a workmanlike manner consistent with standard roofing industry practic- es. Contractor, however, may retain only an amount required to compen- sate Contractor for the actual work performed. 5) COMMERCIAL GENERAL LIABILITY INSURANCE (CGL) This Contractor carries commercial general liability insurance written by Preferred Contractors. You may contact contractor's agent by calling (303) 288-2196. Page TWO of 2 Total Pages A C 0,6 R NACORN CLAIMS - C L A I M S- 5508 N. Farmer Branch Rd Ozark, Missouri 65721 (417) 581-5200 (888)360-7776 ROLDAN_MERCEDITA House Exterior DESCRIPTION QUANTITY UNIT PRICE TAX O&P RCV DEPREC. ACV The following line items account for the replacement of the roofing materials and soft metals. The debris removal is included in the costs of the tear off. The roof is 10 years old. I. Tear off, haul and dispose of comp. 25.08 SQ 51.97 0.00 260.68 1,564.09 (0.00) 1,564.09 shingles - Laminated 2. Roofing felt - 15 lb. 25.08 SQ 30.62 13.43 156.28 937.66 (114.75) 822.91 3. R&R Drip edge 2.57 LF 2.47 0.13 1.30 7.78 (0.64) 7.14 4. R&R Drip edge/gutter apron 269.03 LF 2.58 16.05 142.04 852.19 (78.37) 773.82 5. Laminated - comp. shingle rfg. - w/out 29.00 SQ 223.30 243.52 1,343.84 8,063.06 (1,387.56) 6,675.50 felt 6. R&R Ridge cap - composition shingles 221.54 LF 6.59 20.41 296.08 1,776.44 (139.53) 1,636.91 7. R&R Flashing - pipe jack 4.00 EA 44.51 2.53 36.10 216.67 (12.35) 204.32 8. Additional charge for high roof (2 19.54 SQ 4.91 0.00 19.18 115.12 (0.00) 115.12 stories or greater) 9. Additional charge for high roof (2 19.54 SQ 25.43 0.00 99.38 596.28 (0.00) 596.28 siorics or greater) 10. R&R Rain cap - 4" to 5" 1.00 EA 36.65 1.17 7.56 45.38 (5.73) 39.65 11. R&R Exhaust cap - through roof - up 3.00 EA 80.72 5.66 49.56 297.38 (27.67) 269.71 to 4" 12. Prime & paint roofjack 4.00 EA 33.49 2.14 27.22 163.32 (18.25) 145.07 13. Prime & paint roof vent 8.00 EA 33.49 4.27 54.44 326.63 (36.52) 290.11 14. Step flashing 27.00 LF 8.85 2.77 48.36 290.08 (13.54) 276.54 15. R&R Roof vent - turtle type - Metal 4.00 EA 62.83 4.53 51.18 307.03 (22.12) 284.91 16. Asphalt starter - universal starter 269.03 LF 2.07 13.00 113.98 683.87 (111.11) 572.76 course Totals: Roofl 329.61 2,707.18 16,242.98 1,968.14 14,274.84 DESCRIPTION Gutters/Downspouts QUANTITY UNIT PRICE TAX O&P RCV DEPREC. ACV The following line items account for replacement of the guttering and downspouts of this structure. 100% of gutters are damaged. 269 LF Front Side= 0 Downspout Right Side= 40 Downspout Back Side= 0 Downspout Left Side= 0 Downspout 17. R&R Gutter / downspout - galvanized - 309.00 LF 6.30 44.79 398.30 up to 5" ROLDAN_MERCEDITA 2,389.79 (382.86) 2,006.93 7/18/2019 Page:2 A C * R N ACORN CLAIMS - C L A I M S- 5508 N. Farmer Branch Rd Ozark, Missouri 65721 (417)581-5200 (888)360-7776 Insured: Roldan, Mercedita Property: 732 Fairbourne Way Fort Collins, CO 80525-6964 Home: 732 Fairbourne Way Fort Collins, CO 80525-6964 Claim Rep.: Jordan Sanders . Estimator: Jordan Sanders Position: Adjuster Claim Number: 60003588545 Policy Number: 60030521NS Price List: COFC8X_JUL19 Restoration/Service/Remodel Estimate: ROLDAN MERCEDITA Home: 970-294-4195 E-mail: ram200531@yahoo.com Type of Loss: Hail This is the estimated amount of observed damages for your personal property and/or the estimated cost of covered repairs to your home. This estimate is subject to Arnica Mutual Insurance Company's fmal review. Your policy may contain provisions that could limit or exclude the amount paid for certain items. Your adjuster will explain any applicable coverage limitations to you. This estimate is not a guarantee that coverage will be provided and is not intended to replace any of the terms and conditions in your policy. We will work with you and your chosen contractor to attempt to reach an agreed figure'for the covered repairs and/or replacement of your personal property. If you or your contractor disagree with the extent or cost of repairs outlined in this estimate, or if additional damage is discovered, please contact Amica so we can provide further assistance. Please remember that you are required to provide us with an opportunity to inspect any supplemental damage before the damaged items are repaired or replaced. Your Mortgagee may be included as an additional payee. We recommend you contact your lender to notify them of the loss and discuss their specific requirements for endorsing checks. Please let us know if we can help in this regard. If you have any questions about this estimate or any of the information presented here, please contact us so we can assist you.